{"groups":{"policy:site-control":{"id":"policy:site-control","label":"Evidence of site control","tracker":"policy"},"policy:security":{"id":"policy:security","label":"Financial security","tracker":"policy"},"policy:curtailment":{"id":"policy:curtailment","label":"Emergency response","tracker":"policy"},"policy:emissions":{"id":"policy:emissions","label":"Emissions safeguards","tracker":"policy"},"policy:cost-allocation":{"id":"policy:cost-allocation","label":"Attributable-cost allocation","tracker":"policy"},"policy:departure":{"id":"policy:departure","label":"Departure / reduced-load protection","tracker":"policy"},"policy:supply-review":{"id":"policy:supply-review","label":"Water-supply review","tracker":"policy"},"policy:clean-energy":{"id":"policy:clean-energy","label":"Clean-energy service terms","tracker":"policy"},"policy:water-reporting":{"id":"policy:water-reporting","label":"Water-use reporting","tracker":"policy"},"policy:local-authority":{"id":"policy:local-authority","label":"Preserved local authority","tracker":"policy"},"policy:minimum-payment":{"id":"policy:minimum-payment","label":"Minimum payment commitments","tracker":"policy"},"policy:regulator-reporting":{"id":"policy:regulator-reporting","label":"Regulatory reporting","tracker":"policy"},"policy:environmental-review":{"id":"policy:environmental-review","label":"Environmental assessment","tracker":"policy"},"policy:permit-hold":{"id":"policy:permit-hold","label":"Interim permit restraint","tracker":"policy"},"restriction:local:enacted":{"id":"restriction:local:enacted","label":"Local restriction records: enacted (as recorded)","tracker":"moratorium"},"restriction:local:failed":{"id":"restriction:local:failed","label":"Local restriction records: failed (as recorded)","tracker":"moratorium"},"restriction:local:proposed":{"id":"restriction:local:proposed","label":"Local restriction records: proposed (as recorded)","tracker":"moratorium"},"restriction:local:pause":{"id":"restriction:local:pause","label":"Local restriction records: pause (as recorded)","tracker":"moratorium"},"restriction:states:enacted":{"id":"restriction:states:enacted","label":"State restriction records: enacted (as recorded)","tracker":"moratorium"},"restriction:states:pause":{"id":"restriction:states:pause","label":"State restriction records: pause (as recorded)","tracker":"moratorium"},"restriction:states:proposed":{"id":"restriction:states:proposed","label":"State restriction records: proposed (as recorded)","tracker":"moratorium"},"restriction:states:failed":{"id":"restriction:states:failed","label":"State restriction records: failed (as recorded)","tracker":"moratorium"},"water:reclaimed:enacted":{"id":"water:reclaimed:enacted","label":"Water reclaimed measures: enacted (as recorded)","tracker":"water"},"water:disclosure:enacted":{"id":"water:disclosure:enacted","label":"Water disclosure measures: enacted (as recorded)","tracker":"water"},"water:siting:vetoed":{"id":"water:siting:vetoed","label":"Water siting measures: vetoed (as recorded)","tracker":"water"},"water:reclaimed:failed":{"id":"water:reclaimed:failed","label":"Water reclaimed measures: failed (as recorded)","tracker":"water"},"water:incentive:proposed":{"id":"water:incentive:proposed","label":"Water incentive measures: proposed (as recorded)","tracker":"water"},"water:disclosure:proposed":{"id":"water:disclosure:proposed","label":"Water disclosure measures: proposed (as recorded)","tracker":"water"},"water:disclosure:vetoed":{"id":"water:disclosure:vetoed","label":"Water disclosure measures: vetoed (as recorded)","tracker":"water"},"water:closed-loop:proposed":{"id":"water:closed-loop:proposed","label":"Water closed-loop measures: proposed (as recorded)","tracker":"water"},"water:closed-loop:failed":{"id":"water:closed-loop:failed","label":"Water closed-loop measures: failed (as recorded)","tracker":"water"},"water:disclosure:failed":{"id":"water:disclosure:failed","label":"Water disclosure measures: failed (as recorded)","tracker":"water"},"water:rate:failed":{"id":"water:rate:failed","label":"Water rate measures: failed (as recorded)","tracker":"water"},"water:siting:enacted":{"id":"water:siting:enacted","label":"Water siting measures: enacted (as recorded)","tracker":"water"},"water:study:proposed":{"id":"water:study:proposed","label":"Water study measures: proposed (as recorded)","tracker":"water"},"water:siting:proposed":{"id":"water:siting:proposed","label":"Water siting measures: proposed (as recorded)","tracker":"water"},"water:closed-loop:enacted":{"id":"water:closed-loop:enacted","label":"Water closed-loop measures: enacted (as recorded)","tracker":"water"},"water:moratorium:enacted":{"id":"water:moratorium:enacted","label":"Water moratorium measures: enacted (as recorded)","tracker":"water"},"water:reclaimed:proposed":{"id":"water:reclaimed:proposed","label":"Water reclaimed measures: proposed (as recorded)","tracker":"water"},"water:moratorium:vetoed":{"id":"water:moratorium:vetoed","label":"Water moratorium measures: vetoed (as recorded)","tracker":"water"},"water:study:enacted":{"id":"water:study:enacted","label":"Water study measures: enacted (as recorded)","tracker":"water"},"water:moratorium:failed":{"id":"water:moratorium:failed","label":"Water moratorium measures: failed (as recorded)","tracker":"water"},"water:moratorium:proposed":{"id":"water:moratorium:proposed","label":"Water moratorium measures: proposed (as recorded)","tracker":"water"},"water:shield:enacted":{"id":"water:shield:enacted","label":"Water shield measures: enacted (as recorded)","tracker":"water"},"water:shield:failed":{"id":"water:shield:failed","label":"Water shield measures: failed (as recorded)","tracker":"water"},"water:siting:failed":{"id":"water:siting:failed","label":"Water siting measures: failed (as recorded)","tracker":"water"},"water:study:failed":{"id":"water:study:failed","label":"Water study measures: failed (as recorded)","tracker":"water"},"water:rate:enacted":{"id":"water:rate:enacted","label":"Water rate measures: enacted (as recorded)","tracker":"water"},"water:incentive:enacted":{"id":"water:incentive:enacted","label":"Water incentive measures: enacted (as recorded)","tracker":"water"},"delay:state_moratorium:withdrawn":{"id":"delay:state_moratorium:withdrawn","label":"Delay cause: state moratorium / withdrawn","tracker":"delay"},"delay:transformer_supply:delayed":{"id":"delay:transformer_supply:delayed","label":"Delay cause: transformer supply / delayed","tracker":"delay"},"delay:gas_pipeline_delay:delayed":{"id":"delay:gas_pipeline_delay:delayed","label":"Delay cause: gas pipeline delay / delayed","tracker":"delay"},"delay:corporate_realignment:withdrawn":{"id":"delay:corporate_realignment:withdrawn","label":"Delay cause: corporate realignment / withdrawn","tracker":"delay"},"delay:financing:withdrawn":{"id":"delay:financing:withdrawn","label":"Delay cause: financing / withdrawn","tracker":"delay"},"delay:environmental_review:litigation_active":{"id":"delay:environmental_review:litigation_active","label":"Delay cause: environmental review / litigation_active","tracker":"delay"},"delay:litigation:litigation_active":{"id":"delay:litigation:litigation_active","label":"Delay cause: litigation / litigation_active","tracker":"delay"},"delay:community_opposition:litigation_active":{"id":"delay:community_opposition:litigation_active","label":"Delay cause: community opposition / litigation_active","tracker":"delay"},"delay:zoning_denial:cancelled":{"id":"delay:zoning_denial:cancelled","label":"Delay cause: zoning denial / cancelled","tracker":"delay"},"delay:community_opposition:cancelled":{"id":"delay:community_opposition:cancelled","label":"Delay cause: community opposition / cancelled","tracker":"delay"},"delay:water_dispute:cancelled":{"id":"delay:water_dispute:cancelled","label":"Delay cause: water dispute / cancelled","tracker":"delay"},"delay:zoning_denial:litigation_active":{"id":"delay:zoning_denial:litigation_active","label":"Delay cause: zoning denial / litigation_active","tracker":"delay"},"delay:local_moratorium:litigation_active":{"id":"delay:local_moratorium:litigation_active","label":"Delay cause: local moratorium / litigation_active","tracker":"delay"},"delay:permit_denial:litigation_active":{"id":"delay:permit_denial:litigation_active","label":"Delay cause: permit denial / litigation_active","tracker":"delay"},"delay:community_opposition:withdrawn":{"id":"delay:community_opposition:withdrawn","label":"Delay cause: community opposition / withdrawn","tracker":"delay"},"delay:zoning_denial:withdrawn":{"id":"delay:zoning_denial:withdrawn","label":"Delay cause: zoning denial / withdrawn","tracker":"delay"},"delay:environmental_review:delayed":{"id":"delay:environmental_review:delayed","label":"Delay cause: environmental review / delayed","tracker":"delay"},"delay:community_opposition:delayed":{"id":"delay:community_opposition:delayed","label":"Delay cause: community opposition / delayed","tracker":"delay"},"delay:water_dispute:under_appeal":{"id":"delay:water_dispute:under_appeal","label":"Delay cause: water dispute / under_appeal","tracker":"delay"},"delay:community_opposition:under_appeal":{"id":"delay:community_opposition:under_appeal","label":"Delay cause: community opposition / under_appeal","tracker":"delay"},"delay:water_dispute:delayed":{"id":"delay:water_dispute:delayed","label":"Delay cause: water dispute / delayed","tracker":"delay"},"delay:local_moratorium:delayed":{"id":"delay:local_moratorium:delayed","label":"Delay cause: local moratorium / delayed","tracker":"delay"},"delay:litigation:cancelled":{"id":"delay:litigation:cancelled","label":"Delay cause: litigation / cancelled","tracker":"delay"},"delay:zoning_denial:delayed":{"id":"delay:zoning_denial:delayed","label":"Delay cause: zoning denial / delayed","tracker":"delay"},"delay:zoning_denial:under_appeal":{"id":"delay:zoning_denial:under_appeal","label":"Delay cause: zoning denial / under_appeal","tracker":"delay"},"delay:water_dispute:litigation_active":{"id":"delay:water_dispute:litigation_active","label":"Delay cause: water dispute / litigation_active","tracker":"delay"},"delay:environmental_review:cancelled":{"id":"delay:environmental_review:cancelled","label":"Delay cause: environmental review / cancelled","tracker":"delay"},"delay:litigation:under_appeal":{"id":"delay:litigation:under_appeal","label":"Delay cause: litigation / under_appeal","tracker":"delay"},"delay:community_opposition:approved_but_citywide_moratorium_pending":{"id":"delay:community_opposition:approved_but_citywide_moratorium_pending","label":"Delay cause: community opposition / approved_but_citywide_moratorium_pending","tracker":"delay"},"delay:proposed_moratorium:approved_but_citywide_moratorium_pending":{"id":"delay:proposed_moratorium:approved_but_citywide_moratorium_pending","label":"Delay cause: proposed moratorium / approved_but_citywide_moratorium_pending","tracker":"delay"},"delay:rezoning_denial_or_withdrawal:withdrawn":{"id":"delay:rezoning_denial_or_withdrawal:withdrawn","label":"Delay cause: rezoning denial or withdrawal / withdrawn","tracker":"delay"},"delay:rezoning_denial:rezoning_denied":{"id":"delay:rezoning_denial:rezoning_denied","label":"Delay cause: rezoning denial / rezoning_denied","tracker":"delay"},"delay:community_opposition:rezoning_denied":{"id":"delay:community_opposition:rezoning_denied","label":"Delay cause: community opposition / rezoning_denied","tracker":"delay"},"delay:litigation:active_litigation":{"id":"delay:litigation:active_litigation","label":"Delay cause: litigation / active_litigation","tracker":"delay"},"delay:permit_challenge:active_litigation":{"id":"delay:permit_challenge:active_litigation","label":"Delay cause: permit challenge / active_litigation","tracker":"delay"},"delay:community_opposition:approved_amid_opposition":{"id":"delay:community_opposition:approved_amid_opposition","label":"Delay cause: community opposition / approved_amid_opposition","tracker":"delay"},"delay:missed_milestones:development_agreement_expired":{"id":"delay:missed_milestones:development_agreement_expired","label":"Delay cause: missed milestones / development_agreement_expired","tracker":"delay"},"delay:financing_delay:development_agreement_expired":{"id":"delay:financing_delay:development_agreement_expired","label":"Delay cause: financing delay / development_agreement_expired","tracker":"delay"},"delay:unresolved_commitments:rezoning_denied":{"id":"delay:unresolved_commitments:rezoning_denied","label":"Delay cause: unresolved commitments / rezoning_denied","tracker":"delay"},"delay:county_moratorium:moratorium_in_force":{"id":"delay:county_moratorium:moratorium_in_force","label":"Delay cause: county moratorium / moratorium_in_force","tracker":"delay"},"delay:county_moratorium:moratorium_extended":{"id":"delay:county_moratorium:moratorium_extended","label":"Delay cause: county moratorium / moratorium_extended","tracker":"delay"},"delay:regulatory_review:regulatory_approval_pending":{"id":"delay:regulatory_review:regulatory_approval_pending","label":"Delay cause: regulatory review / regulatory_approval_pending","tracker":"delay"},"delay:power_allocation_dispute:regulatory_approval_pending":{"id":"delay:power_allocation_dispute:regulatory_approval_pending","label":"Delay cause: power allocation dispute / regulatory_approval_pending","tracker":"delay"},"delay:corporate_reassessment:construction_paused":{"id":"delay:corporate_reassessment:construction_paused","label":"Delay cause: corporate reassessment / construction_paused","tracker":"delay"},"delay:openai_relationship_change:construction_paused":{"id":"delay:openai_relationship_change:construction_paused","label":"Delay cause: openai relationship change / construction_paused","tracker":"delay"},"delay:tariff_costs:construction_paused":{"id":"delay:tariff_costs:construction_paused","label":"Delay cause: tariff costs / construction_paused","tracker":"delay"},"delay:local_moratorium:proposed_amid_local_moratorium_and_ballot_fight":{"id":"delay:local_moratorium:proposed_amid_local_moratorium_and_ballot_fight","label":"Delay cause: local moratorium / proposed_amid_local_moratorium_and_ballot_fight","tracker":"delay"},"delay:ballot_initiative_threat:proposed_amid_local_moratorium_and_ballot_fight":{"id":"delay:ballot_initiative_threat:proposed_amid_local_moratorium_and_ballot_fight","label":"Delay cause: ballot initiative threat / proposed_amid_local_moratorium_and_ballot_fight","tracker":"delay"},"delay:ballot_initiative_threat:signature_gathering":{"id":"delay:ballot_initiative_threat:signature_gathering","label":"Delay cause: ballot initiative threat / signature_gathering","tracker":"delay"},"delay:statewide_moratorium_push:signature_gathering":{"id":"delay:statewide_moratorium_push:signature_gathering","label":"Delay cause: statewide moratorium push / signature_gathering","tracker":"delay"},"delay:environmental_review_challenge:active_litigation":{"id":"delay:environmental_review_challenge:active_litigation","label":"Delay cause: environmental review challenge / active_litigation","tracker":"delay"},"delay:regulatory_collateral_dispute:active_litigation":{"id":"delay:regulatory_collateral_dispute:active_litigation","label":"Delay cause: regulatory collateral dispute / active_litigation","tracker":"delay"},"delay:corporate_reassessment:construction_partially_paused":{"id":"delay:corporate_reassessment:construction_partially_paused","label":"Delay cause: corporate reassessment / construction_partially_paused","tracker":"delay"},"delay:design_changes:construction_partially_paused":{"id":"delay:design_changes:construction_partially_paused","label":"Delay cause: design changes / construction_partially_paused","tracker":"delay"},"delay:community_opposition:under_council_consideration":{"id":"delay:community_opposition:under_council_consideration","label":"Delay cause: community opposition / under_council_consideration","tracker":"delay"},"delay:withdrawal:cancelled":{"id":"delay:withdrawal:cancelled","label":"Delay cause: withdrawal / cancelled","tracker":"delay"},"delay:village_infeasibility_finding:cancelled":{"id":"delay:village_infeasibility_finding:cancelled","label":"Delay cause: village infeasibility finding / cancelled","tracker":"delay"},"delay:litigation:construction_halted_by_court":{"id":"delay:litigation:construction_halted_by_court","label":"Delay cause: litigation / construction_halted_by_court","tracker":"delay"},"delay:environmental_review_inadequate:construction_halted_by_court":{"id":"delay:environmental_review_inadequate:construction_halted_by_court","label":"Delay cause: environmental review inadequate / construction_halted_by_court","tracker":"delay"},"delay:city_moratorium:active_litigation":{"id":"delay:city_moratorium:active_litigation","label":"Delay cause: city moratorium / active_litigation","tracker":"delay"},"delay:environmental_review_pending:final_decision_paused":{"id":"delay:environmental_review_pending:final_decision_paused","label":"Delay cause: environmental review pending / final_decision_paused","tracker":"delay"},"delay:city_moratorium:moratorium_in_force":{"id":"delay:city_moratorium:moratorium_in_force","label":"Delay cause: city moratorium / moratorium_in_force","tracker":"delay"},"delay:planning_commission_denial_recommendation:planning_commission_recommended_denial":{"id":"delay:planning_commission_denial_recommendation:planning_commission_recommended_denial","label":"Delay cause: planning commission denial recommendation / planning_commission_recommended_denial","tracker":"delay"},"delay:community_opposition:opposed_planned":{"id":"delay:community_opposition:opposed_planned","label":"Delay cause: community opposition / opposed_planned","tracker":"delay"},"delay:city_council_resolution_against:opposed_planned":{"id":"delay:city_council_resolution_against:opposed_planned","label":"Delay cause: city council resolution against / opposed_planned","tracker":"delay"},"delay:rezoning_denial:rezoning_denied_then_litigation_settled":{"id":"delay:rezoning_denial:rezoning_denied_then_litigation_settled","label":"Delay cause: rezoning denial / rezoning_denied_then_litigation_settled","tracker":"delay"},"delay:litigation:rezoning_denied_then_litigation_settled":{"id":"delay:litigation:rezoning_denied_then_litigation_settled","label":"Delay cause: litigation / rezoning_denied_then_litigation_settled","tracker":"delay"},"delay:city_moratorium:moratorium_delay":{"id":"delay:city_moratorium:moratorium_delay","label":"Delay cause: city moratorium / moratorium_delay","tracker":"delay"},"delay:community_opposition:moratorium_delay":{"id":"delay:community_opposition:moratorium_delay","label":"Delay cause: community opposition / moratorium_delay","tracker":"delay"},"delay:community_opposition:rezoning_paused":{"id":"delay:community_opposition:rezoning_paused","label":"Delay cause: community opposition / rezoning_paused","tracker":"delay"},"delay:planning_commission_postponement:rezoning_paused":{"id":"delay:planning_commission_postponement:rezoning_paused","label":"Delay cause: planning commission postponement / rezoning_paused","tracker":"delay"},"delay:community_opposition:opposed_proposed":{"id":"delay:community_opposition:opposed_proposed","label":"Delay cause: community opposition / opposed_proposed","tracker":"delay"},"delay:transparency_concerns:opposed_proposed":{"id":"delay:transparency_concerns:opposed_proposed","label":"Delay cause: transparency concerns / opposed_proposed","tracker":"delay"},"delay:litigation:abandoned":{"id":"delay:litigation:abandoned","label":"Delay cause: litigation / abandoned","tracker":"delay"},"delay:community_opposition:abandoned":{"id":"delay:community_opposition:abandoned","label":"Delay cause: community opposition / abandoned","tracker":"delay"},"delay:china_ties_backlash:abandoned":{"id":"delay:china_ties_backlash:abandoned","label":"Delay cause: china ties backlash / abandoned","tracker":"delay"},"delay:wetlands_permit_suspended:active_litigation":{"id":"delay:wetlands_permit_suspended:active_litigation","label":"Delay cause: wetlands permit suspended / active_litigation","tracker":"delay"},"delay:community_opposition:opposed_pending_council_vote":{"id":"delay:community_opposition:opposed_pending_council_vote","label":"Delay cause: community opposition / opposed_pending_council_vote","tracker":"delay"},"delay:community_opposition:opposed_effectively_stalled":{"id":"delay:community_opposition:opposed_effectively_stalled","label":"Delay cause: community opposition / opposed_effectively_stalled","tracker":"delay"},"delay:petition_campaign:opposed_effectively_stalled":{"id":"delay:petition_campaign:opposed_effectively_stalled","label":"Delay cause: petition campaign / opposed_effectively_stalled","tracker":"delay"},"delay:public_notice_violation_alleged:active_litigation":{"id":"delay:public_notice_violation_alleged:active_litigation","label":"Delay cause: public notice violation alleged / active_litigation","tracker":"delay"},"delay:rezoning_denial:withdrawn":{"id":"delay:rezoning_denial:withdrawn","label":"Delay cause: rezoning denial / withdrawn","tracker":"delay"},"delay:no_secured_tenant:withdrawn":{"id":"delay:no_secured_tenant:withdrawn","label":"Delay cause: no secured tenant / withdrawn","tracker":"delay"},"delay:council_opposition:withdrawn":{"id":"delay:council_opposition:withdrawn","label":"Delay cause: council opposition / withdrawn","tracker":"delay"},"delay:eminent_domain_threat:active_litigation":{"id":"delay:eminent_domain_threat:active_litigation","label":"Delay cause: eminent domain threat / active_litigation","tracker":"delay"},"delay:rezoning_denial:rezoning_rejected_moratorium_recommended":{"id":"delay:rezoning_denial:rezoning_rejected_moratorium_recommended","label":"Delay cause: rezoning denial / rezoning_rejected_moratorium_recommended","tracker":"delay"},"delay:county_moratorium_recommended:rezoning_rejected_moratorium_recommended":{"id":"delay:county_moratorium_recommended:rezoning_rejected_moratorium_recommended","label":"Delay cause: county moratorium recommended / rezoning_rejected_moratorium_recommended","tracker":"delay"},"delay:environmental_review_order:active_litigation":{"id":"delay:environmental_review_order:active_litigation","label":"Delay cause: environmental review order / active_litigation","tracker":"delay"},"delay:unpermitted_power_plant:active_litigation":{"id":"delay:unpermitted_power_plant:active_litigation","label":"Delay cause: unpermitted power plant / active_litigation","tracker":"delay"},"delay:community_opposition:under_construction_amid_scrutiny":{"id":"delay:community_opposition:under_construction_amid_scrutiny","label":"Delay cause: community opposition / under_construction_amid_scrutiny","tracker":"delay"},"delay:transparency_concerns:under_construction_amid_scrutiny":{"id":"delay:transparency_concerns:under_construction_amid_scrutiny","label":"Delay cause: transparency concerns / under_construction_amid_scrutiny","tracker":"delay"},"delay:permit_denial:permit_denied":{"id":"delay:permit_denial:permit_denied","label":"Delay cause: permit denial / permit_denied","tracker":"delay"},"delay:community_opposition:permit_denied":{"id":"delay:community_opposition:permit_denied","label":"Delay cause: community opposition / permit_denied","tracker":"delay"},"delay:county_moratorium:permit_denied":{"id":"delay:county_moratorium:permit_denied","label":"Delay cause: county moratorium / permit_denied","tracker":"delay"},"delay:county_moratorium:approved_active_litigation":{"id":"delay:county_moratorium:approved_active_litigation","label":"Delay cause: county moratorium / approved_active_litigation","tracker":"delay"},"delay:litigation:approved_active_litigation":{"id":"delay:litigation:approved_active_litigation","label":"Delay cause: litigation / approved_active_litigation","tracker":"delay"},"delay:community_opposition:approved_active_litigation":{"id":"delay:community_opposition:approved_active_litigation","label":"Delay cause: community opposition / approved_active_litigation","tracker":"delay"},"delay:county_moratorium:delayed_amid_moratorium":{"id":"delay:county_moratorium:delayed_amid_moratorium","label":"Delay cause: county moratorium / delayed_amid_moratorium","tracker":"delay"},"delay:community_opposition:delayed_amid_moratorium":{"id":"delay:community_opposition:delayed_amid_moratorium","label":"Delay cause: community opposition / delayed_amid_moratorium","tracker":"delay"},"delay:public_outcry:tax_incentive_withdrawn":{"id":"delay:public_outcry:tax_incentive_withdrawn","label":"Delay cause: public outcry / tax_incentive_withdrawn","tracker":"delay"},"delay:tax_break_withdrawal:tax_incentive_withdrawn":{"id":"delay:tax_break_withdrawal:tax_incentive_withdrawn","label":"Delay cause: tax break withdrawal / tax_incentive_withdrawn","tracker":"delay"},"delay:permit_denial:denied_without_prejudice":{"id":"delay:permit_denial:denied_without_prejudice","label":"Delay cause: permit denial / denied_without_prejudice","tracker":"delay"},"delay:community_opposition:denied_without_prejudice":{"id":"delay:community_opposition:denied_without_prejudice","label":"Delay cause: community opposition / denied_without_prejudice","tracker":"delay"},"delay:community_opposition:under_construction_amid_opposition":{"id":"delay:community_opposition:under_construction_amid_opposition","label":"Delay cause: community opposition / under_construction_amid_opposition","tracker":"delay"},"delay:transparency_concerns:under_construction_amid_opposition":{"id":"delay:transparency_concerns:under_construction_amid_opposition","label":"Delay cause: transparency concerns / under_construction_amid_opposition","tracker":"delay"},"delay:community_opposition:rumored_no_application_filed":{"id":"delay:community_opposition:rumored_no_application_filed","label":"Delay cause: community opposition / rumored_no_application_filed","tracker":"delay"},"delay:meeting_postponed:rumored_no_application_filed":{"id":"delay:meeting_postponed:rumored_no_application_filed","label":"Delay cause: meeting postponed / rumored_no_application_filed","tracker":"delay"},"delay:community_opposition:moratorium_in_force":{"id":"delay:community_opposition:moratorium_in_force","label":"Delay cause: community opposition / moratorium_in_force","tracker":"delay"},"delay:community_opposition:under_review_no_zoning_process":{"id":"delay:community_opposition:under_review_no_zoning_process","label":"Delay cause: community opposition / under_review_no_zoning_process","tracker":"delay"},"delay:no_local_zoning_framework:under_review_no_zoning_process":{"id":"delay:no_local_zoning_framework:under_review_no_zoning_process","label":"Delay cause: no local zoning framework / under_review_no_zoning_process","tracker":"delay"},"delay:regulatory_transparency_dispute:regulatory_disclosure_dispute":{"id":"delay:regulatory_transparency_dispute:regulatory_disclosure_dispute","label":"Delay cause: regulatory transparency dispute / regulatory_disclosure_dispute","tracker":"delay"},"delay:ratepayer_cost_concerns:regulatory_disclosure_dispute":{"id":"delay:ratepayer_cost_concerns:regulatory_disclosure_dispute","label":"Delay cause: ratepayer cost concerns / regulatory_disclosure_dispute","tracker":"delay"},"delay:noise_nuisance:active_litigation":{"id":"delay:noise_nuisance:active_litigation","label":"Delay cause: noise nuisance / active_litigation","tracker":"delay"},"delay:historic_preservation_conflict:permit_denied":{"id":"delay:historic_preservation_conflict:permit_denied","label":"Delay cause: historic preservation conflict / permit_denied","tracker":"delay"},"delay:community_opposition:under_construction_amid_water_concerns":{"id":"delay:community_opposition:under_construction_amid_water_concerns","label":"Delay cause: community opposition / under_construction_amid_water_concerns","tracker":"delay"},"delay:water_capacity_constraints:under_construction_amid_water_concerns":{"id":"delay:water_capacity_constraints:under_construction_amid_water_concerns","label":"Delay cause: water capacity constraints / under_construction_amid_water_concerns","tracker":"delay"},"delay:city_moratorium_partial_exemption:phase_vote_delayed":{"id":"delay:city_moratorium_partial_exemption:phase_vote_delayed","label":"Delay cause: city moratorium partial exemption / phase_vote_delayed","tracker":"delay"},"delay:planning_commission_delay:phase_vote_delayed":{"id":"delay:planning_commission_delay:phase_vote_delayed","label":"Delay cause: planning commission delay / phase_vote_delayed","tracker":"delay"},"delay:community_opposition:approved_expanded_amid_opposition":{"id":"delay:community_opposition:approved_expanded_amid_opposition","label":"Delay cause: community opposition / approved_expanded_amid_opposition","tracker":"delay"},"delay:noise_regulation_review:approved_expanded_amid_opposition":{"id":"delay:noise_regulation_review:approved_expanded_amid_opposition","label":"Delay cause: noise regulation review / approved_expanded_amid_opposition","tracker":"delay"},"delay:multi_year_construction_delay:delayed_extension_requested":{"id":"delay:multi_year_construction_delay:delayed_extension_requested","label":"Delay cause: multi year construction delay / delayed_extension_requested","tracker":"delay"},"delay:design_changes:delayed_extension_requested":{"id":"delay:design_changes:delayed_extension_requested","label":"Delay cause: design changes / delayed_extension_requested","tracker":"delay"},"delay:county_moratorium_neighboring:early_stage_amid_county_moratoriums":{"id":"delay:county_moratorium_neighboring:early_stage_amid_county_moratoriums","label":"Delay cause: county moratorium neighboring / early_stage_amid_county_moratoriums","tracker":"delay"},"delay:regulatory_review:permitting_challenged":{"id":"delay:regulatory_review:permitting_challenged","label":"Delay cause: regulatory review / permitting_challenged","tracker":"delay"},"delay:environmental_petition:permitting_challenged":{"id":"delay:environmental_petition:permitting_challenged","label":"Delay cause: environmental petition / permitting_challenged","tracker":"delay"},"delay:utility_interconnection_timing:abandoned":{"id":"delay:utility_interconnection_timing:abandoned","label":"Delay cause: utility interconnection timing / abandoned","tracker":"delay"},"delay:withdrawal:abandoned":{"id":"delay:withdrawal:abandoned","label":"Delay cause: withdrawal / abandoned","tracker":"delay"},"delay:zoning_approval_challenge:active_litigation":{"id":"delay:zoning_approval_challenge:active_litigation","label":"Delay cause: zoning approval challenge / active_litigation","tracker":"delay"},"delay:litigation:zoning_request_paused_active_litigation":{"id":"delay:litigation:zoning_request_paused_active_litigation","label":"Delay cause: litigation / zoning_request_paused_active_litigation","tracker":"delay"},"delay:council_agenda_removal:zoning_request_paused_active_litigation":{"id":"delay:council_agenda_removal:zoning_request_paused_active_litigation","label":"Delay cause: council agenda removal / zoning_request_paused_active_litigation","tracker":"delay"},"delay:environmental_concerns:zoning_request_paused_active_litigation":{"id":"delay:environmental_concerns:zoning_request_paused_active_litigation","label":"Delay cause: environmental concerns / zoning_request_paused_active_litigation","tracker":"delay"},"delay:litigation:active_litigation_temporary_block":{"id":"delay:litigation:active_litigation_temporary_block","label":"Delay cause: litigation / active_litigation_temporary_block","tracker":"delay"},"delay:state_law_ownership_ban:active_litigation_temporary_block":{"id":"delay:state_law_ownership_ban:active_litigation_temporary_block","label":"Delay cause: state law ownership ban / active_litigation_temporary_block","tracker":"delay"},"delay:quorum_court_rejection:moratorium_exemption_rejected":{"id":"delay:quorum_court_rejection:moratorium_exemption_rejected","label":"Delay cause: quorum court rejection / moratorium_exemption_rejected","tracker":"delay"},"delay:county_moratorium_dispute:moratorium_exemption_rejected":{"id":"delay:county_moratorium_dispute:moratorium_exemption_rejected","label":"Delay cause: county moratorium dispute / moratorium_exemption_rejected","tracker":"delay"},"delay:litigation:active_litigation_records_dispute":{"id":"delay:litigation:active_litigation_records_dispute","label":"Delay cause: litigation / active_litigation_records_dispute","tracker":"delay"},"delay:public_records_dispute:active_litigation_records_dispute":{"id":"delay:public_records_dispute:active_litigation_records_dispute","label":"Delay cause: public records dispute / active_litigation_records_dispute","tracker":"delay"},"delay:litigation:delayed":{"id":"delay:litigation:delayed","label":"Delay cause: litigation / delayed","tracker":"delay"},"delay:permit_denial:delayed":{"id":"delay:permit_denial:delayed","label":"Delay cause: permit denial / delayed","tracker":"delay"},"delay:local_moratorium:cancelled":{"id":"delay:local_moratorium:cancelled","label":"Delay cause: local moratorium / cancelled","tracker":"delay"},"delay:tax_incentive_change:under_appeal":{"id":"delay:tax_incentive_change:under_appeal","label":"Delay cause: tax incentive change / under_appeal","tracker":"delay"},"delay:litigation:halted":{"id":"delay:litigation:halted","label":"Delay cause: litigation / halted","tracker":"delay"},"delay:environmental_review:halted":{"id":"delay:environmental_review:halted","label":"Delay cause: environmental review / halted","tracker":"delay"},"delay:local_moratorium:halted":{"id":"delay:local_moratorium:halted","label":"Delay cause: local moratorium / halted","tracker":"delay"},"delay:water_dispute:halted":{"id":"delay:water_dispute:halted","label":"Delay cause: water dispute / halted","tracker":"delay"},"delay:tax_incentive_change:halted":{"id":"delay:tax_incentive_change:halted","label":"Delay cause: tax incentive change / halted","tracker":"delay"},"delay:community_opposition:halted":{"id":"delay:community_opposition:halted","label":"Delay cause: community opposition / halted","tracker":"delay"},"delay:tax_incentive_change:litigation_active":{"id":"delay:tax_incentive_change:litigation_active","label":"Delay cause: tax incentive change / litigation_active","tracker":"delay"},"delay:corporate_realignment:delayed":{"id":"delay:corporate_realignment:delayed","label":"Delay cause: corporate realignment / delayed","tracker":"delay"},"delay:tax_incentive_change:cancelled":{"id":"delay:tax_incentive_change:cancelled","label":"Delay cause: tax incentive change / cancelled","tracker":"delay"},"delay:financing:litigation_active":{"id":"delay:financing:litigation_active","label":"Delay cause: financing / litigation_active","tracker":"delay"},"delay:state_moratorium:halted":{"id":"delay:state_moratorium:halted","label":"Delay cause: state moratorium / halted","tracker":"delay"},"delay:state_moratorium:litigation_active":{"id":"delay:state_moratorium:litigation_active","label":"Delay cause: state moratorium / litigation_active","tracker":"delay"},"delay:state_moratorium:cancelled":{"id":"delay:state_moratorium:cancelled","label":"Delay cause: state moratorium / cancelled","tracker":"delay"},"delay:water_dispute:withdrawn":{"id":"delay:water_dispute:withdrawn","label":"Delay cause: water dispute / withdrawn","tracker":"delay"},"delay:interconnection_queue:halted":{"id":"delay:interconnection_queue:halted","label":"Delay cause: interconnection queue / halted","tracker":"delay"},"delay:interconnection:cancelled":{"id":"delay:interconnection:cancelled","label":"Delay cause: interconnection / cancelled","tracker":"delay"},"delay:financing:cancelled":{"id":"delay:financing:cancelled","label":"Delay cause: financing / cancelled","tracker":"delay"},"delay:interconnection:denied":{"id":"delay:interconnection:denied","label":"Delay cause: interconnection / denied","tracker":"delay"},"delay:water:cancelled":{"id":"delay:water:cancelled","label":"Delay cause: water / cancelled","tracker":"delay"},"delay:water:denied":{"id":"delay:water:denied","label":"Delay cause: water / denied","tracker":"delay"},"delay:zoning_denial:halted":{"id":"delay:zoning_denial:halted","label":"Delay cause: zoning denial / halted","tracker":"delay"},"delay:permit_denial:halted":{"id":"delay:permit_denial:halted","label":"Delay cause: permit denial / halted","tracker":"delay"},"delay:council_vote_delay:final_vote_delayed":{"id":"delay:council_vote_delay:final_vote_delayed","label":"Delay cause: council vote delay / final_vote_delayed","tracker":"delay"},"delay:community_opposition:final_vote_delayed":{"id":"delay:community_opposition:final_vote_delayed","label":"Delay cause: community opposition / final_vote_delayed","tracker":"delay"},"utility:tariff:pending":{"id":"utility:tariff:pending","label":"Utility action: tariff / pending","tracker":"delay"},"utility:statement:pending":{"id":"utility:statement:pending","label":"Utility action: statement / pending","tracker":"delay"},"utility:tariff:contested":{"id":"utility:tariff:contested","label":"Utility action: tariff / contested","tracker":"delay"},"utility:other:pending":{"id":"utility:other:pending","label":"Utility action: other / pending","tracker":"delay"},"utility:tariff:approved":{"id":"utility:tariff:approved","label":"Utility action: tariff / approved","tracker":"delay"},"utility:rate case:approved":{"id":"utility:rate case:approved","label":"Utility action: rate case / approved","tracker":"delay"},"utility:special contract:approved":{"id":"utility:special contract:approved","label":"Utility action: special contract / approved","tracker":"delay"},"utility:rate case:pending":{"id":"utility:rate case:pending","label":"Utility action: rate case / pending","tracker":"delay"},"utility:special contract:denied":{"id":"utility:special contract:denied","label":"Utility action: special contract / denied","tracker":"delay"},"utility:statement:contested":{"id":"utility:statement:contested","label":"Utility action: statement / contested","tracker":"delay"},"utility:IRP:contested":{"id":"utility:IRP:contested","label":"Utility action: IRP / contested","tracker":"delay"},"utility:complaint:contested":{"id":"utility:complaint:contested","label":"Utility action: complaint / contested","tracker":"delay"},"utility:statement:approved":{"id":"utility:statement:approved","label":"Utility action: statement / approved","tracker":"delay"},"utility:IRP:pending":{"id":"utility:IRP:pending","label":"Utility action: IRP / pending","tracker":"delay"},"utility:special contract:pending":{"id":"utility:special contract:pending","label":"Utility action: special contract / pending","tracker":"delay"},"utility:other:approved":{"id":"utility:other:approved","label":"Utility action: other / approved","tracker":"delay"},"utility:other:contested":{"id":"utility:other:contested","label":"Utility action: other / contested","tracker":"delay"},"utility:IRP:approved":{"id":"utility:IRP:approved","label":"Utility action: IRP / approved","tracker":"delay"},"utility:tariff:denied":{"id":"utility:tariff:denied","label":"Utility action: tariff / denied","tracker":"delay"},"utility:certificate:approved":{"id":"utility:certificate:approved","label":"Utility action: certificate / approved","tracker":"delay"},"utility:policy:approved":{"id":"utility:policy:approved","label":"Utility action: policy / approved","tracker":"delay"},"utility:policy:effective":{"id":"utility:policy:effective","label":"Utility action: policy / effective","tracker":"delay"},"utility:tariff:effective":{"id":"utility:tariff:effective","label":"Utility action: tariff / effective","tracker":"delay"},"utility:policy:rejected":{"id":"utility:policy:rejected","label":"Utility action: policy / rejected","tracker":"delay"},"utility:policy:pending":{"id":"utility:policy:pending","label":"Utility action: policy / pending","tracker":"delay"},"utility:rate_case:pending":{"id":"utility:rate_case:pending","label":"Utility action: rate_case / pending","tracker":"delay"},"utility:other:denied":{"id":"utility:other:denied","label":"Utility action: other / denied","tracker":"delay"},"utility:other:effective":{"id":"utility:other:effective","label":"Utility action: other / effective","tracker":"delay"}},"warnings":[],"credits":["6abc Philadelphia","AEP Ohio Transmission Company (filed with Ohio Power Siting Board)","AI GridWatch moratorium tracker, CC BY 4.0 (aigridwatch.com)","Alabama Reflector","Alaska Beacon","American Transmission Company LLC (filed with PSC of Wisconsin)","Americus Times-Recorder","Arizona Mirror","Arkansas Advocate","Axios Pro Energy","Bisnow","Bisnow National","Bradenton Herald","CNBC Technology","Cardinal News VA","Central Florida Public Media","Chesterfield County public permit records","Chicago Construction News","City of Atlanta public permit records","City of Austin issued construction permits open data","City of Buckeye public permit records","City of Chandler public permit records","City of Charlotte public permit records","City of Chicago building permits open data","City of Fort Worth public permit records","City of Goodyear public permit records","City of Hillsboro public permit records","City of Mesa building permits open data","City of Mesa public permit records","City of Minneapolis construction permits (CCS) open data","City of Papillion public permit records","City of Phoenix public permit records","City of Red Oak public permit records","City of Reno public permit records","City of San Antonio public permit records","City of Statesboro, Georgia","City of Temple, Texas","Clearfield City Council (Utah Public Notice Website)","Colorado Newsline","Colorado Public Radio","Congress.gov (Library of Congress, public domain)","ConstructConnect News","Construction Dive","CourtListener DataCenter Dockets","CourtListener Opinions","Data Center Dynamics","Data Center Dynamics news","DataCenterTracker.org, CC BY 4.0","Dominion Energy Virginia","EIN News","East Bay Insiders Newsletter","Energy Central","FOX19 | Cincinnati","FOX5 Vegas","FOX6 News Milwaukee","Facilities Dive","Fairfax County public permit records","Florida Phoenix","Georgia Department of Community Affairs","Georgia EPD air permit records","Georgia Recorder","GovTech","Greensboro News and Record","Grist","Idaho Capital Sun","Illinois EPA air permit records","Indiana Capital Chronicle","Indiana Department of Environmental Management","Indiana IDEM air permit records","InkFreeNews.com","Iowa Capital Dispatch","Iowa DNR air permit records","KERA News","KEYC News Now","KGW","KRON4","Kansas City MO city issued permits open data","Kansas Reflector","Kentucky Lantern","Law360","Law360 Energy","LegiScan (legiscan.com) and the state legislature","Lehigh Valley Planning Commission","Local News Matters","Loudoun County public permit records","Loudoun Times-Mirror","Louisiana DEQ air permit records","Louisiana Illuminator","Maine Morning Star","Maricopa County Air Quality Department air permit records","Maricopa County public permit records","Maryland Matters","Mecklenburg County public permit records","Michigan Advance","Mid Bay News","Missouri Independent","Montana Free Press","NBC Bay Area","NBC4 Washington","NC Newsline","Native News Online","Nebraska Examiner","Nevada Current","Nevada NDEP air permit records","New Hampshire Bulletin","New Mexico Environment Department","North Carolina DEQ Division of Air Quality air permit records","North Dakota Department of Environmental Quality","North Dakota Monitor","Ohio Capital Journal","Ohio EPA air permit records","Oklahoma DEQ air permit records","Oklahoma Voice","OpenStates v3 (openstates.org), CC BY 4.0","Oregon Capital Chronicle","Orlando Sentinel","Pennsylvania Capital-Star","Pennsylvania Department of Environmental Protection","Pennsylvania Office of Consumer Advocate (filed with PA PUC)","Pioneer Press","Prince William County public permit records","Public Service Commission of Wisconsin","Public record (Legistar Web API, Granicus)","Rhode Island Current","Route Fifty","SEC EDGAR company submissions, public domain","SEC EDGAR full-text search, public domain","Searchlight New Mexico","Smithfield Township, Monroe County, PA","Source New Mexico","South Carolina Department of Environmental Services","South Dakota Searchlight","Springfield Daily Citizen","Stafford County public permit records","Statesman Journal","Strisker data center notes","Tennessee Lookout","Texas Commission on Environmental Quality","Texas TCEQ air permit records","The Baltimore Banner","The Current (GA)","The Detroit News","The Hill Energy","The North State Journal","The Pantagraph","The Real Deal","The Register","The Texas Tribune","The Verge","Times-Standard","Town of Culpeper public permit records","Tuscaloosa Thread","U.S. EPA ECHO","Union-Bulletin","Uprise RI","Utah Division of Air Quality","Utah Division of Air Quality air permit records","Utah News Dispatch","Utah Public Radio","Utility Dive","Virginia Business","Virginia DEQ air permit records","Virginia Electric and Power Company (filed with Virginia SCC)","Virginia Mercury","Visalia Times-Delta","WBUR","WCPO 9 Cincinnati","WGLT","WHEC.com","WJON","WKYT","WLOS","WLUK","WPBF","WQCS","WRAL (NC)","WUNC News","WVPE","Washington County public permit records","Washington Ecology air permit records","Washington State SEPA Register public permit records","Washington State Standard","Washoe County public permit records","Wausau Pilot & Review","West Virginia Watch","Winston-Salem Journal","Wisconsin Department of Natural Resources","Wisconsin Examiner","Yale Daily News","citybiz","contracosta.news","ictnews.org","indianapublicradio.org","inkfreenews.com","lex18.com","mountaintimesoregon.com","newmedia-wi.com","newscentermaine.com","thegazette.com","tuscaloosathread.com","wcpo.com","www.cities929.com"],"omitted":{"unverified_or_pending":1013,"no_explicit_state":136},"revision":"972c2302fa3e955e","trackers":{"policy":{"label":"Policy provisions","url":"#policy-governance"},"moratorium":{"label":"Restrictions & moratoriums","url":"/data-center-moratorium-tracker"},"delay":{"label":"Delays & utility actions","url":"/data-center-delay-tracker"},"water":{"label":"Water measures","url":"/data-center-water-tracker"},"atlas":{"label":"Projects & capital","url":"/data-center-capital-atlas"},"permits":{"label":"Permits & facilities","url":"/data-center-permits-tracker"},"grid":{"label":"Grid operator rules","url":"/data-center-grid-operator-watchlist"}},"selected":{"id":"TX","name":"Texas","records":[{"id":"1deb6f4ebbbba3d4","state":"TX","tracker":"policy","section":"provisions","title":"Back transmission commitments","summary":"Standards must set financial commitments supporting transmission infrastructure for covered loads. Permitted security forms and release rules depend on implementation; not a minimum energy bill.","scope":"ERCOT large-load interconnection; applicability and exceptions in the statute.","status":"Documented in cited instrument","date":null,"sources":[{"url":"https://capitol.texas.gov/tlodocs/89R/billtext/html/SB00006F.htm","label":"Texas SB 6, enrolled text"}],"parties":[],"groups":["policy:security"],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"56b017e8edee0f3b","state":"TX","tracker":"policy","section":"provisions","title":"Define emergency response","summary":"Covered backup-equipped loads may be directed to deploy backup generation or curtail after the specified market-service sequence. An emergency mechanism, not a general voluntary demand-response tariff.","scope":"ERCOT large-load interconnection; applicability and exceptions in the statute.","status":"Documented in cited instrument","date":null,"sources":[{"url":"https://capitol.texas.gov/tlodocs/89R/billtext/html/SB00006F.htm","label":"Texas SB 6, enrolled text"}],"parties":[],"groups":["policy:curtailment"],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"e17cedb3112fd488","state":"TX","tracker":"policy","section":"provisions","title":"Retain emissions limits","summary":"Emergency direction does not authorize violation of emissions or environmental requirements. Backup generation remains constrained by applicable environmental rules.","scope":"ERCOT large-load interconnection; applicability and exceptions in the statute.","status":"Documented in cited instrument","date":null,"sources":[{"url":"https://capitol.texas.gov/tlodocs/89R/billtext/html/SB00006F.htm","label":"Texas SB 6, enrolled text"}],"parties":[],"groups":["policy:emissions"],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"170b3631ad48f5a9","state":"TX","tracker":"policy","section":"provisions","title":"Verify the proposed site","summary":"Interconnection standards must include a way to demonstrate a legal interest in the proposed location. Evidence of site control does not establish that all permits or financing are secured.","scope":"ERCOT large-load interconnection; applicability and exceptions in the statute.","status":"Documented in cited instrument","date":null,"sources":[{"url":"https://capitol.texas.gov/tlodocs/89R/billtext/html/SB00006F.htm","label":"Texas SB 6, enrolled text"}],"parties":[],"groups":["policy:site-control"],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"5d017659f48d4f9f","state":"TX","tracker":"atlas","section":"sites","title":"Abernathy site (with TeraWulf)","summary":"168MW at Abernathy, Texas with TeraWulf, one of the initial Fluidstack sites in Anthropic's approximately $50 billion US data center program. TeraWulf agreed to sell its 50.1% interest in the 168 MW Abernathy joint venture to a Fluidstack-led investor group for approximately $530 million in cash, announced 6 July 2026 with consideration disclosed 5 August 2026  part of Anthropic's ~$50B US program 168MW","scope":"Record-specific: Abernathy","status":"announced","date":null,"sources":[{"url":"https://www.datacenterdynamics.com/en/news/anthropic-plans-50bn-us-data-center-spend-starting-with-fluidstack-sites-in-texas-and-new-york/","label":"DCD"},{"url":"https://investors.terawulf.com/news-events/press-releases/detail/142/terawulf-announces-anthropic-lease-at-justified-data-campus-and-sale-of-majority-interest-in-abernathy-joint-venture-to-fluidstack","label":"TeraWulf"},{"url":"https://www.sec.gov/Archives/edgar/data/1083301/000108330126000162/a_wulfearningsreleaseq22026.htm","label":"SEC EDGAR (TeraWulf 8-K)"}],"parties":[{"role":"Entity","name":"fluidstack"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"4cb594fd1dc0ffb4","state":"TX","tracker":"atlas","section":"sites","title":"Abilene 900MW AI factory campus (Microsoft)","summary":"On March 27, 2026 Crusoe announced a new 900MW Abilene campus supporting Microsoft AI infrastructure, bringing the site total to 2.1GW, with 336MW of critical IT load per building.  n.a. 900MW new campus, bringing the Abilene site total to 2.1GW; 336MW of critical IT load per building","scope":"Record-specific: Abilene","status":"announced","date":"announced March 27, 2026","sources":[{"url":"https://www.crusoe.ai/resources/newsroom/crusoe-announces-new-900-mw-ai-factory-campus-in-abilene-texas-to-support-microsoft-ai-infrastructure","label":"Crusoe"}],"parties":[{"role":"Entity","name":"crusoe-energy"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"d4a5e5e562f3ae2f","state":"TX","tracker":"atlas","section":"sites","title":"Abilene Stargate campus (Crusoe / Blue Owl / Primary Digital JV)","summary":"The JV began with $3.4 billion for a 206MW first phase designed for 100,000 GPUs for a Fortune 100 tenant, then entered phase 2 of a $15 billion joint venture funding six additional buildings to reach 1.2GW. Phase 1 construction began June 2024 and phase 2 in March 2025, targeted to energize mid-2026. Oracle/OpenAI (Stargate) contract value is n.a.  $3.4B phase 1; $15B total JV ($11.6B phase-2 tranche) 206MW first phase, expanded to 1.2GW across eight buildings, each designed for up to 50,000 Nvidia GB200 NVL72s","scope":"Record-specific: Abilene","status":"construction","date":"phase 1 construction June 2024; phase 2 March 2025; energize mid-2026","sources":[{"url":"https://www.crusoe.ai/resources/newsroom/crusoe-blue-owl-capital-primary-digital-joint-venture","label":"Crusoe"},{"url":"https://www.crusoe.ai/resources/newsroom/crusoe-blue-owl-capital-and-primary-digital-infrastructure-enter-joint-venture","label":"Crusoe"},{"url":"https://www.bisnow.com/news/national/data-center/primary-digital-infrastructure-emerges-as-key-player-in-texas-stargate-data-center-campus-129519","label":"Bisnow"},{"url":"https://www.crusoe.ai/resources/newsroom/crusoe-expands-ai-data-center-campus-in-abilene-to-1-2-gigawatts","label":"Crusoe"}],"parties":[{"role":"Entity","name":"crusoe-energy"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"d4609ee3a4870b13","state":"TX","tracker":"atlas","section":"sites","title":"Abilene campus (Oracle tenancy, Stargate-adjacent)","summary":"Oracle's Abilene tenancy runs on GB200 racks, with Oracle beginning delivery of the first NVIDIA GB200 racks in June 2025. Crusoe announced the flagship Abilene data center is live. Nvidia's capital role in this Stargate-adjacent capacity is indirect but material.  n.a. Eight-building campus designed for up to 50,000 Nvidia GB200 NVL72s per building; no MW figure given in this part (n.a.)","scope":"Record-specific: Abilene","status":"operating","date":"First GB200 racks delivered June 2025","sources":[{"url":"https://www.crusoe.ai/resources/newsroom/crusoe-announces-flagship-abilene-data-center-is-live","label":"Crusoe"},{"url":"https://www.crusoe.ai/resources/newsroom/crusoe-blue-owl-capital-and-primary-digital-infrastructure-enter-joint-venture","label":"Crusoe"}],"parties":[{"role":"Entity","name":"nvidia"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"aae94ef47781c62f","state":"TX","tracker":"atlas","section":"sites","title":"Abilene, Texas AI campus","summary":"Newmark structured the $7.1B construction loan for the 1.2 GW Abilene, Texas AI campus inside a $15B JV with Crusoe, Blue Owl Capital and Primary Digital Infrastructure. The project comprises eight buildings targeting 1.4 GW by 2026.  $7.1B construction loan inside a $15B JV 1.2 GW campus, eight buildings targeting 1.4 GW by 2026","scope":"Record-specific: Abilene","status":"construction","date":"targeting 1.4 GW by 2026","sources":[{"url":"https://completeaitraining.com/news/newmark-groups-15-billion-data-center-bet-how-ai/","label":"Complete AI Training"}],"parties":[{"role":"Entity","name":"newmark"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"98cd1d3d6352d702","state":"TX","tracker":"atlas","section":"sites","title":"Advanced Manufacturing Center, Houston","summary":"Apple opened its Advanced Manufacturing Center in Houston on 13 August 2026, stating that in less than nine months it invested hundreds of millions of dollars into the facility, stood up a factory, started production, and shipped the first advanced AI servers off the line, with Mac mini production to begin later in the year. Production started ahead of schedule in late 2025. Houston is a server manufacturing plant, not a data center. Apple opened its 20,000 sq ft Advanced Manufacturing Center in Houston on 13 August 2026, inside the existing plant that builds and ships Apple's AI servers, and said Mac mini production would begin at the site later in 2026. CNBC reported the same day that Apple said $60 billion of its US investment program is going to Texas  hundreds of millions of dollars invested in less than nine months (no precise figure disclosed) n.a.; a server manufacturing plant, not a data center","scope":"Record-specific: Houston","status":"operating","date":"Production started late 2025 ahead of schedule; opened 13 August 2026","sources":[{"url":"https://www.apple.com/newsroom/2026/08/apple-opens-advanced-manufacturing-center-in-houston/","label":"Apple Newsroom"},{"url":"https://www.foxbusiness.com/politics/apple-building-american-made-ai-servers-ahead-schedule-new-houston-facility-answering-trump-call","label":"Fox Business"},{"url":"https://9to5mac.com/2025/10/23/apple-coo-touts-accelerated-timeline-for-houston-built-ai-servers/","label":"9to5Mac"},{"url":"https://timesofoman.com/article/175595-apple-opens-advanced-manufacturing-center-in-houston","label":"Times of Oman"},{"url":"https://www.cnbc.com/video/2026/08/13/apple-says-60-billion-of-its-us-investment-push-is-going-to-texas.html","label":"CNBC"}],"parties":[{"role":"Entity","name":"apple"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"08b6b11eb0631ea6","state":"TX","tracker":"atlas","section":"at_risk","title":"Airport Drive data center rezoning","summary":"The Wichita Falls City Council unanimously rejected the rezoning for a data center on Airport Drive on 5 May 2026. The item had been tabled in February 2026 and a revised offer addressed light, sound and traffic. Council members cited proximity to homes, construction traffic, 24-hour operations and uncertainty about the developer.","scope":"Record-specific: City of Wichita Falls","status":"rejected","date":"Rejected 5 May 2026","sources":[{"url":"https://www.newschannel6now.com/2026/05/05/wichita-falls-city-council-rejects-airport-drive-data-center-rezoning/","label":"KAUZ News Channel 6"}],"parties":[{"role":"Developer","name":"Data Nova X"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"4d37eb448c691ddd","state":"TX","tracker":"atlas","section":"sites","title":"Allen facility","summary":"One of Voltage Park's six US sites.  n.a. part of 60MW across six data centers in four states","scope":"Record-specific: Allen","status":"operating","date":null,"sources":[{"url":"https://www.voltagepark.com/blog/scaling-ai-in-2025-flexibility-speed","label":"Voltage Park"},{"url":"https://www.datacenterdynamics.com/en/news/gpuaas-provider-voltage-park-merges-with-cloud-platform-lightning-ai/","label":"DCD"}],"parties":[{"role":"Entity","name":"voltage-park"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"d57984efffb4a00e","state":"TX","tracker":"atlas","section":"sites","title":"Amazon Data Services Horizon Junction data center campus (County Road 241)","summary":"Amazon Data Services, Inc. registered a new data center building at 1752 County Road 241 in Floydada as CONFIDENTIAL DATA CENTER on 20 July 2026, followed by three Horizon Junction data center buildings at 1762, 1774 and 1782 County Road 241 on 5 August 2026, each with an estimated cost of $300 million and an estimated schedule of 1 August 2026 to 1 April 2027  Four TDLR registrations at $300 million each: a confidential Building A registered 20 July 2026 and Horizon Junction Buildings B, C and D registered 5 August 2026; no company total disclosed; USD field left null to avoid summing separate building registrations Buildings B to D are 189,060 sq ft each per TDLR; MW not disclosed","scope":"Record-specific: Floydada","status":"registered for construction","date":"TDLR registrations 20 July and 5 August 2026","sources":[{"url":"https://www.tdlr.texas.gov/TABS/Search/Project/TABS2026025594","label":"TDLR TABS project TABS2026025594"},{"url":"https://www.tdlr.texas.gov/TABS/Search/Project/TABS2026027103","label":"TDLR TABS project TABS2026027103"},{"url":"https://www.tdlr.texas.gov/TABS/Search/Project/TABS2026027104","label":"TDLR TABS project TABS2026027104"},{"url":"https://www.tdlr.texas.gov/TABS/Search/Project/TABS2026027105","label":"TDLR TABS project TABS2026027105"}],"parties":[{"role":"Entity","name":"Amazon Data Services"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"795fd2a9308c4c1f","state":"TX","tracker":"atlas","section":"sites","title":"Anthropic-Fluidstack Texas data centers","summary":"Texas leg of Anthropic's $50 billion investment in American computing infrastructure, building data centers with Fluidstack, with sites coming online throughout 2026. Specific city and county sites and MW are n.a. in the source.  part of $50 billion program across Texas and New York n.a. (no numeric GW disclosed; Fluidstack chosen for 'rapid delivery of gigawatts of power')","scope":"Record-specific:","status":"announced","date":"announced November 2025; sites coming online throughout 2026","sources":[{"url":"https://www.anthropic.com/news/anthropic-invests-50-billion-in-american-ai-infrastructure","label":"Anthropic"},{"url":"https://www.cnbc.com/2025/11/12/anthropic-ai-data-centers-texas-new-york.html","label":"CNBC"}],"parties":[{"role":"Entity","name":"anthropic"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"2b66025736027e53","state":"TX","tracker":"atlas","section":"sites","title":"Apollo site","summary":"Cipher acquired an option on an approximately 288-acre site within 25 miles of San Antonio, Texas ERCOT studied load, Batch Zero Option price not disclosed Up to 900 MW; submitted as a studied load in ERCOT Batch Zero","scope":"Record-specific: Near San Antonio (within 25 miles)","status":"announced","date":"Disclosed 4 August 2026","sources":[{"url":"https://www.sec.gov/Archives/edgar/data/1819989/000181998926000038/q226_earningsxprxdraftxvf.htm","label":"SEC EDGAR (Cipher Digital 8-K)"}],"parties":[{"role":"Entity","name":"Cipher Digital"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"1b019df78348dbd7","state":"TX","tracker":"atlas","section":"at_risk","title":"Athens data center moratorium","summary":"Athens, Texas, enacted a local data center moratorium or ban, recorded in SAVRN's moratorium tracker as dated August 2026. City Council voted 3-2 to permanently ban data centers within city limits. Defines data center as any facility over 500 sq ft used primarily to house servers. Not a moratorium. a standing zoning ban. The measure has no end date by design and applies at a threshold of 500 sq ft.","scope":"Record-specific: Athens","status":"moratorium","date":"Enacted August 2026","sources":[{"url":"https://www.kltv.com/2026/08/25/athens-city-council-votes-3-2-favor-ordinance-banning-data-centers/","label":"kltv.com"}],"parties":[],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"b2b1643b71fbc5bc","state":"TX","tracker":"atlas","section":"sites","title":"Atlas One compute campus (Project Atlas)","summary":"Azio AI Holdings (Nasdaq: AZIO) announced Atlas One, a 548-acre South Texas site designed for up to 500 MW as the first phase of Project Atlas, combining land, behind-the-meter gas generation, fiber and modular compute. The company reports 6 MW of activated capacity running bitcoin mining workloads and says permits and regulatory approvals are still required for expansion. The county was not identified Behind-the-meter natural gas generation Total capital not disclosed; company cites $2.8 million committed for AT&T fiber connectivity Engineered for up to 500 MW; 100 MW of behind-the-meter gas generation described as secured; 6 MW of compute activated","scope":"Record-specific:","status":"announced","date":"Announced 20 August 2026 (company release); single-outlet report (Enid News & Eagle (GlobeNewswire release))","sources":[{"url":"https://www.enidnews.com/region/azio-ai-holdings-announces-atlas-one-a-500-acre-site-designed-for-up-to-500/article_34caabec-1564-533e-bc6d-8f7f5330c14e.html","label":"Enid News & Eagle (GlobeNewswire release)"}],"parties":[{"role":"Entity","name":"Azio AI Holdings, Inc."}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"9594ac3c5cec692d","state":"TX","tracker":"atlas","section":"sites","title":"BT Gateway Data Center (4989 County Road 2656)","summary":"Houston-based Giga Energy plans the BT Gateway Data Center, an AI computing facility on about 30 acres along County Road 2656 outside Royse City, with about 20 acres to be developed and a main building of about two acres. The TDLR registration lists a 100,000 sq ft new data center with an estimated cost of $384 million, owned by Giga AFM LLC. The company cited closed-loop cooling, about 300 construction workers, 20 to 24 permanent jobs and about $7.2 million a year in county property tax, with completion targeted for mid-2027. Existing three-phase distribution lines; no new high-voltage transmission; Giga Energy to pay for any grid connection upgrades TDLR estimated cost $384 million; Giga Energy said it is not seeking tax abatements or public subsidies Not disclosed","scope":"Record-specific: Royse City","status":"proposed","date":"Registered with TDLR 23 June 2026 (TABS2026023619); town hall reported 28 July 2026","sources":[{"url":"https://www.tdlr.texas.gov/TABS/Search/Project/TABS2026023619","label":"TDLR TABS project TABS2026023619"},{"url":"https://www.yahoo.com/news/us/articles/royse-city-town-hall-scheduled-035900112.html","label":"Yahoo News, 28 July 2026"}],"parties":[{"role":"Entity","name":"Giga Energy (Giga AFM LLC)"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"ba3ac35887ddae9c","state":"TX","tracker":"atlas","section":"sites","title":"Barber Lake data center","summary":"Cipher Barber Lake LLC signed a 10-year lease with Fluidstack USA II Inc. on 25 September 2025 for a 168 MW critical IT facility in Colorado City, Texas, with Google backstopping certain Fluidstack obligations; delivery was then expected by September 2026. On 24 September 2026 Cipher amended the lease and signed a binding commitment with an unnamed leading AI lab for a further 10-year lease after the Fluidstack term, taking contracted revenue from $3.8 billion to over $9 billion. Tenant change orders set a phased delivery of data halls between the fourth quarter of 2026 and the first quarter of 2027, with first rent expected in the fourth quarter of 2026.  Construction budget not disclosed; under the 24 September 2026 amendment Cipher bears the first $359.3 million of costs above the initial budget, and the tenant reimburses 50% of costs above that amount over the 20-year term 168 MW of critical IT load per the 25 September 2025 Form 8-K","scope":"Record-specific: Colorado City","status":"under_construction","date":"Fluidstack lease signed 25 September 2025; amendment and follow-on commitment signed 24 September 2026, announced 25 September 2026","sources":[{"url":"https://www.sec.gov/Archives/edgar/data/1819989/000181998926000043/cifr-20260924.htm","label":"Cipher Digital Form 8-K, 25 September 2026 (SEC)"},{"url":"https://www.sec.gov/Archives/edgar/data/1819989/000181998926000043/barberlakeleaseamendmentpr.htm","label":"Cipher Digital press release, Exhibit 99.1 (SEC)"},{"url":"https://www.sec.gov/Archives/edgar/data/1819989/000095010325012168/dp234624_8k.htm","label":"Cipher Mining Form 8-K, 25 September 2025 (SEC)"}],"parties":[{"role":"Entity","name":"Cipher Digital"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"bb26828b8cac214b","state":"TX","tracker":"atlas","section":"sites","title":"Beacon Point data center","summary":"A turnkey data center comprising six data halls with a combined total of 352 MW of critical IT capacity, to be built on an approximately 521-acre property in Nueces County, Texas, together with a substation on the property. The facility is to be leased to a tenant that the filing states was rated AA- or higher as of the pricing date; the filing does not name the tenant. Press reporting on 31 August and 1 September 2026 identified Nvidia as the holder of the lease on the campus, with Lambda installing Nvidia systems there to serve a reported $35 billion cloud agreement with Anthropic. Hut 8's filings do not name the tenant, and the atlas records the tenant chain as press-reported rather than filing-confirmed. Second 15-year, 352 MW IT lease signed with the same investment-grade tenant, announced 20 July 2026, bringing contracted capacity to 704 MW and campus base-term value to $19.6 billion. 500 MW of Phase 2 utility capacity moved to under construction after 30 June 2026 Beacon Point DC LLC (also known as Lon Hill Infrastructure LLC) registered a 657,130 sq ft data center building with guardhouse, fire water tank and support yards at 4650 FM 1694 near Robstown, Nueces County, with the Texas Department of Licensing and Regulation on 9 September 2026, at an estimated cost of $398,985,153 and an estimated schedule of 28 September 2026 to 5 November 2027 Substation to be constructed on the property No total project cost disclosed; financed in part by a $4.25 billion senior secured note offering priced 4 June 2026 Six data halls with a combined total of 352 MW of critical IT capacity","scope":"Record-specific:","status":"construction","date":"Note offering priced 4 June 2026","sources":[{"url":"https://www.sec.gov/Archives/edgar/data/0001964789/000110465926070744/tm2616926d1_ex99-1.htm","label":"SEC 8-K (Hut 8)"},{"url":"https://finance.yahoo.com/technology/ai/articles/anthropic-signs-35-billion-cloud-111829800.html","label":"Reuters via Yahoo Finance"},{"url":"https://www.bloomberg.com/news/articles/2026-08-31/anthropic-seals-35-billion-cloud-deal-with-nvidia-backed-lambda","label":"Bloomberg"},{"url":"https://www.sec.gov/Archives/edgar/data/1964789/000110465926084862/tm2620835d1_ex99-1.htm","label":"SEC EDGAR (Hut 8 8-K)"},{"url":"https://www.sec.gov/Archives/edgar/data/1964789/000110465926090041/tm2621890d1_ex99-1.htm","label":"SEC EDGAR (Hut 8 Q2 2026 release)"},{"url":"https://www.tdlr.texas.gov/TABS/Search/Project/TABS2027000611","label":"TDLR TABS project TABS2027000611"}],"parties":[{"role":"Entity","name":"hut8"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"75db529d21e329ac","state":"TX","tracker":"atlas","section":"sites","title":"Black Mountain southeast Fort Worth data center campus","summary":"Fort Worth City Council approved Black Mountain's revised site plan for 187 acres south of Lon Stephenson Road between Forest Hill and Anglin drives, with four buildings up to 70 feet, an electrical substation and more than 300 feet of buffer from residences. The plan cuts the project from 3 million sq ft in 18 buildings, tabled in May and June 2026 after resident opposition, to just over 1 million sq ft. The city formed a Data Center and Infrastructure Commission on 11 August 2026, and KERA reports the council's subsequent moratorium does not affect existing projects such as Black Mountain Plan includes an electrical substation $10 billion per Bisnow and CRE Daily MW not disclosed; revised plan is just over 1 million sq ft in four buildings up to 70 feet, down from 3 million sq ft in 18 buildings","scope":"Record-specific: Fort Worth","status":"approved","date":"Approval reported 27 August 2026 by Bisnow and 28 August 2026 by CRE Daily; council vote count not published in the fetched articles","sources":[{"url":"https://www.bisnow.com/news/dallas-ft-worth/data-center-development/fort-worth-approves-plan-for-10b-data-center-campus","label":"Bisnow"},{"url":"https://www.yahoo.com/news/us/articles/fort-worth-data-center-plan-165548053.html","label":"CRE Daily via Yahoo News"},{"url":"https://www.keranews.org/news/2026-09-03/data-center-growth-north-texas-map","label":"KERA News"}],"parties":[{"role":"Entity","name":"Black Mountain"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"975b1d30e7fa0a90","state":"TX","tracker":"atlas","section":"sites","title":"Black Pearl Facility","summary":"Former Bitcoin mining facility being retrofitted for an HPC tenant. Cipher amended the lease on 24 July 2026 to accelerate first delivery, began delivering capacity at the start of August 2026 and said rent had commenced, with remaining Phase I halls in MEP fit-out and Phase II foundations underway Grid-connected $2.0 billion of 6.125% senior secured notes due 2031 issued February 2026 by Black Pearl Compute LLC Approximately 300 gross MW of turnkey data center capacity leased for 15 years","scope":"Record-specific: Wink","status":"partially operational","date":"Lease amended 24 July 2026; first capacity and rent commencement announced 4 August 2026","sources":[{"url":"https://www.sec.gov/Archives/edgar/data/1819989/000181998926000041/cifr-20260630.htm","label":"SEC EDGAR (Cipher Digital 10-Q)"},{"url":"https://www.sec.gov/Archives/edgar/data/1819989/000181998926000038/q226_earningsxprxdraftxvf.htm","label":"SEC EDGAR (Cipher Q2 2026 press release, Ex. 99.1)"}],"parties":[{"role":"Entity","name":"Cipher Digital"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"4f2f723598f986ec","state":"TX","tracker":"atlas","section":"at_risk","title":"Blueprint Data Centers Taylor facility","summary":"Five Taylor residents sued to stop a 135,000 sq ft Blueprint data center, arguing a 1999 deed restriction required the land to be held as parkland. The judge had paused work during the case, but on 8 October 2025 District Judge Ryan Larson dismissed the suit for lack of standing. The residents' group said it was filing an appeal. On 17 September 2026 Texas Attorney General Ken Paxton announced an investigation into whether the 1999 deed restriction holding the land in trust for future use as parkland was modified, released or terminated before the Taylor Economic Development Corporation sold the site to NCP Travis TPP Project, LLC for $10 million in April 2025, and said he may seek court intervention. The city said it would cooperate fully.","scope":"Record-specific: Williamson County District Court / City of Taylor","status":"litigation","date":"Suit 2025; dismissed 8 October 2025; Attorney General investigation announced 17 September 2026","sources":[{"url":"https://www.kut.org/energy-environment/2025-09-30/taylor-data-center-lawsuit-parkland-blueprint","label":"KUT"},{"url":"https://www.kut.org/energy-environment/2025-10-08/judge-dismissed-lawsuit-taylor-data-center-blueprint-texas","label":"KUT"},{"url":"https://www.kut.org/energy-environment/2026-09-17/attorney-general-data-center-taylor-tx","label":"KUT"}],"parties":[{"role":"Developer","name":"Blueprint Data Centers"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"452f5c648497d6a7","state":"TX","tracker":"atlas","section":"sites","title":"Borden County campus (pipeline)","summary":"Named in SB Energy's Form S-1 filed 1 September 2026 as part of the near-term data center pipeline, where the company has secured land and is actively pursuing development and lease negotiations. Neither county site is currently included in the Data Center Contracted Portfolio or in the backlog calculation. Secured ERCOT interconnection per the registration statement No site capital figure disclosed. The site is not included in SB Energy's Data Center Contracted Portfolio, its backlog, or its backlog-associated capex. Borden County and Scurry County together represent approximately 1.7 GW-IT of near-term critical IT capacity in ERCOT with secured interconnection. The registration statement gives the combined figure only, so no per-site megawatt figure is recorded here.","scope":"Record-specific:","status":"announced","date":"Disclosed in the Form S-1 filed 1 September 2026","sources":[{"url":"https://www.sec.gov/Archives/edgar/data/2133037/000162828026059639/sbenergy-sx1.htm","label":"SEC Form S-1 (SB Energy, Inc.)"}],"parties":[{"role":"Entity","name":"sb-energy"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"5ba7f44dad193ea0","state":"TX","tracker":"atlas","section":"sites","title":"Cameron County AI data center campus","summary":"Fluidstack received a site work permit on 10 September 2026 for a campus of more than 1,100 acres in unincorporated Cameron County, roughly four miles southwest of Rio Hondo, east of FM 509 and west of FM 106. Phase one is budgeted at $4 billion and targeted for completion in mid-2028, with more than 2,500 construction jobs expected. Water is supplied by the East Rio Hondo Water Supply Corporation at approximately 50,000 gallons a day during construction, falling to around 7,000 gallons a day in operation. Fluidstack broke ground on 10 September 2026 on a $4 billion project on more than 1,100 acres east of Valley International Airport and west of the Port of Harlingen near Rio Hondo, expecting more than 2,500 construction jobs. A week earlier Harlingen city commissioners tabled a drainage agreement to route stormwater into a city canal; Fluidstack said it received a worksite permit from Cameron County and is pursuing alternative plans for discharge. Fluidstack said on 21 September 2026 that it has begun construction on the $4 billion first phase of its AI data center campus in Cameron County, Texas, which it says is planned to support up to 1.5 GW of capacity. The company expects more than 2,500 construction jobs and several hundred permanent positions. It says it requested and received no local property tax abatements or county incentives, will pay for the campus's energy, infrastructure and water, will use closed-loop cooling supplied by East Rio Hondo Water Supply Corporation, and will limit sound at the property line to 60 decibels. The company did not name a customer or disclose financing. AEP Texas transmission, with Fluidstack funding its own electrical infrastructure $4 billion for phase one Fluidstack states the $4 billion first phase is planned to support up to 1.5 GW (company post, 21 September 2026)","scope":"Record-specific: Rio Hondo","status":"under construction","date":"Site work permit issued 10 September 2026; construction of the first phase announced 21 September 2026","sources":[{"url":"https://constructionreviewonline.com/fluidstack-starts-site-work-on-4-billion-cameron-county-ai-data-center-campus/","label":"Construction Review"},{"url":"https://www.krgv.com/news/fluidstack-breaks-ground-on-4-billion-data-center-campus-in-cameron-county","label":"KRGV"},{"url":"https://fluidstack.io/community/building-compute-in-cameron-county","label":"Fluidstack, 'Construction begins on our 1.5GW, $4B first phase in Cameron County' (21 September 2026)"},{"url":"https://theenergymag.com/news/2026-09-22/fluidstack-texas-ai-construction-cameron-county","label":"TheEnergyMag"}],"parties":[{"role":"Entity","name":"fluidstack"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"78ad3cbf327cfee2","state":"TX","tracker":"atlas","section":"sites","title":"Cedar Creek data center and gas plant campus (382 Earl Callahan Road), Anthropic in lease talks","summary":"The Austin Business Journal reported on 24 August 2026 that Anthropic is in talks to lease a planned data center on a 2,842-acre site near Cedar Creek in Bastrop County, backed by a gas-fired plant. The developers withdrew requests for Bastrop County and school district tax abatements, which the outlet attributed to Anthropic. Power plant construction could start in the third quarter of 2026 with completion tentatively in 2028. Axios reported that Anthropic had not finalized a deal and that county officials were reviewing development applications. On 22 and 23 September 2026 the Austin Business Journal, as relayed by KXAN, reported that the campus appears to be paused after Governor Greg Abbott ordered a halt to new state permits for data center projects on 21 September 2026. Neither the developers nor Bastrop County had publicly confirmed a pause, and no project-specific TCEQ action on the pending Pacifico air permit registration was found. Aqua Water Supply Corp.'s board has approved large-volume water service to Pacifico Energy Development for the 2,842-acre development; Pacifico must pay a $3,500 legal deposit by 30 November 2026 and enter a non-standard service agreement by 28 February 2027 or risk losing the approval (Community Impact, reported 25 September 2026). On-site natural gas turbines, 710 MW site-rated; TCEQ air permit pending Data center investment not disclosed; Pacifico proposes investing about $2.24 billion in the 710 MW on-site gas-fired power facility, per its Texas Comptroller JETI application (Community Impact, 15 July 2026) Public documents describe 710 MW of site-rated redundant gas-turbine power supporting 490 MW of data center load","scope":"Record-specific: Cedar Creek","status":"proposed","date":"Reported by the Austin Business Journal on 24 August 2026; no deal finalized as of 26 August 2026","sources":[{"url":"https://therealdeal.com/texas/2026/08/25/anthropic-eyes-bastrop-for-new-data-hub/","label":"The Real Deal"},{"url":"https://www.msn.com/en-us/technology/general/anthropic-goes-big-on-texas/ar-AA2aZaIS","label":"Axios Austin via MSN"},{"url":"https://www.yahoo.com/news/videos/bastrop-county-data-center-project-222505670.html","label":"KXAN Austin via Yahoo News"},{"url":"https://communityimpact.com/bastrop-cedar-creek/business/aqua-oks-water-service-for-pacifico-development/","label":"Community Impact, 25 September 2026"},{"url":"https://communityimpact.com/bastrop-cedar-creek/business/new-22b-cedar-creek-data-center-project-abatements-under-review/","label":"Community Impact, 15 July 2026"}],"parties":[{"role":"Entity","name":"anthropic"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"50535baa5d7f15db","state":"TX","tracker":"atlas","section":"at_risk","title":"Cedar Creek data center and gas plant campus (Pacifico Energy and BlackChamber Partners; Anthropic in lease talks)","summary":"TCEQ Air Permits Division director Samuel Short told Bastrop County residents by email, as reported by the San Antonio Current on 29 September 2026, that the Pacifico project is on hold because TCEQ has paused all air and water permits and authorizations for infrastructure directly supporting data centers under Governor Abbott's 21 September 2026 directive (row 769). The campus's on-site gas plant air permit was pending. The pause runs until the ERCOT and Texas Water Development Board audits are complete, with a TCEQ compliance update due 19 October 2026. Anthropic is reported to be in lease talks for the campus; no lease has been finalized.","scope":"Record-specific: Texas Commission on Environmental Quality (statewide data center permit pause)","status":"paused","date":"TCEQ email confirming the hold reported 29 September 2026 (single outlet); runs until the ERCOT and TWDB audits are complete, TCEQ compliance update due 19 October 2026","sources":[{"url":"https://www.sacurrent.com/news/abbott-orders-pause-of-air-permits-for-data-centers-experts-question-whether-he-has-the-authority/","label":"San Antonio Current"},{"url":"https://therealdeal.com/texas/2026/08/25/anthropic-eyes-bastrop-for-new-data-hub/","label":"The Real Deal"},{"url":"https://communityimpact.com/bastrop-cedar-creek/business/new-22b-cedar-creek-data-center-project-abatements-under-review/","label":"Community Impact"}],"parties":[{"role":"Developer","name":"Pacifico Energy and BlackChamber Partners"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"a633af5bac184f1e","state":"TX","tracker":"atlas","section":"sites","title":"Childress campus (Horizon 1-4)","summary":"IREN is deploying Nvidia GB300 systems in four Horizon 1-4 phases totaling 200MW of critical IT load at its 750MW campus in Childress, Texas, under the approximately $9.7 billion five-year Microsoft agreement. Horizon 1, the first of four 50 MW (IT) liquid-cooled deployments under the Microsoft contract, was delivered to and accepted by Microsoft, announced 13 August 2026 On 13 August 2026 IREN announced Horizon 1, the first of four 50 MW IT direct-to-chip liquid cooled deployments for Microsoft at Childress, had been delivered to and accepted by Microsoft, with Horizons 2 to 4 due later in 2026 backed by a 3GW secured NA power portfolio ~$9.7B Microsoft contract; ~$5.8B Dell equipment purchases 750MW campus; four Horizon 1-4 phases totaling 200MW of critical IT load for the Microsoft deployment","scope":"Record-specific: Childress","status":"construction","date":"agreement signed November 3, 2025","sources":[{"url":"https://iren.com/resources/blog/iren-signs97-billion-agreement-with-microsoft-to-deploy-ai-cloud-infrastructure","label":"IREN"},{"url":"https://www.sec.gov/Archives/edgar/data/1878848/000114036126032638/ef20080141_ex99-1.htm","label":"SEC EDGAR (IREN 8-K)"}],"parties":[{"role":"Entity","name":"iren"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"cca713bafe61ec58","state":"TX","tracker":"atlas","section":"at_risk","title":"Circle T Data Center (Westlake)","summary":"On 17 August 2026 Judge Kimberly Fitzpatrick of the 342nd District Court issued a temporary restraining order, sought by The Lakes at Marshall Ridge Homeowners Association in Keller and two residents, blocking the Westlake Town Council from approving the Circle T Data Center development agreement. At a 26 August hearing the restraint was extended through 8 September 2026. Plaintiffs allege the site plan lacked required setbacks and that building height was raised from 45 to 80 feet without proper notice. Separately, the Keller City Council approved a motion to begin a 90-day moratorium process within its own limits. On 26 August 2026 Judge Kimberly Fitzpatrick of the 342nd District Court extended the temporary restraining order barring a Westlake vote on the data center development plans until a 10 a.m. hearing on 8 September 2026. The Fort Worth Star-Telegram describes the project as a 1.1 million-square-foot complex on 87.9 acres at 13580 Denton Highway, 506 feet from homes in Keller's Lakes at Marshall Ridge neighborhood, and reports the Keller City Council passed a resolution opposing the project and authorizing legal action. On 15 September 2026 the Westlake Town Council voted unanimously not to renew its police services agreement with Keller, which expires in 2028, amid the dispute. The Dallas Morning News describes Circle T as eight buildings on 88 acres. The Fort Worth Star-Telegram reported on 16 September 2026 that the judge has extended the temporary restraining order against a Westlake vote twice to allow more time to study evidence, and that the latest hearing is scheduled for 25 September 2026. On Friday 25 September 2026 Judge Kimberly Fitzpatrick dissolved the temporary restraining order that had kept Westlake from voting to approve the data center, after criticizing both sides for filing about 1,000 pages of documents the night before, and set a 23 October 2026 hearing on the Lakes at Marshall Ridge Homeowners Association lawsuit, in which the city of Keller is an intervener. Westlake said it was pleased and would continue to follow Governor Abbott's directives on data center development; Keller's mayor and an intervening resident said the suit continues. The Dallas Morning News reported on 28 September 2026 that the parties met for mediation before the 25 September hearing without reaching a settlement, and a status report said the plaintiffs' claims reached an impasse while Keller, Westlake and Circle T continue a settlement dialogue. At the 23 October 2026 hearing the judge is to decide whether the plaintiffs have standing to continue the suit. Westlake says the site has been zoned commercial and industrial since 1998, making the data center allowable by right.","scope":"Record-specific: Town of Westlake / 342nd District Court, Tarrant County","status":"litigation","date":"TRO issued 17 August 2026, extended twice, dissolved 25 September 2026; lawsuit hearing set for 23 October 2026","sources":[{"url":"https://fortworthreport.org/2026/08/17/westlake-data-center-agreement-temporarily-blocked-by-tarrant-county-court/","label":"Fort Worth Report"},{"url":"https://www.cbsnews.com/texas/news/judge-blocks-westlake-vote-data-center-restraining-order-keller-hoa/","label":"CBS Texas"},{"url":"https://dmnews.com/dmn-westlake-texas-had-its-88-acre-circle-t-data-center-vote-frozen-by-a-tarrant-county-judge-an-hour-before-the-town-council-could-sign-and-the-pause-now-runs-through-september-8/","label":"DMNews"},{"url":"https://www.yahoo.com/news/us/articles/keller-mayor-promises-consider-legal-013612328.html","label":"Yahoo News"},{"url":"https://www.msn.com/en-us/news/other/judge-keeps-temporary-restraining-order-in-place-against-westlake-to-study-more-evidence/ar-AA2b42VZ","label":"Fort Worth Star-Telegram via MSN"},{"url":"https://www.msn.com/en-us/technology/tech-companies/how-we-got-here-a-timeline-of-events-in-the-westlake-keller-data-center-fight/ar-AA2bqmwO","label":"Fort Worth Star-Telegram via MSN"},{"url":"https://www.dallasnews.com/news/public-safety/article/westlake-does-not-renew-keller-police-contract-22435339.php","label":"Dallas Morning News"},{"url":"https://www.star-telegram.com/news/local/community/northeast-tarrant/article317269014.html","label":"Fort Worth Star-Telegram"},{"url":"https://www.star-telegram.com/news/local/community/northeast-tarrant/article317374071.html","label":"Fort Worth Star-Telegram"},{"url":"https://www.msn.com/en-us/news/other/judge-dissolves-westlake-data-center-restraining-order-but-fight-continues/ar-AA2d00GP","label":"Fort Worth Star-Telegram via MSN"},{"url":"https://www.msn.com/en-us/news/other/judge-dissolves-restraining-order-tied-to-westlake-data-center-kellers-lawsuit-is-ongoing/ar-AA2d8Pk8","label":"Dallas Morning News via MSN"}],"parties":[{"role":"Developer","name":"PowerHouse Data Centers"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"f576e770f51edf2a","state":"TX","tracker":"atlas","section":"sites","title":"Circle T Data Center, Westlake","summary":"Kimley-Horn filed for a data center on about 87.96 acres in Westlake. The first building is allowed by right and later buildings need specific use permits. PowerHouse lists 11 active and planned Texas projects totaling 10 GW PowerHouse paid Oncor to bring a 350 MW substation to Westlake that will serve the data center and the town's pump station Capital cost not disclosed Up to four 300,000 square foot buildings totaling 300 MW per site plans","scope":"Record-specific: Westlake","status":"announced","date":"Filing reported 6 August 2026","sources":[{"url":"https://www.datacenterdynamics.com/en/news/powerhouse-files-for-300mw-data-center-campus-outside-dallas-fort-worth/","label":"Data Center Dynamics"}],"parties":[{"role":"Entity","name":"PowerHouse Data Centers"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"bea4fb06cf909bd0","state":"TX","tracker":"atlas","section":"sites","title":"CleanSpark Brazoria campus","summary":"Part of CleanSpark's Texas portfolio placed under a letter of intent and exclusivity arrangement with the Sandersville tenant. Map point is the county seat, Angleton The Sandersville tenant holding the Texas LOI was disclosed on 17 September 2026 as Anviran, LLC, a wholly owned Meta subsidiary  Land acquisitions of $28.7 million (27 February 2026) and $9.6 million (adjacent land, 28 May 2026); development capex not disclosed 447 acres; 300 MW initial demand with expansion potential to 600 MW","scope":"Record-specific: Not disclosed","status":"announced","date":"Announced 14 July 2026","sources":[{"url":"https://investors.cleanspark.com/news/news-details/2026/CleanSpark-Secures-Twenty-Year-Lease-with-High-Investment-Grade-Global-Technology-Company-for-Data-Center-in-Sandersville-Georgia/default.aspx","label":"CleanSpark"},{"url":"https://www.sec.gov/Archives/edgar/data/827876/000119312526338382/clsk-20260630.htm","label":"SEC Form 10-Q (CleanSpark)"},{"url":"https://www.sec.gov/Archives/edgar/data/827876/000119312526393758/clsk-ex99_1.htm","label":"SEC Form 8-K Exhibit 99.1 (CleanSpark Sandersville investor presentation)"}],"parties":[{"role":"Entity","name":"CleanSpark"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"b6232987a3d4982c","state":"TX","tracker":"atlas","section":"sites","title":"CleanSpark Sealy campus","summary":"Part of CleanSpark's 718-acre, up to 885 MW Texas portfolio placed under a letter of intent and exclusivity arrangement with the Sandersville tenant The Sandersville tenant holding the Texas LOI was disclosed on 17 September 2026 as Anviran, LLC, a wholly owned Meta subsidiary  Land acquisitions of $65.7 million (from Priority Power Management) and $15.1 million (adjacent land, 17 April 2026); development capex not disclosed 271 acres with nearly 300 MW","scope":"Record-specific: Sealy","status":"announced","date":"Announced 14 July 2026","sources":[{"url":"https://investors.cleanspark.com/news/news-details/2026/CleanSpark-Secures-Twenty-Year-Lease-with-High-Investment-Grade-Global-Technology-Company-for-Data-Center-in-Sandersville-Georgia/default.aspx","label":"CleanSpark"},{"url":"https://www.sec.gov/Archives/edgar/data/827876/000119312526338382/clsk-20260630.htm","label":"SEC Form 10-Q (CleanSpark)"},{"url":"https://www.sec.gov/Archives/edgar/data/827876/000119312526393758/clsk-ex99_1.htm","label":"SEC Form 8-K Exhibit 99.1 (CleanSpark Sandersville investor presentation)"}],"parties":[{"role":"Entity","name":"CleanSpark"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"d58337a5598f8859","state":"TX","tracker":"atlas","section":"sites","title":"Colovore Alliance data center (14700 Heritage Parkway, AllianceTexas)","summary":"Colovore registered a one-story, 156,500 sq ft data center with an administrative area, four data halls and a 42,000 sq ft screened equipment yard at 14700 Heritage Parkway along Interstate 35W in Hillwood's AllianceTexas development, north Fort Worth (Denton County), with the Texas Department of Licensing and Regulation on 22 September 2026. The estimated cost is $430 million, with construction scheduled from 1 December 2026 to 1 December 2028. The owner of record is AIL Investment LP of Fort Worth and the design firm is Ci Design. The Dallas Morning News noted that Colovore's website lists a 32 MW DFW02 facility in Fort Worth, but the filing does not state capacity or link the project to DFW02.  $430,000,000 estimated construction cost per TDLR registration TABS2027001701 MW not stated in the filing; one-story 156,500 sq ft building with four data halls and a 42,000 sq ft screened equipment yard","scope":"Record-specific: Fort Worth","status":"proposed","date":"TDLR registration 22 September 2026; reported 24 September 2026 (The Dallas Morning News)","sources":[{"url":"https://www.tdlr.texas.gov/TABS/Search/Project/TABS2027001701","label":"TDLR TABS project TABS2027001701"},{"url":"https://www.msn.com/en-us/news/other/430m-data-center-project-planned-for-fort-worth-state-filing-shows/ar-AA2cTQfx","label":"The Dallas Morning News (via MSN)"},{"url":"https://www.dallasnews.com/business/energy/article/430-million-data-center-project-fort-worth-22446239.php","label":"The Dallas Morning News"}],"parties":[{"role":"Entity","name":"Colovore"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"3c8beb5f2e370d29","state":"TX","tracker":"atlas","section":"sites","title":"Colovore Hutto AI data center (2401 Innovation Blvd)","summary":"Colovore filed plans with the state for a $250 million liquid-cooled AI data center at the Hutto Crossing business park, about two years after announcing its entry to the Austin market. Construction is set to begin in December 2026 with completion anticipated by the end of 2028 per the TDLR filing  $250 million per the Austin American-Statesman and $280 million estimated cost per the TDLR filing as listed by Community Impact; USD field left null because the two reported figures differ 40 MW per the Austin American-Statesman; one-story building of 192,694 sq ft per the TDLR filing, with about five data halls and liquid cooling","scope":"Record-specific: Hutto","status":"planned; construction to begin December 2026","date":"TDLR filing reported 3 to 8 September 2026","sources":[{"url":"https://www.msn.com/en-us/technology/tech-companies/colovore-plans-250-million-ai-data-center-in-hutto-industrial-park-that-may-house-blue-origin/ar-AA2bvYln","label":"Austin American-Statesman via MSN"},{"url":"https://communityimpact.com/pflugerville-hutto/development/data-center-7-brew-check-out-5-major-austin-area-permits-filed-this-week/","label":"Community Impact"}],"parties":[{"role":"Entity","name":"Colovore"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"12d03445f121c319","state":"TX","tracker":"atlas","section":"sites","title":"Compass Red Oak facilities","summary":"Compass closed a $326M refinancing on five Red Oak, Texas facilities across 5 data centers and 180 MW, with full build-out at 10 buildings and 360 MW served by Oncor. served by Oncor $326M refinancing 5 data centers / 180 MW, with full build-out at 10 buildings / 360 MW","scope":"Record-specific: Red Oak","status":"operating","date":"maturing 2050","sources":[{"url":"https://www.connectcre.com/stories/compass-datacenters-lands-refi-on-5-red-oak-facilities-to-add-three-more/","label":"Connect CRE"},{"url":"https://asreport.americanbanker.com/news/compass-datacenters-raises-326-million-from-five-buildings","label":"Asset Securitization Report"}],"parties":[{"role":"Entity","name":"compass-datacenters"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"2a861335e1fd625e","state":"TX","tracker":"atlas","section":"sites","title":"Coravel Dallas-Fort Worth campus","summary":"First anchor campus of the Coravel platform, with staggered service dates through 2028. Exact city and county not disclosed  Capital not disclosed About 140 MW critical IT under the first hyperscaler agreement across three facilities, with rights to about 100 MW more in two additional facilities","scope":"Record-specific: Dallas-Fort Worth","status":"announced","date":"Announced 15 July 2026","sources":[{"url":"https://finance.yahoo.com/technology/articles/acs-group-global-infrastructure-partners-140000714.html","label":"Yahoo Finance"}],"parties":[{"role":"Entity","name":"Coravel (ACS Group and Global Infrastructure Partners)"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"c95aba0828c928a5","state":"TX","tracker":"atlas","section":"sites","title":"CoreSite DA1, Irving (2701 E. Grauwyler Road)","summary":"CoreSite registered a two-story, 230,000 sq ft data center at 2701 E. Grauwyler Road in Irving with the state on 31 August 2026, with work expected from January 2027 to the end of 2028. Owners are listed as CanTex Grauwyler LLC and CoreSite Real Estate IRV LLC. Irving City Council approved plans for the campus in February 2026, per KERA as cited by the Dallas Morning News  $200 million estimated construction cost in a TDLR registration filed 31 August 2026 Two-story, 230,000 sq ft; MW not disclosed","scope":"Record-specific: Irving","status":"planned","date":"TDLR registration 31 August 2026; reported 16 September 2026","sources":[{"url":"https://www.msn.com/en-us/news/other/12-billion-in-d-fw-data-center-projects-filed-in-recent-weeks/ar-AA2cnhQU","label":"Dallas Morning News via MSN"},{"url":"https://www.tdlr.texas.gov/TABS/Search/Project/TABS2026029194","label":"TDLR TABS project TABS2026029194"},{"url":"https://www.datacenterdynamics.com/en/news/digital-realty-colovore-hut-8-coresite-and-databank-file-to-build-data-centers-in-texas/","label":"Data Center Dynamics"}],"parties":[{"role":"Entity","name":"CoreSite"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"640ed024f89b4d21","state":"TX","tracker":"atlas","section":"sites","title":"Cortex 1 and Cortex 2 AI training clusters, Gigafactory Texas","summary":"Tesla's Q2 2026 shareholder update said it more than doubled onsite compute in Texas, measured in MW, during the first half of 2026. Cortex 2 at Gigafactory Texas began running training workloads by April 2026 and supports vehicle and humanoid robot autonomy software. Tesla guided to 2026 capital expenditures of more than $25 billion, with AI compute among the main uses  No site-level capital disclosed. Tesla's Form 10-Q for the quarter ended 30 June 2026 reports company-wide AI infrastructure assets but no Cortex-specific figure Over 90 MW (Cortex 1) plus over 115 MW (Cortex 2) in production per Tesla's Q2 2026 update as reported by EVwire; onsite Texas compute of about 260 MW at end of Q2 2026 and a planned ramp to about 400 MW by end of 2026 as reported by Not a Tesla App. The 205 MW value is the sum of the two stated cluster floors","scope":"Record-specific: Austin","status":"operational","date":"Q2 2026 update published 22 July 2026","sources":[{"url":"https://evwire.com/p/tesla-record-capex-q2-2026-ai-compute-fab-solar","label":"EVwire"},{"url":"https://www.notateslaapp.com/news/4509/tesla-doubles-texas-ai-compute-capacity-in-q2-2026","label":"Not a Tesla App"},{"url":"https://convergedigest.com/tesla-activates-cortex-2-data-center-at-gigatexas/","label":"Converge Digest"}],"parties":[{"role":"Entity","name":"tesla"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"8f82ba09d8e59bc8","state":"TX","tracker":"atlas","section":"sites","title":"Cosmos Technology Campus","summary":"SB Energy's first data center campus, in Travis County, Texas, disclosed in the Form S-1 registration statement filed 1 September 2026. Cosmos and the Milam County data center are the company's two projects under construction; no SB Energy data center capacity is in operation. SoftBank is both a strategic investor and the tenant at Cosmos. Not separately disclosed in the registration statement for this campus Financed with $999.0 million aggregate principal amount of 8.875% senior secured notes due 2031 issued in May 2026; a parent entity provided a completion guaranty for the benefit of the noteholders and the tenant. Total project cost is not disclosed. Approximately 50 MW of critical IT capacity, described in the registration statement as the facility where SB Energy expects to first achieve first-phase revenue","scope":"Record-specific: Austin","status":"construction","date":"Disclosed in the Form S-1 filed 1 September 2026; notes issued May 2026","sources":[{"url":"https://www.sec.gov/Archives/edgar/data/2133037/000162828026059639/sbenergy-sx1.htm","label":"SEC Form S-1 (SB Energy, Inc.)"}],"parties":[{"role":"Entity","name":"sb-energy"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"087478289d4f04f9","state":"TX","tracker":"atlas","section":"sites","title":"Crow Holdings North Stemmons data center campus (Market Hall)","summary":"40-acre campus on the North Stemmons Freeway corridor that may replace the Dallas Market Hall exhibition building, which has stopped booking events  Investment not disclosed 245 MW campus","scope":"Record-specific: Dallas","status":"announced","date":"Reported 29 July 2026","sources":[{"url":"https://www.nbcdfw.com/news/local/dallas-morning-news/crow-holdings-data-center-may-spell-the-end-for-dallas-market-hall-building/4055677/","label":"NBC DFW (Dallas Morning News)"}],"parties":[{"role":"Entity","name":"Crow Holdings"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"d35cb02626b5f7af","state":"TX","tracker":"atlas","section":"at_risk","title":"Crusoe Technologies Leon County data center tax abatement","summary":"On 13 July 2026 Leon County commissioners rejected Crusoe Technologies' initial tax abatement application for its proposed data center because the submission was incomplete. The company was expected to submit a new application. A public hearing was scheduled for 27 July 2026 in Marquez.","scope":"Record-specific: Leon County Commissioners Court","status":"rejected","date":"Application rejected 13 July 2026","sources":[{"url":"https://www.kxxv.com/news/local-news/data-centers-controversy/leon-county-commissioners-reject-initial-tax-break-application-for-crusoe-technologies-data-center","label":"KXXV"}],"parties":[{"role":"Developer","name":"Crusoe Technologies, LLC"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"ee4048218637417f","state":"TX","tracker":"atlas","section":"sites","title":"Crusoe and Lancium Childress AI data center campus","summary":"Crusoe and Lancium announced a 1.0 GW AI data center campus on 270 acres in Childress, Texas, their second joint site after Abilene. Construction is scheduled to begin in Q3 2026, with thousands of construction jobs and more than 100 permanent positions expected. The tenant was not named. This is a separate project from the existing IREN Childress campus record Three Project Hyper - Childress buildings at 525 A, B and C County Road 23 were registered with the Texas Department of Licensing and Regulation on 11 September 2026 by Childress DC1, DC2 and DC3 LLCs, each a single-story data center of 806,359 sq ft with an estimated cost of $2.4 billion, designed by HKS, with estimated starts of 6 July, 1 September and 5 October 2026 and completions from 28 February to 31 May 2028. The owner contact on the filings, Nader Pakfar, is Crusoe's General Counsel, Real Estate. No tenant is listed Grid-connected with energy storage resources; closed-loop, non-evaporative liquid cooling Crusoe announcement gave no cost; three TDLR registrations dated 11 September 2026 list an estimated $2.4 billion each for Childress Buildings 1 to 3; USD field left null to avoid summing separate building registrations 1.0 GW on 270 acres","scope":"Record-specific: Childress","status":"announced","date":"Announced 15 July 2026","sources":[{"url":"https://www.crusoe.ai/resources/newsroom/crusoe-and-lancium-announce-1-gigawatt-ai-data-center-campus-in-childress-texas","label":"Crusoe"},{"url":"https://www.tdlr.texas.gov/TABS/Search/Project/TABS2027000824","label":"TDLR TABS project TABS2027000824"},{"url":"https://www.tdlr.texas.gov/TABS/Search/Project/TABS2027000830","label":"TDLR TABS project TABS2027000830"},{"url":"https://www.tdlr.texas.gov/TABS/Search/Project/TABS2027000835","label":"TDLR TABS project TABS2027000835"},{"url":"https://finance.yahoo.com/news/crusoe-appoints-nader-pakfar-founder-150000807.html","label":"Crusoe (GlobeNewswire via Yahoo Finance)"},{"url":"https://www.tdlr.texas.gov/TABS/Search/Project/TABS2024024946","label":"TDLR TABS project TABS2024024946"}],"parties":[{"role":"Entity","name":"crusoe-energy"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"0ef6dc6a32d949ec","state":"TX","tracker":"atlas","section":"sites","title":"CyrusOne Castroville data center","summary":"One-story facility at 3397 U.S. 90 West, CyrusOne's sixth San Antonio-area facility and first in Castroville. CyrusOne owns at least 244 acres in Medina County. Completion expected June 2027 CyrusOne's project page says early earth-moving and grading are under way and puts expected capital investment at about $4 billion to $6 billion across multiple phases, using closed-loop cooling  $500 million per TDLR filing for the first building (SAT14A); CyrusOne cites about $4 billion to $6 billion across multiple phases Not disclosed; 460,000 square feet","scope":"Record-specific: Castroville","status":"under_construction","date":"Reported 18 July 2026","sources":[{"url":"https://finance.yahoo.com/technology/articles/dallas-company-plans-500m-data-150000158.html","label":"Yahoo Finance (San Antonio Express-News)"},{"url":"https://www.cyrusone.com/data-centers/north-america/medina-county","label":"CyrusOne Medina County project page"}],"parties":[{"role":"Entity","name":"cyrusone"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"ef6feba53f163d50","state":"TX","tracker":"atlas","section":"sites","title":"CyrusOne DFW10 campus (Thad Hill Energy Center)","summary":"CyrusOne's Texas development is anchored on dedicated generation: a $1.2 billion infrastructure investment and 190MW agreement with Calpine for the DFW10 campus adjacent to the Thad Hill Energy Center, announced July 30, 2025 and expected operational by Q4 2026. dedicated generation from Calpine's Thad Hill Energy Center; Constellation later signed a 380MW agreement near the Freestone Energy Center with a second phase of another 380MW $1.2 billion infrastructure investment 190-megawatt agreement with Calpine; Calpine capable of delivering up to 400 MW to Bosque County data centers","scope":"Record-specific:","status":"construction","date":"announced July 30, 2025; expected operational by Q4 2026","sources":[{"url":"https://www.cyrusone.com/resources/press-releases/cyrusone-and-calpine-announce-newhyperscale-data-center-development-in-texas","label":"CyrusOne"},{"url":"https://www.reuters.com/business/energy/constellation-energy-inks-380-megawatt-deal-with-cyrusone-2026-02-09/","label":"Reuters"}],"parties":[{"role":"Entity","name":"kkr"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"4859823bc959c2d0","state":"TX","tracker":"atlas","section":"sites","title":"CyrusOne DFW8 (9501 Asphalt Drive)","summary":"CyrusOne registered with TDLR the 'CyrusOne DFW8 Fit Out', an interior fit-out of data halls, support spaces and tenant office space in an existing 82,997 sq ft core-and-shell precast concrete building at 9501 Asphalt Drive, Fort Worth, including exterior generators. Estimated cost is $257.1 million, with work scheduled from 1 October 2026 to 30 October 2027; no tenant is assigned. Exterior generators in a service yard (per TDLR scope) TDLR estimated cost $257,109,000 for the interior fit-out Not stated in the TDLR filing","scope":"Record-specific: Fort Worth","status":"proposed","date":"Registered with TDLR 24 September 2026; reported by The Real Deal 28 September 2026","sources":[{"url":"https://www.tdlr.texas.gov/TABS/Search/Project/TABS2027001907","label":"TDLR TABS project TABS2027001907"},{"url":"https://therealdeal.com/data/texas/2026/290m-north-texas-data-center-leads-week-in-construction/","label":"The Real Deal, 28 September 2026"}],"parties":[{"role":"Entity","name":"cyrusone"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"f5a538d0f2b65a3d","state":"TX","tracker":"atlas","section":"sites","title":"CyrusOne Freestone County campus (Freestone Energy Center)","summary":"Constellation announced on 9 February 2026 that Calpine LLC signed a 380 MW agreement with CyrusOne to connect and serve a new data center adjacent to the Freestone Energy Center in Freestone County, Texas, and that Calpine had entered an exclusive agreement to provide power, grid connectivity and site infrastructure for a Phase 2 of an additional 380 MW. Constellation stated the arrangement is structured so electricity continues to flow to the regional grid. The agreements are in addition to 400 MW of Calpine-CyrusOne agreements at the Thad Hill Energy Center in Bosque County, Texas. CyrusOne filed with the Texas Department of Licensing and Regulation for three buildings on FM 488 in Fairfield for the 760 MW project next to Calpine's Freestone Energy Campus. Construction had started on two buildings, with the third due to start the following month and completion expected by the end of August 2027. No tenants were listed in the filings (reported 31 July 2026). On 23 July 2026 CL Freestone 1 LLC, using CyrusOne's 2850 N. Harwood Street Dallas address and Corgan as designer, registered three one-story data center buildings, DFW20A, DFW20B and DFW20C, at 1354 to 1360 FM 488 in Fairfield with the Texas Department of Licensing and Regulation, each 306,216 sq ft with an estimated cost of $500 million and completions estimated between March and August 2027. Interior fit-outs of each building were registered on 4 August 2026 at an estimated $100 million each. Calpine LLC, a Constellation business unit, provides power, grid connectivity and site infrastructure adjacent to the Freestone Energy Center $1.5 billion per TDLR construction filings reported by DCD 380 MW under the announced agreement, with an exclusive agreement covering an additional 380 MW for Phase 2, for 760 MW across both phases","scope":"Record-specific: Fairfield","status":"under_construction","date":"Announced 9 February 2026","sources":[{"url":"https://www.constellationenergy.com/news/2026/02/constellation-and-cyrusone-announce-agreement-to-support-new-data-center-facility-at-freestone-energy-center-in-texas.html","label":"Constellation Energy"},{"url":"https://www.cyrusone.com/resources/press-releases/constellation-and-cyrusone-announce-agreement-to-support-new-data-center-facility-at-freestone-energy-center-in-texas","label":"CyrusOne"},{"url":"https://www.reuters.com/business/energy/constellation-energy-inks-380-megawatt-deal-with-cyrusone-2026-02-09/","label":"Reuters"},{"url":"https://www.datacenterdynamics.com/en/news/cyrusone-files-to-develop-three-buildings-for-15bn-data-center-campus-in-fairfield-texas/","label":"Data Center Dynamics"},{"url":"https://www.tdlr.texas.gov/TABS/Search/Project/TABS2026026013","label":"TDLR TABS project TABS2026026013"},{"url":"https://www.tdlr.texas.gov/TABS/Search/Project/TABS2026026016","label":"TDLR TABS project TABS2026026016"},{"url":"https://www.tdlr.texas.gov/TABS/Search/Project/TABS2026026017","label":"TDLR TABS project TABS2026026017"},{"url":"https://www.tdlr.texas.gov/TABS/Search/Project/TABS2026026904","label":"TDLR TABS project TABS2026026904"}],"parties":[{"role":"Entity","name":"cyrusone"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"51a146f05af4dd4e","state":"TX","tracker":"atlas","section":"sites","title":"Dallas datacenter","summary":"One of six new datacenters announced March 11, 2025; Dallas was online at announcement.  n.a. MW n.a.","scope":"Record-specific: Dallas","status":"operating","date":"announced March 11, 2025","sources":[{"url":"https://www.cerebras.ai/press-release/cerebras-announces-six-new-ai-datacenters-across-north-america-and-europe-to-deliver-industry-s","label":"Cerebras"}],"parties":[{"role":"Entity","name":"cerebras"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"d3decca306937d29","state":"TX","tracker":"atlas","section":"sites","title":"DataBank DFW15, Red Oak campus","summary":"DataBank filed to build DFW15, a two-story building on Batchler Road at its 292-acre Red Oak campus, with construction from February 2027 to August 2029. It is the fifth building and the first of four more planned; full build-out is eight buildings of 200,000 square feet each  $425 million per TDLR filing About 444,000 square feet; MW not stated","scope":"Record-specific: Red Oak","status":"announced","date":"TDLR filing reported 15 September 2026","sources":[{"url":"https://www.datacenterdynamics.com/en/news/digital-realty-colovore-hut-8-coresite-and-databank-file-to-build-data-centers-in-texas/","label":"Data Center Dynamics"},{"url":"https://therealdeal.com/data/texas/2026/top-permits-three-100m-plus-data-centers-on-tap-in-texas/","label":"The Real Deal"}],"parties":[{"role":"Entity","name":"DataBank"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"b4f20ac3facf5c73","state":"TX","tracker":"atlas","section":"sites","title":"DataBank Dallas allocation","summary":"Dallas received a 480 MW allocation of DataBank's $2B funding supporting 850 MW. DataBank registered a $425 million, nearly 450,000 sq ft two-story DFW15 building on Batchler Road in Red Oak with the Texas Department of Licensing and Regulation, reported 16 September 2026, with work expected from February 2027 to July 2029. It follows a $325 million DFW14 registration the prior month; the 300-acre Red Oak campus is planned for eight buildings, DFW9 through DFW16  part of $2B raise supporting 850 MW 480 MW allocation of the $2B / 850 MW program","scope":"Record-specific: Dallas","status":"announced","date":null,"sources":[{"url":"https://www.constructiondive.com/news/databank-data-centers-dallas-virginia-atlanta/730800/","label":"Construction Dive"},{"url":"https://www.msn.com/en-us/news/other/12-billion-in-d-fw-data-center-projects-filed-in-recent-weeks/ar-AA2cnhQU","label":"Dallas Morning News via MSN"},{"url":"https://www.tdlr.texas.gov/TABS/Search/Project/TABS2027000733","label":"TDLR TABS project TABS2027000733"},{"url":"https://www.tdlr.texas.gov/TABS/Search/Project/TABS2026027681","label":"TDLR TABS project TABS2026027681"}],"parties":[{"role":"Entity","name":"databank"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"7ca5677cae1b632c","state":"TX","tracker":"atlas","section":"sites","title":"DataNovaX Wichita Falls data center (2236 Airport Drive)","summary":"The Wichita Falls Planning and Zoning Commission voted on Wednesday 12 August 2026 to approve a conditional use request from Dallas-based DataNovaX to operate a data center in an existing building at 2236 Airport Drive. The approval is limited to the existing building, and the city said the 12 MW load is below the 75 MW threshold in the governor's data center directive. Any additional buildings would need separate approval  $1 billion data center per the company as reported by the Times Record News Up to 12 MW in the existing 37,000 sq ft building per the city development services director; DataNovaX describes a possible second phase of 550,000 sq ft and 150 MW requiring separate approval","scope":"Record-specific: Wichita Falls","status":"approved (conditional use)","date":"Conditional use approved Wednesday 12 August 2026","sources":[{"url":"https://www.yahoo.com/news/us/articles/wichita-falls-panel-oks-data-222056447.html","label":"Times Record News via Yahoo"},{"url":"https://www.aol.com/articles/wichita-falls-planning-zoning-commission-001116000.html","label":"KFDX via AOL"}],"parties":[{"role":"Entity","name":"DataNovaX"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"228069777f470afe","state":"TX","tracker":"atlas","section":"sites","title":"Denton HPC data center","summary":"Core Scientific hosts CoreWeave GPUs with OpenAI as end user at a 260MW site load. CoreWeave deployed more than 16,000 GPUs by end-December at the delayed site, with a $6.1 billion contract conversion involved. Core Scientific disclosed on 10 September 2026 that Denton's existing 297 MW was conditionally approved by ERCOT as longstanding existing Base Load not subject to Batch Zero allocation, and an additional 74 MW to be energized was already included in ERCOT's 2025 Regional Transmission Plan study cases Core Scientific registered a $110 million interior fit-out of an existing building at 8171 Jim Christal Road in Denton as a 27,678 sq ft data hall (DTO Building A) with the Texas Department of Licensing and Regulation on 19 August 2026, with work estimated from 1 September 2026 to 31 May 2027  +70MW contract worth $1.2B (Feb 2025 increment) 260MW site load","scope":"Record-specific: Denton","status":"operating","date":"delivery delays disclosed November 11, 2025; >16,000 GPUs deployed by end-December","sources":[{"url":"https://investors.corescientific.com/news-events/press-releases/detail/110/core-scientific-and-coreweave-expand-partnership-with-new-70-mw-contract","label":"Core Scientific"},{"url":"https://www.datacenterdynamics.com/en/news/coreweave-deploys-16000-gpus-at-delayed-data-center-in-denton-texas/","label":"DCD"},{"url":"https://www.sec.gov/Archives/edgar/data/1839341/000183934126000023/core-20260910.htm","label":"SEC EDGAR (Core Scientific 8-K)"},{"url":"https://www.tdlr.texas.gov/TABS/Search/Project/TABS2026028247","label":"TDLR TABS project TABS2026028247"}],"parties":[{"role":"Entity","name":"core-scientific"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"2aec1c3c3da18995","state":"TX","tracker":"atlas","section":"sites","title":"Digital Realty DFW45, Digital Garland campus (1602 Ferris Road)","summary":"Digital Realty registered a 672,000 sq ft hyperscale data center at 1602 Ferris Road near the George Bush Turnpike with the Texas Department of Licensing and Regulation on 8 September 2026. Work started in summer 2026 and is expected to finish by the start of 2029. Garland approved economic incentives for portions of the campus in 2024, including fee rebates up to $500,000 and 40% property tax rebates. Registered owner Digital Garland 2C, L.P.; the TDLR scope describes ten 8 MW DR800 suites for an ultimate capacity of 80 MW  $300 million estimated construction cost in a TDLR registration filed 8 September 2026 672,000 sq ft building with 10 data hall suites of 8 MW each per the TDLR filing as reported","scope":"Record-specific: Garland","status":"under construction","date":"TDLR registration 8 September 2026; reported 16 September 2026","sources":[{"url":"https://www.msn.com/en-us/news/other/12-billion-in-d-fw-data-center-projects-filed-in-recent-weeks/ar-AA2cnhQU","label":"Dallas Morning News via MSN"},{"url":"https://www.tdlr.texas.gov/TABS/Search/Project/TABS2027000488","label":"TDLR TABS project TABS2027000488"},{"url":"https://www.datacenterdynamics.com/en/news/digital-realty-colovore-hut-8-coresite-and-databank-file-to-build-data-centers-in-texas/","label":"Data Center Dynamics"},{"url":"https://therealdeal.com/data/texas/2026/top-permits-three-100m-plus-data-centers-on-tap-in-texas/","label":"The Real Deal"}],"parties":[{"role":"Entity","name":"Digital Realty"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"f126f06149d39f4d","state":"TX","tracker":"atlas","section":"at_risk","title":"Diode Ventures Cedar Creek Lake data center","summary":"Kansas-based Diode Ventures withdrew its proposed data center near Cedar Creek Lake in Henderson County on 23 July 2026, saying it would not advance the site beyond preliminary planning. The Governor's office said the project did not meet the five data center standards Gov. Greg Abbott set in June 2026 directives to the PUC and ERCOT. A volunteer Save Cedar Creek Lake coalition had gathered thousands of petition signatures over water supply concerns. Henderson County has no zoning rules, so the county had no approval to deny.","scope":"Record-specific: Henderson County","status":"withdrawn","date":"Withdrawn 23 July 2026","sources":[{"url":"https://gov.texas.gov/news/post/east-texas-data-center-withdraws-after-falling-short-of-governor-abbotts-standards","label":"Office of the Texas Governor"},{"url":"https://www.texastribune.org/2026/07/23/east-texas-data-center-withdrawn/","label":"Texas Tribune"}],"parties":[{"role":"Developer","name":"Diode Ventures"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"f862b4a43947d636","state":"TX","tracker":"atlas","section":"sites","title":"ECP-KKR Bosque County campus","summary":"A separate approximately $4 billion, 190MW (144MW initial IT load) Bosque County campus sits under the $50 billion Energy Capital Partners-KKR partnership, targeted operational in Q4 2026.  ~$4 billion 190MW with 144MW initial IT load","scope":"Record-specific:","status":"construction","date":"targeted operational in Q4 2026","sources":[{"url":"https://www.ecpgp.com/about/news-and-insights/press-releases/2025/energy-capital-partners--ecp--and-kkr-announce-development-of-hy","label":"ECP"}],"parties":[{"role":"Entity","name":"kkr"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"9cfbaf003a709561","state":"TX","tracker":"atlas","section":"sites","title":"EdgeConneX Cedar Creek campus (AUS02)","summary":"Construction on the first buildings began in Q4 2024 and AUS02 was set for completion by mid-June 2026. CoreWeave received a 75 percent abatement on the value of improvements Community Impact reported on 24 July 2026 that the first building was expected to open in August 2026, and that a second EdgeConneX listing for buildings 11 to 16 received state data center certification on 24 April 2026 with the occupant not identified MySA reported that EdgeConneX filed two $700 million buildings, EDCAUS11 and EDCAUS12, on a nearly 180-acre property at 6682 FM 535 in May 2026 and two more, EDCAUS13 and EDCAUS14, at the same address in August 2026 with construction from 1 September 2026 to 31 March 2029, separate from its $440 million AUS02 facility at 6752 FM 535. Further filings under the same EDCAUS naming followed: EDCAUS31 and EDCAUS32 at 6543 FM 535 (Uppingham Adams Holdings LLC, $700 million each, registered 21 and 24 August 2026) and EDCAUS15 and EDCAUS16 at 6402 FM 535 (Burr Computer Environment Inc, $600 million each, registered 11 and 14 September 2026), all designed by Gensler with no tenant listed  $440 million estimated cost for AUS02 per state records; TDLR registrations for EDCAUS11 to 14 and EDCAUS31 and 32 list $700 million each and EDCAUS15 and 16 $600 million each; campus total not disclosed and USD field not summed MW not stated; TDLR lists EDCAUS11 to 14 at 729,537 sq ft each (6682 FM 535), EDCAUS15 and 16 at 591,400 sq ft each (6402 FM 535) and EDCAUS31 and 32 at 576,777 sq ft each (6543 FM 535)","scope":"Record-specific: Cedar Creek","status":"under_construction","date":"Reported 27 July 2026","sources":[{"url":"https://www.datacenterdynamics.com/en/news/coreweave-to-lease-capacity-from-edgeconnex-at-data-center-campus-in-cedar-creek-texas/","label":"Data Center Dynamics"},{"url":"https://communityimpact.com/bastrop-cedar-creek/development/ai-cloud-company-coreweave-to-fill-440m-cedar-creek-data-center/","label":"Community Impact"},{"url":"https://www.yahoo.com/news/us/articles/two-700-million-data-centers-040200034.html","label":"MySA via Yahoo News"},{"url":"https://finance.yahoo.com/sectors/technology/articles/tiny-texas-town-solidifies-tech-125700852.html","label":"MySA via Yahoo Finance"},{"url":"https://www.mysanantonio.com/business/article/edgeconnex-bastrop-data-center-22398245.php","label":"MySA"},{"url":"https://www.tdlr.texas.gov/TABS/Search/Project/TABS2026021187","label":"TDLR TABS project TABS2026021187"},{"url":"https://www.tdlr.texas.gov/TABS/Search/Project/TABS2026021191","label":"TDLR TABS project TABS2026021191"},{"url":"https://www.tdlr.texas.gov/TABS/Search/Project/TABS2026028410","label":"TDLR TABS project TABS2026028410"},{"url":"https://www.tdlr.texas.gov/TABS/Search/Project/TABS2026028423","label":"TDLR TABS project TABS2026028423"},{"url":"https://www.tdlr.texas.gov/TABS/Search/Project/TABS2026028550","label":"TDLR TABS project TABS2026028550"},{"url":"https://www.tdlr.texas.gov/TABS/Search/Project/TABS2026028609","label":"TDLR TABS project TABS2026028609"},{"url":"https://www.tdlr.texas.gov/TABS/Search/Project/TABS2027000881","label":"TDLR TABS project TABS2027000881"},{"url":"https://www.tdlr.texas.gov/TABS/Search/Project/TABS2027001020","label":"TDLR TABS project TABS2027001020"},{"url":"https://www.tdlr.texas.gov/TABS/Search/Project/TABS2025023484","label":"TDLR TABS project TABS2025023484"}],"parties":[{"role":"Entity","name":"EdgeConneX"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"5302251ef99525f3","state":"TX","tracker":"atlas","section":"sites","title":"Edged Project Outpost second building (southwest Fort Worth)","summary":"Edged registered a nearly 486,000 sq ft data center at 9720 Team Rockbrook Parkway in southwest Fort Worth, the second building of its Project Outpost development, with work expected to start in November 2026 and finish by April 2028. Commercial building permits were filed with the city in early August 2026. The first building at 9999 Chapin School Road was registered with the state in May 2026. Registered owner EDC Fort Worth LLC; 485,947 sq ft per TDLR  $300 million estimated construction cost in a TDLR filing dated 14 September 2026 Nearly 486,000 sq ft; MW not disclosed","scope":"Record-specific: Fort Worth","status":"planned","date":"TDLR filing 14 September 2026; reported 16 September 2026","sources":[{"url":"https://www.msn.com/en-us/news/other/12-billion-in-d-fw-data-center-projects-filed-in-recent-weeks/ar-AA2cnhQU","label":"Dallas Morning News via MSN"},{"url":"https://www.tdlr.texas.gov/TABS/Search/Project/TABS2027000903","label":"TDLR TABS project TABS2027000903"},{"url":"https://therealdeal.com/data/texas/2026/top-permits-three-100m-plus-data-centers-on-tap-in-texas/","label":"The Real Deal"}],"parties":[{"role":"Entity","name":"Edged"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"8b97d140a8524d42","state":"TX","tracker":"atlas","section":"sites","title":"El Paso AI data center","summary":"Meta committed $1.5 billion to an El Paso AI data center in October 2025, then in March 2026 raised the plan to $10 billion with 1 GW by 2028. In July 2026 Meta repeated the Blue Owl playbook with BlackRock in a venture with approximately $14 billion of total development costs; CNBC framed it as a $14 billion El Paso data center venture.  over $10 billion from Meta; approximately $14 billion in total development costs under the BlackRock venture ($1.5 billion original October 2025 commitment) 1 GW by 2028","scope":"Record-specific: El Paso","status":"construction","date":"Committed October 2025; $10B/1GW March 2026; BlackRock venture July 2026","sources":[{"url":"https://www.reuters.com/business/meta-commits-15-billion-ai-data-center-texas-2025-10-15/","label":"Reuters"},{"url":"https://www.cnbc.com/2026/03/26/meta-to-spend-10-billion-on-ai-data-center-in-el-paso-1gw-by-2028.html","label":"CNBC"},{"url":"https://investor.atmeta.com/investor-news/press-release-details/2026/Meta-Announces-New-Strategic-Venture-with-BlackRock-to-Develop-Data-Center-in-El-Paso/default.aspx","label":"Meta investor relations"},{"url":"https://www.cnbc.com/2026/07/28/meta-blackrock-partner-on-14-billion-el-paso-data-center.html","label":"CNBC"}],"parties":[{"role":"Entity","name":"meta"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"369b112ec4decfa1","state":"TX","tracker":"atlas","section":"at_risk","title":"El Paso data center moratorium","summary":"El Paso, Texas, enacted a local data center moratorium or ban, recorded in SAVRN's moratorium tracker as dated January 2026. Council unanimously approved data center policy: 300-ft buffer from residential/ecological sites, special use permit, no more tax breaks. Developers must submit resource use, emissions, noise, and water treatment plans. The measure has no end date by design.","scope":"Record-specific: El Paso","status":"moratorium","date":"Enacted January 2026","sources":[{"url":"https://elpasomatters.org/2026/07/20/meta-data-center-el-paso-texas-policy-framework-rules-city-council/","label":"elpasomatters.org"}],"parties":[],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"41cb17d22ca52c8f","state":"TX","tracker":"atlas","section":"sites","title":"Equinix DA12 data center (1550 West Mockingbird Lane)","summary":"Equinix registered two Texas Department of Licensing and Regulation projects for DA12 at 1550 West Mockingbird Lane, Dallas, near the Medical District: DA12-1 (TABS2026006348), a four-story 372,517 sq ft data center with twenty generators, estimated at $542.8 million with construction from 19 February 2026 to 12 October 2027; and DA12-2 (TABS2026006556), a $293.7 million interior fit-out of the first and second floors scheduled from 29 September 2027 to 30 March 2028. The owner of record, DA12, uses Equinix's 1 Lagoon Drive, Redwood City address. The Dallas Business Journal reported that the nearly billion-dollar data center from the Infomart owner has begun to rise. Twenty generators on five generator pads (TDLR scope); utility service not disclosed $836.5 million combined TDLR estimated cost: $542,809,034 for DA12-1 (new four-story building) plus $293,692,007 for DA12-2 (first and second floor fit-out); the two registrations cover different scopes of the same building Not disclosed; four-story, 372,517 sq ft building with twenty generators","scope":"Record-specific: Dallas","status":"under_construction","date":"Backfill (not previously recorded). Registered with TDLR in November 2025 (DA12-1 on 19 November 2025, DA12-2 on 21 November 2025); construction start 19 February 2026 per TDLR","sources":[{"url":"https://www.tdlr.texas.gov/TABS/Search/Project/TABS2026006348","label":"TDLR TABS DA12-1 (TABS2026006348)"},{"url":"https://www.tdlr.texas.gov/TABS/Search/Project/TABS2026006556","label":"TDLR TABS DA12-2 (TABS2026006556)"},{"url":"https://www.bizjournals.com/dallas/news/2026/09/30/equinix-data-center-begins-to-rise-west-dallas.html","label":"Dallas Business Journal (paywalled)"}],"parties":[{"role":"Entity","name":"equinix"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"f24eb4d823468478","state":"TX","tracker":"atlas","section":"sites","title":"Flexential Kaufman County data center campus (Talty)","summary":"Flexential acquired 110 acres in Talty, Kaufman County, for its fourth and largest Dallas-area data center campus, planned for wholesale and multi-tenant colocation with closed-loop cooling targeting zero water usage effectiveness. Site work is planned for early 2027 with first customer availability in late 2028 Talty officials told NBC 5 the city has no regulatory authority over the site because it was released from the city's extraterritorial jurisdiction earlier in 2026  Not disclosed in the company release 108 MW across three 36 MW buildings; Phase 1 is 36 MW in 375,000 sq ft","scope":"Record-specific: Talty","status":"announced","date":"Announced 28 July 2026 (company release)","sources":[{"url":"https://finance.yahoo.com/technology/articles/flexential-build-dallas-area-data-130400302.html","label":"PR Newswire via Yahoo Finance"},{"url":"https://www.dallasnews.com/business/real-estate/article/data-centers-kaufman-county-22364129.php","label":"The Dallas Morning News"},{"url":"https://www.nbcdfw.com/news/local/data-center-spanning-hundreds-of-acres-planned-in-kaufman-county/4055993/","label":"NBC 5 Dallas-Fort Worth"}],"parties":[{"role":"Entity","name":"Flexential"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"0aa80b706fbcb9ee","state":"TX","tracker":"atlas","section":"at_risk","title":"Fort Worth 90-day data center moratorium process","summary":"On 11 August 2026 the Fort Worth City Council voted unanimously to start the process for a 90-day moratorium on data center rezonings and permits. A Data Center and Infrastructure Committee must report by 3 November 2026, with public hearings on 10 November 2026 and 5 January 2027. Adoption is scheduled for 16 February 2027, with the moratorium ending 17 May 2027. Projects with zoning applications already submitted or approved are excluded. The moratorium itself has not yet been adopted. FOX 4 reported the unanimous vote at the 11 August 2026 meeting came after midnight, early on 12 August 2026.","scope":"Record-specific: City of Fort Worth","status":"other","date":"Process approved 11 August 2026; adoption scheduled 16 February 2027","sources":[{"url":"https://fortworthreport.org/2026/08/12/data-center-moratorium-takes-first-steps-after-fort-worth-city-councils-unanimous-vote/","label":"Fort Worth Report"},{"url":"https://www.fox4news.com/news/fort-worth-set-vote-data-center-moratorium","label":"FOX 4 Dallas-Fort Worth"}],"parties":[],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"fb1386ed19609056","state":"TX","tracker":"atlas","section":"sites","title":"Fort Worth facility","summary":"One of Voltage Park's six US sites.  n.a. part of 60MW across six data centers in four states","scope":"Record-specific: Fort Worth","status":"operating","date":null,"sources":[{"url":"https://www.voltagepark.com/blog/scaling-ai-in-2025-flexibility-speed","label":"Voltage Park"},{"url":"https://www.datacenterdynamics.com/en/news/gpuaas-provider-voltage-park-merges-with-cloud-platform-lightning-ai/","label":"DCD"}],"parties":[{"role":"Entity","name":"voltage-park"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"5f511c7d284f4203","state":"TX","tracker":"atlas","section":"sites","title":"GW Ranch data center and power campus","summary":"Amazon confirmed in August 2026 that it acquired GW Ranch, an 8,000-plus-acre behind-the-meter data center and power campus in Pecos County developed by Pacifico Energy Group, its first private behind-the-meter campus. Three TDLR filings registered 4 August 2026 list 189,000 sq ft buildings for Amazon Data Services at $300 million each. Texas permits authorize up to 33 million tons per year of greenhouse gases from the gas plant, and Amazon said the initial phase needs no water for power-generation cooling Off-grid natural gas turbines (up to 7.65 GW permitted), planned solar and batteries; designed to transition to grid service later TDLR filings list three 189,000 sq ft buildings at $300 million each ($900 million). Pacifico estimated the needed investment at about $12 billion in February 2026 comments to Forbes; Amazon has not disclosed a total Data center MW not disclosed; state permits allow 35 gas turbines generating up to 7.65 GW, with plans for up to 750 MW of solar and 1.8 GW of battery storage","scope":"Record-specific: Fort Stockton area","status":"under_construction","date":"TDLR filings 4 August 2026; Amazon confirmation reported 7 to 11 August 2026","sources":[{"url":"https://www.enr.com/articles/63464-amazon-discloses-ownership-of-gw-ranch-giant-texas-data-center-gas-power-complex","label":"Engineering News-Record"},{"url":"https://finance.yahoo.com/technology/articles/amazon-seemingly-plans-nearly-1b-230200275.html","label":"Yahoo Finance"}],"parties":[{"role":"Entity","name":"amazon"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"d609cb892839d1e1","state":"TX","tracker":"atlas","section":"sites","title":"Google Project Raptor hyperscale data center (Three Way Road)","summary":"Google's proposed hyperscale data center known as Project Raptor would occupy about 2,500 acres along Three Way Road in northern Archer County near Wichita Falls. Builder Dynamo Ventures LLC has applied to TCEQ for a wastewater treatment plant permit (WQ0017005001) to discharge up to a daily average of 95,000 gallons of treated wastewater toward Lake Wichita and a Texas Land Application Permit (WQ0016998001); TCEQ has approved a concrete batch plant permit for City Concrete Inc. at the site. On Monday 28 September 2026 the Archer County Commissioners Court passed two resolutions opposing the wastewater permits and asking TCEQ to reevaluate the batch plant permit, citing Gov. Abbott's 21 September 2026 directive to TCEQ; the county judge said the county has no authority to stop the permits. State Rep. James Frank said he opposes the site's location next to homes and plans legislation on data center setbacks.  $1 billion per KAUZ (single outlet for the figure) Not disclosed; about 2,500 acres per KFDX","scope":"Record-specific: Near Lakeside City (Three Way Road, south of FM 1954)","status":"proposed","date":"TCEQ permit applications reported 25 August 2026; county opposition resolutions passed Monday 28 September 2026; residents' meeting 28 September 2026 (KFDX, KAUZ, Times Record News)","sources":[{"url":"https://www.newschannel6now.com/2026/09/29/rep-james-frank-joins-archer-county-residents-opposing-purposed-data-center/","label":"KAUZ News Channel 6, 29 September 2026"},{"url":"https://www.msn.com/en-us/news/other/archer-county-residents-fight-against-proposed-google-data-center/ar-AA2dc3H2","label":"KFDX (via MSN), 29 September 2026"},{"url":"https://www.msn.com/en-us/news/other/archer-county-officials-make-moves-against-data-center-plans/ar-AA2dkKHH","label":"Times Record News (via MSN), 1 October 2026"}],"parties":[{"role":"Entity","name":"alphabet"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"6a30a08b30ac51d7","state":"TX","tracker":"atlas","section":"at_risk","title":"Harlingen data center moratorium","summary":"Harlingen, Texas, enacted a local data center moratorium or ban, recorded in SAVRN's moratorium tracker as dated May 2026. 120-day moratorium on data center development within city limits, adopted in May 2026 after public hearings, running to mid-October; commissioners approved first reading of a 60-day extension to December in August, second reading pending. City hired Ambiotec Engineering to study water, wastewater and power impacts. The measure has a stated duration whose end date is not recorded.","scope":"Record-specific: Harlingen","status":"moratorium","date":"Enacted May 2026","sources":[{"url":"https://www.krgv.com/news/harlingen-city-officials-look-to-extend-moratorium-on-data-centers","label":"krgv.com"}],"parties":[],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"482c95a38d1827bb","state":"TX","tracker":"atlas","section":"sites","title":"Helios II data center (Dickens County)","summary":"Two buildings containing eight data halls with a combined total of 400 MW of utility capacity and 260 MW of critical IT capacity, to be built on an approximately 260-acre property in Dickens County, Texas. The July 2026 note offering finances a portion of development and construction and funds debt service reserves. Galaxy said on 8 September 2026 that Helios I (800 MW) and Helios II (830 MW) are classified as Batch Zero Base Load, while a 1,000 MW Helios III request and new projects Caspian (700 MW) and Selene (900 MW) were conditionally classified as Studied Load. Galaxy put its Texas pipeline at more than 5.7 GW across four sites, including Merlin in McGregor Galaxy's Q2 2026 results (5 August 2026) state that Helios Phase I delivered 200 MW gross, or 133 MW critical IT, to CoreWeave by quarter end, expected to generate about $80 million of quarterly leasing revenue, and that construction began on the 260 MW critical IT Phase II with HITT Contracting. Galaxy also executed a development agreement for 500 acres at McGregor Industrial Park (Merlin) and acquired the Caspian and Selene sites 400 MW of utility capacity No total project cost disclosed; financed in part by a $3.507 billion senior secured note offering priced 23 July 2026 400 MW of utility capacity and 260 MW of critical IT capacity across eight data halls","scope":"Record-specific:","status":"construction","date":"Note offering priced 23 July 2026","sources":[{"url":"https://www.sec.gov/Archives/edgar/data/0001859392/000185939226000074/exhibit991-pressreleasepri.htm","label":"SEC 8-K (Galaxy Digital)"},{"url":"https://www.newswire.ca/news-releases/galaxy-provides-update-on-ercot-batch-zero-large-load-classifications-802676736.html","label":"Galaxy (PR Newswire via Newswire.ca)"},{"url":"https://www.sec.gov/Archives/edgar/data/1859392/000185939226000084/glxy-20260630xpressrelease.htm","label":"SEC EDGAR (Galaxy Q2 2026 press release, Ex. 99.1)"}],"parties":[{"role":"Entity","name":"galaxy-digital"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"f800f49040185d64","state":"TX","tracker":"atlas","section":"at_risk","title":"Highlander SM One data center","summary":"Highlander SM One's first map amendment failed in August 2025 without the required supermajority. A second application reached City Council in early 2026, and on 17 February 2026 the council voted 5-2 to deny it after a nearly nine-hour meeting. The applicant could reapply after six months, on or after 17 August 2026; no new application had been filed as of April 2026.","scope":"Record-specific: City of San Marcos","status":"rejected","date":"First denial August 2025; final denial 17 February 2026","sources":[{"url":"https://spectrumlocalnews.com/tx/south-texas-el-paso/news/2026/02/18/san-marcos-city-council-rejects-data-center-land-plan","label":"Spectrum News"},{"url":"https://centexdatacenters.org/projects/highlander-sm-one","label":"Central Texas Data Center Tracker"}],"parties":[{"role":"Developer","name":"Highlander SM One LLC"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"d3cf0a37ba2c92a5","state":"TX","tracker":"atlas","section":"sites","title":"Hunt County HPC data center","summary":"New build site in the AMD lease package. Core Scientific said it has commenced construction and estimates initial delivery in the first half of 2028 ERCOT; 431 MW stability study approved, collateral posted, long-lead equipment ordered Not disclosed Approximately 110 MW of critical IT leased to AMD; planned 431 MW of electrical power conditionally approved in ERCOT Batch Zero as Base Load","scope":"Record-specific:","status":"under construction","date":"AMD lease 27 July 2026; ERCOT status disclosed 10 September 2026","sources":[{"url":"https://www.sec.gov/Archives/edgar/data/1839341/000183934126000012/core-20260727.htm","label":"SEC EDGAR (Core Scientific 8-K)"},{"url":"https://www.sec.gov/Archives/edgar/data/1839341/000183934126000012/q2fy26earningsdeck728am.htm","label":"SEC EDGAR (Core Scientific investor presentation, Ex. 99.2)"},{"url":"https://www.sec.gov/Archives/edgar/data/1839341/000183934126000023/core-20260910.htm","label":"SEC EDGAR (Core Scientific 8-K, ERCOT update)"}],"parties":[{"role":"Entity","name":"Core Scientific"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"24807fcbd74ad0a5","state":"TX","tracker":"atlas","section":"sites","title":"HyperGrid campus, Amarillo","summary":"Fermi Inc. is building the HyperGrid campus on land leased from the Texas Tech University System in the Texas Panhandle. The company reports approximately 8,400 acres secured or under long-term lease, 11.3 miles of perimeter fencing, 4.6 miles of on-campus gas pipeline and 7.2 miles of water line, with 300,000 MMBtu per day of firm gas and up to 18.5 MGD of water supply. Its first tenant lease, with TensorWave, covers 222 MW of total facility power over 15 years for approximately $6.5 billion of contracted revenue, entered 9 August 2026 and announced 11 August 2026. On 18 September 2026 Fermi announced that three Siemens Energy SGT6-5000F gas turbines, the first power generation assets to reach the site, had arrived at Project Matador after landing at the Port of Houston in July. Fermi's 21 July 2026 release rated the three units at up to 780 MW together in simple-cycle mode and said they will anchor the second phase of the power buildout. Fermi did not report installation or give a new first-power date. Behind-the-meter generation: GE Frame 6B turbines rated 114 MW simple cycle and over 200 MW combined cycle, three Siemens SGT6-5000F units up to 1.1 GW, and six SGT-800 units rated 478 MW at ISO conditions in combined cycle. Grid connection of 86 MW on initial energization ramping to 200 MW. Clean Air Permit of approximately 6 GW with an application for approximately 5 GW more filed 27 March 2026. $1,547.9 million of property, plant and equipment at 30 June 2026, of which $1,539.2 million is construction in progress Fermi reports 1.5 GW of landed generation assets and targets approximately 200 MW of initial commercial power within six months of its Q2 2026 report and approximately 1.5 GW within 18 to 24 months; the company describes the site as expandable up to approximately 17 GW. No campus IT load has been disclosed.","scope":"Record-specific: Amarillo","status":"construction","date":"Figures as of the Form 10-Q for the quarter ended 30 June 2026, filed 14 August 2026","sources":[{"url":"https://www.sec.gov/Archives/edgar/data/2071778/000207177826000051/frmi-20260630.htm","label":"SEC Form 10-Q (Fermi Inc., Q2 2026)"},{"url":"https://www.sec.gov/Archives/edgar/data/2071778/000207177826000046/fermiq22026erex_991.htm","label":"SEC Form 8-K exhibit: Q2 2026 earnings release"},{"url":"https://www.sec.gov/Archives/edgar/data/2071778/000207177826000007/frmiex991fy2025shletter.htm","label":"SEC Form 8-K exhibit: FY2025 shareholder letter"},{"url":"https://fermiamerica.com/first-power-generation-assets-arrive-at-project-matador/","label":"Fermi America news, 18 September 2026"},{"url":"https://www.nasdaq.com/press-release/fermi-announces-first-siemens-turbines-arrive-port-houston-2026-07-21","label":"Fermi release, 21 July 2026 (via Nasdaq)"},{"url":"https://abc7amarillo.com/news/local/project-matador-reaches-new-milestone-with-arrival-of-power-generation-equipment","label":"KVII ABC 7 Amarillo, 18 September 2026"}],"parties":[{"role":"Entity","name":"fermi-inc"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"575248a519be2d9a","state":"TX","tracker":"atlas","section":"sites","title":"InfraTech Capital Carson County data center campus","summary":"InfraTech Capital announced an initiative for a campus of more than 5,000 acres in Carson County near Amarillo with an undisclosed hyperscaler expected to anchor it, plus expanded fiber optic cable manufacturing with a global partner. The release says the project remains subject to due diligence and definitive agreements, and no local approvals were cited  About $2.7 billion initiative covering a data center campus and expanded fiber optic cable manufacturing, per the company's Business Wire release Not disclosed; campus of more than 5,000 acres","scope":"Record-specific:","status":"announced","date":"Announced 18 August 2026 (company release); single-outlet report (Business Wire via Yahoo Finance)","sources":[{"url":"https://finance.yahoo.com/technology/articles/infratech-capital-advances-2-7-164400730.html","label":"Business Wire via Yahoo Finance"},{"url":"https://constructionreviewonline.com/proposed-2-7b-5000-acre-data-center-campus-advances-in-carson-county-texas/","label":"Construction Review Online"}],"parties":[{"role":"Entity","name":"InfraTech Capital"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"1e41a6adfc33e557","state":"TX","tracker":"atlas","section":"sites","title":"Infrakey hyperscale data center campus (Ross area, proposed Lacy Lakeview annexation)","summary":"Infrakey and the City of Lacy Lakeview are pursuing a $10 billion hyperscale data center on a 520-acre site in the Ross area north of Waco, which Lacy Lakeview would annex through a three-mile corridor and which city officials say could bring $50 million a year in tax revenue. The plan relies on reclaimed wastewater for cooling, up to about 2 million gallons a day, and needs the cooperation of Waco, which owns the regional sewer system and holds water service rights to the site. Waco officials said they lacked basic information and some oppose the project; the engineering feasibility study was not complete as of May 2026. On 2 May 2026 Lacy Lakeview voters elected a data center opponent to the city council, and the incoming McLennan County judge said he would oppose tax abatements. Not stated $10 billion project per the Texas Tribune and Waco Bridge No MW disclosed; 520-acre site; opponents describe 21 buildings","scope":"Record-specific: Near Ross","status":"proposed","date":"Public since November 2025; reported 14 May 2026 (Texas Tribune and Waco Bridge) and 22 June 2026","sources":[{"url":"https://www.click2houston.com/news/texas/2026/05/14/lacy-lakeview-needs-wacos-help-to-realize-its-data-center-dreams-its-not-going-well/","label":"Texas Tribune and Waco Bridge via KPRC Click2Houston (14 May 2026)"},{"url":"https://www.yahoo.com/news/politics/articles/two-texas-mayors-once-coach-045400738.html","label":"The Cool Down via Yahoo News, citing Fortune (22 June 2026)"}],"parties":[{"role":"Entity","name":"Infrakey"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"d38bb944c8efdd40","state":"TX","tracker":"atlas","section":"at_risk","title":"Lewisville data center moratorium","summary":"Lewisville, Texas, enacted a local data center moratorium or ban, recorded in SAVRN's moratorium tracker as dated January 2026. Council voted unanimously to require Special Use Permit for data centers; banned in all residential areas. Each proposal needs two public hearings. The measure has no end date by design.","scope":"Record-specific: Lewisville","status":"moratorium","date":"Enacted January 2026","sources":[{"url":"https://www.keranews.org/news/2026-06-25/lewisville-sets-proactive-limits-on-ai-data-centers-before-they-arrive","label":"keranews.org"}],"parties":[],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"1988391b47667b7c","state":"TX","tracker":"atlas","section":"at_risk","title":"Lubbock 90-day large-scale data center moratorium process","summary":"The Lubbock City Council voted 5-2 on 22 September 2026 to adopt a resolution starting the process for a 90-day moratorium on large-scale data centers, after the Save Lubbock group's petition for an 18-month moratorium, which organizers said was not feasible under Texas law. Planning staff are to develop guidelines on water use, power reliability, zoning, noise and lighting while the ordinance is drafted, and a work session will be held within 90 days. The moratorium ordinance itself had not been adopted.","scope":"Record-specific: Lubbock City Council","status":"other","date":"Resolution adopted 5-2 on 22 September 2026; moratorium ordinance pending","sources":[{"url":"https://www.kcbd.com/2026/09/23/city-council-adopts-resolution-regarding-large-scale-data-centers-lubbock-starting-process-potential-moratorium/","label":"KCBD"},{"url":"https://www.msn.com/en-us/news/other/city-council-adopts-resolution-regarding-large-scale-data-centers-in-lubbock-starting-process-for-potential-moratorium/ar-AA2cMpz3","label":"KCBD via MSN"}],"parties":[{"role":"Developer","name":"n.a."}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"9c0fedf3f8d351c8","state":"TX","tracker":"atlas","section":"sites","title":"Matagorda County powered land site","summary":"More than 1,200 acres planned as a digital infrastructure campus for HPC workloads and bitcoin mining. Phased construction is expected to begin in 2026, contingent on regulatory approvals Utility power agreement for 2,000 MW Acquisition consideration of up to $600 million in milestone payments; development cost not disclosed Up to an initial 1 GW of grid capacity by October 2027 and up to 2 GW by April 2028","scope":"Record-specific: Approximately 90 miles southwest of Houston","status":"announced","date":"Acquired 2 July 2026; announced 9 July 2026","sources":[{"url":"https://www.sec.gov/Archives/edgar/data/1507605/000095014226002012/eh260804074_8k.htm","label":"SEC EDGAR (MARA 8-K)"},{"url":"https://www.globenewswire.com/news-release/2026/07/09/3324769/0/en/MARA-Signs-Agreement-with-HIF-to-Acquire-Strategic-Powered-Land-Site-in-Texas.html","label":"GlobeNewswire"},{"url":"https://ir.mara.com/sec-filings/all-sec-filings/content/0001507605-26-000020/q226shareholderletter.htm","label":"MARA (Q2 2026 shareholder letter)"}],"parties":[{"role":"Entity","name":"MARA Holdings"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"de82d56c6538ea17","state":"TX","tracker":"atlas","section":"sites","title":"Merlin campus, McGregor Industrial Park","summary":"Galaxy disclosed a 500-acre site in the McGregor Industrial Park alongside two further Texas pipeline sites, Caspian (about 700 MW potential) and Selene (about 900 MW potential), subject to ERCOT interconnection  Acquisition price not disclosed Initial phase of 74 MW contracted capacity; expansion potential up to 500 MW","scope":"Record-specific: McGregor","status":"announced","date":"Disclosed in Q2 2026 results, 5 August 2026; acquisition date not disclosed","sources":[{"url":"https://www.prnewswire.com/news-releases/galaxy-announces-second-quarter-2026-financial-results-302843529.html","label":"PR Newswire (Galaxy)"}],"parties":[{"role":"Entity","name":"Galaxy Digital"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"9f04981906014fdd","state":"TX","tracker":"atlas","section":"sites","title":"Meta Temple Data Center, Industrial Boulevard","summary":"Meta opened its AI data center on Industrial Boulevard in Temple, Texas, in July 2026 after breaking ground in 2022 and restarting construction under a redesign in 2023. The two-building campus exceeds 760,000 square feet, supported more than 1,200 construction workers at peak and has nearly 100 operations roles. Meta also cited $8 million invested in local water and wastewater infrastructure. This is separate from the Rowan Project Temple campus record Meta says all energy use is matched with 100% clean and renewable energy More than $1.2 billion once completed, per Meta No MW figure disclosed; campus exceeds 760,000 sq ft across two buildings","scope":"Record-specific: Temple","status":"operational","date":"Opened 22 July 2026","sources":[{"url":"https://www.kwtx.com/2026/07/22/meta-goes-live-temple-with-12-billion-ai-data-center/","label":"KWTX"}],"parties":[{"role":"Entity","name":"meta"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"b3c232a25003b3a9","state":"TX","tracker":"atlas","section":"sites","title":"Midlothian / Red Oak campuses (Ellis County)","summary":"At the Midlothian/Red Oak campuses, Google plans to invest $1 billion in Texas this year, taking spending in the Lone Star State to $2.7 billion, with 375 MW of carbon-free energy capacity in new solar PPAs. 375 MW of carbon-free energy capacity in new solar PPAs $1 billion in Texas this year, taking spending in the state to $2.7 billion 375 MW of carbon-free energy capacity in new solar PPAs","scope":"Record-specific: Midlothian and Red Oak","status":"expansion","date":null,"sources":[{"url":"https://www.datacenterdynamics.com/en/news/google-to-invest-1bn-expanding-dallas-data-centers-signs-375mw-in-solar-ppas/","label":"DCD"}],"parties":[{"role":"Entity","name":"alphabet"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"b0b0c622b9beab10","state":"TX","tracker":"atlas","section":"at_risk","title":"Midtown Business Park data center land sale","summary":"The College Station City Council voted unanimously on 11 September 2025, after nearly six hours of discussion, to reject the sale of city land for a data center of up to 200 acres. More than 75 people registered to speak and a petition with 5,047 signatures was delivered to the council.","scope":"Record-specific: City of College Station","status":"rejected","date":"Land sale rejected 11 September 2025","sources":[{"url":"https://www.kbtx.com/2025/09/12/college-station-city-council-unanimously-rejects-land-sale-ai-data-center/","label":"KBTX"},{"url":"https://wtaw.com/college-station-city-council-unanimously-votes-against-the-sale-of-city-land-for-a-data-center/","label":"WTAW"}],"parties":[{"role":"Developer","name":"Priority Power Management"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"7bf5679c59080fdb","state":"TX","tracker":"atlas","section":"sites","title":"Milam County Data Center (Stargate site)","summary":"Listed in the summary table among the announced US Stargate sites. SB Energy's Form S-1, filed 1 September 2026, identifies the Milam County Data Center as one of the company's two data center projects under construction, alongside the Cosmos Technology Campus, and states that Milam County Buildings 1 and 2 sit within its 0.8 GW-IT of under-construction capacity. The filing records warrants issued on 9 January 2026 in connection with the Milam County data center facility lease arrangements with OpenAI, remeasurement of which drove a $2,573.1 million change in fair value of warrant liability for the six months ended 30 June 2026. No site-level dollar or megawatt figure is disclosed. A TDLR registration (TABS2026017746) filed in April 2026 lists 'Freebird Data Center Phase 1' (facility DC01) on County Road 133 in Burlington, Milam County: a single-story 548,950 sq ft building with four data halls, estimated cost $470,000,000, owner Milam County Data Center LLC and tenant OpenAI, with construction from October 2025 to October 2026. KCEN-TV traced quarry truck traffic through Temple to the project in August 2026, and an SB Energy spokesperson responded on the company's behalf.  TDLR estimated cost of $470 million for Freebird Data Center Phase 1 (building DC01) only; total site cost not disclosed No separate megawatt figure is disclosed for Milam County. SB Energy's Form S-1 places Milam County Buildings 1 and 2 inside 0.8 GW-IT of under-construction capacity that also includes the Cosmos Technology Campus, so the Milam share of that figure is not separable from the filing.","scope":"Record-specific: Burlington (County Road 133)","status":"construction","date":"Under construction per the Form S-1 filed 1 September 2026; lease arrangements dated 9 January 2026","sources":[{"url":"https://openai.com/index/expanding-stargate-to-michigan/","label":"OpenAI Oct 2025"},{"url":"https://openai.com/index/announcing-the-stargate-project/","label":"OpenAI Jan 2025"},{"url":"https://www.sec.gov/Archives/edgar/data/2133037/000162828026059639/sbenergy-sx1.htm","label":"SEC Form S-1 (SB Energy, Inc.)"},{"url":"https://www.tdlr.texas.gov/TABS/Search/Project/TABS2026017746","label":"TDLR TABS project TABS2026017746 (registered 15 April 2026)"},{"url":"https://www.msn.com/en-us/technology/tech-companies/several-rock-trucks-driving-through-downtown-temple-traced-to-470-million-openai-data-center-project/ar-AA29Dn9B","label":"KCEN-TV (via MSN), 7 August 2026"}],"parties":[{"role":"Entity","name":"openai-stargate"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"53e13d4d3806c121","state":"TX","tracker":"atlas","section":"at_risk","title":"Milam County data center moratorium","summary":"Milam County, Texas, enacted a local data center moratorium or ban, recorded in SAVRN's moratorium tracker as dated January 2026. Resolution calling for stricter statewide standards on data centers: public disclosure of electrical demand, water consumption, cooling technologies, and infrastructure impact. Non-binding. The measure has no documented term.","scope":"Record-specific: Milam County","status":"moratorium","date":"Enacted January 2026","sources":[{"url":"https://www.multistate.us/insider/2026/8/19/the-local-fight-over-data-centers-a-texas-case-study","label":"multistate.us"}],"parties":[],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"af2b9c0cba5326b6","state":"TX","tracker":"atlas","section":"sites","title":"Nexus Data Centers Hubbard AI campus","summary":"2,900-acre multi-phase campus about 70 miles south of Dallas with Anthropic as expected anchor tenant. W.Media dates Building 1 construction from January 2026 to October 2027 and Building 2 from June 2026 to January 2028. Final investment decision reached with the August 2026 financing On-site gas-fired generation, behind the meter Project finance package reported at about $16 billion, of which $1.3 billion is Eagle Point HoldCo debt; this is financing, not reported total capex W.Media reports up to 600 MW with behind-the-meter power; not confirmed in other fetched sources","scope":"Record-specific: Hubbard","status":"under_construction","date":"FID reported 19 August 2026","sources":[{"url":"https://w.media/eagle-point-loan-greenlights-first-phase-of-nexus-hyperscale-campus/","label":"W.Media"},{"url":"https://thenextweb.com/news/eagle-point-nexus-anthropic-texas-data-center-loan","label":"The Next Web"}],"parties":[{"role":"Entity","name":"Nexus Data Centers"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"15162ed214e6a4f5","state":"TX","tracker":"atlas","section":"sites","title":"Nexus Data Centers Hubbard AI campus (Anthropic anchor tenant)","summary":"Nexus Data Centers is building a multi-phase data center and behind-the-meter power campus in Hubbard, Texas, about 70 miles south of Dallas, with Anthropic as primary tenant under four data center leases. Google agreed to guarantee Anthropic's lease and power-payment obligations to support the senior debt, and Anthropic plans to equip the site with Google TPUs financed separately with Broadcom. Eagle Point said on 19 August 2026 that its HoldCo loan completed the capital structure for phase one and allowed Nexus to reach a final investment decision. Bloomberg reported the campus at 2,900 acres Behind-the-meter natural gas generation on site, reported at 1.6 GW No total project cost disclosed; reported financing of about $16 billion comprises about $15 billion of Morgan Stanley-led senior debt and a $1.3 billion HoldCo mezzanine loan Data center MW not disclosed; the Wall Street Journal reported an on-site natural gas plant of 1.6 GW, relayed by Stocktwits on TradingView","scope":"Record-specific: Hubbard","status":"under_construction","date":"Financing reported 30 July 2026 by the Wall Street Journal and confirmed by CNBC; final investment decision announced 19 August 2026","sources":[{"url":"https://www.cnbc.com/2026/07/30/nexus-data-centers-in-advanced-talks-to-secure-15b-for-google-backed-anthropic-data-center.html","label":"CNBC"},{"url":"https://www.tradingview.com/news/stocktwits:01dbbca1e094b:0-googl-backs-15b-financing-for-anthropic-linked-texas-ai-campus-project-reportedly-includes-1-6gw-power-plant/","label":"TradingView (Stocktwits, citing WSJ)"},{"url":"https://www.rutlandherald.com/news/business/eagle-point-leads-holdco-financing-for-nexus-ai-data-center-campus-in-texas/article_7388e548-8ae6-550f-91b3-3f580e102665.html","label":"Eagle Point via Business Wire (Rutland Herald)"},{"url":"https://thenextweb.com/news/eagle-point-nexus-anthropic-texas-data-center-loan","label":"The Next Web (citing Bloomberg)"}],"parties":[{"role":"Entity","name":"anthropic"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"16b1041e13d10cc8","state":"TX","tracker":"atlas","section":"sites","title":"North Dallas Corridor turnkey data center","summary":"A turnkey data center with 54 MW of critical capacity on a 74 MW site in the North Dallas Corridor, announced 3 September 2026 for delivery in late 2027. The parties describe it as the first project under a framework to develop inference-ready sites in top tier United States markets. Not disclosed in the announcement No dollar figure disclosed in the joint venture announcement 54 MW critical capacity on a 74 MW site","scope":"Record-specific:","status":"announced","date":null,"sources":[{"url":"https://uk.finance.yahoo.com/news/northampton-capital-partners-forms-joint-123000620.html","label":"Yahoo Finance / press release"},{"url":"https://www.datacenterdynamics.com/en/news/jv-plans-54mw-data-center-in-dallas-texas/","label":"DCD"}],"parties":[],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"0a91a2765c08d737","state":"TX","tracker":"atlas","section":"sites","title":"Nscale Texas campus (Microsoft)","summary":"Approximately 104,000 of the roughly 200,000 Nvidia GB300 GPUs under the expanded Microsoft agreement deploy at a ~240MW Texas campus starting Q3 2026, with Microsoft holding an option on a second 700MW Texas phase from late 2027 against a 1.2GW site target. Nscale's Form S-1 filed 18 September 2026 places its Texas facility in Ward County, held under a net lease for which NVIDIA agreed on 14 October 2025 to guarantee up to $860.3 million of Nscale's obligations in exchange for warrants. The filing also describes a $1.85 billion delayed draw term loan entered in August 2026 to finance GPU infrastructure at the Ward County site, maturing in February 2033. Nscale's earlier Microsoft release states the roughly 240 MW Texas campus is leased from Ionic Digital. The S-1 does not itself state that the Ward County site is the Microsoft campus.  Microsoft deal reported at approximately $14 billion ~240MW starting Q3 2026; Microsoft option on a second 700MW phase from late 2027; 1.2GW site target","scope":"Record-specific:","status":"announced","date":"deployment starting Q3 2026","sources":[{"url":"https://www.nscale.com/press-releases/nscale-microsoft-2025","label":"Nscale"},{"url":"https://www.sec.gov/Archives/edgar/data/2110365/000119312526395475/ck0002110365-20260918.htm","label":"Nscale Ltd Form S-1 (SEC)"}],"parties":[{"role":"Entity","name":"nscale"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"0811dcabf2b039f9","state":"TX","tracker":"atlas","section":"at_risk","title":"ONMINE computing and energy research annex (6509 S. Fort Hood Street)","summary":"The Killeen Planning and Zoning Commission voted 4-1 on 27 April 2026 against a conditional use permit for ONMINE's proposed $30 million facility, despite a staff recommendation for approval, after nearly 30 residents spoke in opposition. The city listed the project as a computing and energy research annex, similar to a data center at a smaller scale. The city confirmed on 12 May 2026 that the applicant had withdrawn the request before a city council hearing set for 2 June 2026, where it would have needed six votes.","scope":"Record-specific: City of Killeen","status":"withdrawn","date":"Planning and Zoning Commission vote 27 April 2026; withdrawal confirmed 12 May 2026","sources":[{"url":"https://kdhnews.com/news/local/applicant-for-killeen-data-center-rezoning-withdraws-request/article_bc1255d3-487c-4e1e-9e55-e4bd2e2b75a6.html","label":"Killeen Daily Herald (12 May 2026)"},{"url":"https://www.kwtx.com/2026/04/28/killeen-planning-commission-denies-permit-proposed-data-center/","label":"KWTX (28 April 2026)"}],"parties":[{"role":"Developer","name":"ONMINE"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"f3278925a3ca36af","state":"TX","tracker":"atlas","section":"sites","title":"Oppidan Connect Temple data center (2313 Eberhardt Road)","summary":"Minnesota-based Oppidan Investment Company is building the Connect Temple data center at 2313 Eberhardt Road near Meta's northwest Temple campus. KDH News (Temple Daily Telegram) reported in June 2026 that the project represents a 14 MW, $80 million investment, versus the 5 MW, $31 million building cost in its TDLR filing; the Temple EDC said the difference is about $49 million of servers and equipment. The developer said the facility creates 12 permanent jobs and 150 to 200 construction jobs and received no local tax incentives; completion was expected in October.  $80 million total investment per Temple officials and the city's FY2025 ACFR, including about $49 million of servers and equipment; TDLR lists $31 million for the building Designed for up to 14 MW per the developer; state filing and city report list 5 MW; 61,500 sq ft","scope":"Record-specific: Temple","status":"under_construction","date":"Backfill (not previously recorded). Reported 13 June 2026 (KDH News); single outlet","sources":[{"url":"https://kdhnews.com/news/region/another-data-center-near-meta-temple-campus-brings-80-million-investment-12-jobs/article_5bfc8e2b-0278-5879-a9cb-f4dbf5bdd244.html","label":"KDH News (Temple Daily Telegram), 13 June 2026"}],"parties":[{"role":"Entity","name":"Oppidan Investment Company"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"3ea0174bbfcfb61b","state":"TX","tracker":"atlas","section":"sites","title":"Pecos HPC data center","summary":"Former Core Scientific site included in the 27 July 2026 AMD leases covering 377 MW across Pecos, Muskogee and Hunt County. Initial delivery estimated in the first half of 2027 ERCOT; 300 MW existing load plus 300 MW studied load, conditional Not disclosed Approximately 185 MW of critical IT leased to AMD per the July 2026 investor presentation; 300 MW existing power conditionally approved as Base Load and 300 MW as Studied Load in ERCOT Batch Zero","scope":"Record-specific: Pecos","status":"under development","date":"AMD lease 27 July 2026; ERCOT status disclosed 10 September 2026","sources":[{"url":"https://www.sec.gov/Archives/edgar/data/1839341/000183934126000012/core-20260727.htm","label":"SEC EDGAR (Core Scientific 8-K)"},{"url":"https://www.sec.gov/Archives/edgar/data/1839341/000183934126000012/q2fy26earningsdeck728am.htm","label":"SEC EDGAR (Core Scientific investor presentation, Ex. 99.2)"},{"url":"https://www.sec.gov/Archives/edgar/data/1839341/000183934126000023/core-20260910.htm","label":"SEC EDGAR (Core Scientific 8-K, ERCOT update)"}],"parties":[{"role":"Entity","name":"Core Scientific"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"e5e817bc9d052897","state":"TX","tracker":"atlas","section":"sites","title":"Pecos datacenter campus","summary":"In June 2026 Microsoft announced a new campus in Pecos, Texas, expanding its global datacenter capacity by approximately 2 gigawatts, described as a multibillion-dollar datacenter campus investment over the next five to seven years, with no precise dollar total disclosed.  multibillion-dollar investment over the next five to seven years (no precise dollar total disclosed) expanding global datacenter capacity by approximately 2 gigawatts","scope":"Record-specific: Pecos","status":"announced","date":"Announced June 2026","sources":[{"url":"https://blogs.microsoft.com/blog/2026/06/22/powering-the-next-wave-of-ai-expanding-capacity-with-our-new-datacenter-in-pecos/","label":"Microsoft blog"}],"parties":[{"role":"Entity","name":"microsoft"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"f16ff1f776df0f22","state":"TX","tracker":"atlas","section":"sites","title":"Plano data center (1000 Coit Road)","summary":"A $1.6 billion, 450,000 sq ft facility at 1000 Coit Road in Plano, Texas.  $1.6 billion 450,000 sq ft facility; MW n.a.","scope":"Record-specific: Plano","status":"announced","date":null,"sources":[{"url":"https://communityimpact.com/plano-south/development/coreweave-to-open-16b-data-center-in-plano/","label":"Community Impact"}],"parties":[{"role":"Entity","name":"coreweave"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"5b20eafa00a9f716","state":"TX","tracker":"atlas","section":"sites","title":"PowerPlay AI greater Abilene behind-the-meter AI data center","summary":"Unincorporated site in the greater Abilene area of West Texas with installed natural gas and adjacent fiber. Land assembly and acquisition were completed before the joint venture announcement Behind-the-meter natural gas generation; natural gas service agreements in progress and independent power producer selection pending Not disclosed Initial 400 MW of behind-the-meter power targeted for delivery in 2028","scope":"Record-specific:","status":"planned","date":"Announced 20 July 2026","sources":[{"url":"https://finance.yahoo.com/technology/ai/articles/powerplay-ai-announces-400-mw-140000052.html","label":"PowerPlay AI (PR Newswire via Yahoo Finance)"}],"parties":[{"role":"Entity","name":"PowerPlay AI"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"ef669a5085de492a","state":"TX","tracker":"atlas","section":"sites","title":"Prime Data Centers AUS01 and AUS02 (1395 Bob White Road)","summary":"A TDLR registration lists 'Prime Data Center AUS-01', two new 380,000 sq ft shell buildings (760,000 sq ft in total) for future data center use at 1395 Bob White Road, Lockhart, Caldwell County, with an estimated cost of $400 million. The owner of record is Lockhart Property, LLC; no tenant is assigned. Scheduled construction runs from 1 June 2026 to 30 September 2027.  TDLR estimated cost $400 million for two 380,000 sq ft shell buildings Not stated in the TDLR filing","scope":"Record-specific: Lockhart","status":"proposed","date":"Registered with TDLR 5 May 2026 (TABS2026019473); reported by Data Center Dynamics May 2026","sources":[{"url":"https://www.tdlr.texas.gov/TABS/Search/Project/TABS2026019473","label":"TDLR TABS project TABS2026019473"},{"url":"https://www.datacenterdynamics.com/en/news/prime-files-to-build-two-data-centers-outside-austin-texas/","label":"Data Center Dynamics, 13 May 2026 (walled)"}],"parties":[{"role":"Entity","name":"prime-data-centers"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"2958855cd1ae7f86","state":"TX","tracker":"atlas","section":"at_risk","title":"Princeton data center moratorium","summary":"Princeton, Texas, enacted a local data center moratorium or ban, recorded in SAVRN's moratorium tracker as dated January 2026. City amended regulations to require a Specific Use Permit for data centers, updated definitions, and established per-project public review. The measure has no end date by design.","scope":"Record-specific: Princeton","status":"moratorium","date":"Enacted January 2026","sources":[{"url":"https://princetonherald.com/2026/06/11/council-plans-data-center-regulation/","label":"princetonherald.com"}],"parties":[],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"5dd41941a10d94ac","state":"TX","tracker":"atlas","section":"sites","title":"Project Dorothy 3","summary":"Soluna closed the purchase of 397 acres adjacent to Projects Dorothy 1 and 2 to host Dorothy 3. The acreage exceeds the 300 acres originally identified, leaving room for more data halls Behind-the-meter access to Soluna's 150 MW Briscoe Wind Farm, whose substation sits across from the parcel Land purchase price not disclosed Planned renewable-first AI computing campus with potential capacity of up to 300 MW","scope":"Record-specific:","status":"planned","date":"Land purchase closed, announced 24 August 2026","sources":[{"url":"https://www.sec.gov/Archives/edgar/data/64463/000149315226039781/ex99-1.htm","label":"SEC EDGAR (Soluna press release, Ex. 99.1)"}],"parties":[{"role":"Entity","name":"Soluna Holdings"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"406afc6443bb685a","state":"TX","tracker":"atlas","section":"sites","title":"Project Eagle campus, Boling","summary":"Amazon Data Services filed four Texas Department of Licensing and Regulation applications for identical 189,060 sq ft buildings at about $300 million each near FM 1301 and FM 442 in Boling, on roughly 2,700 acres. The filings list construction starting 1 August 2026, with three buildings completing in January 2027 and the fourth in August 2027. Reporting in August 2026 said site preparation was underway but additional county permits were still required and the schedule was affected by new state audit requirements for data center power hookups. Wharton County officials signed a nondisclosure agreement with Amazon consultant VisionFirst Advisors. The Coastal Bend Groundwater Conservation District issued contested groundwater permits on 8 September 2026 allowing Amazon to withdraw up to 78.2 million gallons over two and a half years from three wells for offices, construction and fire protection, in addition to May 2026 permits for 16.9 million gallons from two other wells. The permits do not cover surface water for cooling. The Houston Chronicle describes the campus as a $10 billion project on nearly 3,000 acres with data center buildings that could span more than 1.9 million sq ft.  TDLR filings list $300 million per building, $1.2 billion for the first four buildings. A $10 billion campus figure was reported by the Houston Chronicle and The Real Deal and is not a company disclosure, so it is not recorded as capital_usd_m Up to 75 MW at peak for the 10-building campus, as reported by the Houston Chronicle via CRE Daily; not a company disclosure","scope":"Record-specific: Boling","status":"announced","date":"TDLR filings reported 9 July 2026; permitting headwinds reported 17 to 18 August 2026; groundwater permits issued 8 September 2026","sources":[{"url":"https://usdatacenterprojects.com/texas/aws-files-1-2-billion-permit-for-four-building-data-center-campus-in-wharton-county-texas","label":"US Data Center Projects (TDLR filings)"},{"url":"https://finance.yahoo.com/real-estate/articles/amazon-10b-houston-data-center-164242528.html","label":"Yahoo Finance (CRE Daily)"},{"url":"https://www.msn.com/en-us/money/general/amazon-clears-first-water-hurdle-for-10b-data-center-near-houston-bigger-obstacles-remain/ar-AA2dpHVY","label":"Houston Chronicle via MSN"}],"parties":[{"role":"Entity","name":"amazon"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"6bc308880481e1e8","state":"TX","tracker":"atlas","section":"sites","title":"Project Horizon (Longfellow Ranch)","summary":"A 2GW West Texas campus at Longfellow Ranch structured in eight 250MW phases, with more than 40,000 Nvidia GB300 NVL72 GPUs to be supplied from December 2025. CoreWeave subsequently ended the 2GW deal, leaving a $2 billion funding gap. power procurement challenges cited at the 2GW campus CoreWeave exit left a $2 billion funding gap 2GW campus in eight 250MW phases on a 568-acre site","scope":"Record-specific:","status":"cancelled","date":"partnership announced October 2025; deal later ended","sources":[{"url":"https://www.datacenterdynamics.com/en/news/ai-startup-poolside-teams-up-with-coreweave-on-2gw-data-center-in-texas/","label":"DCD Project Horizon"},{"url":"https://mlq.ai/news/coreweave-ends-2-gw-texas-data-center-deal-with-poolside/","label":"MLQ"}],"parties":[{"role":"Entity","name":"poolside"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"4cbb4912f4bb017c","state":"TX","tracker":"atlas","section":"sites","title":"Project Hyper data center campus (Spur Buildings 1 and 2), County Road 233, Jayton","summary":"Two projects named Project Hyper were registered with the Texas Department of Licensing and Regulation on 1 October 2026: Spur Building 1 (TABS2027002494, owner Spur DC Owner 1 LLC, construction 31 January 2027 to 7 June 2029) and Spur Building 2 (TABS2027002499, owner Spur DC Owner 2 LLC, construction 13 January 2027 to 25 May 2029). Each is new construction of a single story data center of 759,262 sq ft with office and support space at County Road 233 and P2390, Jayton, Kent County, estimated at $2.4 billion, designed by HKS. The filings do not name Crusoe; Data Center Dynamics attributes the $4.8 billion campus to Crusoe in its headline (article walled), so the attribution rests on that single trade report.  $4.8 billion: two TDLR registrations at an estimated $2.4 billion each (Spur Building 1 and Spur Building 2). TDLR estimated construction cost, not a company announcement No MW disclosed; each filing is a single story data center of 759,262 sq ft","scope":"Record-specific: Jayton","status":"proposed","date":"Registered with TDLR 1 October 2026; reported by Data Center Dynamics 1 to 2 October 2026","sources":[{"url":"https://www.tdlr.texas.gov/TABS/Search/Project/TABS2027002494","label":"TDLR TABS Project Hyper, Spur Building 1 (TABS2027002494)"},{"url":"https://www.tdlr.texas.gov/TABS/Search/Project/TABS2027002499","label":"TDLR TABS Project Hyper, Spur Building 2 (TABS2027002499)"},{"url":"https://www.datacenterdynamics.com/en/news/crusoe-files-for-48bn-data-center-campus-in-jayton-texas/","label":"Data Center Dynamics (walled; headline attributes the filings to Crusoe)"}],"parties":[{"role":"Entity","name":"crusoe-energy"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"6946e0508efd98ac","state":"TX","tracker":"atlas","section":"sites","title":"Project Kati (Kati 1 and Kati 2)","summary":"Soluna energized the final 14 MW at Kati 1 in September 2026. The Kati 2 AI expansion is being developed through a joint venture with Metrobloks signed 3 June 2026 Behind the meter, powered by the Las Majadas wind energy project; full 166 MW conditionally classified as Base Load in ERCOT Batch Zero Not disclosed 166 MW campus: Kati 1 at 83 MW for Bitcoin hosting, completed; Kati 2 planned at 83 MW for AI and HPC; Kati 2 JV with Metrobloks targets 100 MW critical IT in Phase I and a further 250 MW in Phase II","scope":"Record-specific:","status":"operating (Kati 1); planned (Kati 2)","date":"Kati 1 completion and ERCOT classification announced 8 September 2026","sources":[{"url":"https://www.sec.gov/Archives/edgar/data/64463/000149315226041699/ex99-1.htm","label":"SEC EDGAR (Soluna press release, Ex. 99.1, 8 September 2026)"},{"url":"https://www.sec.gov/Archives/edgar/data/64463/000149315226037734/ex99-1.htm","label":"SEC EDGAR (Soluna Q2 2026 press release, Ex. 99.1)"}],"parties":[{"role":"Entity","name":"Soluna Holdings"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"9f60ea110541dc0c","state":"TX","tracker":"atlas","section":"at_risk","title":"Project Patriot (Knox Ranch)","summary":"Granbury annexed the roughly 2,000-acre Knox Ranch from Hood County and rezoned it for Bilateral Energy's power generation and data center plan known as Project Patriot. Four Hood County property owners sued, alleging a Texas Open Meetings Act violation through a walking quorum during a data center tour, and the suit remained unresolved as of July 2026. On 8 July 2026 residents presented a no-confidence petition with more than 800 signatures against the city manager and city attorney. On 17 August 2026 Granbury residents petitioned the Second Court of Appeals in Fort Worth for a writ of mandamus ordering the city to validate five recall petitions against the mayor, mayor pro tem and three council members, citing Project Patriot approvals. The city had verified only 26 of more than 5,000 signatures. The court set an expedited schedule that could put recalls on the November 2026 ballot.","scope":"Record-specific: City of Granbury","status":"litigation","date":"Annexation January 2026; suit by April 2026","sources":[{"url":"https://www.keranews.org/government/2026-07-08/granbury-residents-submit-no-confidence-petition-for-city-manager-city-attorney-over-data-centers","label":"KERA News"},{"url":"https://www.keranews.org/politics/2026-08-17/granbury-residents-sue-to-revive-recall-effort-over-data-centers-ahead-of-november-elections","label":"KERA News"}],"parties":[{"role":"Developer","name":"Bilateral Energy LLC"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"df1db6dd560a2eaf","state":"TX","tracker":"atlas","section":"at_risk","title":"Project Red and Project Yellow","summary":"The developers of two proposed Hood County data center campuses sued, arguing their plans were automatically approved because the county missed a 30-day statutory deadline. District Judge Bryan Bufkin granted the county's plea to the jurisdiction and dismissed the suit with prejudice in July 2026, finding the projects were not development plans under state law. The companies indicated in filings that they will appeal.","scope":"Record-specific: Hood County","status":"litigation","date":"Dismissed July 2026","sources":[{"url":"https://www.keranews.org/energy-environment/2026-07-20/hood-county-judge-dismisses-lawsuit-seeking-automatic-approval-of-proposed-data-centers","label":"KERA News"}],"parties":[{"role":"Developer","name":"National CRE Holdings LLC; Greenland Capital LLC"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"8925ddbaa8785156","state":"TX","tracker":"atlas","section":"sites","title":"Project Rise 1A and Rise 2A data centers, Vernon","summary":"Google filed two TDLR registrations for Project Rise 1A and Rise 2A in Vernon, Texas, each a new data center of 991,000 sq ft with mechanical and electrical yards, with construction listed to finish by the end of March 2028. The filings follow Google's February 2026 statement that it would develop a Wilbarger County data center co-located with AES clean energy, part of its $40 billion Texas commitment through 2027 TDLR lists the owner as Planton Investments LLC (Platon Investments LLC on the Rise 2A filing) at Google's Mountain View address, at FM 2897 S in Vernon, with a listed start date of 31 March 2026 Google said in February 2026 its Wilbarger County data center would be co-located with on-site clean energy from AES TDLR filings list $500 million for each of Rise 1A and Rise 2A, $1 billion combined No MW figure disclosed; each building is listed at 991,000 sq ft","scope":"Record-specific: Vernon","status":"filed","date":"TDLR filings registered 11 and 15 July 2026; reported 19 to 20 July 2026","sources":[{"url":"https://constructionreviewonline.com/1bn-project-rise-1a-and-rise-2a-data-centers-by-google-filed-for-development-in-vernon-texas/","label":"Construction Review Online"},{"url":"https://www.tdlr.texas.gov/TABS/Search/Project/TABS2026025053","label":"TDLR TABS filing (Project Rise 1A)"},{"url":"https://www.tdlr.texas.gov/TABS/Search/Project/TABS2026025297","label":"TDLR TABS filing (Rise 2A)"},{"url":"https://blog.google/innovation-and-ai/infrastructure-and-cloud/global-network/data-center-wilbarger-county/","label":"Google blog"}],"parties":[{"role":"Entity","name":"alphabet"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"113809c1e59b1281","state":"TX","tracker":"atlas","section":"sites","title":"Project Temple data center campus","summary":"Rowan broke ground on Project Temple in January 2026 on approximately 700 acres in Temple, Bell County, Texas, for a single unnamed global technology tenant, with operations expected in 2027, roughly 600 construction jobs and more than 40 permanent positions. The company closed nearly $3 billion of debt financing for the campus on 27 May 2026 under its Green Finance Framework. Rowan says its Temple footprint of six buildings across Project Temple, Project Stampede and Project Ranger represents at least $4.2 billion of investment, with five buildings approved or under construction. The sixth, the Lasso Building, the third and final Project Temple building at about $700 million, was moved to a replacement site after the city needed the original land for a landfill expansion; the City Council was scheduled to take up its second zoning reading on 17 September 2026. Rowan said it has no further Temple data centers planned (reported 12 August and 13 September 2026) Rowan Digital Infrastructure registered AUS02 (Building 2) at 1855 Bob White Road in Temple with the Texas Department of Licensing and Regulation on 24 July 2026: a one-story, 500,000 sq ft data center with an estimated cost of $780 million, estimated start 28 August 2026 and completion 27 August 2027. On 17 September 2026 Temple City Council approved annexation and PD-LI zoning for Phase 1B (Project Lasso), the Project Lasso development agreement, and an infrastructure agreement across all three phases under which Rowan funds $38,545,796 (about $25 million for the South Temple water program and $13 million in contributions), with water-use caps of 13,800, 8,200 and 10,100 gallons per day for Phases 1, 2 (Stampede) and 3 (Ranger) served by Oncor nearly $3 billion of green debt financing closed 27 May 2026 for the campus; the January 2026 groundbreaking release cited a minimum $700 million investment 300 MW; first of the developer's Temple campuses","scope":"Record-specific: Temple","status":"construction","date":null,"sources":[{"url":"https://rowan.digital/news/rowan-powers-texas-growth-as-construction-begins-on-300-mw-temple-data-center/","label":"Rowan Digital Infrastructure"},{"url":"https://rowan.digital/rowan-closes-3b-green-financing-for-turnkey-hyperscale-campus-in-high-growth-texas-market/","label":"Rowan Digital Infrastructure"},{"url":"https://kdhnews.com/business/rowan-s-4-2-billion-temple-data-center-campus-advances-as-water-power-questions-persist/article_4f7053a3-e6d2-4770-bd09-ad2e4b6341d1.html","label":"Killeen Daily Herald"},{"url":"https://www.kwtx.com/2026/08/12/rowan-digital-infrastructure-seeks-approval-6th-final-data-center-temple/","label":"KWTX"},{"url":"https://www.yahoo.com/news/us/articles/weve-got-stop-texas-residents-172700427.html","label":"Yahoo News"},{"url":"https://www.tdlr.texas.gov/TABS/Search/Project/TABS2026026121","label":"TDLR TABS project TABS2026026121"},{"url":"https://city-of-temple.prowly.com/471932-september-17-council-recap","label":"City of Temple council recap"},{"url":"https://www.kxxv.com/news/local-news/in-your-neighborhood/bell-county/temple/temple-council-approves-rowan-data-center-tax-break-38m-investment-deal-after-months-of-push-back","label":"KXXV"}],"parties":[{"role":"Entity","name":"rowan-digital-infrastructure"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"b5becfc472e6a993","state":"TX","tracker":"atlas","section":"at_risk","title":"Project Tomahawk Prosper data center (rezoning denied by Planning and Zoning Commission; withdrawn)","summary":"The Prosper Planning and Zoning Commission unanimously denied a zoning change request for a proposed data center at a Tuesday night meeting after hours of public opposition, including from neighboring Aubrey residents. Commissioners cited the lack of net benefit to the town, electricity use, environmental impacts and noise, and noted data centers are not a defined use in the future land use plan. The commission also unanimously denied related amendments. The project, White Rose Partners Project Tomahawk, a US$580 million data center on 37.3 acres at Parvin Road and FM 1385, was scheduled for the Town Council on Tuesday 8 September 2026, but the developer withdrew both items hours before the meeting and the town closed the application; a revised plan would need a new application and a new Planning and Zoning hearing.","scope":"Record-specific: Town of Prosper Planning and Zoning Commission","status":"withdrawn","date":"Denied 7-0 by Planning and Zoning Commission 1 September 2026; application withdrawn before 8 September 2026 Town Council meeting","sources":[{"url":"https://www.msn.com/en-us/news/other/prosper-planning-and-zoning-commission-unanimously-denies-controversial-data-center-rezoning-request/ar-AA2bnnsM","label":"WFAA via MSN"},{"url":"https://communityimpact.com/prosper-celina/development/prosper-commission-recommends-denial-of-580-million-data-center/","label":"Community Impact"},{"url":"https://communityimpact.com/prosper-celina/government/project-tomahawk-developer-scraps-plans-for-prosper-data-center/","label":"Community Impact"},{"url":"https://www.cbsnews.com/texas/news/prosper-tx-project-tomahawk-pulled-9-8-2026/","label":"CBS News Texas"}],"parties":[],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"2ab3c2f050412dc6","state":"TX","tracker":"atlas","section":"sites","title":"QTS DFW2 campus, building DC7 (1341 Sunrise Road)","summary":"QTS Dallas I, LLC registered a new two-story, 363,500 sq ft building with office and shell data hall space, named QTS DFW2-DC7, at 1341 Sunrise Road, Lancaster, Dallas County, with the Texas Department of Licensing and Regulation on 22 September 2026. The estimated cost is $290 million, with an estimated schedule of 1 September 2026 to 1 December 2027. Corgan Associates is the design firm and no tenant is assigned. The DC7 designation implies earlier buildings on the DFW2 campus, which the filing does not describe. The Real Deal's weekly permit roundup (28 September 2026) reported the $290 million, 364,000 sq ft two-story QTS project at 1341 Sunrise Road, with construction from September 2026 to December 2027.  $290,000,000 estimated construction cost for building DC7 per TDLR registration TABS2027001648; campus total not disclosed MW not stated; new two-story 363,500 sq ft building with office and shell data hall space","scope":"Record-specific: Lancaster","status":"proposed","date":"TDLR registration 22 September 2026; reported by The Real Deal 28 September 2026","sources":[{"url":"https://www.tdlr.texas.gov/TABS/Search/Project/TABS2027001648","label":"TDLR TABS project TABS2027001648"},{"url":"https://therealdeal.com/data/texas/2026/290m-north-texas-data-center-leads-week-in-construction/","label":"The Real Deal, 28 September 2026"}],"parties":[{"role":"Entity","name":"QTS Data Centers"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"9b341e7097d64221","state":"TX","tracker":"atlas","section":"sites","title":"QTS data center campus on Lancium Clean Campus (near Turkey)","summary":"QTS and Lancium announced a data center campus in unincorporated Hall County about five miles south of Turkey, with QTS designing, building and operating the buildings on Lancium land under an agreement with the county. The companies project up to 7,000 construction jobs at peak and 350 permanent jobs, closed-loop cooling with water from onsite wells or external sources rather than the Turkey system. Nexstar reported the project as a $10 billion, 465-acre, 11-building campus breaking ground in September 2026 Lancium to provide electrical and civil infrastructure with its own power from battery storage and solar; companies fund 100% of energy infrastructure improvements More than $10 billion in capital investment per the companies; separately QTS announced $250 million for water infrastructure, conservation and replenishment on 31 August 2026 465-acre, 11-building campus; MW not disclosed","scope":"Record-specific: Near Turkey","status":"announced","date":"Announced 15 to 17 July 2026; water commitment reported 1 September 2026","sources":[{"url":"https://www.newschannel10.com/2026/07/17/hall-county-set-receive-data-center-near-turkey/","label":"KFDA NewsChannel 10"},{"url":"https://www.msn.com/en-us/urban-infrastructure/water-supply-and-sanitation/new-water-tower-could-be-a-win-win-for-rural-texas-town-and-data-center-company/ar-AA2bnPpq","label":"KLBK (Nexstar) via MSN"}],"parties":[{"role":"Entity","name":"QTS Data Centers"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"f2806027e52b234f","state":"TX","tracker":"atlas","section":"at_risk","title":"RCM Hill project","summary":"County adopted then rescinded a one-year rural ban after the developer sued in federal court","scope":"Record-specific: Hill County","status":"other","date":"Suit May 27 2026; rescinded Jun 4 2026; dollar value n.a.","sources":[{"url":"https://www.interconnectedcapital.com/research/data-center-moratoriums","label":"Interconnected Capital"},{"url":"https://www.techradar.com/ai-platforms-assistants/usd130-billion-worth-of-ai-data-center-projects-were-cancelled-or-delayed-in-q1-2026-developers-sick-of-losing-are-fighting-back-and-are-already-finding-victory","label":"TechRadar"}],"parties":[{"role":"Developer","name":"RCM Hill LLC"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"b7809dfdc70d1cb9","state":"TX","tracker":"atlas","section":"sites","title":"RELLIS Data and Research Center","summary":"Brazos County commissioners voted 4-0, with one absent, to transfer the tax abatement agreement for the nearly complete RELLIS Campus data center to ThisWay Global, which emerged from the bankruptcy of the prior developer, RELLIS Campus Data and Research Center, LLC. KBTX reports the county receives 50% of taxable valuation for the first 10 years and 100% for the remaining 30 years of a 40-year agreement  At least $700 million per KBTX, up from an original $298 million estimate Not disclosed in the fetched coverage","scope":"Record-specific: Bryan","status":"under_construction","date":"County approval 18 August 2026; single-outlet report (KBTX)","sources":[{"url":"https://www.kbtx.com/2026/08/18/brazos-county-commissioners-approve-new-owner-rellis-data-center-heres-what-it-means-your-wallet/","label":"KBTX"},{"url":"https://www.kbtx.com/2026/08/18/brazos-county-could-vote-new-ownership-delayed-700-million-rellis-data-center/?outputType=amp","label":"KBTX"}],"parties":[{"role":"Entity","name":"ThisWay Global, Inc."}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"bc985ff09d7a73a6","state":"TX","tracker":"atlas","section":"sites","title":"Related Digital data center campus (adjacent to Project Star energy campus)","summary":"In a joint statement of 30 September 2026, NextEra Energy Resources, Related Companies and Lewis Energy Group said the Project Star energy campus in Encinal is expected, at full scale, to power a privately funded 5 GW data center campus that Related Digital is developing on an adjacent site. The companies said the adjacent data center is expected to create hundreds of permanent jobs. No tenant, data center cost or construction schedule was given in the fetched source. Project Star, a 6.47 GW natural gas energy campus on the adjacent site (initial generation as early as 2029, subject to permitting); excess electricity to the Texas grid; Lewis Energy Group to supply land, produced water and natural gas No data center capital figure disclosed; described as privately funded. The adjacent Project Star energy campus is more than $22 billion and is recorded separately as a deal, not as site capital 5 GW data center campus at full scale, per the developers' joint statement; served by the 6.47 GW Project Star gas generation campus","scope":"Record-specific: Encinal","status":"announced","date":"Announced in the developers' joint statement of 30 September 2026; reported 2 October 2026 (single trade outlet for the data center details)","sources":[{"url":"https://dailyenergyinsider.com/news/53979-nextera-selected-to-develop-22b-texas-energy-campus-to-power-data-center/","label":"Daily Energy Insider, 2 October 2026"}],"parties":[{"role":"Entity","name":"Related Digital"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"b3a96b464ba958cc","state":"TX","tracker":"atlas","section":"at_risk","title":"Rock Creek","summary":"Delayed","scope":"Record-specific: Fort Worth","status":"delayed","date":"2024-25","sources":[{"url":"https://www.datacenterwatch.org/report","label":"Data Center Watch"}],"parties":[],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"6c481194d388bee4","state":"TX","tracker":"atlas","section":"sites","title":"Rockdale AI/HPC campus (Milam County)","summary":"Bitdeer announced on 1 September 2026 the completed acquisition of approximately 200 acres of greenfield property in Milam County, Texas for approximately $100 million in cash, adjacent to its existing Rockdale data center on land formerly part of an Alcoa aluminum smelting plant. The company states that following the transaction it owns or operates approximately 255 acres and 742 MW of existing and pipeline power capacity in Milam County. Approximately 563 MW interconnected, scaling to a stated 742 MW of existing and pipeline capacity, plus a dedicated water supply No total project cost disclosed; $100 million paid in cash for the adjacent 200-acre parcel Approximately 563 MW of interconnected grid capacity today, with existing plans expected to scale to 742 MW","scope":"Record-specific: Rockdale","status":"expansion","date":"Acquisition announced 1 September 2026","sources":[{"url":"https://www.globenewswire.com/news-release/2026/09/01/3354593/0/en/bitdeer-announces-acquisition-of-200-acres-near-rockdale-facility-in-milam-county-texas-to-support-ai-hpc-infrastructure-development.html","label":"Bitdeer press release (GlobeNewswire)"},{"url":"https://www.datacenterdynamics.com/en/news/bitdeer-buys-200-acres-in-milam-county-texas-to-expand-ai-and-hpc-data-center/","label":"DCD"}],"parties":[{"role":"Entity","name":"bitdeer"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"0b7072e5ba8747b2","state":"TX","tracker":"atlas","section":"sites","title":"Rockdale campus AI data center","summary":"Riot's existing Rockdale bitcoin mining campus, where a 20-year lease with a frontier AI lab was signed after 30 June 2026  Riot presented an illustrative capex range of $11.0 million to $12.0 million per IT MW; no total disclosed 191 MW critical IT under lease; 96 MW by December 2027 and full 191 MW by June 2028","scope":"Record-specific: Rockdale","status":"announced","date":"Lease announced 10 August 2026","sources":[{"url":"https://www.riotplatforms.com/riot-platforms-reports-second-quarter-2026-financial-results-and-strategic-highlights/","label":"Riot Platforms"},{"url":"https://www.sec.gov/Archives/edgar/data/1167419/000110465926097330/riot-20260810x8k.htm","label":"SEC EDGAR (Riot Platforms 8-K)"},{"url":"https://www.stocktitan.net/sec-filings/RIOT/8-k-riot-platforms-inc-reports-material-event-55bed99b80cf.html","label":"Stock Titan (Riot 8-K)"}],"parties":[{"role":"Entity","name":"Riot Platforms"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"238328933f75292a","state":"TX","tracker":"atlas","section":"sites","title":"SAT 82, Castroville","summary":"A Castroville building, SAT 82, carries an estimated cost of $400m, with work set to begin in mid-August 2026 and an aimed completion of June 2028.  an estimated cost of $400m","scope":"Record-specific: Castroville","status":"announced","date":"Work set to begin mid-August 2026; aimed completion June 2028","sources":[{"url":"https://www.datacenterdynamics.com/en/news/microsoft-plans-400m-data-center-in-castroville-texas/","label":"DCD"}],"parties":[{"role":"Entity","name":"microsoft"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"a0323ad02a6d58e6","state":"TX","tracker":"atlas","section":"sites","title":"SAT16","summary":"Microsoft has SAT16 in the San Antonio corridor at an expected $215 million.  expected $215 million","scope":"Record-specific: San Antonio","status":"announced","date":null,"sources":[{"url":"https://www.datacenterdynamics.com/en/news/microsoft-files-to-build-two-more-data-centers-in-san-antonio-texas/","label":"DCD"}],"parties":[{"role":"Entity","name":"microsoft"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"eec499589760b7af","state":"TX","tracker":"atlas","section":"sites","title":"SAT93 and SAT94, San Antonio/Medina County","summary":"Microsoft filed for SAT93 and SAT94, two 245,000 sq ft buildings at $350 million each in the San Antonio/Medina County corridor, with construction from May 2025 to June 2027.  $350 million each ($700M combined)","scope":"Record-specific: San Antonio","status":"construction","date":"Construction May 2025 to June 2027","sources":[{"url":"https://www.datacenterdynamics.com/en/news/microsoft-files-to-build-two-more-data-centers-in-san-antonio-texas/","label":"DCD"}],"parties":[{"role":"Entity","name":"microsoft"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"9c187563e5b3a82c","state":"TX","tracker":"atlas","section":"at_risk","title":"San Marcos citywide data center zoning ban","summary":"On 16 June 2026 the San Marcos City Council voted 4-3 to adopt a zoning ordinance that defines data centers and makes them ineligible in every zoning district in the city. State Sen. Paul Bettencourt said he would challenge the ban as a violation of state law, including HB 2559. The city had earlier rejected the Highlander SM One LLC annexation request.","scope":"Record-specific: City of San Marcos","status":"moratorium","date":"Adopted 4-3 on 16 June 2026; reported 4 July 2026","sources":[{"url":"https://www.sanmarcosrecord.com/news/article_d675774f-f82d-4316-adb8-a4a2310e82eb.html","label":"San Marcos Daily Record"},{"url":"https://www.aol.com/articles/san-marcos-council-votes-prohibit-200127000.html","label":"KXAN via AOL"}],"parties":[],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"f43c0a82e5fee647","state":"TX","tracker":"atlas","section":"sites","title":"Scurry County campus (pipeline)","summary":"Named in SB Energy's Form S-1 filed 1 September 2026 as part of the near-term data center pipeline, where the company has secured land and is actively pursuing development and lease negotiations. Neither county site is currently included in the Data Center Contracted Portfolio or in the backlog calculation. Secured ERCOT interconnection per the registration statement No site capital figure disclosed. The site is not included in SB Energy's Data Center Contracted Portfolio, its backlog, or its backlog-associated capex. Borden County and Scurry County together represent approximately 1.7 GW-IT of near-term critical IT capacity in ERCOT with secured interconnection. The registration statement gives the combined figure only, so no per-site megawatt figure is recorded here.","scope":"Record-specific:","status":"announced","date":"Disclosed in the Form S-1 filed 1 September 2026","sources":[{"url":"https://www.sec.gov/Archives/edgar/data/2133037/000162828026059639/sbenergy-sx1.htm","label":"SEC Form S-1 (SB Energy, Inc.)"}],"parties":[{"role":"Entity","name":"sb-energy"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"91ce8c015ce591ce","state":"TX","tracker":"atlas","section":"sites","title":"Shackelford County Stargate AI Campus","summary":"One of the campuses identified in coverage of the September 2025 five-site expansion, the Shackelford County, Texas site was later designated an official Stargate AI Campus.","scope":"Record-specific:","status":"announced","date":"five new sites announced September 2025","sources":[{"url":"https://www.foxbusiness.com/economy/openai-announces-five-new-stargate-data-center-locations-multiple-states-ai-project","label":"Fox Business"},{"url":"https://www.thealbanynews.net/news/shackelford-data-center-named-official-stargate-ai-campus","label":"The Albany News"}],"parties":[{"role":"Entity","name":"openai-stargate"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"50e92c1d51741727","state":"TX","tracker":"atlas","section":"sites","title":"Skybox Hutto data center campus (3399 County Road 132)","summary":"Hutto Data Center Campus, LLC registered Skybox Hutto 4 with the Texas Department of Licensing and Regulation on 30 September 2026 (TABS2027002367): site improvements and a new one-story core and shell building of about 844,300 sq ft for future data center use, plus a 20,000 sq ft office, at 3399 County Road 132, Hutto, estimated at $550 million, with construction scheduled from 20 January 2027 to 30 October 2028. TDLR shows earlier Skybox Hutto registrations for Building 1 (core, initial improvements and fit-out, $398 million combined, 2023 to 2024), Building 2 (core and shell and fit-out, $673.3 million combined, 2024 to 2025) and Building 3 core and shell ($283.0 million, 2024). No tenant is assigned in the filing. On 1 October 2026 the Hutto City Council approved Skybox's request to rezone a 140-acre parcel in the Hutto Megasite for a data center and power station, with stipulations requiring closed-loop cooling, compliance with Hutto land development codes and payment of local sales taxes on construction and power generation. Skybox Chief Development Officer Haynes Strader told the council there is no tenant yet, that securing power from ERCOT has become more challenging and may take another two years, and that the next phase would be the fifth and sixth data centers in the Megasite. Skybox's agreement with the Hutto Economic Development Corp. expires in February 2027.  $550 million TDLR estimated cost for Building 4 core and shell (registered 30 September 2026). Earlier TDLR registrations for Buildings 1 to 3 (core, shell and fit-out, 2023 to 2025) list a further $1,354.3 million; they cover separate scopes and are not included in capital_usd_m Not disclosed; Building 4 is a one-story data center of about 844,300 sq ft with a 20,000 sq ft office","scope":"Record-specific: Hutto","status":"under_construction","date":"Building 4 registered with TDLR 30 September 2026; 140-acre Megasite rezoning approved by Hutto City Council 1 October 2026 (single outlet, Taylor Press)","sources":[{"url":"https://www.tdlr.texas.gov/TABS/Search/Project/TABS2027002367","label":"TDLR TABS Skybox Hutto 4 (TABS2027002367)"},{"url":"https://www.tdlr.texas.gov/TABS/Search/Project/TABS2024018308","label":"TDLR TABS Skybox Hutto 3 core shell (TABS2024018308)"},{"url":"https://www.tdlr.texas.gov/TABS/Search/Project/TABS2026001377","label":"TDLR TABS Skybox Hutto 2 fit up (TABS2026001377)"},{"url":"https://www.taylorpress.net/article/12411,skybox-seeks-rezoning-for-hutto-megasite","label":"Taylor Press, 2 October 2026"}],"parties":[{"role":"Entity","name":"Skybox Datacenters"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"fec523e0d3b8dbbf","state":"TX","tracker":"atlas","section":"sites","title":"Snyder AI Campus","summary":"Energy Vault began construction of its powered AI infrastructure campus in Snyder for Crusoe Cloud using Crusoe Spark modular data centers. Commercial operation of the initial 8 MW was targeted for Q1 2027 at groundbreaking and was stated as the first half of 2027 in Energy Vault's Q2 2026 results Powered land with battery energy storage and N+1 redundancy Not disclosed Initial 8 MW of powered shell for Crusoe Cloud, expandable to 25 MW in a second phase; site planned for up to 500 MW","scope":"Record-specific: Snyder","status":"under construction","date":"Construction start announced 27 July 2026","sources":[{"url":"https://markets.ft.com/data/announce/detail?dockey=600-202607270900BIZWIRE_USPRX____20260727_BW272502-1","label":"Energy Vault (Business Wire via FT Markets)"},{"url":"https://www.sec.gov/Archives/edgar/data/1828536/000182853626000100/ex991_evpressreleasex2026q2.htm","label":"SEC Form 8-K (Energy Vault), Ex. 99.1"}],"parties":[{"role":"Entity","name":"Energy Vault"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"c62ca0bf4e8fad55","state":"TX","tracker":"atlas","section":"sites","title":"Stargate Abilene","summary":"Flagship Stargate campus of 1.2 GW across eight buildings and roughly 4 million square feet, with the first two buildings live in September 2025 carrying over 200MW of IT. The planned expansion from a 2 GW ambition was cancelled, leaving the built 1.2 GW, with OpenAI preferring to deploy Vera Rubin silicon at a new campus and Meta in talks to pick up Crusoe capacity. power unavailable 'for a year' cited as reason the 2 GW expansion was dropped  1.2 GW / eight buildings / ~4 million sq ft; first two buildings live September 2025 with 200MW+ of IT","scope":"Record-specific: Abilene","status":"operating","date":"first two buildings live September 2025; expansion cancellation reported 2026","sources":[{"url":"https://www.crusoe.ai/resources/newsroom/crusoe-announces-flagship-abilene-data-center-is-live","label":"Crusoe"},{"url":"https://www.datacenterdynamics.com/en/news/crusoe-tops-out-final-building-at-openai-stargate-data-center-campus-in-abilene-texas/","label":"DCD"},{"url":"https://www.datacenterdynamics.com/en/news/oracleopenai-drop-plans-to-expand-flagship-abilene-stargate-site-meta-in-talks-to-pick-up-crusoe-capacity-with-nvidias-help/","label":"DCD"}],"parties":[{"role":"Entity","name":"openai-stargate"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"b304894b05b4f1fb","state":"TX","tracker":"atlas","section":"sites","title":"Stargate flagship campus, Abilene (Crusoe/Lancium Clean Campus)","summary":"Crusoe announced the first phase of Stargate's flagship campus in Abilene up and running on Oracle Cloud Infrastructure on 30 September 2025; construction of the multi-building campus began in June 2024 and Oracle began delivering the first NVIDIA GB200 racks in June 2025. At completion the planned eight-building campus will support hundreds of thousands of GPUs on a single integrated network fabric. Oracle and OpenAI later dropped plans to expand the site to 2 GW, with power not ready for a year and OpenAI preferring to deploy Nvidia Vera Rubin chips at a new campus; Meta is in talks to pick up Crusoe capacity.  n.a. (site developed by Crusoe and leased to Oracle and OpenAI; no site capex figure disclosed) First two buildings span 980,000 sq ft and support 200MW+ of IT; phase two adds six more buildings to approximately 4 million sq ft and a total power capacity of 1.2 GW, expected complete mid-2026; planned expansion to 2 GW was dropped (implied ~0.8 GW cancelled/deferred)","scope":"Record-specific: Abilene","status":"operating","date":"Construction began June 2024; first phase live 30 September 2025; phase two expected complete mid-2026; 2 GW expansion dropped","sources":[{"url":"https://www.crusoe.ai/resources/newsroom/crusoe-announces-flagship-abilene-data-center-is-live","label":"Crusoe"},{"url":"https://www.datacenterdynamics.com/en/news/crusoe-tops-out-final-building-at-openai-stargate-data-center-campus-in-abilene-texas/","label":"DCD"},{"url":"https://www.oracle.com/data-centers/abilene/","label":"Abilene data center page"},{"url":"https://www.datacenterdynamics.com/en/news/oracleopenai-drop-plans-to-expand-flagship-abilene-stargate-site-meta-in-talks-to-pick-up-crusoe-capacity-with-nvidias-help/","label":"DCD"}],"parties":[{"role":"Entity","name":"oracle"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"e745901226a02eaf","state":"TX","tracker":"atlas","section":"sites","title":"Stargate site, Shackelford (announced)","summary":"Listed in the summary table among the 7+ announced US Stargate sites. No site-level dollar or MW figure appears in this part.  n.a. (listed among announced US Stargate sites in the summary table)","scope":"Record-specific:","status":"announced","date":null,"sources":[{"url":"https://openai.com/index/expanding-stargate-to-michigan/","label":"OpenAI Oct 2025"},{"url":"https://openai.com/index/announcing-the-stargate-project/","label":"OpenAI Jan 2025"}],"parties":[{"role":"Entity","name":"openai-stargate"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"cf249b6b3a1b6fc8","state":"TX","tracker":"atlas","section":"sites","title":"Stream Data Centers Graham site (former Plug Power Limestone project)","summary":"Stream agreed to buy the 66-acre former green hydrogen site west of Graham. Stream had not commented on its plans for the site as of the DCD report 164 MW of grid interconnection assets transferred from Plug Power Land and interconnection purchase up to $76.5 million; development capex not disclosed 164 MW grid interconnection reference capacity in the purchase agreement","scope":"Record-specific: Graham","status":"announced","date":"Purchase agreement signed 9 July 2026","sources":[{"url":"https://www.sec.gov/Archives/edgar/data/1093691/000110465926082854/tm2620282d1_8k.htm","label":"SEC Form 8-K (Plug Power)"},{"url":"https://www.datacenterdynamics.com/en/news/plug-power-sells-texas-site-to-stream-data-centers/","label":"Data Center Dynamics"}],"parties":[{"role":"Entity","name":"Stream Data Centers"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"480e45b58ecbe2c0","state":"TX","tracker":"atlas","section":"at_risk","title":"Sulphur Springs Thermo mine data center campus","summary":"The City of Sulphur Springs sued Vistra to remove a deed restriction barring power generation on former Luminant mine land where it planned a large data center campus with MSB Global; Vistra countersued, and a resident separately sued the city under the Open Meetings Act over its developer agreements. On 2 June 2026 the mayor said MSB Global would be phased out, and the council re-adopted the letter of intent and Chapter 380 agreement to address the open-meetings claims. On 7 July 2026 Judge Dan Moore heard Vistra's Rule 91a motion to dismiss six of the city's 11 counts; the September 2026 trial date was vacated and trial is likely in 2027. CyrusOne held a community meeting on 24 September 2026 about a potential self-powered, natural gas campus on the site and said the project is not a done deal.","scope":"Record-specific: City of Sulphur Springs; Hopkins County district court","status":"litigation","date":"Land conveyed 2019; lawsuits pending through 2026; developer change announced 2 June 2026; dismissal hearing 7 July 2026; CyrusOne community meeting 24 September 2026; trial likely 2027","sources":[{"url":"https://www.kltv.com/2026/07/07/vistra-seeks-dismissal-key-claims-sulphur-springs-legal-fight-over-data-center-site/","label":"KLTV, 7 July 2026"},{"url":"https://www.kltv.com/2026/06/03/new-developer-take-over-data-center-project-sulphur-springs-amid-legal-battles/","label":"KLTV, 3 June 2026"},{"url":"https://www.kltv.com/2026/09/25/data-center-developer-holds-community-meeting-potential-sulphur-springs-project/","label":"KLTV, 25 September 2026"},{"url":"https://www.kltv.com/2026/02/10/judge-denies-major-motion-city-sulphur-springs-data-center-lawsuits/","label":"KLTV"}],"parties":[{"role":"Developer","name":"City of Sulphur Springs with MSB Global (phased out June 2026); CyrusOne evaluating the site"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"8560e392eca535fb","state":"TX","tracker":"atlas","section":"sites","title":"Sweetwater Hub (Sweetwater 1 and 2)","summary":"IREN said the 2 GW Sweetwater Hub was conditionally classified as Base Load in ERCOT Batch Zero. Delivery of the first 300 MW gross at Sweetwater 1 is targeted for Q4 2027 IREN high-voltage substation at Sweetwater 1 energized in 2026; hub conditionally included in ERCOT Batch Zero as Base Load Not disclosed 2 GW hub: Sweetwater 1 at 1,400 MW and Sweetwater 2 at 600 MW; 300 MW gross of data center capacity under construction at Sweetwater 1","scope":"Record-specific: Sweetwater","status":"under construction","date":"ERCOT classification announced 8 September 2026","sources":[{"url":"https://markets.businessinsider.com/news/stocks/iren-s-2gw-sweetwater-hub-included-as-base-load-in-ercot-batch-zero-1036528001","label":"IREN (GlobeNewswire via Markets Insider)"},{"url":"https://iren.com/data-centers/sweetwater","label":"IREN (company site)"},{"url":"https://finance.yahoo.com/technology/ai/articles/iren-building-ai-power-footprint-124749661.html","label":"Stocktwits via Yahoo Finance"}],"parties":[{"role":"Entity","name":"IREN"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"d4cb133b97df6f01","state":"TX","tracker":"atlas","section":"sites","title":"Taylor Technology Campus (formerly Project Mustang), between FM 112 and U.S. 79","summary":"South Dakota-based Big Watt Digital LLC and Virginia-based PowerHouse Data Centers plan a data center campus with on-site gas generation on about 665 acres just east of Taylor. The City of Taylor announced the proposal and a negotiated voluntary annexation in early August 2026; after resident opposition and a 1,400-signature petition the developers withdrew the annexation and zoning application in early September 2026 and said the project would proceed in unincorporated Williamson County, where the city has no authority. On 2 October 2026 the city said it had reached a proposed agreement to annex the site, renamed Taylor Technology Campus, with standards on noise, water use, setbacks and community benefits; the City Council is set to vote on 8 October 2026. No incentives are offered. On-site 477 MW gas-fired generation; closed-loop cooling with reclaimed water under the proposed city agreement Not disclosed Data center load not disclosed; the proposal includes a 477 MW gas-fired on-site generating plant and at least two data centers on about 664 to 665 acres","scope":"Record-specific: Taylor (unincorporated, east of city limits)","status":"proposed","date":"Announced August 2026; annexation request withdrawn early September 2026; proposed annexation agreement announced 2 October 2026; council vote set for 8 October 2026","sources":[{"url":"https://www.kut.org/energy-environment/2026-10-02/taylor-annexing-data-center-development","label":"KUT News, 2 October 2026"},{"url":"https://www.statesman.com/business/technology/article/taylor-data-center-project-mustang-annexation-22416658.php","label":"Austin American-Statesman, 6 September 2026"},{"url":"https://austinfreepress.org/corralling-mustang/","label":"Austin Free Press, 7 August 2026"}],"parties":[{"role":"Entity","name":"Big Watt Digital LLC and PowerHouse Data Centers"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"c4ea7c0ba8a53f60","state":"TX","tracker":"atlas","section":"sites","title":"Temple Data Center TTX03 (2230 Eberhardt Road)","summary":"Polmer LLC registered a new single-story 145,177 sq ft data center building, facility TTX03, at 2230 Eberhardt Road in Temple, Texas, with the Texas Department of Licensing and Regulation (TABS2026008019), at an estimated cost of $197 million, with construction scheduled to start 15 December 2025 and finish at the end of the third quarter of 2026. The Eberhardt Road corridor in northwest Temple also hosts Meta's Temple campus and Oppidan's Connect Temple facility. The end user is not identified in the filing.  $197 million TDLR estimated cost Not disclosed; single-story 145,177 sq ft data center building","scope":"Record-specific: Temple","status":"under_construction","date":"Backfill (not previously recorded). Registered with TDLR 15 December 2025; single source (TDLR filing)","sources":[{"url":"https://www.tdlr.texas.gov/TABS/Search/Project/TABS2026008019","label":"TDLR TABS (TABS2026008019)"}],"parties":[{"role":"Entity","name":"Polmer LLC"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"461d6c1e3b5834c3","state":"TX","tracker":"atlas","section":"sites","title":"Texas Critical Data Centers (TCDC)","summary":"New Era announced on 14 August 2026 that construction permits for Texas Critical Data Centers are in hand, including development structure and drive approach permits from Ector County, TCEQ approval of a notice of intent to begin grading, and a Phase 1 plat submitted to Ector County and the City of Odessa. The company closed a 54-acre corridor acquisition bringing the campus to 493 acres and is in advanced negotiations for a Phase 1 power purchase agreement. On 18 September 2026 New Era contracted Phase 1 power for Texas Critical Data Centers under a 20 year agreement with Luminant, a Vistra affiliate, for 200 MW to 207 MW from Vistra's adjacent 1,180 MW gas fired plant in Odessa, expected to be available in the third quarter of 2027, with Vistra to receive a 5 percent non voting interest in the powered portion of the project after deliveries begin. Phase 1: 20-year PPA with Luminant (Vistra) for 200 to 207 MW from Vistra's adjacent 1,180 MW Odessa gas plant, expected in the third quarter of 2027; Phase 2 standard air permit application filed with TCEQ by a Thunderhead subsidiary Investment not disclosed; company reports $270 million undrawn under an up to $290 million Macquarie facility About 757 MW gross for Phases 1 and 2 combined, with Phase 2 power expected at about 550 MW; 493-acre site anticipated to scale to 1.4 GW","scope":"Record-specific: Near Odessa","status":"construction permits received","date":"Announced 14 August 2026 (company release); Phase 1 PPA signed 18 September 2026 (Form 8-K)","sources":[{"url":"https://finance.yahoo.com/energy/articles/era-energy-digital-files-q2-203100563.html","label":"New Era Energy & Digital (GlobeNewswire via Yahoo Finance)"},{"url":"https://www.sec.gov/Archives/edgar/data/2028336/000121390026101642/ea0305716-8k_newera.htm","label":"New Era Form 8-K (SEC)"},{"url":"https://www.sec.gov/Archives/edgar/data/2028336/000121390026101642/ea030571601ex99-1.htm","label":"New Era release, Exhibit 99.1 (SEC)"}],"parties":[{"role":"Entity","name":"New Era Energy & Digital"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"bfb597e063e27377","state":"TX","tracker":"atlas","section":"sites","title":"Texas Research Park plan","summary":"Microsoft owns 158 acres in Texas Research Park where it plans to spend $1 billion on one million square feet.  $1 billion planned on one million square feet","scope":"Record-specific: San Antonio","status":"announced","date":null,"sources":[{"url":"https://www.datacenterdynamics.com/en/news/microsoft-files-to-build-two-more-data-centers-in-san-antonio-texas/","label":"DCD"}],"parties":[{"role":"Entity","name":"microsoft"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"7cbd49b38e0b69a4","state":"TX","tracker":"atlas","section":"sites","title":"Texas data center tied to OpenAI's Stargate","summary":"Newmark advised on a $2.3B loan financing a Texas data center tied to OpenAI's Stargate. The source does not name the specific city or capacity; status not stated in the source.  $2.3B loan","scope":"Record-specific:","status":"Not recorded","date":"reported alongside Newmark's 2024 deal closings","sources":[{"url":"https://www.bisnow.com/national/news/capital-markets/newmark-projects-40-growth-by-2026-predicting-data-center-boom-will-lead-to-more-industrial-strength-128057","label":"Bisnow"}],"parties":[{"role":"Entity","name":"newmark"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"7da2c459a39d40a0","state":"TX","tracker":"atlas","section":"at_risk","title":"Texas enforcement directive on data center water-use reporting","summary":"Gov. Greg Abbott announced on 14 September 2026 that he directed the Texas Water Development Board to use its enforcement authority against data centers that fail to complete the state's mandatory water use survey, both for past failures and future noncompliance. Existing law makes failure to respond a Class C misdemeanor, and the directive includes referring violations to county or district attorneys. Response rates were 32% of 22 surveyed data centers in 2023, 28% of 67 in 2024 and about 30% of 329 in 2025. Abbott asked the board for a compliance and enforcement update by 14 October 2026.","scope":"Record-specific: State of Texas","status":"other","date":"Directive announced 14 September 2026; update due 14 October 2026","sources":[{"url":"https://www.texastribune.org/2026/09/14/texas-data-centers-abbott-water-survey-enforcement/","label":"Texas Tribune"},{"url":"https://texasstandard.org/stories/gov-greg-abbott-orders-texas-water-agency-to-penalize-data-centers-that-dont-report-their-water-usage/","label":"Texas Standard"}],"parties":[],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"98b1278060ff373e","state":"TX","tracker":"atlas","section":"sites","title":"Texas program (Armstrong County, Haskell County, Midlothian)","summary":"Google announced a new $40 billion investment in Texas through 2027, naming Armstrong County, Haskell County and Midlothian. DCD adds that how much of the $40bn will go toward the Ellis County campuses has not been stated, and that Ellis County had a separate $1bn expansion plan from August 2024. GN DC1 LLC registered Llano Building 3 (23 July 2026) and Llano Building 4 (24 July 2026) at 10001 Lima Road, Claude, Armstrong County, with the Texas Department of Licensing and Regulation: each an approximately 805,380 sq ft single-story data center with an estimated cost of $500 million. On 28 September 2026 Crusoe announced it is the developer of Google's data center campus under construction in Armstrong County near Amarillo, which broke ground in June 2025 and has more than 5,500 workers on site daily. The campus connects directly to Serena's adjacent Goodnight 1 (265.5 MW, operating) and Goodnight 2 (265.5 MW, under construction) wind farms, with surplus generation going to the grid, and uses closed-loop non-evaporative liquid cooling. Crusoe did not disclose the campus's power demand, cost or opening date. More than 6,200 MW of new energy generation and capacity contracted through PPAs a new $40 billion investment through 2027 More than 6,200 megawatts of new energy generation and capacity contracted to date through power purchase agreements","scope":"Record-specific:","status":"announced","date":"Through 2027","sources":[{"url":"https://blog.google/company-news/inside-google/company-announcements/google-american-innovation-texas/","label":"Google"},{"url":"https://www.datacenterdynamics.com/en/news/google-commits-40bn-to-expand-cloud-and-ai-infrastructure-in-texas-through-2027/","label":"DCD"},{"url":"https://www.tdlr.texas.gov/TABS/Search/Project/TABS2026026002","label":"TDLR TABS project TABS2026026002"},{"url":"https://www.tdlr.texas.gov/TABS/Search/Project/TABS2026026118","label":"TDLR TABS project TABS2026026118"},{"url":"https://www.crusoe.ai/resources/newsroom/crusoe-developing-data-center-campus-in-armstrong-county-texas","label":"Crusoe newsroom, 28 September 2026"},{"url":"https://theminermag.com/news/2026-09-29/crusoe-google-texas-ai-armstrong","label":"TheEnergyMag, 29 September 2026"}],"parties":[{"role":"Entity","name":"alphabet"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"3957fc1e45baa0fe","state":"TX","tracker":"atlas","section":"at_risk","title":"Texas statewide halt on TCEQ permits for data centers pending ERCOT and TWDB audits","summary":"On 21 September 2026 Gov. Greg Abbott directed the Texas Commission on Environmental Quality to halt all permits sought by data centers until ERCOT completes its audit, in a letter to TCEQ Executive Director Kelly Keel. The governor's release says that because the PUCT, ERCOT and the Texas Water Development Board need the audit information to make informed decisions, no state agency shall move forward with regulatory approvals related to data center development until it is acquired. TCEQ must report on its compliance by Monday 19 October 2026. The directive follows the 3 August 2026 order for the PUCT and ERCOT to audit all data centers in ERCOT's interconnection process and the 14 September 2026 water-use reporting directive to the TWDB. Houston Public Media reported that the August pause reached only ERCOT connections of at least 75 MW, while TCEQ permits for river water use or on-site power plants now also stop, and that ERCOT and the TWDB are surveying more than 400 data centers for the audit. The governor also said he will work with the Legislature next session to eliminate financial incentives for data centers. The San Antonio Current reported on 29 September 2026 that Samuel Short, director of TCEQ's Air Permits Division, wrote in an email to Bastrop County residents that, at the direction of Governor Abbott, TCEQ has paused the issuance of all air and water permits and authorizations related to the construction or development of infrastructure directly supporting data centers while ERCOT completes its audit, that the Pacifico Energy campus near Cedar Creek (row 823) is on hold, and that TCEQ will give the Governor's Office a full compliance update by 19 October 2026. Public Citizen's Texas office told the outlet that TCEQ has previously said it lacks authority to halt all permits for an entire industry. At a stop in Hemphill reported on 29 September 2026, Abbott said new data centers must provide their own power and that local communities should have authority to decide whether to allow them; KTRE reported that state permits for two proposed Angelina County projects, AmpZ and Hyper Data Grid, remain on hold.","scope":"Record-specific: State of Texas (Office of the Governor; Texas Commission on Environmental Quality)","status":"paused","date":"Directive issued 21 September 2026; TCEQ compliance update due 19 October 2026; runs until the ERCOT and TWDB audits are complete","sources":[{"url":"https://gov.texas.gov/news/post/governor-abbott-directs-tceq-to-halt-data-center-permits","label":"Office of the Texas Governor"},{"url":"https://www.keranews.org/texas-news/2026-09-22/gov-abbott-orders-tceq-to-pause-environmental-permits-for-data-centers-until-audit-is-complete","label":"Houston Public Media via KERA News"},{"url":"https://www.sacurrent.com/news/abbott-orders-pause-of-air-permits-for-data-centers-experts-question-whether-he-has-the-authority/","label":"San Antonio Current"},{"url":"https://www.msn.com/en-us/money/general/abbott-says-data-center-permits-frozen-until-power-water-concerns-addressed/ar-AA2ddQH2","label":"KTRE via KLTV (MSN)"}],"parties":[{"role":"Developer","name":"n.a."}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"4fcc2be6fbcaf275","state":"TX","tracker":"atlas","section":"sites","title":"Tract Caldwell County technology park","summary":"Tract closed the acquisition of 1,515 acres in Caldwell County, Texas for a multi-gigawatt data center technology park at 2 GW.   1,515 acres / 2 GW","scope":"Record-specific:","status":"announced","date":null,"sources":[{"url":"https://tractcapital.com/news/tract-closes-acquisition-of-1515-acres-in-caldwell-county-texas-for-multi-gigawatt-data-center-technology-park/","label":"Tract Capital"}],"parties":[{"role":"Entity","name":"tract"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"ea294bf18c62cc30","state":"TX","tracker":"atlas","section":"sites","title":"US Army hyperscale program at Fort Bliss (Carlyle)","summary":"Carlyle is developing on approximately 1,384 acres at Fort Bliss, El Paso, Texas, with initial operating capability in FY2027 and a stated path to 3GW by 2029. Water and electricity use has drawn local scrutiny; no formal pause disclosed.  n.a. stated path to 3GW by 2029; approximately 1,384 acres","scope":"Record-specific: El Paso","status":"announced","date":"initial operating capability FY2027; 3GW by 2029","sources":[{"url":"https://www.army.mil/article/291360/army_reaches_conditional_agreement_with_private_industry_for_hyperscaled_data_centers","label":"U.S. Army"},{"url":"https://elpasomatters.org/2026/04/30/fort-bliss-data-center-water-electricity-use-army-carlyle-group-meta-project-jupiter/","label":"El Paso Matters"},{"url":"https://www.datacenterdynamics.com/en/news/us-army-taps-carlyle-and-cyrusone-to-develop-data-centers-on-army-owned-land/","label":"DCD"}],"parties":[{"role":"Entity","name":"carlyle"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"897ea95c990edf9c","state":"TX","tracker":"atlas","section":"sites","title":"Vantage Frontier mega-campus","summary":"Vantage announced Frontier on August 19, 2025: over $25 billion, 1,200 acres in Shackelford County, Texas, 10 data centers, 3.7 million square feet, 1.4GW and 250kW+ rack density, with the first building delivered in 2H 2026.  over $25 billion 1.4GW, 10 data centers, 3.7 million square feet, 250kW+ rack density on 1,200 acres","scope":"Record-specific:","status":"announced","date":"announced Aug. 19, 2025; first building delivered in 2H 2026","sources":[{"url":"https://vantage-dc.com/news/vantage-data-centers-unveils-plans-for-frontier-a-25b-mega-campus-in-texas-to-meet-unprecedented-ai-demand/","label":"Vantage"}],"parties":[{"role":"Entity","name":"digitalbridge"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"f057f71daa9078a3","state":"TX","tracker":"atlas","section":"at_risk","title":"Vantage Westover Hills data center campuses (Rogers Road and Omicron Drive) and VoltaGrid on-site gas plants","summary":"On Monday 21 September 2026 the Environmental Integrity Project, the Sierra Club and Public Citizen filed a federal Clean Air Act lawsuit in San Antonio against Vantage and VoltaGrid over two Vantage data center campuses and the co-located gas-fueled power plants VoltaGrid built and manages. The groups allege the facilities should have obtained major source permits, with best available control technology, monitoring and public participation, before construction, instead of minor source permits, in an area that fails federal smog standards. The groups sent a notice of intent to sue in July 2026. The Rogers Road facility was partly operational before the first public hearing. The case is Public Citizen, Inc. and Sierra Club, Inc. v. Vantage Data Centers Management Company, LLC, Vantage Data Centers TX11, LLC, Vantage Data Centers TX21, LLC and VoltaGrid LLC, No. 5:26-cv-06032 in the U.S. District Court for the Western District of Texas, San Antonio Division (Judge Jason K. Pulliam, referred to Magistrate Judge Elizabeth S. Chestney), filed under the Clean Air Act citizen suit provision. With the complaint the plaintiffs filed a motion for a preliminary injunction. On 29 September 2026 the Vantage entities and VoltaGrid each filed opposed motions for more time to respond to the preliminary injunction motion, and Vantage also sought more time to answer the complaint; answers had been due 14 and 15 October 2026. The TX11 entity named in the suit is a San Antonio registration, not the Vantage Frontier campus in Shackelford County.","scope":"Record-specific: Federal court in San Antonio","status":"litigation","date":"Suit and preliminary injunction motion filed 21 September 2026; defendants' opposed motions for extension of time filed 29 September 2026; notice of intent sent July 2026","sources":[{"url":"https://www.sacurrent.com/news/environmental-groups-sue-over-san-antonio-data-centers/","label":"San Antonio Current"},{"url":"https://www.courtlistener.com/docket/74825504/public-citizen-inc-v-vantage-data-centers-management-company-llc/","label":"CourtListener RECAP docket 5:26-cv-06032 (W.D. Tex.)"},{"url":"https://www.courtlistener.com/api/rest/v4/search/?q=docket_id%3A74825504&type=rd&order_by=entry_date_filed%20desc","label":"CourtListener search API"}],"parties":[{"role":"Developer","name":"Vantage Data Centers; VoltaGrid (power supplier)"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"a74dcb1693519e0b","state":"TX","tracker":"atlas","section":"sites","title":"Zone Frontier West Texas data center campus (Potter County)","summary":"A Zone Frontier subsidiary signed a long-term ground lease on about 4,077 acres in Potter County, Texas, securing land, water and development rights for the West Texas campus it is developing with HST Technologies. Zone may designate 200 to 800 acres for data center facilities. The company says it is now focused on tenants, permitting and interconnection studies. Surrounds Southwestern Public Service (Xcel Energy) Potter County 345 kV substation in SPP; at least 1,800 acres reserved for solar, battery storage and supporting infrastructure; near two natural gas pipelines No investment figure disclosed; company says it will evaluate co-investment equity and project finance as tenant talks progress Initial 200 MW of critical IT load targeted by early 2029 (Form 10-K), with potential to expand above 500 MW by 2030","scope":"Record-specific: Near Amarillo (Potter County substation)","status":"proposed","date":"Ground lease announced 29 September 2026 (company release); campus first announced 9 July 2026","sources":[{"url":"https://finance.yahoo.com/technology/ai/articles/zone-frontier-inc-signs-long-123000399.html","label":"Zone Frontier release (PR Newswire via Yahoo Finance)"},{"url":"https://w.media/zone-frontier-leases-land-for-up-to-500-mw-texas-data-center-campus/","label":"W.Media"},{"url":"https://www.sec.gov/Archives/edgar/data/1956741/000121390026104157/ea0306318-10k_zone.htm","label":"Zone Frontier Form 10-K (SEC)"},{"url":"https://www.prnewswire.com/news-releases/zone-frontier-inc-signs-long-term-ground-lease-with-purchase-option-for-more-than-4-000-acres-in-potter-county-texas-302892101.html","label":"Zone Frontier release (PR Newswire), 29 September 2026"}],"parties":[{"role":"Entity","name":"Zone Frontier Inc."}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"0a9ea35950d5a63c","state":"TX","tracker":"atlas","section":"at_risk","title":"Zydeco Development Hutto data center (450 Ed Schmidt Boulevard)","summary":"Zydeco Development formally withdrew its request to rezone the site and amend the future land use map ahead of a special Planning and Zoning Commission meeting set for 20 April 2026, which was canceled. City staff had recommended against approval on 7 April 2026, and residents were organizing a formal protest that would have required a three-fourths council vote. KUT reported the withdrawal effectively ends the project.","scope":"Record-specific: City of Hutto Planning and Zoning Commission","status":"withdrawn","date":"Withdrawn before the 20 April 2026 commission meeting (reported 20 April 2026)","sources":[{"url":"https://www.huttotx.gov/CivicAlerts.aspx?AID=424","label":"City of Hutto"},{"url":"https://www.kut.org/energy-environment/2026-04-20/hutto-tx-zydeco-data-center-rezoning-request","label":"KUT (20 April 2026)"},{"url":"https://communityimpact.com/austin/pflugerville-hutto/development/2026/04/09/hutto-residents-air-concerns-over-proposed-data-center/","label":"Community Impact (9 April 2026)"}],"parties":[{"role":"Developer","name":"Zydeco Development"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"410a4a1160155875","state":"TX","tracker":"atlas","section":"at_risk","title":"~1,800 projects in ERCOT interconnection","summary":"Gov. Abbott ordered PUCT and ERCOT to audit all data centers in the interconnection process before further approvals; non-compliant projects to be denied connection","scope":"Record-specific: statewide","status":"paused","date":"Aug 3 2026","sources":[{"url":"https://www.texastribune.org/2026/08/03/texas-data-center-project-audit-greg-abbott/","label":"Texas Tribune"},{"url":"https://www.troutman.com/insights/texas-hits-pause-on-data-center-grid-connections-amid-growing-oversight-push/","label":"Troutman Pepper"},{"url":"https://www.techradar.com/ai-platforms-assistants/usd130-billion-worth-of-ai-data-center-projects-were-cancelled-or-delayed-in-q1-2026-developers-sick-of-losing-are-fighting-back-and-are-already-finding-victory","label":"TechRadar"}],"parties":[{"role":"Developer","name":"multiple"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"ecc5b89ff5cb7890","state":"TX","tracker":"delay","section":"utility_actions","title":"AEP Texas","summary":"AEP Texas has a pending large-load tariff proposal addressing cost responsibility for new large loads. The utility has 36 GW of large loads that comply with Senate Bill 6 and are backed by letters of agreement.","scope":"Record-specific: TX","status":"pending","date":null,"sources":[{"url":"https://www.utilitydive.com/news/aep-large-load-data-center-earnings/812181/","label":"www.utilitydive.com"}],"parties":[{"role":"Named utility / authority","name":"AEP Texas"}],"groups":["utility:tariff:pending"],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"2389206912998d2d","state":"TX","tracker":"delay","section":"projects","title":"Amazon 7.65 GW Gas Plant / Self-Contained Island","summary":"35 turbines, 5 GW campus delivery, operates as self-contained energy island off ERCOT. Announced days AFTER moratorium ,  no delay impact.","scope":"Record-specific: TX","status":"delayed","date":null,"sources":[{"url":"https://cryptobriefing.com/amazon-natural-gas-power-plant-ai-data-center-texas/","label":"cryptobriefing.com"},{"url":"https://www.politico.com/newsletters/power-switch/2026/08/11/amazon-in-texas-its-all-about-the-gas-01034090","label":"www.politico.com"},{"url":"https://www.datacenterknowledge.com/energy-power-supply/amazon-explores-grid-connection-for-8-000-acre-ai-campus","label":"www.datacenterknowledge.com"}],"parties":[{"role":"Operator","name":"Amazon Web Services / partner"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"471523586fdcade7","state":"TX","tracker":"delay","section":"county_restrictions","title":"Archer County","summary":"The Archer County Commissioners Court passed two resolutions on Monday, September 28, 2026 against a proposed Google data center being built by Dynamo Ventures LLC. One opposes two wastewater permit applications filed with the Texas Commission on Environmental Quality that could send treated wastewater through open tributaries into Lake Wichita, and asks that any TCEQ hearing be held in Archer County. The second asks TCEQ to reevaluate an approved permit for a City Concrete Inc. concrete batch plant at the site. The county judge said the county has no authority to stop the permits.","scope":"county: Archer County","status":"enacted","date":"2026-09-28","sources":[{"url":"https://www.timesrecordnews.com/story/news/local/2026/10/01/archer-county-officials-pass-resolutions-aimed-at-stopping-data-center/92028119007/","label":"www.timesrecordnews.com"}],"parties":[{"role":"Authority","name":"Archer County Commissioners Court"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"aed4fabd0e2dc51c","state":"TX","tracker":"delay","section":"utility_actions","title":"Austin Energy","summary":"The City’s memorandum describes Austin Energy’s implementation of Texas Senate Bill 6 for data centers and other large loads. Loads exceeding 75 MW require a full interconnection study, must fund identified interconnection and transmission upgrades, and may be subject to remote curtailment requirements and ERCOT emergency-management authority.","scope":"Record-specific: TX","status":"approved","date":"2025-12-23","sources":[{"url":"https://services.austintexas.gov/edims/document.cfm?id=464924","label":"services.austintexas.gov"}],"parties":[{"role":"Named utility / authority","name":"Austin Energy"}],"groups":["utility:tariff:approved"],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"234c8b4fd863479c","state":"TX","tracker":"delay","section":"utility_actions","title":"Austin Energy","summary":"At an Austin Energy Utility Oversight Committee meeting, Interim General Manager Stewart Riley presented an overview of ERCOT large-load growth and Austin Energy’s challenges in serving large customers, including data centers and industrial facilities. The discussion addressed capacity constraints, long equipment lead times, customer requests below the 75 MW threshold established by Texas Senate Bill 6, cost recovery, stranded-cost prevention, and existing rates.","scope":"Record-specific: TX","status":"pending","date":"2025-10-07","sources":[{"url":"https://services.austintexas.gov/edims/document.cfm?id=460265","label":"services.austintexas.gov"}],"parties":[{"role":"Named utility / authority","name":"Austin Energy"}],"groups":["utility:other:pending"],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"8a59f0bede74a94b","state":"TX","tracker":"delay","section":"county_restrictions","title":"Bell County","summary":"Commissioners passed a two-year construction moratorium halting a project by Murray Industries, which had already begun clearing land. It is unclear whether the moratorium covers Meta's already-operational Temple facility nearby. This is a distinct company/action from the broader Rowan Digital Infrastructure / tax-abatement fight already tracked for Temple-area (Bell County) data centers.","scope":"county: Bell County","status":"in_force","date":"2026-07-02","sources":[{"url":"https://www.wymt.com/2026/07/02/bell-county-passes-data-center-moratorium-halting-construction-2-years/","label":"www.wymt.com"}],"parties":[{"role":"Authority","name":"Board of Supervisors/County Commission"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"792ce5aec9329c29","state":"TX","tracker":"delay","section":"projects","title":"Blueprint Data Centers Taylor Facility","summary":"135,000 sq ft facility; case highlights title/deed-restriction risk as an emerging litigation vector for Texas data center siting distinct from zoning or environmental claims.","scope":"Record-specific: Taylor (Williamson County)","status":"litigation_active","date":"2025-09","sources":[{"url":"https://www.kut.org/energy-environment/2025-09-30/taylor-data-center-lawsuit-parkland-blueprint","label":"www.kut.org"}],"parties":[{"role":"Operator","name":"Blueprint Data Centers"}],"groups":["delay:litigation:litigation_active","delay:community_opposition:litigation_active"],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"ff2ad7188ab3cf6c","state":"TX","tracker":"delay","section":"county_restrictions","title":"Boerne (Kendall County)","summary":"The Boerne Planning and Zoning Commission on Monday, September 14, 2026 unanimously recommended a Unified Development Code amendment that would require a special use permit for data centers, limit them to the city's most intense industrial zoning and keep them at least 1,000 feet from homes. No data center is currently proposed in the city. The recommendation is expected to be presented to the City Council on October 27, 2026. Next date: 2026-10-27.","scope":"city: Boerne (Kendall County)","status":"pending","date":"2026-09-14","sources":[{"url":"https://www.mysanantonio.com/news/hill-country/article/boerne-data-centers-1000-foot-buffer-22432860.php","label":"www.mysanantonio.com"},{"url":"https://news4sanantonio.com/news/local/restrictions-on-data-centers-move-to-boerne-city-council","label":"news4sanantonio.com"}],"parties":[{"role":"Authority","name":"Boerne Planning and Zoning Commission"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"a3860d8a31c533e3","state":"TX","tracker":"delay","section":"county_restrictions","title":"Brazoria County","summary":"Brazoria County, Texas, commissioners unanimously rejected a package of tax abatements sought by Nightpeak Energy for its proposed $3.5 billion Old Ocean Data Center campus outside Sweeny, about 65 miles southwest of Houston. The project calls for two 310-megawatt hyperscale data centers paired with two 310-megawatt combustion turbine power plants on a 158-acre site. Each data center carries a pro","scope":"county: Brazoria County","status":"expired","date":"2026-03-13","sources":[{"url":"https://therealdeal.com/texas/2026/03/13/brazoria-county-rejects-tax-break-for-3-5b-data-center/","label":"therealdeal.com"},{"url":"https://nightpeak.energy/project/old-ocean-data-center/","label":"nightpeak.energy"},{"url":"https://thefacts.com/news/brazoria-county-rejects-tax-abatement-package-for-data-center/article_132f70fc-473b-4ab2-bcb0-bb11b8b16fae.html","label":"thefacts.com"}],"parties":[{"role":"Authority","name":"Board of Supervisors/County Commission"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"179ce9c6749195ff","state":"TX","tracker":"delay","section":"utility_actions","title":"Brazos Electric Power Cooperative, Inc.","summary":"Brazos Electric published an Interconnection Guidebook describing requirements and procedures for entities establishing or significantly modifying connections to the ERCOT grid through its transmission system. It includes interconnection requirements for Large Load Customers with peak demand of at least 75 MW, including feasibility, interconnection, facilities, system-upgrade, financial-security, and energization requirements.","scope":"Record-specific: TX","status":"pending","date":"2025-11","sources":[{"url":"https://www.brazoselectric.com/sites/default/files/2025-12/brazos-electric-interconnection-guidebook.pdf","label":"www.brazoselectric.com"}],"parties":[{"role":"Named utility / authority","name":"Brazos Electric Power Cooperative, Inc."}],"groups":["utility:tariff:pending"],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"3bef75b6ce346902","state":"TX","tracker":"delay","section":"county_restrictions","title":"Bryan","summary":"Bryan, Texas, City Council proactively annexed 162 acres near the RELLIS campus and adopted a Planned Development zoning district allowing data centers with stricter-than-normal standards including increased setbacks, noise requirements, and screening specifications. No data center project has been formally proposed yet. The preemptive zoning measures represent a community win in establishing regu","scope":"city: Bryan","status":"in_force","date":"2025-09-16","sources":[{"url":"https://www.texastribune.org/2026/02/13/texas-data-centers-local-governments-power/","label":"www.texastribune.org"},{"url":"https://www.kbtx.com/2025/09/17/bryan-annexes-land-near-rellis-campus-with-potential-retail-data-center-use/","label":"www.kbtx.com"}],"parties":[{"role":"Authority","name":"City Council"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"d04486225e3fbb69","state":"TX","tracker":"delay","section":"utility_actions","title":"CenterPoint Energy","summary":"In a first-quarter earnings presentation, CenterPoint Energy stated that ERCOT had approved 3.2 GW of data-center load, with another 9 GW expected to be submitted for approval. The company expects 8 GW to be energized by 2029, followed by an additional 4.2 GW, and is conducting a refreshed load study for transmission planning.","scope":"Record-specific: TX","status":"pending","date":null,"sources":[{"url":"https://www.utilitydive.com/news/centerpoint-energy-data-center-load-earnings/818293/","label":"www.utilitydive.com"}],"parties":[{"role":"Named utility / authority","name":"CenterPoint Energy"}],"groups":["utility:statement:pending"],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"b7530737048520f8","state":"TX","tracker":"delay","section":"county_restrictions","title":"City of Fort Worth","summary":"Fort Worth city staff presented proposed citywide data center rules on June 2, 2026: ban cryptocurrency mining as a primary data center use; require a 250-ft setback from homes (300-ft for generators); mandate closed-loop cooling capped at 1M gallons/month; impose 70 dB day / 60 dB night noise limits; and cap tax abatements at 50% for $500M+ investments. No vote was taken; a zoning commission vote Update 2026-08-11: RECHECK outcome: the data center zoning ordinance presented to Council on June 2 was not adopted. The Fort Worth Zoning Commission voted 7-4 on July 8, 2026 to recommend denial of the proposed regulations. On August 11, 2026 the City Council initiated the process for a 90-day moratorium on data center development, created the Fort Worth Data Center and Infrastructure Commission, and adopted an application requirement for data centers. The city's data center page lists the first of two required public hearings on the moratorium for the November 10, 2026 council meeting, with the commission's report presented at a work session the same day. The moratorium adoption vote is tentatively set for February 16, 2027 and requires a supermajority. Next date: 2026-11-10. (Previously recorded as pending, dated 2026-06-02.)","scope":"city: City of Fort Worth","status":"pending","date":"2026-08-11","sources":[{"url":"https://fortworthreport.org/2026/06/03/fort-worth-could-ban-cryptocurrency-mining-data-centers-might-be-here-to-stay/","label":"fortworthreport.org"},{"url":"https://fortworthreport.org/2026/07/08/zoning-commissioners-deny-data-center-rules-return-ordinance-to-fort-worth-city-council/","label":"fortworthreport.org"},{"url":"https://fortworthreport.org/2026/07/09/majority-of-fort-worth-council-members-call-for-data-center-moratorium/","label":"fortworthreport.org"},{"url":"https://fortworthreport.org/2026/07/21/can-proposed-data-center-moratorium-in-fort-worth-lead-to-meaningful-long-term-solutions/","label":"fortworthreport.org"},{"url":"https://www.fortworthtexas.gov/departments/city-manager/datacenters","label":"www.fortworthtexas.gov"},{"url":"https://www.nbcdfw.com/news/local/fort-worth-data-center-moratorium-zoning-vote/4046474/","label":"www.nbcdfw.com"}],"parties":[{"role":"Authority","name":"City Council"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"eaa8db52c6da2ea1","state":"TX","tracker":"delay","section":"county_restrictions","title":"City of Thorndale","summary":"Data Factory Austin proceeded with bitcoin mining near Thorndale despite city opposition. The city passed a resolution voicing concerns about the 15 MW facility, and residents launched a Change.org petition. However, Data Factory leased a 10-acre site 2.5 miles north of Thorndale on FM 486 and began operations. Existing noise complaints from a 10 MW Data Factory mine near Rockdale peaked at 99 dec","scope":"city: City of Thorndale","status":"expired","date":"2024-10-01","sources":[{"url":"https://theminermag.com/news/2024-10-11/thorndale-bitcoin-mine-oppose","label":"theminermag.com"},{"url":"https://www.kxxv.com/news/local-news/in-your-neighborhood/thorndale-residents-voice-concerns-over-proposed-bitcoin-mining-company","label":"www.kxxv.com"},{"url":"https://www.change.org/p/halt-data-factory-austin-s-proposed-bitcoin-factory-in-thorndale","label":"www.change.org"},{"url":"https://www.texasobserver.org/crypto-energy-grid-texas-bitcoin-water/","label":"www.texasobserver.org"}],"parties":[{"role":"Authority","name":"City Council"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"97ee67b98e19005d","state":"TX","tracker":"delay","section":"county_restrictions","title":"College Station","summary":"College Station residents mounted strong opposition to Priority Power's proposed 600MW datacenter on 200 acres of Midtown Drive. More than 75 individuals registered to speak in person and a petition with over 5,000 signatures was submitted. Concerns included noise pollution, procedural issues, environmental impacts, and utility demands. The city rejected the land sale and is now proactively consid","scope":"city: College Station","status":"expired","date":"2025-09-12","sources":[{"url":"https://www.kbtx.com/2025/09/12/college-station-city-council-unanimously-rejects-land-sale-ai-data-center/","label":"www.kbtx.com"},{"url":"https://www.datacenterdynamics.com/en/news/college-station-texas-rejects-land-sale-for-data-center/","label":"www.datacenterdynamics.com"},{"url":"https://www.datacenterdynamics.com/en/news/600mw-data-center-campus-proposed-in-texas/","label":"www.datacenterdynamics.com"},{"url":"https://www.governing.com/infrastructure/texas-towns-push-back-on-data-center-expansion","label":"www.governing.com"},{"url":"https://www.kbtx.com/2025/09/07/college-station-city-council-discuss-potential-data-center-midtown-drive-sept-11-meeting/","label":"www.kbtx.com"}],"parties":[{"role":"Authority","name":"City Council"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"168b4298a9ab289d","state":"TX","tracker":"delay","section":"projects","title":"Comanche Circle / Sailfish Investors Data Center","summary":"Included here as a delay/opposition case even though ultimately approved, given the scale of community pushback documented in local coverage; distinct 2,100-acre parcel from the Project Patriot/Knox Ranch dispute in the same county. Update 2026-09-08: Outcome of the September 8, 2026 agenda item: after public comment, the Hood County Commissioners Court voted to move its discussion and possible action on multiple proposed data center projects to October 13, 2026 so the item can be properly advertised for a public hearing. The main proposal is Comanche Circle, backed by Florida-based Sailfish Investors, a multi-campus data center park near Tolar that could span 2,100 to 2,600 acres with up to nine campuses. No vote was taken on the projects. The vote count on the postponement is not stated. Next date: 2026-10-13.","scope":"Record-specific: Hood County","status":"delayed","date":"2026-06","sources":[{"url":"https://www.keranews.org/government/2026-06-09/hood-county-approves-comanche-circle-data-center-without-conditions-after-contentious-meeting","label":"www.keranews.org"},{"url":"https://www.nbcdfw.com/news/local/hood-county-commissioners-set-to-discuss-proposed-data-center-projects-amid-ongoing-debate/4073892/","label":"www.nbcdfw.com"}],"parties":[{"role":"Operator","name":"Sailfish Investors (developer Ryan Hughes)"}],"groups":["delay:community_opposition:delayed"],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"f96111910622ea2e","state":"TX","tracker":"delay","section":"county_restrictions","title":"Dallas","summary":"Five Dallas City Council members (Chad West, Kathy Stewart, Laura Cadena, Paul Ridley and Jaime Resendez) submitted a memo to Mayor Eric Johnson on September 16, 2026 asking that a data center moratorium be referred to a committee and placed on a council voting agenda within 30 days. The request would authorize a public hearing on a moratorium covering construction permits and certificates of occupancy for new hyperscale data centers. It starts the process and does not halt construction. Data centers are currently allowed by right in many Dallas zoning districts.","scope":"city: Dallas","status":"proposed","date":"2026-09-16","sources":[{"url":"https://www.dallasobserver.com/news/southern-dallas-neighborhood-begging-to-be-part-of-the-process-amid-data-center-fight-40719881/","label":"www.dallasobserver.com"},{"url":"https://www.dallasnews.com/news/dallas-local-government/article/dallas-data-center-permits-pause-22445814.php","label":"www.dallasnews.com"}],"parties":[{"role":"Authority","name":"Dallas City Council (five-member memo)"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"7752575e97aca9f5","state":"TX","tracker":"delay","section":"county_restrictions","title":"Denton","summary":"2026-09-22: The Denton City Council held the first of two required public hearings on a proposed moratorium that would temporarily pause new data center development and permitting. No vote was taken. The second public hearing is set for October 27, 2026, and the council could vote on the moratorium as early as December 1, 2026. The proposed pause is 90 days with a possible extension. City staff said the electric transmission system is near capacity; Core Scientific operates a 391 MW facility in the city. The article gives the hearing as Tuesday;. 2026-09-23: The Denton Planning and Zoning Commission voted 5-0 to recommend development code amendments that strengthen data center regulations. The amendments would require a specific use permit for all new warehouse data centers, bar them from several zoning districts, increase the residential setback from 100 to 300 feet, require water and wastewater impact studies and mandate closed-loop or free-air cooling. The City Council is scheduled to vote on the amendments on October 13, 2026. The article gives the vote as Wednesday;. Next date: 2026-10-13.","scope":"city: Denton","status":"pending","date":"2026-09-23","sources":[{"url":"https://communityimpact.com/denton/government/denton-officials-weigh-data-center-moratorium-during-first-public-hearing/","label":"communityimpact.com"},{"url":"https://dentonrc.com/news/denton/amendments-to-strengthen-data-center-rules-in-denton-s-development-code-now-head-to-the/article_e5693fe4-b22d-43f2-8d18-186c80ae9813.html","label":"dentonrc.com"}],"parties":[{"role":"Authority","name":"Denton Planning and Zoning Commission"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"a8fe02f84bc4a666","state":"TX","tracker":"delay","section":"projects","title":"Diode Ventures Cedar Creek Lake","summary":"Pre-moratorium withdrawal ,  cited by Governor's office as example","scope":"Record-specific: Cedar Creek Lake","status":"withdrawn","date":"2026-07-24","sources":[{"url":"https://gov.texas.gov/news/post/east-texas-data-center-withdraws-after-falling-short-of-governor-abbotts-standards","label":"gov.texas.gov"}],"parties":[{"role":"Operator","name":"Diode Ventures"}],"groups":["delay:state_moratorium:withdrawn"],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"0581ab61da4d6697","state":"TX","tracker":"delay","section":"projects","title":"Diode Ventures Cedar Creek Lake Data Center","summary":"Update/confirmation of previously tracked entry - confirms formal withdrawal date and cause; Cedar Creek Lake is a major regional drinking-water and recreation reservoir, which drove opposition.","scope":"Record-specific: Henderson County (Cedar Creek Lake / Cedar Creek Reservoir)","status":"withdrawn","date":"2026-07-23","sources":[{"url":"https://www.keranews.org/news/2026-07-23/texas-data-center-project-pulled-after-facing-community-backlash","label":"www.keranews.org"},{"url":"https://www.texastribune.org/2026/07/23/east-texas-data-center-withdrawn/","label":"www.texastribune.org"}],"parties":[{"role":"Operator","name":"Diode Ventures"}],"groups":["delay:water_dispute:withdrawn","delay:community_opposition:withdrawn"],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"9a879f558b598ed3","state":"TX","tracker":"delay","section":"utility_actions","title":"ERCOT","summary":"The PUCT approved ERCOT-sponsored NPRR1234, establishing interconnection, modeling, visibility, study, and Subsynchronous Oscillation requirements for Large Loads and certain other load additions. Large Loads are defined as one or more facilities at a single site with aggregate peak demand of 75 MW or more; the filing also adds a Large Load Interconnection Study Request fee to the ERCOT Fee Schedule.","scope":"Record-specific: TX","status":"approved","date":"2025-05-15","sources":[{"url":"https://www.ercot.com/mktrules/issues/NPRR1234","label":"www.ercot.com"}],"parties":[{"role":"Named utility / authority","name":"ERCOT"}],"groups":["utility:tariff:approved"],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"a068f88c8918edb0","state":"TX","tracker":"delay","section":"utility_actions","title":"ERCOT","summary":"At its September 14 to 15, 2026 meeting, the ERCOT Board received a policy update stating that large load integration remains a priority as the Public Utility Commission continues to approve Senate Bill 6 rulemakings. ERCOT said it is moving from Batch Zero to ongoing batch-based planning under a single Comprehensive Transmission Planning framework. Stakeholder workshops were scheduled for August 31 and September 24, initial revision requests are to be filed in November 2026, and Board consideration of the ongoing batch study revision requests is targeted for April 2027. The same update lists NOGRR289, an extension for large computational load cooling load ride-through compliance.","scope":"Record-specific: TX","status":"pending","date":"2026-09-15","sources":[{"url":"https://www.ercot.com/files/docs/2026/09/09/4-High-Impact-Policy-Discussions-in-the-Stakeholder-Process.pdf","label":"www.ercot.com"}],"parties":[{"role":"Named utility / authority","name":"ERCOT"},{"role":"Authority","name":"ERCOT Board of Directors"}],"groups":["utility:other:pending"],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"b540667ef8b17e0f","state":"TX","tracker":"delay","section":"utility_actions","title":"ERCOT transmission/distribution utilities (statewide SB6 rulemaking)","summary":"The Public Utility Commission of Texas voted to publish draft rule 16 TAC §25.194 to implement Texas SB 6 interconnection standards for new loads of 75 MW or greater. The proposed rule would impose interconnection fees, financial-security requirements, study fees, disclosure obligations, and payment of direct interconnection costs on affected large-load customers.","scope":"Record-specific: TX","status":"pending","date":"2026-03-12","sources":[{"url":"https://www.gtlaw.com/en/insights/2026/3/texas-senate-bill-6-update-what-data-centers-large-load-customers-should-know-about-proposed-interconnection-standards","label":"www.gtlaw.com"}],"parties":[{"role":"Named utility / authority","name":"ERCOT transmission/distribution utilities (statewide SB6 rulemaking)"}],"groups":["utility:other:pending"],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"87c2bcaca8770a64","state":"TX","tracker":"delay","section":"utility_actions","title":"ERCOT transmission/distribution utilities (statewide SB6 rulemaking)","summary":"Texas Senate Bill 6 directs the Public Utility Commission of Texas to establish new interconnection standards and cost-sharing requirements for ERCOT large-load customers, including customers with expected system demand exceeding 75 MW. It also requires rules addressing co-location with existing generation, demand-management programs, and review of transmission-cost allocation methodology; implementation is underway in Project No. 58317.","scope":"Record-specific: TX","status":"pending","date":"2025-07-29","sources":[{"url":"https://www.weil.com/-/media/files/pdfs/2025/july/weil-energy-alert--senate-bill-6-reforms-interconnection-and-colocation-rules-for-data-centers-and-o.pdf","label":"www.weil.com"}],"parties":[{"role":"Named utility / authority","name":"ERCOT transmission/distribution utilities (statewide SB6 rulemaking)"}],"groups":["utility:other:pending"],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"ca36e7d667fd52d5","state":"TX","tracker":"delay","section":"utility_actions","title":"ERCOT transmission/distribution utilities (statewide SB6 rulemaking)","summary":"The Public Utility Commission of Texas is developing rules and evaluating policies under Texas Senate Bill 6 concerning large-load forecasting, interconnection standards, net-metering arrangements, demand-management services, and transmission-cost allocation. The materials state that proposed rules had been published for Projects 58480 and 58479, with final adoption for Project 58480 expected by March 2026.","scope":"Record-specific: TX","status":"pending","date":"2025-10-17","sources":[{"url":"https://www.naseo.org/Data/Sites/1/media/tknaseo/sb6-puct-17-oct-2025.pdf","label":"www.naseo.org"}],"parties":[{"role":"Named utility / authority","name":"ERCOT transmission/distribution utilities (statewide SB6 rulemaking)"}],"groups":["utility:other:pending"],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"624c21796e30622a","state":"TX","tracker":"delay","section":"utility_actions","title":"ERCOT transmission/distribution utilities (statewide SB6 rulemaking)","summary":"The Public Utility Commission of Texas voted to publish draft 16 TAC §25.194 implementing Senate Bill 6 interconnection standards for new loads of 75 MW or greater. The proposed rule would require interconnection fees, financial security, disclosures, study fees, upfront payment of direct interconnection costs, and potential penalties for milestone delays.","scope":"Record-specific: TX","status":"pending","date":"2026-03-12","sources":[{"url":"https://www.gtlaw.com/-/media/files/insights/alerts/2026/03/gt-alert_texas-senate-bill-6-update-what-data-centers-and-large-load-customers-should-know-about-proposed-interconnection-standards.pdf?rev=6dbf3460e37546b0964437d268dfa59b","label":"www.gtlaw.com"}],"parties":[{"role":"Named utility / authority","name":"ERCOT transmission/distribution utilities (statewide SB6 rulemaking)"}],"groups":["utility:other:pending"],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"75dc99c20658fe92","state":"TX","tracker":"delay","section":"utility_actions","title":"ERCOT transmission/distribution utilities (statewide SB6 rulemaking, 16 TAC §25.194)","summary":"The Public Utility Commission of Texas adopted new 16 TAC §25.194, Large Load Interconnection Standards, implementing PURA §37.0561 as enacted by Senate Bill 6, with changes to the text proposed in the March 27, 2026 Texas Register. The signed adoption order was filed in Project No. 58481 on September 18, 2026, and the project listing shows an effective date of October 8, 2026. Before a large load customer can be included in an ERCOT interconnection study it must execute an intermediate agreement, make specified disclosures and post financial security of $50,000 per megawatt. It must then execute a standard large load interconnection agreement, update its disclosures, post further security and pay contribution in aid of construction for direct interconnection costs. The rule sets consequences for withdrawing requested or contracted peak demand and for providing false or inaccurate information. A customer that withdraws before its study begins can recover all security less amounts owed; one that withdraws after ERCOT has allocated transmission capacity forfeits 20% of the security tied to that capacity. The commission noted that eligibility for the Batch Zero study is governed separately by PGRR 145, approved June 18, 2026.","scope":"Record-specific: TX","status":"approved","date":"2026-09-18","sources":[{"url":"https://interchange.puc.texas.gov/Search/Filings?ControlNumber=58481","label":"interchange.puc.texas.gov"},{"url":"https://interchange.puc.texas.gov/Documents/58481_218_1684654.PDF","label":"interchange.puc.texas.gov"},{"url":"https://interchange.puc.texas.gov/Documents/58481_219_1684678.PDF","label":"interchange.puc.texas.gov"}],"parties":[{"role":"Named utility / authority","name":"ERCOT transmission/distribution utilities (statewide SB6 rulemaking, 16 TAC §25.194)"}],"groups":["utility:tariff:approved"],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"c7c2a7a3b4cd9ee5","state":"TX","tracker":"delay","section":"utility_actions","title":"El Paso","summary":"Meta expanded its El Paso data center investment from $1.5B to $10B (1GW capacity, 1,000 acres).","scope":"Record-specific: TX","status":"rejected","date":"2026-06-18","sources":[{"url":"https://elpasomatters.org/2026/03/29/meta-data-center-el-paso-10-billion-expansion-water-gas-electricity-usage/","label":"elpasomatters.org"},{"url":"https://www.cnbc.com/2026/03/26/meta-to-spend-10-billion-on-ai-data-center-in-el-paso-1gw-by-2028.html","label":"www.cnbc.com"},{"url":"https://www.texastribune.org/2026/01/26/texas-el-paso-meta-data-center-natural-gas-power-plant/","label":"www.texastribune.org"},{"url":"https://kvia.com/news/2026/04/14/city-of-el-paso-gives-update-on-meta-data-center-project-policy-framework/","label":"kvia.com"},{"url":"https://www.elpasotexas.gov/assets/Press-Releases/2026.04.02-NEWS-RELEASE_City-of-El-Paso-Continues-Community-Engagement-on-Data-Center-Policy-Framework.pdf","label":"www.elpasotexas.gov"},{"url":"https://elpasomatters.org/2026/06/03/el-paso-texas-meta-data-center-tax-breaks-cancel-contract-water-air-pollution/","label":"elpasomatters.org"},{"url":"https://elpasomatters.org/2026/06/18/meta-data-center-el-paso-texas-water-electricity-rates-community-benefit-agreement/","label":"elpasomatters.org"},{"url":"https://kvia.com/news/business-technology/2026/07/07/el-paso-water-reassures-public-on-meta-data-centers-water-usage/","label":"kvia.com"},{"url":"https://kfoxtv.com/news/local/meta-data-center-water-cap-set-at-25m-gallons-a-day-average-pegged-at-480000","label":"kfoxtv.com"},{"url":"https://elpasomatters.org/2026/07/20/meta-data-center-el-paso-texas-policy-framework-rules-city-council/","label":"elpasomatters.org"},{"url":"https://kvia.com/news/business-technology/2026/07/20/el-paso-city-council-approves-data-center-policy-framework/","label":"kvia.com"}],"parties":[{"role":"Named utility / authority","name":"El Paso"}],"groups":["utility:policy:rejected"],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"8de00f3d12e2fbeb","state":"TX","tracker":"delay","section":"county_restrictions","title":"El Paso","summary":"Meta expanded its El Paso data center investment from $1.5B to $10B (1GW capacity, 1,000 acres). Construction began November 2025 with completion targeted February 2029. El Paso Electric filed with the PUC to build a $473M, 366MW natural gas power plant (813 small gas generators) exclusively for Meta for the first 5 years. On April 14, 2026, the City of El Paso provided an update on the Meta data","scope":"city: El Paso","status":"expired","date":"2026-06-18","sources":[{"url":"https://elpasomatters.org/2026/03/29/meta-data-center-el-paso-10-billion-expansion-water-gas-electricity-usage/","label":"elpasomatters.org"},{"url":"https://www.cnbc.com/2026/03/26/meta-to-spend-10-billion-on-ai-data-center-in-el-paso-1gw-by-2028.html","label":"www.cnbc.com"},{"url":"https://www.texastribune.org/2026/01/26/texas-el-paso-meta-data-center-natural-gas-power-plant/","label":"www.texastribune.org"},{"url":"https://kvia.com/news/2026/04/14/city-of-el-paso-gives-update-on-meta-data-center-project-policy-framework/","label":"kvia.com"},{"url":"https://www.elpasotexas.gov/assets/Press-Releases/2026.04.02-NEWS-RELEASE_City-of-El-Paso-Continues-Community-Engagement-on-Data-Center-Policy-Framework.pdf","label":"www.elpasotexas.gov"}],"parties":[{"role":"Authority","name":"City Council"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"3af74a147ed90618","state":"TX","tracker":"delay","section":"utility_actions","title":"El Paso Electric","summary":"El Paso Electric is seeking Public Utility Commission of Texas approval to amend its existing Economic Development Rate for data centers. The El Paso City Council authorized intervention, including retaining legal counsel and technical experts, to evaluate whether the proposed changes comply with prior settlement terms and protect customers from subsidizing costs associated with large energy users. Update 2026-09-23: Two administrative law judges issued a recommendation on September 23, 2026 in El Paso Electric's application to build the 366 MW natural gas McCloud Generation Facility to serve Meta's El Paso data center. They recommended approval only with protections that keep customers other than Meta's data center from paying the plant's construction and operating costs for the life of the facility, and said they would otherwise recommend denial. The judges also found the utility did not adequately consider alternatives. The five PUCT commissioners make the final decision, with a final order expected by December 7, 2026. The El Paso City Council was briefed on September 28. The docket number is not given in the report. Next date: 2026-12-07.","scope":"Record-specific: TX","status":"pending","date":null,"sources":[{"url":"https://www.elpasotexas.gov/assets/Press-Releases/2026.07.20-NEWS-RELEASE_City-Council-Authorizes-Intervention-in-EP-Electric-EDR.pdf","label":"www.elpasotexas.gov"},{"url":"https://www.ktsm.com/news/el-paso-epe-meta-plant/","label":"www.ktsm.com"}],"parties":[{"role":"Named utility / authority","name":"El Paso Electric"}],"groups":["utility:rate case:pending"],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"0b11ccddef1877eb","state":"TX","tracker":"delay","section":"utility_actions","title":"Electric Reliability Council of Texas (ERCOT)","summary":"Texas Gov. Greg Abbott ordered the PUCT and ERCOT to audit all data center projects in the ERCOT interconnection queue before additional projects advance. ERCOT suspended the first scheduled deliverable of its Batch Zero large-load interconnection process and planned to seek a good-cause exception regarding the timelines and process. Update 2026-09-14: At its September 14 to 15, 2026 meeting the ERCOT Board received a Batch Zero update, for information only with no action requested. ERCOT gave interconnecting transmission providers conditional Batch Zero classifications on September 3: 204 projects (66.4 GW) conditionally included as base load and 158 projects (127.9 GW in the key takeaways slide) as studied load, with 373 projects (302.2 GW) excluded. ERCOT has paused energization of new large load data centers and crypto mining facilities of 75 MW or more until the verification and audit and the community impact review are complete. ERCOT will file the Batch Zero Eligibility Verification Report and the Community Impact Review Report with the PUCT by December 10, 2026, and final inclusion or exclusion determinations will be provided in December. The PUCT granted ERCOT's three good cause exception requests for PGRR 145 on August 20, 2026. Next date: 2026-12-10.","scope":"Record-specific: TX","status":"pending","date":"2026-08-03","sources":[{"url":"https://www.powermag.com/texas-audit-could-delay-49-8-gw-of-data-center-load-cost-projects-up-to-15-billion-bnef-warns/","label":"www.powermag.com"},{"url":"https://www.ercot.com/files/docs/2026/09/11/14-Batch-Zero-Update.pdf","label":"www.ercot.com"}],"parties":[{"role":"Named utility / authority","name":"Electric Reliability Council of Texas (ERCOT)"}],"groups":["utility:other:pending"],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"99a349313213c782","state":"TX","tracker":"delay","section":"utility_actions","title":"Electric Reliability Council of Texas (ERCOT)","summary":"Texas Governor Greg Abbott directed the Public Utility Commission of Texas and ERCOT to conduct a comprehensive verification and audit of all data centers advancing through ERCOT’s interconnection process before additional projects may move forward. ERCOT stated that it would not issue project classifications by the scheduled August 7, 2026 deadline and would seek a good-cause exception concerning Batch Zero timelines and procedures.","scope":"Record-specific: TX","status":"pending","date":"2026-08-03","sources":[{"url":"https://www.akingump.com/en/insights/alerts/texas-pauses-data-center-interconnections-pending-statewide-audit","label":"www.akingump.com"}],"parties":[{"role":"Named utility / authority","name":"Electric Reliability Council of Texas (ERCOT)"}],"groups":["utility:other:pending"],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"9c025e183c521d78","state":"TX","tracker":"delay","section":"county_restrictions","title":"Forney","summary":"The City of Forney, Texas, is considering new zoning rules that would formally regulate data center development within city limits. A public hearing is scheduled for March 17, 2026 on a proposed ordinance amending Forney's Comprehensive Zoning Ordinance. The amendment would include a formal definition of a data center, establish specific development regulations, and require a Conditional Use Permi","scope":"city: Forney","status":"pending","date":"2026-03-17","sources":[{"url":"https://www.inforney.com/local-news/forney-proposes-new-rules-for-data-centers/article_51ff32ba-83f3-44aa-91c1-73c022a88384.html","label":"www.inforney.com"},{"url":"https://www.texastribune.org/2026/02/13/texas-data-centers-local-governments-power/","label":"www.texastribune.org"}],"parties":[{"role":"Authority","name":"City Council"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"0f6400e16727bf31","state":"TX","tracker":"delay","section":"county_restrictions","title":"Fort Worth","summary":"Black Mountain Power LLC has obtained rezoning approval for over 450 acres in southeast Fort Worth for a $10B data center. The City Council approved zoning changes in multiple phases: 141 acres in January 2025, 171 additional acres in June, and 119 more acres on September 30. However, in February 2026, city officials tabled a vote on further land expansion, citing concerns about infrastructure, re","scope":"city: Fort Worth","status":"pending","date":"2025-01-01","sources":[{"url":"https://fortworthreport.org/2026/02/11/10b-data-center-hits-wall-after-fort-worth-leaders-cite-resources-land-usage-concerns/","label":"fortworthreport.org"},{"url":"https://www.wfaa.com/article/news/local/tarrant-county/fort-worth-council-delays-proposed-450-acre-data-center-rezoning-vote/287-3ac6b783-f553-47d5-8106-b009d799bec5","label":"www.wfaa.com"},{"url":"https://www.nbcdfw.com/news/local/fort-worth-data-center-zoning-approval/3649273/","label":"www.nbcdfw.com"},{"url":"https://www.govtech.com/infrastructure/fort-worth-data-center-approved-over-residents-opposition","label":"www.govtech.com"},{"url":"https://www.keranews.org/environment-nature/2025-10-01/data-center-on-431-acres-in-southeast-fort-worth-moving-forward-amid-environmental-concerns","label":"www.keranews.org"}],"parties":[{"role":"Authority","name":"City Council"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"66c6d40a38c26049","state":"TX","tracker":"delay","section":"county_restrictions","title":"Fort Worth","summary":"Fort Worth City Council unanimously voted on March 31, 2026 to delay a decision on a 10-year, 50% tax abatement worth ~$18.2 million for Edged Data Centers' proposed $1.1 billion data center at Veale Ranch (186 acres). Council member Michael Crain cited a need for 'more robust conversation' before moving forward. Residents raised concerns about the scope of the tax break and data center impacts. O","scope":"city: Fort Worth","status":"pending","date":"2026-03-31","sources":[{"url":"https://www.keranews.org/news/2026-04-01/enough-concern-today-1b-data-center-stalls-city-residents-raise-questions-about-tax-break","label":"www.keranews.org"},{"url":"https://therealdeal.com/texas/2026/04/02/fort-worth-delays-tax-incentives-for-1b-plus-data-center/","label":"therealdeal.com"},{"url":"https://www.cbsnews.com/texas/news/fort-worth-data-center-tax-abatement-delayed-after-community-opposition/","label":"www.cbsnews.com"},{"url":"https://fortworthreport.org/2026/03/31/enough-concern-today-1b-data-center-stalls-city-residents-raise-questions-about-tax-break/","label":"fortworthreport.org"}],"parties":[{"role":"Authority","name":"City Council"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"caf61b8dc7373bbf","state":"TX","tracker":"delay","section":"projects","title":"GW Ranch (Fort Stockton)","summary":"5 GW off-grid gas + 1.8 GW battery. Bypasses ERCOT entirely. Not affected by moratorium.","scope":"Record-specific: Fort Stockton","status":"delayed","date":null,"sources":[{"url":"https://frontier.datacenterstress.com/","label":"frontier.datacenterstress.com"}],"parties":[{"role":"Operator","name":"Pacifico Energy"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"f621f0bf38be6dbd","state":"TX","tracker":"delay","section":"projects","title":"Good Data Center Campus (Armstrong County)","summary":"Private natural gas turbines under state air permit. Not affected by moratorium.","scope":"Record-specific: Armstrong County","status":"delayed","date":null,"sources":[{"url":"https://www.wired.com/story/a-new-google-funded-data-center-will-be-powered-by-a-massive-gas-plant/","label":"www.wired.com"}],"parties":[{"role":"Operator","name":"Google (via developer)"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"1e598cd29a1c25ff","state":"TX","tracker":"delay","section":"jurisdictional_actions","title":"Governor Greg Abbott / PUCT / ERCOT","summary":"ERCOT reported to the Commission that it had reviewed 290 dynamic models and that approximately 18 percent were acceptable on first review. Six large loads representing approximately 1,959 MW were expected in the August 1, 2026 Quarterly Stability Assessment with projected energization in Q1 2027, and seventeen large loads representing approximately 6,874 MW were potentially eligible for the November 1, 2026 QSA with projected energization in Q2 2027. Seventeen large loads representing 6,608 MW of peak demand over five years have completed every ERCOT process except approval to energize and are held by the pause. ERCOT received 41 developer requests for exceptions to Batch Zero eligibility criteria on July 23, 2026: it does not plan to advance 27 of them (21 seeking exception to the qualifying interconnection study requirement, 2 to the dynamic model deadline, 3 submitted late or by the ILLE, and 1 seeking full exemption from the security requirement) and plans to consider 11 (9 relating to the financial security deadline and 2 to the Form W submission deadline). Medium loads, defined as at least 25 MW and less than 75 MW, are not verified as part of Batch Zero and continue to interconnect through the transmission and distribution providers' own approval to energize processes.","scope":"state: TX","status":"audit_in_progress","date":"2026-08-03","sources":[{"url":"https://www.ercot.com/services/comm/mkt_notices/M-A080326-02","label":"www.ercot.com"},{"url":"https://interchange.puc.texas.gov/Documents/59142_52_1675838.PDF","label":"interchange.puc.texas.gov"},{"url":"https://interchange.puc.texas.gov/Documents/59142_53_1675960.PDF","label":"interchange.puc.texas.gov"},{"url":"https://www.ercot.com/services/comm/mkt_notices/M-A080326-01","label":"www.ercot.com"},{"url":"https://www.ercot.com/files/docs/2026/07/29/ERCOT-Senate-July-29-Panel-1-Assessing-The-Grid.pdf","label":"www.ercot.com"},{"url":"https://www.reuters.com/business/energy/texas-governor-orders-pause-new-data-center-approvals-pending-audit-2026-08-04/","label":"www.reuters.com"},{"url":"https://www.reuters.com/legal/litigation/hundreds-millions-grid-deposits-linger-uncertainty-following-texas-data-center-2026-08-07/","label":"www.reuters.com"},{"url":"https://www.texastribune.org/2026/08/14/texas-data-center-approval-pause-ercot-power-grid/","label":"www.texastribune.org"},{"url":"https://www.bakerbotts.com/thought-leadership/publications/2026/august/texas-large-load-interconnection-update---ercot-batch-zero-pause-and-verification-process","label":"www.bakerbotts.com"},{"url":"https://www.powermag.com/texas-audit-could-delay-49-8-gw-of-data-center-load-cost-projects-up-to-15-billion-bnef-warns/","label":"www.powermag.com"},{"url":"https://gov.texas.gov/news/post/governor-abbott-directs-puc-and-ercot-to-shield-texans-from-data-center-infrastructure-costs","label":"gov.texas.gov"},{"url":"https://gov.texas.gov/news/post/east-texas-data-center-withdraws-after-falling-short-of-governor-abbotts-standards","label":"gov.texas.gov"},{"url":"https://gov.texas.gov/news/post/governor-abbott-announces-puc-and-ercot-actions-protecting-residential-ratepayers-from-data-center-costs","label":"gov.texas.gov"},{"url":"https://gov.texas.gov/news/post/governor-abbott-directs-comprehensive-data-center-audit","label":"gov.texas.gov"},{"url":"https://gov.texas.gov/news/post/governor-abbott-announces-qts-data-centers-will-meet-texas-standards","label":"gov.texas.gov"},{"url":"https://gov.texas.gov/news/post/governor-abbott-announces-meta-commits-to-comply-with-his-data-center-standards","label":"gov.texas.gov"},{"url":"https://gov.texas.gov/news/post/governor-abbott-announces-open-ai-commits-to-comply-with-his-data-center-standards-8-10","label":"gov.texas.gov"},{"url":"https://gov.texas.gov/news/post/governor-abbott-announces-edge-connex-and-stream-data-centers-commit-to-comply-with-his-data-center-standards","label":"gov.texas.gov"},{"url":"https://gov.texas.gov/news/post/governor-abbott-announces-google-rowan-and-cleanspark-commit-to-comply-with-his-data-center-standards","label":"gov.texas.gov"},{"url":"https://gov.texas.gov/news/post/governor-abbott-announces-core-scientific-vantage-data-centers-and-sb-energy-commit-to-comply-with-his-data-center-standards","label":"gov.texas.gov"},{"url":"https://gov.texas.gov/news/post/governor-abbott-announces-galaxy-compass-datacenters-and-montera-infrastructure-commit-to-comply-with-his-data-center-standards","label":"gov.texas.gov"},{"url":"https://gov.texas.gov/news/post/governor-abbott-announcesskyboxdigital-realtymara-commit-to-comply-with-his-data-center-standards","label":"gov.texas.gov"},{"url":"https://www.ercot.com/services/comm/mkt_notices/M-B062326-01","label":"www.ercot.com"},{"url":"https://www.ercot.com/services/comm/mkt_notices/M-B062326-04","label":"www.ercot.com"},{"url":"https://interchange.puc.texas.gov/Documents/58481_122_1600475.PDF","label":"interchange.puc.texas.gov"},{"url":"https://capitol.texas.gov/BillLookup/History.aspx?LegSess=89R&Bill=SB6","label":"capitol.texas.gov"},{"url":"https://interchange.puc.texas.gov/Search/Filings?ControlNumber=59142","label":"interchange.puc.texas.gov"},{"url":"https://www.utilitydive.com/news/ercot-texas-puc-data-center-audit/828472/","label":"www.utilitydive.com"},{"url":"https://www.keranews.org/texas-news/2026-08-21/ercot-says-it-plans-to-complete-governors-data-center-audit-by-december","label":"www.keranews.org"}],"parties":[{"role":"Authority","name":"Governor Greg Abbott / PUCT / ERCOT"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"1c9387886e878150","state":"TX","tracker":"delay","section":"county_restrictions","title":"Guadalupe County","summary":"The Seguin Gazette reported on September 26, 2026 that a state criminal investigations agency is looking into allegations involving Guadalupe County Judge Kyle Kutscher in connection with his family's pending sale of property to a data center project. Sheriff Joshua Ray said he received information over the summer and forwarded it to the county attorney to avoid any appearance of a conflict. A separate civil lawsuit by residents over proposed data center tax incentives was filed against the Commissioners Court in July. Event date is the report date.","scope":"county: Guadalupe County","status":"pending","date":"2026-09-26","sources":[{"url":"https://seguingazette.com/news/guadalupe-county-judge-faces-state-inquiry-over-data-center-deal/article_41970ad5-b4e1-42c8-927f-95fd4b2a0877.html","label":"seguingazette.com"}],"parties":[{"role":"Authority","name":"Guadalupe County Sheriff / Guadalupe County Attorney (referral to state investigators)"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"6218dc8d9c2c19aa","state":"TX","tracker":"delay","section":"utility_actions","title":"HILCO Electric Cooperative, Inc.","summary":"Infrakey DC Parks LLC and HILCO Electric Cooperative, Inc. signed a Memorandum of Understanding establishing a framework for 150 MW of dedicated nameplate power capacity for the Lacy Lakeview Data District in McLennan County, Texas. The parties intend to finalize definitive electric service agreements, subject to final approvals.","scope":"Record-specific: TX","status":"pending","date":null,"sources":[{"url":"https://infrakeyglobal.com/news/hilco-mou","label":"infrakeyglobal.com"}],"parties":[{"role":"Named utility / authority","name":"HILCO Electric Cooperative, Inc."}],"groups":["utility:other:pending"],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"e7a28503c00b617e","state":"TX","tracker":"delay","section":"county_restrictions","title":"Harlingen","summary":"Harlingen city commissioners on April 1, 2026 called for public hearings and signaled plans to impose a 120-day moratorium on data centers to study impact on residents, resources and environment ,  but the moratorium has NOT yet been adopted. Texas law requires 30-day notice and two public hearings before imposition. Context: the Harlingen WaterWorks board in Sept 2025 entered an agreement with RGV","scope":"city: Harlingen","status":"in_force","date":"2026-02-26","sources":[{"url":"https://myrgv.com/local-news/2026/04/02/harlingen-calls-for-public-hearings-on-proposed-data-center-moratorium/","label":"myrgv.com"},{"url":"https://www.rgvbusinessjournal.com/news/02/04/2026/harlingen-considers-a-temporary-ban-on-data-centers-heres-what-comes-next/","label":"www.rgvbusinessjournal.com"},{"url":"https://myrgv.com/local-news/2026/02/19/harlingen-drafting-ordinance-aimed-at-data-centers/","label":"myrgv.com"},{"url":"https://www.change.org/p/stop-mega-data-centers-in-hidalgo-county-protect-our-water-grid-and-public-health","label":"www.change.org"},{"url":"https://www.rgvbusinessjournal.com/news/28/02/2026/harlingen-data-center-regulation-eneus-energy/","label":"www.rgvbusinessjournal.com"}],"parties":[{"role":"Authority","name":"City Council"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"9832792554ff4c9d","state":"TX","tracker":"delay","section":"projects","title":"Hays County / San Marcos DC","summary":"San Marcos City Council voted 5-2 against zoning in February 2026.","scope":"Record-specific: Hays County / San Marcos","status":"cancelled","date":null,"sources":[{"url":"https://spectrumlocalnews.com/tx/austin/news/2026/02/23/hays-county-data-centers","label":"spectrumlocalnews.com"}],"parties":[],"groups":["delay:zoning_denial:cancelled","delay:water_dispute:cancelled","delay:community_opposition:cancelled"],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"a1bb576b290d6353","state":"TX","tracker":"delay","section":"projects","title":"Highlander SM One LLC Data Center (San Marcos)","summary":"Distinct developer/parcel from the already-tracked Hays County/San Marcos data center entry; this project was rejected outright twice rather than approved.","scope":"Record-specific: San Marcos (Hays County)","status":"cancelled","date":"2025","sources":[{"url":"https://www.datacenterdynamics.com/en/news/proposal-for-200-acre-data-center-rejected-in-southern-texas/","label":"www.datacenterdynamics.com"}],"parties":[{"role":"Operator","name":"Highlander SM One LLC"}],"groups":["delay:zoning_denial:cancelled","delay:community_opposition:cancelled"],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"d7bad28de0d321a8","state":"TX","tracker":"delay","section":"county_restrictions","title":"Hill County","summary":"One-year data center moratorium (rescinded) (Failed / vetoed).","scope":"county: Hill County","status":"expired","date":"2026-06-01","sources":[{"url":"https://texastribune.org","label":"texastribune.org"}],"parties":[{"role":"Authority","name":"City Council/Board of Supervisors"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"ef15dfcac805aa22","state":"TX","tracker":"delay","section":"jurisdictional_actions","title":"Hill County","summary":"Developer filed a $100M suit challenging the moratorium.","scope":"county: Hill County","status":"litigation_active","date":"2026-06-05","sources":[{"url":"https://dcmap.us/insights/policy/","label":"dcmap.us"},{"url":"https://www.texastribune.org/2026/06/05/texas-hill-county-moratorium-rescinded-data-centers/","label":"www.texastribune.org"}],"parties":[{"role":"Authority","name":"Hill County Commissioners Court"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"9b6f1b3a4e5b017b","state":"TX","tracker":"delay","section":"county_restrictions","title":"Hood County","summary":"Hood County (40 miles SW of Fort Worth) has received at least five data center applications (proposed by Sailfish Development). Commissioners voted down a proposed moratorium 3-2, twice, despite 8 hours of public testimony. The 2,100-acre Comanche Circle project sits in a recharge zone for the Upper Trinity Aquifer and could use 1M gallons/day. State Sen. Paul Bettencourt sent a letter to AG Paxto","scope":"county: Hood County","status":"expired","date":"2026-02-10","sources":[{"url":"https://www.texastribune.org/2026/02/10/texas-hood-county-rejects-data-center-development-pause-ai/","label":"www.texastribune.org"},{"url":"https://www.keranews.org/energy-environment/2026-02-25/data-center-moratorium-texas-hood-county-ken-paxton","label":"www.keranews.org"},{"url":"https://www.keranews.org/energy-environment/2026-01-13/hood-county-data-centers-comanche-circle","label":"www.keranews.org"},{"url":"https://www.citizen.org/news/hood-county-residents-left-vulnerable-as-commissioners-reject-data-center-moratorium/","label":"www.citizen.org"},{"url":"https://www.cbsnews.com/texas/news/hood-county-commissioners-reject-data-center-moratorium-again-3-2-vote-residents-call-for-resignations/","label":"www.cbsnews.com"}],"parties":[{"role":"Authority","name":"Board of Supervisors/County Commission"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"2b94997aeb7a95c7","state":"TX","tracker":"delay","section":"county_restrictions","title":"Hood County","summary":"Hood County (TX) commissioners approved the Comanche Circle data center (Sailfish Development; up to ~9 campuses / ~2,600 acres near Tolar, up to 5 GW) WITHOUT conditions after the developer threatened to sue. County Attorney Matthew Mills said commissioners felt compelled to approve to avoid litigation ('we got to pick our battles here'); a recent public meeting devolved into a shouting match bet","scope":"county: Hood County","status":"in_force","date":"2026-06-17","sources":[{"url":"https://www.keranews.org/energy-environment/2026-06-17/rural-north-texas-counties-data-center-moratorium-regulation-lawsuits","label":"www.keranews.org"}],"parties":[{"role":"Authority","name":"Board of Supervisors/County Commission"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"7fe77fa7f3b523eb","state":"TX","tracker":"delay","section":"county_restrictions","title":"Hutto","summary":"On April 17, 2026, Zydeco Development withdrew its rezoning application for a proposed 950,000-square-foot data center at the southeast corner of County Road 119 and Limmer Loop in Hutto, Texas, ahead of an April 20 special Hutto Planning and Zoning Commission meeting. The withdrawal followed organized community opposition through 'Stop the Hutto Data Center,' more than 30 opposition letters from","scope":"city: Hutto","status":"expired","date":"2026-04-17","sources":[{"url":"https://communityimpact.com/austin/pflugerville-hutto/development/2026/04/09/hutto-residents-air-concerns-over-proposed-data-center/","label":"communityimpact.com"},{"url":"https://www.kxan.com/news/local/hutto/proposed-hutto-data-center-faces-opposition-from-nearby-residents/","label":"www.kxan.com"},{"url":"https://www.kvue.com/article/news/local/williamson-county/hutto-data-center-resident-concerns/269-f1fcb072-1224-4b97-8c77-c02108eae987","label":"www.kvue.com"},{"url":"https://www.kut.org/energy-environment/2026-04-20/hutto-tx-zydeco-data-center-rezoning-request","label":"www.kut.org"},{"url":"https://communityimpact.com/austin/pflugerville-hutto/government/2026/04/22/zydeco-development-withdraws-zoning-request-for-data-center-in-hutto/","label":"communityimpact.com"}],"parties":[{"role":"Authority","name":"City Council"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"08adc0d2a3094c70","state":"TX","tracker":"delay","section":"county_restrictions","title":"Killeen (Bell County)","summary":"The Killeen City Council voted 6-1 on Tuesday, September 15, 2026 to direct staff to draft an ordinance requiring a conditional use permit for any future data center. Proposed standards presented by staff include electric service approval from ERCOT or Oncor, a water and sewer study by the city engineer and standardized setbacks. Councilman Charles Kimble dissented, saying the city should wait for state action. There are no current data center proposals in the city.","scope":"city: Killeen (Bell County)","status":"proposed","date":"2026-09-15","sources":[{"url":"https://kdhnews.com/news/local/killeen-council-puts-forward-staff-direction-that-could-regulate-data-centers/article_66d27789-c0de-4b7f-87c1-7096ee034a35.html","label":"kdhnews.com"}],"parties":[{"role":"Authority","name":"Killeen City Council"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"512b15031ff70fc5","state":"TX","tracker":"delay","section":"lawsuits","title":"LAWSUIT-Environmental-Integrity-Project-v-Vantage-an-2026-09","summary":"About two months before filing, the Environmental Integrity Project, Sierra Club and Public Citizen sent a notice of intent to sue Vantage and VoltaGrid over alleged Clean Air Act violations. The groups then filed a federal Clean Air Act lawsuit in San Antonio against the two companies, developers of two West Side data center campuses. They allege the companies are building and partially operating two gas-fired plants, with a combined capacity of 405 megawatts, under minor source permits when major source permits are required. They say the companies failed to correct the violations after the notice. No hearing date is reported.","scope":"Record-specific: TX","status":"litigation_active","date":null,"sources":[{"url":"https://www.expressnews.com/business/article/vantage-voltagrid-data-centers-clean-air-act-22442049.php","label":"www.expressnews.com"}],"parties":[],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"0e691feffccc2c0a","state":"TX","tracker":"delay","section":"lawsuits","title":"LAWSUIT-Lakes-at-Marshall-Ridge-HOA-v-Town-of-Westla-2026-09","summary":"The Lakes at Marshall Ridge Homeowners Association and several residents sued the Town of Westlake over a proposed 1.1 million square foot data center along U.S. 377 near homes in Keller. The suit alleges the site plan omits a 150-foot setback and landscaped buffer required by the town's zoning ordinance and that a December 2024 agenda notice did not mention a data center. A judge issued a temporary restraining order requiring Westlake to pause a vote on the development agreement, and an earlier CBS Texas report says the order was extended through September 8, 2026; the dates of those orders are not stated. On Friday, September 25, 2026 Judge Kimberly Fitzpatrick dissolved the temporary restraining order, saying she lacked time to review about 1,000 pages filed the night before. She set a hearing for October 23, 2026. One CBS Texas report calls the association Lakes of Marshall Ridge and describes the City of Keller as a co-plaintiff, while the Star-Telegram describes Keller as an intervenor. The filing date, case number and developer are not stated in the reports.","scope":"Record-specific: TX","status":"litigation_active","date":null,"sources":[{"url":"https://www.cbsnews.com/texas/news/westlake-data-center-court-hearing-tarrant-county-september-2026/","label":"www.cbsnews.com"},{"url":"https://www.cbsnews.com/texas/news/westlake-data-center-lawsuit-homeowners-zoning-dispute-august-2026/","label":"www.cbsnews.com"},{"url":"https://www.star-telegram.com/news/local/community/northeast-tarrant/article317374071.html","label":"www.star-telegram.com"}],"parties":[],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"6a497c66f1da1de1","state":"TX","tracker":"delay","section":"lawsuits","title":"LAWSUIT-Save-Our-Springs-v-City-of-Austin-Tesla-data-2026-09","summary":"Save Our Springs requested City of Austin water records for Tesla's data center at Gigafactory Texas under the state public information law. The group sued the city in Travis County's 98th District Court, arguing the city over-redacted the records and disregarded an Attorney General determination on the request. Tesla is not a party. The city said it had not yet been served, and no hearing date or case number is reported.","scope":"Record-specific: TX","status":"litigation_active","date":null,"sources":[{"url":"https://www.statesman.com/business/technology/article/austin-data-center-lawsuit-tesla-22454968.php","label":"www.statesman.com"}],"parties":[],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"94a6ad4e2ea8eb8f","state":"TX","tracker":"delay","section":"county_restrictions","title":"Lubbock","summary":"Planning and Zoning Commission voted 4-3 to reject a 936-acre hyperscale AI data center zoning change from Low Density Single Family to General Industrial, requested by Hugo Reed and Associates on behalf of Texas Solar Works. The site is off Northeast Loop 289, and the facility would require significant power from ERCOT lines, solar, and gas. About 10 north and east Lubbock residents objected to t Update 2026-09-22: 2026-09-08: The Lubbock City Council unanimously passed a non-binding resolution pledging to hold off on large-scale data centers until regulations are developed. The resolution asks the city manager and planning department to draft rules on water use, electricity, setbacks, screening, landscaping and outdoor lighting. The report says the first reading of the new rules would go to the Planning and Zoning Commission the following week, and that the council would vote later in September on a petition-led 18-month data center moratorium that had a public hearing. 2026-09-10: The Lubbock Planning and Zoning Commission delayed its decision on proposed large-scale data center restrictions for the city's Unified Development Code, as reported September 10, 2026 (the report does not state the meeting day). The proposal would create a new land use for large-scale data centers with water use restrictions, a 500-foot setback from other properties and a power use feasibility study. The commission plans another work session the following month. Its recommendations will then go to the City Council. 2026-09-22: On Tuesday, September 22, 2026 the Lubbock City Council approved, 5-2, a resolution that starts the process for a 90-day moratorium on large-scale data centers. The citizen petition for an 18-month moratorium by the Save Lubbock group did not come to a vote. The moratorium ordinance must still be drafted and go through two public hearings. Planning staff are to develop guidelines on water use, power reliability, zoning, noise and lighting, and a work session with experts is to be held within 90 days. Councilman Tim Collins was one of the no votes. (Previously recorded as expired, dated 2026-01-08.)","scope":"city: Lubbock","status":"proposed","date":"2026-09-22","sources":[{"url":"https://www.kcbd.com/2026/01/16/lubbock-data-center-proposal-heads-city-council-after-planning-commission-rejection/","label":"www.kcbd.com"},{"url":"https://www.datacenterdynamics.com/en/news/936-acre-data-center-could-come-to-lubbock-texas/","label":"www.datacenterdynamics.com"},{"url":"https://www.everythinglubbock.com/news/local-news/lubbock-city-council-passes-intent-to-wait-on-data-centers-until-regulations-are-ready/amp/","label":"www.everythinglubbock.com"},{"url":"https://writing.strisker.com/data-centers-daily-notes-september-09-2026/","label":"writing.strisker.com"},{"url":"https://www.kcbd.com/2026/09/10/lubbock-commission-delays-vote-data-center-zoning-rules/","label":"www.kcbd.com"},{"url":"https://www.kcbd.com/2026/09/23/city-council-adopts-resolution-regarding-large-scale-data-centers-lubbock-starting-process-potential-moratorium/","label":"www.kcbd.com"},{"url":"https://www.everythinglubbock.com/news/local-news/lubbock-city-council-moves-toward-90-day-ban-on-large-scale-data-centers/","label":"www.everythinglubbock.com"}],"parties":[{"role":"Authority","name":"Planning Commission"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"e64562363a75f207","state":"TX","tracker":"delay","section":"county_restrictions","title":"Lufkin","summary":"Denver-based Amp Z proposed Project Lufkin, a multi-gigawatt data center on 1,000+ acres at the former Southland Paper Mill site near the Neches River in Angelina County, TX. Total investment estimated at $1.05-$1.5 billion. Phased buildout: 175MW grid-connected by 2026, 1.1GW by 2028, ultimately 2.1GW. Estimated 500 construction jobs over 4+ years and ~30 permanent positions. As of early 2026, th","scope":"city: Lufkin","status":"in_force","date":"2025-11-01","sources":[{"url":"https://www.change.org/p/stop-ai-data-center-lufkin-tx","label":"www.change.org"},{"url":"https://www.ketk.com/news/local-news/1b-ai-data-center-project-planned-near-lufkin-officials-release-details/","label":"www.ketk.com"},{"url":"https://lufkindailynews.com/news/community/texas-county-rejects-a-moratorium-on-data-center-development-amid-ai-boom/article_8c75c882-3ed8-5d5a-8ec0-508b9f6d6fb0.html","label":"lufkindailynews.com"},{"url":"https://www.datacenterdynamics.com/en/news/multi-gigawatt-data-center-campus-planned-in-east-texas/","label":"www.datacenterdynamics.com"},{"url":"https://lufkindailynews.com/news/local/ai-data-center-planned-on-1-000-acres-at-former-southland-paper-mill-site/article_ff9e97bf-361d-5649-835b-68a75818bd94.html","label":"lufkindailynews.com"}],"parties":[{"role":"Authority","name":"City Council"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"0120772c7188f042","state":"TX","tracker":"delay","section":"projects","title":"Meta Temple Data Center","summary":"Part of the same Meta redesign wave that paused the Kuna, Idaho facility.","scope":"Record-specific: Temple (Bell County)","status":"delayed","date":"2025","sources":[{"url":"https://www.datacenterdynamics.com/en/news/meta-pauses-construction-of-temple-texas-data-center-as-part-of-ai-rescope/","label":"www.datacenterdynamics.com"}],"parties":[{"role":"Operator","name":"Meta"}],"groups":["delay:corporate_realignment:delayed"],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"82188765798d775d","state":"TX","tracker":"delay","section":"county_restrictions","title":"Milam County","summary":"Milam County (TX) has become a flashpoint for data center buildout as SB Energy (SoftBank) and partners advance the Stargate / Milam County campus near Sharp (Rockdale / Thorndale area), a multi-building site associated with OpenAI and SoftBank. Local opposition and the nearby City of Thorndale have pushed back on the scale, power demand, and water impact of the project, and Milam County commissio","scope":"county: Milam County","status":"in_force","date":"2026-01-09","sources":[{"url":"https://time.com/7362401/ai-stargate-data-center-abilene-housing-crisis/","label":"time.com"},{"url":"https://www.texasobserver.org/abilene-texas-stargate-natural-gas-plant-harms/","label":"www.texasobserver.org"},{"url":"https://www.texasmonthly.com/news-politics/abilene-stargate-artificial-intelligence/","label":"www.texasmonthly.com"},{"url":"https://finance.yahoo.com/news/openais-100-billion-texas-stargate-180016053.html","label":"finance.yahoo.com"},{"url":"https://www.datacenterdynamics.com/en/news/openai-pledges-to-pay-its-own-way-to-power-stargate-data-centers/","label":"www.datacenterdynamics.com"}],"parties":[{"role":"Authority","name":"Board of Supervisors/County Commission"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"f70bcf2339f86b49","state":"TX","tracker":"delay","section":"utility_actions","title":"Oncor Electric Delivery Company LLC","summary":"The Public Utility Commission of Texas voted unanimously on August 28, 2026 to approve amendments to two Certificates of Convenience and Necessity filed by Oncor, authorizing construction of more than 400 miles of 765 kV transmission line running southwest from Bosque County and spanning at least 30 counties. These are the first proposals under the 2023 Permian Basin Reliability Plan to win regulatory approval. The Commission tabled a decision on the Howard Solstice line in South Texas for further deliberation. The vote came over calls from the Texas Senate and some House members to delay approvals pending legislative reform, and on the same morning Attorney General Ken Paxton filed an amicus brief supporting the landowner group American Liberty Stewards in legal challenges against Oncor, AEP Texas and CPS Energy, arguing the governing statute does not expressly mandate 765 kV lines.","scope":"Record-specific: TX","status":"approved","date":"2026-08-28","sources":[{"url":"https://www.texastribune.org/2026/08/28/transmission-lines-texas-energy/","label":"www.texastribune.org"}],"parties":[{"role":"Named utility / authority","name":"Oncor Electric Delivery Company LLC"}],"groups":["utility:certificate:approved"],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"0b929d848501d87d","state":"TX","tracker":"delay","section":"utility_actions","title":"Oncor Electric Delivery Company LLC (intervenor); ERCOT","summary":"In a July 24, 2026 order in Docket No. 59220, the Public Utility Commission of Texas approved a net metering arrangement under PURA §39.169 between FGE Goodnight I's 265.5 MW GOODNIT1 wind facility in Armstrong County and a second co-located 260 MW AI data center complex (the Crusoe Two Load) developed by Crusoe Energy Systems and to be operated by Ensign Infrastructure. The approval carries the same conditions imposed on the first 265 MW Crusoe One Load in Docket No. 58881: within 30 minutes of an ERCOT instruction during an actual or anticipated transmission emergency or Energy Emergency Alert, the data center load must fully curtail, and the load is barred from being offered into other services. On August 18, 2026, Ensign filed a motion for rehearing arguing that the order would require curtailment of more than 520 MW of firm load against a 265.5 MW intermittent generator and exceeds what PURA §39.169 authorizes. On August 31, 2026, Commission Advising notified parties that the Commission voted not to add the motion for rehearing to any open meeting agenda.","scope":"Record-specific: TX","status":"approved","date":"2026-08-31","sources":[{"url":"https://www.whitecase.com/insight-alert/puct-affirms-curtailment-authority-over-co-located-data-centers-first-net-metering","label":"www.whitecase.com"},{"url":"https://interchange.puc.texas.gov/Documents/59220_69_1668205.PDF","label":"interchange.puc.texas.gov"},{"url":"https://interchange.puc.texas.gov/Documents/59220_73_1675222.PDF","label":"interchange.puc.texas.gov"},{"url":"https://interchange.puc.texas.gov/Documents/59220_74_1678681.PDF","label":"interchange.puc.texas.gov"}],"parties":[{"role":"Named utility / authority","name":"Oncor Electric Delivery Company LLC (intervenor); ERCOT"}],"groups":["utility:other:approved"],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"15ca382a6f880e9f","state":"TX","tracker":"delay","section":"projects","title":"Oracle/OpenAI Texas Expansion (Original Plan)","summary":"Oracle/OpenAI abandoned Texas expansion March 6, 2026 over financing negotiations. Pre-moratorium. Microsoft later stepped in.","scope":"Record-specific: TX","status":"withdrawn","date":"2026-03-06","sources":[{"url":"https://www.reuters.com/business/oracle-openai-end-plans-expand-texas-data-center-site-bloomberg-news-reports-2026-03-06/","label":"www.reuters.com"}],"parties":[{"role":"Operator","name":"Oracle"},{"role":"Named customer","name":"OpenAI (originally)"}],"groups":["delay:corporate_realignment:withdrawn","delay:financing:withdrawn"],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"b02c68dffcc16003","state":"TX","tracker":"delay","section":"county_restrictions","title":"Pecos County","summary":"Pacifico Energy's GW Ranch project in Pecos County, Texas, ~17 miles north of Fort Stockton, received TCEQ approval in early 2026 as the 'largest permitted data center campus' in the U.S. The 7.65 GW, 8,000+ acre facility was granted the largest air pollution permit in U.S. history (33 million tons/year GHG, approximately 5% of Canada's total emissions). On March 13, 2026, the U.S. Senate EPW Comm","scope":"county: Pecos County","status":"in_force","date":"2026-02-01","sources":[{"url":"https://www.kcbd.com/2026/02/01/texas-approves-largest-permitted-data-center-campus-us/","label":"www.kcbd.com"},{"url":"https://www.texastribune.org/2026/02/13/texas-data-centers-local-governments-power/","label":"www.texastribune.org"},{"url":"https://insideclimatenews.org/news/29012026/developer-calls-gw-ranch-in-pecos-county-texas-the-largest-power-project-in-u-s/","label":"insideclimatenews.org"},{"url":"https://www.datacenterdynamics.com/en/news/pacifico-energy-unveils-5gw-offgrid-natural-gas-project-in-texas-slated-to-serve-a-hyperscale-data-center/","label":"www.datacenterdynamics.com"},{"url":"https://bigbendsentinel.com/2026/02/04/massive-ai-data-center-coming-to-pecos-county/","label":"bigbendsentinel.com"}],"parties":[{"role":"Authority","name":"Board of Supervisors/County Commission"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"a60e9b00093891d5","state":"TX","tracker":"delay","section":"projects","title":"Project Matador (Amarillo)","summary":"11 GW at build-out; 600 MW gas turbines procured; 1 GW target by end of 2026. Not affected by moratorium (BTM). Continuing construction.","scope":"Record-specific: Amarillo / Potter County","status":"delayed","date":null,"sources":[{"url":"https://www.sec.gov/Archives/edgar/data/2071778/000207177826000027/fermi1q26erex_991.htm","label":"www.sec.gov"},{"url":"https://execgraphenergy.com/blog/data-center-power-procurement-texas-2026","label":"execgraphenergy.com"},{"url":"https://www.datacenterdynamics.com/en/news/?oo-step=true&term=the-mission-critical-power-channel","label":"www.datacenterdynamics.com"}],"parties":[{"role":"Operator","name":"Fermi America"},{"role":"Named customer","name":"TBD (planned hyperscale)"}],"groups":["delay:transformer_supply:delayed"],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"109278a363838f96","state":"TX","tracker":"delay","section":"projects","title":"Project Patriot / Knox Ranch (Granbury)","summary":"One of several Hood County data center disputes (see also Comanche Circle/Sailfish and Project Red/Yellow entries) reflecting a concentration of Central Texas litigation around Granbury-area projects.","scope":"Record-specific: Granbury (Hood County)","status":"litigation_active","date":"2026","sources":[{"url":"https://www.datacenterdynamics.com/en/news/residents-of-granbury-texas-sue-the-city-after-authorities-rezone-2100-acres-for-potential-data-center-project/","label":"www.datacenterdynamics.com"}],"parties":[{"role":"Operator","name":"Bilateral Energy"}],"groups":["delay:litigation:litigation_active","delay:community_opposition:litigation_active"],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"f08287b22f91f244","state":"TX","tracker":"delay","section":"projects","title":"Project Red and Project Yellow (Hood County)","summary":"Two related data center proposals in Hood County, adding to the county's concentration of contested projects alongside Comanche Circle and Project Patriot/Knox Ranch.","scope":"Record-specific: Hood County","status":"under_appeal","date":"2025","sources":[{"url":"https://www.keranews.org/energy-environment/2026-07-20/hood-county-judge-dismisses-lawsuit-seeking-automatic-approval-of-proposed-data-centers","label":"www.keranews.org"}],"parties":[{"role":"Operator","name":"National CRE Holdings and Greenland Capital"}],"groups":["delay:litigation:under_appeal"],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"adfb727c5dd4e1cc","state":"TX","tracker":"delay","section":"projects","title":"Project Tomahawk (Parvin Road and FM 1385)","summary":"White Rose Partners sought rezoning of about 37 acres at Parvin Road and FM 1385 for a 225,000 square foot data center estimated at about $580 million. On September 1, 2026 the Prosper Planning and Zoning Commission voted 7-0 to recommend denial after more than 400 opposition comments. Hours before the September 8 Town Council meeting the developer withdrew both agenda items; the town said the proposal is closed and any new plan would require a new application, notices and a Planning and Zoning hearing. A petition against the project had more than 2,000 signatures.","scope":"Record-specific: Prosper (Collin and Denton Counties)","status":"withdrawn","date":"2026-09-01","sources":[{"url":"https://communityimpact.com/prosper-celina/government/project-tomahawk-developer-scraps-plans-for-prosper-data-center/","label":"communityimpact.com"},{"url":"https://www.cbsnews.com/texas/news/prosper-tx-project-tomahawk-pulled-9-8-2026/","label":"www.cbsnews.com"}],"parties":[{"role":"Operator","name":"White Rose Partners"}],"groups":["delay:zoning_denial:withdrawn","delay:community_opposition:withdrawn"],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"f27cb758664748d7","state":"TX","tracker":"delay","section":"projects","title":"RCM Hill LLC Data Center (Hill County)","summary":"Notable as a case where litigation pressure from the developer side successfully forced a county to reverse its own moratorium.","scope":"Record-specific: Hill County","status":"litigation_active","date":"2025","sources":[{"url":"https://www.klgates.com/thought-leadership/Facing-a-Federal-Lawsuit-Hill-County-Repeals-Blanket-Pause-on-Data-Center-Construction-Adopting-New-Approval-Procedures-Instead-6-10-2026","label":"www.klgates.com"}],"parties":[{"role":"Operator","name":"RCM Hill LLC"}],"groups":["delay:litigation:litigation_active","delay:local_moratorium:litigation_active"],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"2e380fe2f7f014dc","state":"TX","tracker":"delay","section":"projects","title":"Red Oak Data Center Rezoning (Compass Datacenters)","summary":"Included as a documented opposition/delay case with a notable community-benefit concession, even though the rezoning was ultimately approved.","scope":"Record-specific: Red Oak (Ellis County)","status":"delayed","date":"2025","sources":[{"url":"https://www.elliscountypress.com/news/red-oak-rezones-land-data-center-campus-despite-protests","label":"www.elliscountypress.com"}],"parties":[{"role":"Operator","name":"Compass Datacenters"}],"groups":["delay:zoning_denial:delayed","delay:community_opposition:delayed"],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"f7513e35f7c721c0","state":"TX","tracker":"delay","section":"projects","title":"Skybox Datacenters San Angelo Project","summary":"City-owned land angle distinguishes this from typical private-parcel disputes; raised transparency and public-benefit questions locally.","scope":"Record-specific: San Angelo (Tom Green County)","status":"delayed","date":"2026","sources":[{"url":"https://sanangelolive.com/news/business/2025-12-31/skybox-datacenter-controversy","label":"sanangelolive.com"}],"parties":[{"role":"Operator","name":"Skybox Datacenters"}],"groups":["delay:community_opposition:delayed"],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"85e644b149d44cc3","state":"TX","tracker":"delay","section":"utility_actions","title":"Southwestern Public Service Company (SPS)","summary":"SPS entered into an Electric Service Agreement with Fermi America to provide up to 200 MW of electricity to Fermi’s Project Matador Campus. Service is scheduled to begin at 86 MW in January 2026 and gradually expand to 200 MW under the ESA and applicable tariffs.","scope":"Record-specific: TX","status":"pending","date":"2026-01","sources":[{"url":"https://finance.yahoo.com/news/xels-unit-supply-200-mw-184000535.html","label":"finance.yahoo.com"}],"parties":[{"role":"Named utility / authority","name":"Southwestern Public Service Company (SPS)"}],"groups":["utility:special contract:pending"],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"71467c40dcb68f72","state":"TX","tracker":"delay","section":"projects","title":"Stargate / Abilene (Phase 1)","summary":"900 MW BTM gas microgrid + grid blend at 1.2 GW. Continuing. Additional 4.5 GW gas capacity secured by Crusoe.","scope":"Record-specific: Abilene","status":"delayed","date":null,"sources":[{"url":"https://www.datacenterdynamics.com/en/news/crusoe-secures-45gw-of-natural-gas-for-ai-data-centers-report/","label":"www.datacenterdynamics.com"},{"url":"https://frontier.datacenterstress.com/","label":"frontier.datacenterstress.com"}],"parties":[{"role":"Operator","name":"Crusoe"},{"role":"Named customer","name":"Microsoft / OpenAI / Oracle"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"d96680676aa3d9ea","state":"TX","tracker":"delay","section":"county_restrictions","title":"Sulphur Springs (Hopkins County)","summary":"The Sulphur Springs City Council on September 1, 2026 rejected, 4-3, Councilman Jay Julian's motion to audit compliance with the city's Chapter 380 economic development agreement with SSDC1, LLC for a proposed data center. The developer's attorney told the council that construction litigation had paused work under force majeure provisions and that a restraining order was dissolved July 22. CyrusOne, now associated with the project, scheduled a community town hall for September 24 at the Sulphur Springs Civic Center.","scope":"city: Sulphur Springs (Hopkins County)","status":"denied","date":"2026-09-01","sources":[{"url":"https://www.ssnewstelegram.com/news/article_fa28b31a-399e-4426-b79f-9d0d25ddb277.html","label":"www.ssnewstelegram.com"}],"parties":[{"role":"Authority","name":"Sulphur Springs City Council"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"3d7707fd83b91f79","state":"TX","tracker":"delay","section":"county_restrictions","title":"Taylor","summary":"Five Taylor residents sued to stop a 135,000 sq ft data center with an on-site electrical substation on land deeded in 1999 as parkland. Judge Ryan Larson initially issued a temporary block but dismissed the case on Oct. 8, 2025, ruling residents lacked standing. Construction is proceeding. The Blueprint Data Centers project involves a 60 MW capacity, $1 billion in investment, 52 acres, 135,000 square feet of building space. The developer promised 30 permanent jobs. Opposition was led by Griffin family plaintiffs, Taylor community residents (led by Carrie D'Anna), and Halt the BPP Project in Taylor. Lawsuit dismissed October 8, 2025; construction is proceeding. Update 2026-09-17: Attorney General Ken Paxton announced on September 17, 2026 an investigation into whether land in Taylor that was conveyed in 1999 for future parkland can lawfully be used for a private 60 MW AI data center. The Taylor Economic Development Corporation sold the tract in April 2025 for $10 million to NCP Travis TPP Project, LLC, an entity tied to Blueprint Projects Data Centers. The office will examine whether the trust and restrictions in the 1999 deed were properly modified, released or terminated. If the property remains subject to a charitable trust or other restriction, the Attorney General said he will seek court intervention. The official release URL returned an access error and is listed as found by the Data Center Census changelog. (Previously recorded as approved, dated 2025-09-26.)","scope":"local: Taylor","status":"pending","date":"2026-09-17","sources":[{"url":"https://datacenterwatch.substack.com/p/briefing-10032025","label":"datacenterwatch.substack.com"},{"url":"https://www.datacenterdynamics.com/en/news/blueprint-projects-gets-greenlight-for-data-center-in-taylor-texas/","label":"www.datacenterdynamics.com"},{"url":"https://taylortx.gov/1293/Blueprint-Projects-Data-Center","label":"taylortx.gov"},{"url":"https://www.kut.org/energy-environment/2025-09-26/taylor-texas-blueprint-data-centers-lawsuit","label":"www.kut.org"},{"url":"https://www.kut.org/energy-environment/2025-10-08/judge-dismissed-lawsuit-taylor-data-center-blueprint-texas","label":"www.kut.org"},{"url":"https://www.kvue.com/article/news/local/taylor-residents-data-center-concerns/269-5a505a20-d721-4c49-85a4-4f78c27bfc7c","label":"www.kvue.com"},{"url":"https://texasscorecard.com/local/paxton-begins-investigation-into-planned-data-center-in-taylor/","label":"texasscorecard.com"},{"url":"https://www.texasattorneygeneral.gov/news/releases/attorney-general-paxton-investigates-ai-data-center-development-taylor-over-potential-misuse-land","label":"www.texasattorneygeneral.gov"}],"parties":[{"role":"Authority","name":"Taylor"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"090f1a8f3d512ef7","state":"TX","tracker":"delay","section":"county_restrictions","title":"Taylor","summary":"Five Taylor residents sued to stop a 135,000 sq ft data center with an on-site electrical substation on land deeded in 1999 as parkland. Judge Ryan Larson initially issued a temporary block but dismissed the case on Oct. 8, 2025, ruling residents lacked standing. Construction is proceeding. The Blueprint Data Centers project involves a 60 MW capacity, $1 billion in investment, 52 acres, 135,000 square feet of building space. The developer promised 30 permanent jobs. Opposition was led by Griffin family plaintiffs, Taylor community residents (led by Carrie D'Anna), and Halt the BPP Project in Taylor. Lawsuit dismissed October 8, 2025; construction is proceeding.","scope":"local: Taylor","status":"approved","date":"2025-09-26","sources":[{"url":"https://datacenterwatch.substack.com/p/briefing-10032025","label":"datacenterwatch.substack.com"},{"url":"https://www.datacenterdynamics.com/en/news/blueprint-projects-gets-greenlight-for-data-center-in-taylor-texas/","label":"www.datacenterdynamics.com"},{"url":"https://taylortx.gov/1293/Blueprint-Projects-Data-Center","label":"taylortx.gov"},{"url":"https://www.kut.org/energy-environment/2025-09-26/taylor-texas-blueprint-data-centers-lawsuit","label":"www.kut.org"},{"url":"https://www.kut.org/energy-environment/2025-10-08/judge-dismissed-lawsuit-taylor-data-center-blueprint-texas","label":"www.kut.org"},{"url":"https://www.kvue.com/article/news/local/taylor-residents-data-center-concerns/269-5a505a20-d721-4c49-85a4-4f78c27bfc7c","label":"www.kvue.com"}],"parties":[{"role":"Authority","name":"Taylor"}],"groups":[],"attribution":"DataCenterTracker.org, CC BY 4.0","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"7d4ea42dca3eafa1","state":"TX","tracker":"delay","section":"county_restrictions","title":"Temple (Bell County)","summary":"At its meeting on Thursday, September 17, 2026 the Temple City Council approved amendments to the Unified Development Code that set minimum development standards for new data centers and require future data center projects to obtain a conditional use permit. At the same meeting the council approved voluntary annexation, planned development light industrial zoning and development agreements for a new data center project. Other reports identify the project as part of Rowan's Temple data center campus.","scope":"city: Temple (Bell County)","status":"enacted","date":"2026-09-17","sources":[{"url":"https://www.kcentv.com/article/news/local/temple-city-council-new-data-center-requirements-development-agreement/500-34548ff0-f338-452a-8ba1-16c7b687d254","label":"www.kcentv.com"}],"parties":[{"role":"Authority","name":"Temple City Council"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"ad4e34e0dfe00af1","state":"TX","tracker":"delay","section":"utility_actions","title":"Texas (statewide)","summary":"Gov. Greg Abbott on June 10, 2026 released six data center legislative priorities for the 2027 session and issued immediate directives to state agencies.","scope":"Record-specific: TX","status":"effective","date":"2026-06-10","sources":[{"url":"https://www.texastribune.org/2026/06/10/texas-greg-abbott-data-centers-regulation-sales-tax/","label":"www.texastribune.org"},{"url":"https://thehill.com/homenews/state-watch/5920754-abbott-texas-data-center-limits/","label":"thehill.com"},{"url":"https://gov.texas.gov/news/post/governor-abbott-announces-puc-and-ercot-actions-protecting-residential-ratepayers-from-data-center-costs","label":"gov.texas.gov"}],"parties":[{"role":"Named utility / authority","name":"Texas (statewide)"}],"groups":["utility:policy:effective"],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"3ef9200b981fb042","state":"TX","tracker":"delay","section":"jurisdictional_actions","title":"Texas (statewide)","summary":"BNEF estimates the audit could delay 49.8 GW of data center load and cost projects up to $15 billion; Texas also enacted SB 6 (2025) creating large-load curtailment and cost-allocation rules.","scope":"state: Texas (statewide)","status":"audit_paused","date":"2026-08-03","sources":[{"url":"https://www.houstonpublicmedia.org/articles/news/energy-environment/2026/08/03/558529/gov-greg-abbott-pauses-new-data-centers-until-ercot-puct-audit-energy-water-usage/","label":"www.houstonpublicmedia.org"},{"url":"https://www.texastribune.org/2026/08/14/texas-data-center-approval-pause-ercot-power-grid/","label":"www.texastribune.org"},{"url":"https://www.powermag.com/texas-audit-could-delay-49-8-gw-of-data-center-load-cost-projects-up-to-15-billion-bnef-warns/","label":"www.powermag.com"}],"parties":[{"role":"Authority","name":"Gov. Greg Abbott / ERCOT / PUCT"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"9e802ea7b758dc81","state":"TX","tracker":"delay","section":"jurisdictional_actions","title":"Texas (statewide)","summary":"The directive states that data centers must share the duty to protect Texas water and that the Texas Water Code requires a complete and accurate water use survey. Failing to return the survey is a Class C misdemeanor. As few as 28 percent of surveyed data centers responded in recent years; TWDB surveyed 329 facilities in 2025 with just under 30 percent compliance. TWDB is to coordinate with the PUCT and ERCOT, whose August 3, 2026 data center audit also covers water consumption and supply sources.","scope":"state: Texas (statewide)","status":"in_force","date":"2026-09-14","sources":[{"url":"https://gov.texas.gov/news/post/governor-abbott-directs-twdb-to-penalize-data-center-reporting-failures","label":"gov.texas.gov"},{"url":"https://www.texastribune.org/2026/09/14/texas-data-centers-abbott-water-survey-enforcement/","label":"www.texastribune.org"}],"parties":[{"role":"Authority","name":"Governor Greg Abbott / Texas Water Development Board"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"7732734a798f9223","state":"TX","tracker":"delay","section":"jurisdictional_actions","title":"Texas (statewide)","summary":"Governor Greg Abbott directed the Texas Commission on Environmental Quality to halt all permits sought by data center projects until ERCOT completes its audit of data centers in the interconnection process. The directive ties the end of the halt to completion of the ERCOT, PUCT and Texas Water Development Board audits and sets no fixed end date. TCEQ must give the Office of the Governor a compliance update by October 19, 2026. This follows the August 3 interconnection audit directive and the September 14 water reporting enforcement directive. Next date: 2026-10-19.","scope":"state: Texas (statewide)","status":"in_force","date":"2026-09-21","sources":[{"url":"https://gov.texas.gov/news/post/governor-abbott-directs-tceq-to-halt-data-center-permits","label":"gov.texas.gov"},{"url":"https://www.cbsnews.com/texas/news/texas-gov-greg-abbott-pause-new-data-center-permits-sept-21-2026/","label":"www.cbsnews.com"},{"url":"https://www.texastribune.org/2026/09/21/texas-data-center-moratorium-water-energy/","label":"www.texastribune.org"}],"parties":[{"role":"Authority","name":"Office of the Governor (directive to the Texas Commission on Environmental Quality)"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"d5e9430ff55efa0d","state":"TX","tracker":"delay","section":"projects","title":"Texas Statewide Data Center Interconnection Audit (ERCOT Batch Zero)","summary":"Sherman/Grayson County is a major semiconductor and data-infrastructure growth corridor (Texas Instruments, GlobiTech) directly affected by the pause; this is a statewide interconnection-integrity action rather than a single-project denial.","scope":"Record-specific: Statewide (ERCOT footprint, incl. Sherman/Grayson County)","status":"halted","date":"2026-08","sources":[{"url":"https://www.hklaw.com/en/insights/publications/2026/08/texas-gov-abbott-directs-data-center-audit","label":"www.hklaw.com"},{"url":"https://www.texastribune.org/2026/08/14/texas-data-center-approval-pause-ercot-power-grid/","label":"www.texastribune.org"},{"url":"https://www.akingump.com/en/insights/alerts/texas-pauses-data-center-interconnections-pending-statewide-audit","label":"www.akingump.com"}],"parties":[{"role":"Operator","name":"Multiple (up to ~300 projects statewide, including Sherman/Grayson County pipeline)"}],"groups":["delay:interconnection_queue:halted"],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"87485593349454ff","state":"TX","tracker":"delay","section":"projects","title":"Voltagrid Shackelford County","summary":"210 industrial gas gensets. 700 MW. Off-grid. Delayed to 2029 per SemiAnalysis due to gas pipeline permitting.","scope":"Record-specific: Shackelford County","status":"delayed","date":null,"sources":[{"url":"https://www.constructionowners.com/news/oracle-and-openai-to-power-new-texas-data-center-off-the-grid","label":"www.constructionowners.com"}],"parties":[{"role":"Operator","name":"Voltagrid"},{"role":"Named customer","name":"STACK Infrastructure / Oracle / OpenAI"}],"groups":["delay:gas_pipeline_delay:delayed"],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"2b48aea344656e70","state":"TX","tracker":"delay","section":"county_restrictions","title":"Weatherford","summary":"Black Mountain ,  the Fort Worth-based energy consortium developing the separate $10B, 530-acre data center campus in southeast Fort Worth (see fort-worth-southeast-tx-2025-01-01) ,  purchased over 2,000 acres near Azle Highway and Pearson Ranch Road in unincorporated Parker County, about 7 miles northeast of downtown Weatherford, assessed at over $57 million per the Parker County Appraisal District","scope":"county: Weatherford","status":"pending","date":"2026-06-09","sources":[{"url":"https://www.star-telegram.com/news/local/article315770666.html","label":"www.star-telegram.com"},{"url":"https://weatherfordtx.gov/m/newsflash/home/detail/647","label":"weatherfordtx.gov"},{"url":"https://weatherfordtx.gov/m/newsflash/Home/Detail/657","label":"weatherfordtx.gov"},{"url":"https://www.govtech.com/artificial-intelligence/north-texas-counties-continue-weighing-data-center-proposals","label":"www.govtech.com"},{"url":"https://www.springtownepigraph.com/article/1488,no-action-regarding-proposed-data-center","label":"www.springtownepigraph.com"}],"parties":[{"role":"Authority","name":"Board of Supervisors/County Commission"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"c0108d2842a6c97a","state":"TX","tracker":"delay","section":"county_restrictions","title":"Weatherford (Parker County)","summary":"Black Mountain, the Fort Worth-based energy consortium developing the separate $10B, 530-acre data center campus in southeast Fort Worth (see fort-worth-southeast-tx-2025-01-01), purchased over 2,000 acres near Azle Highway and Pearson Ranch Road in unincorporated Parker County, about 7 miles northeast of downtown Weatherford, assessed at over $57 million per the Parker County Appraisal District. In April 2025 the TCEQ approved a related shell entity, Fort Worth Power Core LLC (Black Mountain CEO Rhett Bennett listed as CEO), to operate five natural gas turbines at 501 Pearson Ranch Road as “backup/bridge power for a new data center”; Weatherford's city manager said he wasn't told of the filing until a reporter asked, calling it “concerning.” The City of Weatherford declined to add data centers as an allowed zoning use on Jan 16, 2026 (“data centers will remain NOT ALLOWED in Weatherford”) and, after the Star-Telegram broke the land-purchase/TCEQ story on May 20, 2026, issued a follow-up statement criticizing the lack of public notice for the turbine permit; the property itself sits outside city limits, so Weatherford has no zoning authority over it. On June 9, 2026, the Parker County Commissioners Court held a standing-room-only special meeting and unanimously passed a resolution opposing large-scale data center development, specifically targeting high-volume open-loop water cooling, and committing to deny tax abatements to such projects, while acknowledging Texas counties have little formal land-use authority. Bennett has said Black Mountain is only “considering” a “potential” site here and disputes that Weatherford ever told the company it wasn't wanted; no source confirms the project has been formally committed or abandoned as of this writing.","scope":"county: Weatherford (Parker County)","status":"proposed","date":"2026-06-09","sources":[{"url":"https://www.star-telegram.com/news/local/article315770666.html","label":"www.star-telegram.com"},{"url":"https://weatherfordtx.gov/m/newsflash/home/detail/647","label":"weatherfordtx.gov"},{"url":"https://weatherfordtx.gov/m/newsflash/Home/Detail/657","label":"weatherfordtx.gov"},{"url":"https://www.govtech.com/artificial-intelligence/north-texas-counties-continue-weighing-data-center-proposals","label":"www.govtech.com"},{"url":"https://www.springtownepigraph.com/article/1488,no-action-regarding-proposed-data-center","label":"www.springtownepigraph.com"},{"url":"https://www.springtownepigraph.com/article/1548,parker-county-approves-resolution-opposing-data-centers","label":"www.springtownepigraph.com"},{"url":"https://www.yahoo.com/news/us/articles/overwhelming-outrage-public-floods-courthouse-191100405.html","label":"www.yahoo.com"}],"parties":[{"role":"Authority","name":"Weatherford (Parker County)"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"44a2c2af078e7a65","state":"TX","tracker":"delay","section":"county_restrictions","title":"Wichita Falls","summary":"The Wichita Falls City Council is scheduled to consider creating an Emerging Technologies Advisory Commission at its Tuesday, October 6, 2026 meeting. Mayor Tim Short said the panel would focus on artificial intelligence governance, data privacy and security, and data center development. Skybox bought 225 acres in the Wichita Falls Business Park in February for a hyperscale data center. Event date is the report date. Next date: 2026-10-06.","scope":"city: Wichita Falls","status":"pending","date":"2026-10-01","sources":[{"url":"https://www.timesrecordnews.com/story/news/local/2026/10/01/mayor-says-wichita-falls-to-form-data-center-commission/92039235007/","label":"www.timesrecordnews.com"}],"parties":[{"role":"Authority","name":"Wichita Falls City Council"}],"groups":[],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"0b4408147f79994e","state":"TX","tracker":"delay","section":"projects","title":"Wichita Falls Data Center Rezoning (Data Nova X)","summary":"Rezoning rejection halted the project as proposed; local coverage noted skepticism over the developer's rebranding partway through the approval process.","scope":"Record-specific: Wichita Falls","status":"cancelled","date":"2026","sources":[{"url":"https://www.timesrecordnews.com/story/news/local/2026/05/05/wichita-falls-city-council-rejects-data-center/89943201007/","label":"www.timesrecordnews.com"}],"parties":[{"role":"Operator","name":"Data Nova X (originally proposed under different developer branding)"}],"groups":["delay:zoning_denial:cancelled","delay:community_opposition:cancelled"],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"4bbd796802e5b2a9","state":"TX","tracker":"moratorium","section":"local","title":"Brownsville starts 90-day data center moratorium process","summary":"The Brownsville City Commission voted at its early September 2026 meeting (Resolution No. 2026-121) to begin the formal process for a 90-day moratorium on high-intensity data processing facilities. The moratorium would last 90 days after ordinance adoption, with one possible 90-day extension under state law. Two public hearings are required before a final determination, and the commission also reactivated its Environmental and Conservation Task Force to study data centers.","scope":"Local: Brownsville","status":"proposed","date":"2026-09","sources":[{"url":"https://myrgv.com/publications/the-brownsville-herald/2026/09/02/brownsville-commissioners-move-forward-with-data-center-moratorium/","label":"myrgv.com"}],"parties":[{"role":"Jurisdiction","name":"Brownsville"}],"groups":["restriction:local:proposed"],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"347c664b42d6867c","state":"TX","tracker":"moratorium","section":"local","title":"Citizen-petitioned 18-month data center moratorium","summary":"On September 23, 2026, the Lubbock City Council voted 5-2 to initiate the state-required process for a 90-day moratorium on rezoning, building permit and annexation applications for large-scale data centers; two public hearings are required before it takes effect.","scope":"Local: Lubbock","status":"proposed","date":"2026-09","sources":[{"url":"https://www.tpr.org/news/2026-09-23/lubbock-takes-first-step-toward-data-center-moratorium-questions-remain-with-approaching-legislative-session","label":"www.tpr.org"}],"parties":[{"role":"Jurisdiction","name":"Lubbock"}],"groups":["restriction:local:proposed"],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"5a6631afcf14f245","state":"TX","tracker":"moratorium","section":"local","title":"County moratorium on data centers","summary":"Resolution calling for stricter statewide standards on data centers: public disclosure of electrical demand, water consumption, cooling technologies, and infrastructure impact. Non-binding. The measure has no documented term.","scope":"Local: Milam County","status":"enacted","date":"2026-01","sources":[{"url":"https://www.multistate.us/insider/2026/8/19/the-local-fight-over-data-centers-a-texas-case-study","label":"www.multistate.us"}],"parties":[{"role":"Jurisdiction","name":"Milam County"}],"groups":["restriction:local:enacted"],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"c154399207131e2f","state":"TX","tracker":"moratorium","section":"local","title":"Data center moratorium not pursued","summary":"At an Aug. 26, 2026 session, the San Antonio City Council declined to move forward with a temporary moratorium on data center development requested by three council members, with four members in support. The council instead directed work on Unified Development Code amendments, with a council vote on those amendments planned for Oct. 15. No formal vote tally on the moratorium was reported.","scope":"Local: San Antonio","status":"failed","date":"2026-08","sources":[{"url":"https://www.sacurrent.com/?p=419403","label":"www.sacurrent.com"}],"parties":[{"role":"Jurisdiction","name":"San Antonio"}],"groups":["restriction:local:failed"],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"98ec338e6e03cba0","state":"TX","tracker":"moratorium","section":"states","title":"Enforcement of data center water-use reporting requirements","summary":"On September 14, 2026, Gov. Greg Abbott directed the Texas Water Development Board to use its statutory authority to compel large water users, including data centers, to file the water-use information required by the Texas Water Code. He told the board to refer violations to county or district attorneys and to notify the Texas Commission on Environmental Quality, since noncompliance can make a facility ineligible for certain Chapter 11 water permits, amendments or renewals. Abbott asked for a compliance update by October 14, 2026. This is an enforcement directive, not a moratorium.","scope":"State: Texas","status":"enacted","date":"2026-09","sources":[{"url":"https://www.ksat.com/news/texas/2026/09/14/gov-greg-abbott-orders-texas-water-agency-to-penalize-data-centers-that-dont-report-their-water-usage/","label":"www.ksat.com"}],"parties":[],"groups":["restriction:states:enacted"],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"707703d5f96368d1","state":"TX","tracker":"moratorium","section":"states","title":"Freeze on new data center grid connections pending audit","summary":"Gov. Abbott directed PUCT and ERCOT on Aug 3, 2026 to audit every data center project advancing through the ERCOT interconnection process (1,800+ requests) before any of them moves forward. The directive has no carve-out: it asks each project to report projected consumption and any on-site generation it is building or procuring, and projects that fail compliance face denial of grid access. Non-ERCOT areas fall outside it only because ERCOT does not serve them.","scope":"State: Texas","status":"pause","date":"2026-08","sources":[{"url":"https://gov.texas.gov/news/post/governor-abbott-directs-comprehensive-data-center-audit","label":"gov.texas.gov"}],"parties":[],"groups":["restriction:states:pause"],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"41c39b9ee7a58df2","state":"TX","tracker":"moratorium","section":"states","title":"Governor's directive pausing ERCOT data center interconnection pending an audit (not a construction ban)","summary":"Gov. Abbott directed ERCOT and the PUC on Aug 3, 2026 to freeze data center interconnection progress pending a comprehensive audit. ERCOT halted its Batch Zero large-load study and suspended Aug 7 classification notices. The directive does not exempt projects with on-site generation; it requires them to report that generation as part of the audit. The hold runs until the audit is complete, which ERCOT is targeting for Dec 10, 2026. Same action as the Texas executive directive entry.","scope":"State: Texas","status":"pause","date":"2026-08","sources":[{"url":"https://www.texastribune.org/2026/08/03/texas-data-center-project-audit-greg-abbott/","label":"www.texastribune.org"}],"parties":[],"groups":["restriction:states:pause"],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"9607cd1000488b0d","state":"TX","tracker":"moratorium","section":"states","title":"Halt on state environmental permits for data center projects pending audits","summary":"On September 21, 2026, Gov. Greg Abbott directed the Texas Commission on Environmental Quality to halt all permits sought by data center projects until ERCOT and the Texas Water Development Board complete their data center audits, and said no state agency should move forward with regulatory approvals for data center development until that information is in hand. TCEQ must report compliance to the Governor by October 19, 2026. The Texas Tribune reported that the order appears aimed at developers building behind-the-meter generation, who could otherwise avoid the ERCOT interconnection audit. It is statewide and not limited to the ERCOT region.","scope":"State: Texas","status":"pause","date":"2026-09","sources":[{"url":"https://gov.texas.gov/news/post/governor-abbott-directs-tceq-to-halt-data-center-permits","label":"gov.texas.gov"}],"parties":[],"groups":["restriction:states:pause"],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"4cf9e86df26cb47f","state":"TX","tracker":"moratorium","section":"local","title":"Hays County data center moratorium (failed)","summary":"Water advocates identified 5 data centers proposed for the Hays County, Texas, region during historic drought (proposed by CloudBurst Data Centers / Highlander SC One LLC) (1.2GW, $1.2B, 200 acres). County Judge Ruben Becerra proposed a 30-day moratorium on high-water-use building permits but was forced to table it after county attorneys warned it would trigger a lawsuit the county would likely lose. San Marcos City Council scored a major win Feb. 17, voting 5-2 at 2:14 AM to block a $1.5B Highlander SM One data center after 8+ hours of testimony from 100+ residents. Hays County aquifers are at historic lows. Hays County Judge Ruben Becerra proposed a moratorium on permits for large industrial water users (>20,000 gal/day) but the Commissioners Court tabled it on Feb 25 after county attorneys warned it would trigger a lawsuit the county would lose. State Sen. Bettencourt warned counties lack authority for moratoriums. Water advocates have identified 5 potential data center developments in the region and continue organizing.","scope":"Local: Hays County","status":"failed","date":"2026-02","sources":[{"url":"https://www.kut.org/energy-environment/2026-02-26/hays-county-tx-data-centers-water-resources","label":"www.kut.org"}],"parties":[{"role":"Jurisdiction","name":"Hays County"}],"groups":["restriction:local:failed"],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"8fbbd5e4d1430368","state":"TX","tracker":"moratorium","section":"local","title":"Hood County data center moratorium (failed)","summary":"Hood County (40 miles SW of Fort Worth) has received at least five data center applications (proposed by Sailfish Development). Commissioners voted down a proposed moratorium 3-2, twice, despite 8 hours of public testimony. The 2,100-acre Comanche Circle project sits in a recharge zone for the Upper Trinity Aquifer and could use 1M gallons/day. State Sen. Paul Bettencourt sent a letter to AG Paxton warning that counties lack constitutional authority to impose moratoriums, chilling local opposition. Residents are still adjusting to a nearby bitcoin mining operation in Granbury where neighbors report constant noise affecting people, pets, and wildlife. Hood County commissioners rejected the moratorium a second time on Feb 25, 2026, in a 3-2 vote. Instead, they voted to seek an opinion from TX Attorney General Ken Paxton on whether counties have authority to enact development moratoriums. State Sen. Paul Bettencourt warned counties lack constitutional authority for moratoriums. Residents called for commissioner resignations after the second block.","scope":"Local: Hood County","status":"failed","date":"2026-02","sources":[{"url":"https://www.texastribune.org/2026/02/10/texas-hood-county-rejects-data-center-development-pause-ai/","label":"www.texastribune.org"}],"parties":[{"role":"Jurisdiction","name":"Hood County"}],"groups":["restriction:local:failed"],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"35fcd20bf3d4a4e3","state":"TX","tracker":"moratorium","section":"states","title":"Large-load interconnection standards and grid curtailment","summary":"Enacted 2025 (PUCT rulemaking in 2026): interconnection standards and cost obligations on 75 MW+ loads plus authority for ERCOT to curtail or remotely disconnect data centers during grid emergencies. A grid-reliability restriction.","scope":"State: Texas","status":"enacted","date":"2025-06","sources":[{"url":"https://www.utilitydive.com/news/texas-law-gives-grid-operator-power-to-disconnect-data-centers-during-crisi/751587/","label":"www.utilitydive.com"}],"parties":[],"groups":["restriction:states:enacted"],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"9cd0e5a2740b6579","state":"TX","tracker":"moratorium","section":"local","title":"Local moratorium on data centers for a stated term","summary":"120-day moratorium on data center development within city limits, adopted in May 2026 after public hearings, running to mid-October; commissioners approved first reading of a 60-day extension to December in August, second reading pending. City hired Ambiotec Engineering to study water, wastewater and power impacts. The measure has a stated duration whose end date is not recorded.","scope":"Local: Harlingen","status":"enacted","date":"2026-05","sources":[{"url":"https://www.krgv.com/news/harlingen-city-officials-look-to-extend-moratorium-on-data-centers","label":"www.krgv.com"}],"parties":[{"role":"Jurisdiction","name":"Harlingen"}],"groups":["restriction:local:enacted"],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"cb4fae95f6ec62e9","state":"TX","tracker":"moratorium","section":"local","title":"Local moratorium on data centers with no end date","summary":"City Council voted 3-2 to permanently ban data centers within city limits. Defines data center as any facility over 500 sq ft used primarily to house servers. Not a moratorium -- a standing zoning ban. The measure has no end date by design and applies at a threshold of 500 sq ft.","scope":"Local: Athens","status":"enacted","date":"2026-08","sources":[{"url":"https://www.kltv.com/2026/08/25/athens-city-council-votes-3-2-favor-ordinance-banning-data-centers/","label":"www.kltv.com"}],"parties":[{"role":"Jurisdiction","name":"Athens"}],"groups":["restriction:local:enacted"],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"8725a51570228ad5","state":"TX","tracker":"moratorium","section":"local","title":"Local moratorium on data centers with no end date","summary":"Council unanimously approved data center policy: 300-ft buffer from residential/ecological sites, special use permit, no more tax breaks. Developers must submit resource use, emissions, noise, and water treatment plans. The measure has no end date by design.","scope":"Local: El Paso","status":"enacted","date":"2026-01","sources":[{"url":"https://elpasomatters.org/2026/07/20/meta-data-center-el-paso-texas-policy-framework-rules-city-council/","label":"elpasomatters.org"}],"parties":[{"role":"Jurisdiction","name":"El Paso"}],"groups":["restriction:local:enacted"],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"49d98f654070e13e","state":"TX","tracker":"moratorium","section":"local","title":"Local moratorium on data centers with no end date","summary":"Council voted unanimously to require Special Use Permit for data centers; banned in all residential areas. Each proposal needs two public hearings. The measure has no end date by design.","scope":"Local: Lewisville","status":"enacted","date":"2026-01","sources":[{"url":"https://www.keranews.org/news/2026-06-25/lewisville-sets-proactive-limits-on-ai-data-centers-before-they-arrive","label":"www.keranews.org"}],"parties":[{"role":"Jurisdiction","name":"Lewisville"}],"groups":["restriction:local:enacted"],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"1526c144af9c4197","state":"TX","tracker":"moratorium","section":"local","title":"Local moratorium on data centers with no end date","summary":"City amended regulations to require a Specific Use Permit for data centers, updated definitions, and established per-project public review. The measure has no end date by design.","scope":"Local: Princeton","status":"enacted","date":"2026-01","sources":[{"url":"https://princetonherald.com/2026/06/11/council-plans-data-center-regulation/","label":"princetonherald.com"}],"parties":[{"role":"Jurisdiction","name":"Princeton"}],"groups":["restriction:local:enacted"],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"226d9579a44729dd","state":"TX","tracker":"moratorium","section":"local","title":"Moratorium on AI data centers and battery energy storage systems","summary":"Austin County Commissioners Court unanimously adopted a countywide moratorium on new AI data center and battery energy storage developments in unincorporated areas while the county evaluates impacts and a possible energy development zone.","scope":"Local: Austin County","status":"enacted","date":"2026-07","sources":[{"url":"https://kwhi.com/2026/07/28/austin-co-commissioners-enact-moratorium-on-data-centers-battery-energy-storage-systems/","label":"kwhi.com"}],"parties":[{"role":"Jurisdiction","name":"Austin County"}],"groups":["restriction:local:enacted"],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"036f9e40cb83532e","state":"TX","tracker":"moratorium","section":"local","title":"One-year data center moratorium (rescinded)","summary":"Hill County commissioners adopted a one-year moratorium on May 12, 2026 (the first by a Texas county) but rescinded it June 5, 2026 after a developer lawsuit.","scope":"Local: Hill County","status":"failed","date":"2026-06","sources":[{"url":"https://www.texastribune.org/2026/06/05/texas-hill-county-moratorium-rescinded-data-centers/","label":"www.texastribune.org"}],"parties":[{"role":"Jurisdiction","name":"Hill County"}],"groups":["restriction:local:failed"],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"e3d9ca006093dd8c","state":"TX","tracker":"moratorium","section":"local","title":"Proposed 90-day data center moratorium","summary":"City Council unanimously approved the first steps on Aug. 11, 2026 to initiate a 90-day moratorium on new data center applications, expected to take effect in early 2027; not yet in force.","scope":"Local: Fort Worth","status":"proposed","date":"2026-08","sources":[{"url":"https://www.keranews.org/news/2026-08-12/data-center-moratorium-takes-first-steps-after-fort-worth-city-councils-unanimous-vote","label":"www.keranews.org"}],"parties":[{"role":"Jurisdiction","name":"Fort Worth"}],"groups":["restriction:local:proposed"],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"aa120245d3cde2b5","state":"TX","tracker":"moratorium","section":"local","title":"Proposed local moratorium on data centers","summary":"Council unanimously directed staff to draft Land Development Code rules for large-scale data centers (location, size, water, noise, heat, lighting) that could regulate or ban facilities above 75 MW, with the first ordinance due back by end of 2026. At least five members back a full ban on hyperscale sites. No moratorium is in effect. The measure has no documented term and applies at a threshold of 75 MW.","scope":"Local: Austin","status":"proposed","date":"2026-08","sources":[{"url":"https://www.kut.org/austin/2026-08-27/austin-tx-data-center-rules-bans-city-council","label":"www.kut.org"}],"parties":[{"role":"Jurisdiction","name":"Austin"}],"groups":["restriction:local:proposed"],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"29dbbc44e88a23f5","state":"TX","tracker":"moratorium","section":"local","title":"Proposed local moratorium on data centers","summary":"Council directed staff to pursue prohibiting data centers in all zoning districts; requires data centers to fully fund own infrastructure. Drought context: severe water crisis threatening city reservoirs. The measure has no documented term.","scope":"Local: Corpus Christi","status":"proposed","date":"2026-01","sources":[{"url":"https://www.kristv.com/news/local-news/in-your-neighborhood/corpus-christi/corpus-christi-city-council-moves-to-develop-data-center-regulations-for-the-city","label":"www.kristv.com"}],"parties":[{"role":"Jurisdiction","name":"Corpus Christi"}],"groups":["restriction:local:proposed"],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"d4ddebe26453aec0","state":"TX","tracker":"moratorium","section":"local","title":"Proposed local moratorium on data centers","summary":"The Denton City Council held the first of two required public hearings on a proposed temporary data center moratorium on September 23, 2026, with no vote taken; the second hearing is scheduled for October 27.","scope":"Local: Denton","status":"proposed","date":"2026-09","sources":[{"url":"https://www.cbsnews.com/texas/news/denton-data-center-moratorium-public-hearing-september-2026/","label":"www.cbsnews.com"}],"parties":[{"role":"Jurisdiction","name":"Denton"}],"groups":["restriction:local:proposed"],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"f141990e3f9ddb5c","state":"TX","tracker":"moratorium","section":"local","title":"Proposed local moratorium on data centers","summary":"Proposed framework: 5-acre min lot, 65 dB noise limit, banned in residential/agricultural/commercial districts. Staff recommended ordinance over moratorium. Not yet enacted. The measure has no documented term.","scope":"Local: Mesquite","status":"proposed","date":"2026-01","sources":[{"url":"https://www.keranews.org/news/2026-06-02/mesquite-city-council-tighter-regulations-data-centers-north-texas","label":"www.keranews.org"}],"parties":[{"role":"Jurisdiction","name":"Mesquite"}],"groups":["restriction:local:proposed"],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"fd40bfb18bd582d1","state":"TX","tracker":"moratorium","section":"local","title":"Proposed local moratorium on data centers with no end date","summary":"Council directed staff to amend zoning to prohibit data centers in all districts -- effectively a proposed citywide ban. Escalation from April 2026 regulations requiring 5,000-ft setbacks. The measure has no end date by design.","scope":"Local: Forney","status":"proposed","date":"2026-01","sources":[{"url":"https://www.inforney.com/business/forney-council-moves-to-ban-future-data-centers-a/article_33ab99f5-98c7-446c-80c9-40f5e7953141.html","label":"www.inforney.com"}],"parties":[{"role":"Jurisdiction","name":"Forney"}],"groups":["restriction:local:proposed"],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"0148c0779dde3d94","state":"TX","tracker":"moratorium","section":"local","title":"Rejected county moratorium on data centers","summary":"Commissioners rejected a 12-month moratorium on large-scale data centers, BESS, and power generation in Precinct 4; cited legal risk after Hill County's moratorium drew a $100M federal lawsuit. The measure has no documented term.","scope":"Local: Tom Green County","status":"failed","date":"2026-01","sources":[{"url":"https://sanangelolive.com/news/county/2026-06-02/tom-green-county-commissioners-reject-data-center-moratorium","label":"sanangelolive.com"}],"parties":[{"role":"Jurisdiction","name":"Tom Green County"}],"groups":["restriction:local:failed"],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"8d85cc66b1113104","state":"TX","tracker":"moratorium","section":"states","title":"Relating to the temporary sales and use tax exemptions for certain tangible personal property related to data centers and large data center projects.","summary":"Texas SB2888 (89th Legislature Regular Session): Relating to the temporary sales and use tax exemptions for certain tangible personal property related to data centers and large data center projects.. Last action 2025-04-07: Referred to Finance.","scope":"State: Texas","status":"proposed","date":"2025-04","sources":[{"url":"https://capitol.texas.gov/BillLookup/History.aspx?LegSess=89R&Bill=SB2888","label":"capitol.texas.gov"}],"parties":[],"groups":["restriction:states:proposed"],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"07b7360c48f3c46e","state":"TX","tracker":"moratorium","section":"states","title":"Texas: The Texas Public Utility Commission is implementing SB 6 through multiple rulemaking dockets.","summary":"The Texas Public Utility Commission is implementing SB 6 through multiple rulemaking dockets. PUCT Chair Thomas Gleeson proposed rules to pare back proposed requirements for data centers seeking to connect to ERCOT, lowering fees for large loads and adding alternative standards developers can use to demonstrate site readiness. April 17, 2026 was the deadline for stakeholder comments on PUCT draft rule 16 TAC §25.194 implementing SB 6's interconnection standards for new loads of 75 MW or greater. The draft rule includes non-refundable interconnection fees of $50,000/MW of contracted peak demand, requires customers to pay 100% of direct interconnection costs (radial lines, substations), and demands additional security for transmission upgrades. ERCOT is tracking approximately 410 GW of large-load interconnection requests, ~87% from data centers. The PUCT approved ERCOT's 'Batch Zero' large-load interconnection framework, which batches large-load (75MW+) interconnection requests, roughly 89% of which are data centers. ERCOT is now tracking 438,000+ MW in the interconnection queue, up from ~410GW cited in March 2026 reporting.","scope":"State: Texas","status":"enacted","date":"2026-03","sources":[{"url":"https://www.ercot.com/news/release/06182026-puct-approves-ercots","label":"www.ercot.com"}],"parties":[],"groups":["restriction:states:enacted"],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"bfaeb2b05925f9bf","state":"TX","tracker":"moratorium","section":"local","title":"Zoning ban on data centers","summary":"City Council voted 4-3 on June 16, 2026 to define data centers and make them ineligible in all zoning districts, becoming the first Texas city to ban them; relies on home-rule authority.","scope":"Local: San Marcos","status":"enacted","date":"2026-06","sources":[{"url":"https://www.texastribune.org/2026/06/30/texas-san-marcos-data-center-ban-zoning-laws/","label":"www.texastribune.org"}],"parties":[{"role":"Jurisdiction","name":"San Marcos"}],"groups":["restriction:local:enacted"],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"e9f7b95e804c6ca8","state":"TX","tracker":"permits","section":"building_permits","title":"100 - 500 blocks Farmer Road (FM 3325) at Interstate 20","summary":"From Unzoned to G, PD for R1, R2, D,G, I uses excluding \"A-5\" One-Family Residential development, permanent asphalt or concrete batch plant, data center; development waivers & MFD site plan waiver requested, PD site plan required","scope":"Facility:","status":"Approved","date":"2026-06-23","sources":[{"url":"https://aca-prod.accela.com/CFW/Cap/GlobalSearchResults.aspx?QueryText=ZC-26-042","label":"aca-prod.accela.com"}],"parties":[{"role":"Applicant","name":"Dean & Lawson Foundation/Standbridge Co/Westwoods"}],"groups":[],"attribution":"City of Fort Worth public permit records","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"cf5172341a84d580","state":"TX","tracker":"permits","section":"building_permits","title":"10200 HICKS FIELD RD","summary":"X TEAM /// ACS Data Center Campus - Substation Retaining Wall X TEAM /// New retaining wall for the ACS Data Center substation.","scope":"Facility:","status":"Awaiting Client Reply","date":"2026-07-01","sources":[{"url":"https://aca-prod.accela.com/CFW/Cap/GlobalSearchResults.aspx?QueryText=PB26-09476","label":"aca-prod.accela.com"}],"parties":[],"groups":[],"attribution":"City of Fort Worth public permit records","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"922bcfcd7ba85a52","state":"TX","tracker":"permits","section":"building_permits","title":"10200 HICKS FIELD RD","summary":"X TEAM /// ACS Data Center Phase I Substation X TEAM /// /// Control House Permit Related to PB26-06650","scope":"Facility:","status":"Awaiting Client Reply","date":"2026-08-03","sources":[{"url":"https://aca-prod.accela.com/CFW/Cap/GlobalSearchResults.aspx?QueryText=PB26-11057","label":"aca-prod.accela.com"}],"parties":[],"groups":[],"attribution":"City of Fort Worth public permit records","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"10e48c220888d657","state":"TX","tracker":"permits","section":"building_permits","title":"14460 HERITAGE PKWY","summary":"DFW SPE 2 LLC construct a 1 story 156,866 sf data center with attached administration area.","scope":"Facility:","status":"Pending","date":"2026-09-25","sources":[{"url":"https://aca-prod.accela.com/CFW/Cap/GlobalSearchResults.aspx?QueryText=PB26-13452","label":"aca-prod.accela.com"}],"parties":[{"role":"Applicant","name":"ADL DEVELOPMENT LP"}],"groups":[],"attribution":"City of Fort Worth public permit records","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"1d285ec89fdd2e99","state":"TX","tracker":"permits","section":"building_permits","title":"26060025 FOR REVIEW ONLY WAY","summary":"X TEAM /// ACS Data Center - Phase 2 Perimeter Fence X TEAM /// Refer to PB26-08604","scope":"Facility:","status":"Awaiting Client Reply","date":"2026-07-01","sources":[{"url":"https://aca-prod.accela.com/CFW/Cap/GlobalSearchResults.aspx?QueryText=PB26-09538","label":"aca-prod.accela.com"}],"parties":[],"groups":[],"attribution":"City of Fort Worth public permit records","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"fc585283d077c847","state":"TX","tracker":"permits","section":"building_permits","title":"300 TRINITY CAMPUS CIR","summary":"Data Center Enclosure & MEP Upgrades/Tarrant County College District B1_WORK_DESC","scope":"Facility:","status":"Pending","date":"2026-09-16","sources":[{"url":"https://aca-prod.accela.com/CFW/Cap/GlobalSearchResults.aspx?QueryText=PB26-13010","label":"aca-prod.accela.com"}],"parties":[{"role":"Applicant","name":"TARRANT COUNTY COLLEGE DISTRICT"}],"groups":[],"attribution":"City of Fort Worth public permit records","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"dd9af85c89631161","state":"TX","tracker":"permits","section":"building_permits","title":"3500 - 4712 (evens) Lon Stephenson Road, 7500 - 7524 (evens) Anglin Drive, 7701-7721 (odds) Forest Hill Drive","summary":"From PD 1420 Planned Development for Specific Uses including data center with development standards: Site plan required to Amend \"PD1420\" to add electrical substation, increase maximum building height to 70 feet, increase maximum building setback to 150 feet, data center to be parked at 1 per 4 employees; site plan included","scope":"Facility:","status":"Not recorded","date":"2026-04-08","sources":[{"url":"https://aca-prod.accela.com/CFW/Cap/GlobalSearchResults.aspx?QueryText=ZC-26-041","label":"aca-prod.accela.com"}],"parties":[{"role":"Applicant","name":"Walls, Nanowsky, et al/Black Mountain,Halff Assoc."}],"groups":[],"attribution":"City of Fort Worth public permit records","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"0a00a998629f9cdd","state":"TX","tracker":"permits","section":"building_permits","title":"3545 WISEMAN BLVD, City of San Antonio, TX 78251","summary":"SP - Special Project - SAT14 Data Center Site Foundation & Shell - 3545 Wiseman Blvd., Bldgs 1-3 / Phased","scope":"Facility:","status":"Not recorded","date":"2026-09-29","sources":[{"url":"https://aca-prod.accela.com/COSA/Cap/GlobalSearchResults.aspx?QueryText=COM-RW-PMT26-41100031","label":"aca-prod.accela.com"}],"parties":[{"role":"Applicant","name":"Lauren Alexander"}],"groups":[],"attribution":"City of San Antonio public permit records","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"f064b5bae972e4b6","state":"TX","tracker":"permits","section":"building_permits","title":"4500 & 8212 Anglin Circle","summary":"From AG, B to PD for certain I uses plus data center with development waivers for increased setbacks, height; site plan waived","scope":"Facility:","status":"Approved","date":"2026-04-28","sources":[{"url":"https://aca-prod.accela.com/CFW/Cap/GlobalSearchResults.aspx?QueryText=ZC-25-205","label":"aca-prod.accela.com"}],"parties":[{"role":"Applicant","name":"Black Mountain Power, et al / Halff Assoc."}],"groups":[],"attribution":"City of Fort Worth public permit records","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"4fbf86b98e824b96","state":"TX","tracker":"permits","section":"building_permits","title":"5207 ROGERS RD, City of San Antonio, TX 78251","summary":"SP-Special Project-Vantage Data Centers TX21 - Lightspeed-5207 ROGERS RD","scope":"Facility:","status":"Not recorded","date":"2026-06-04","sources":[{"url":"https://aca-prod.accela.com/COSA/Cap/GlobalSearchResults.aspx?QueryText=COM-FEN-PMT26-40600084","label":"aca-prod.accela.com"}],"parties":[{"role":"Applicant","name":"amanda flores"}],"groups":[],"attribution":"City of San Antonio public permit records","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"a44c364341099759","state":"TX","tracker":"permits","section":"building_permits","title":"5207 ROGERS RD, City of San Antonio, TX 78251","summary":"SP-Special Project-Vantage Data Centers TX21 - Lightspeed-5207 ROGERS RD","scope":"Facility:","status":"Not recorded","date":"2026-06-04","sources":[{"url":"https://aca-prod.accela.com/COSA/Cap/GlobalSearchResults.aspx?QueryText=COM-ITM-PMT26-40800032","label":"aca-prod.accela.com"}],"parties":[{"role":"Applicant","name":"amanda flores"}],"groups":[],"attribution":"City of San Antonio public permit records","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"56f6d4e8f2044691","state":"TX","tracker":"permits","section":"building_permits","title":"5207 ROGERS RD, City of San Antonio, TX 78251","summary":"SPC Site Work - Vantage Data Center -TX-22 Site Work Only-5207 ROGERS RD","scope":"Facility:","status":"Not recorded","date":"2026-02-13","sources":[{"url":"https://aca-prod.accela.com/COSA/Cap/GlobalSearchResults.aspx?QueryText=COM-SIT-PMT25-40100446","label":"aca-prod.accela.com"}],"parties":[{"role":"Applicant","name":"amanda flores"}],"groups":[],"attribution":"City of San Antonio public permit records","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"306ad04601724574","state":"TX","tracker":"permits","section":"building_permits","title":"5207 ROGERS RD, City of San Antonio, TX 78251","summary":"SP-Special Project-Vantage Data Centers TX21 - Lightspeed-5207 ROGERS RD","scope":"Facility:","status":"Not recorded","date":"2026-06-04","sources":[{"url":"https://aca-prod.accela.com/COSA/Cap/GlobalSearchResults.aspx?QueryText=COM-SIT-PMT26-40100192","label":"aca-prod.accela.com"}],"parties":[{"role":"Applicant","name":"amanda flores"}],"groups":[],"attribution":"City of San Antonio public permit records","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"daf1a88d2042e66c","state":"TX","tracker":"permits","section":"building_permits","title":"7000 BURLESON RD BLDG B UNIT 100","summary":"ePlan: Commercial Expedited Review - Finish out to Expand Data Center into existing Shell Areas. Scope of Work Includes 2 AE Transformers. (10000 SF)","scope":"Facility:","status":"Active","date":"2025-12-18","sources":[{"url":"https://data.austintexas.gov/d/3syk-w9eu","label":"data.austintexas.gov"}],"parties":[],"groups":[],"attribution":"City of Austin issued construction permits open data","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"676fa8921ed399c8","state":"TX","tracker":"permits","section":"building_permits","title":"811 CLAYTON LN","summary":"ePlan: Commercial Expedited Review - [APPROVED] New Construction of Exterior Pad for Modular Data Center Foundation.","scope":"Facility:","status":"Active","date":"2026-03-27","sources":[{"url":"https://data.austintexas.gov/d/3syk-w9eu","label":"data.austintexas.gov"}],"parties":[{"role":"Applicant","name":"Novo Construction **Main** Novo Construction **Main**"}],"groups":[],"attribution":"City of Austin issued construction permits open data","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"d1bc564d5e8d852a","state":"TX","tracker":"permits","section":"building_permits","title":"9700 TEAM ROCKBROOK PKWY","summary":"X TEAM /// Edged Energy Outpost Building 2 X TEAM /// 488,628 SF 196MW data center","scope":"Facility:","status":"Plan Review","date":"2026-08-03","sources":[{"url":"https://aca-prod.accela.com/CFW/Cap/GlobalSearchResults.aspx?QueryText=PB26-11109","label":"aca-prod.accela.com"}],"parties":[],"groups":[],"attribution":"City of Fort Worth public permit records","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"d45dd83aa361256d","state":"TX","tracker":"permits","section":"air_permits","title":"ABILENE DATA CENTER BUILDINGS 9 & 10","summary":"Facility listing; a permit or issuance date may not be recorded.","scope":"Facility: Abilene","status":"Not recorded","date":null,"sources":[{"url":"https://echodata.epa.gov/echo/echo_rest_services.get_facility_info?output=JSON&p_fn=DATA%20CENTER&responseset=1000","label":"echodata.epa.gov"},{"url":"https://echo.epa.gov/detailed-facility-report?fid=TXR1536ZN","label":"echo.epa.gov"}],"parties":[],"groups":[],"attribution":"U.S. EPA ECHO","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"7d3396f79270dbc1","state":"TX","tracker":"permits","section":"air_permits","title":"ABILENE DATA CENTER BUILDINGS B9B10","summary":"Facility listing; a permit or issuance date may not be recorded.","scope":"Facility: Abilene","status":"Not recorded","date":null,"sources":[{"url":"https://echodata.epa.gov/echo/echo_rest_services.get_facility_info?output=JSON&p_fn=DATA%20CENTER&responseset=1000","label":"echodata.epa.gov"},{"url":"https://echo.epa.gov/detailed-facility-report?fid=110071960386","label":"echo.epa.gov"}],"parties":[],"groups":[],"attribution":"U.S. EPA ECHO","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"3b83b0d023f845b3","state":"TX","tracker":"permits","section":"air_permits","title":"ABILENE DATA CENTER SUBSTATION","summary":"Facility listing; a permit or issuance date may not be recorded.","scope":"Facility: Abilene","status":"Not recorded","date":null,"sources":[{"url":"https://echodata.epa.gov/echo/echo_rest_services.get_facility_info?output=JSON&p_fn=DATA%20CENTER&responseset=1000","label":"echodata.epa.gov"},{"url":"https://echo.epa.gov/detailed-facility-report?fid=110071947112","label":"echo.epa.gov"}],"parties":[],"groups":[],"attribution":"U.S. EPA ECHO","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"49a83a626a73bce4","state":"TX","tracker":"permits","section":"air_permits","title":"ACS - DFW CAMPUS HICKS FIELD (TURNER CONSTRUCTION COMPANY)","summary":"Facility listing; a permit or issuance date may not be recorded.","scope":"Facility: Fort Worth","status":"PENDING","date":"2025-11-04","sources":[{"url":"https://data.texas.gov/resource/t34q-qzi3.json","label":"data.texas.gov"},{"url":"https://data.texas.gov/d/t34q-qzi3","label":"data.texas.gov"}],"parties":[],"groups":[],"attribution":"Texas TCEQ air permit records","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"2d3f4349a5ac39e4","state":"TX","tracker":"permits","section":"substations","title":"ACS Data Center Phase I Substation","summary":"X TEAM /// ACS Data Center Phase I Substation X TEAM /// /// Control House Permit Related to PB26-06650 Commercial Accessory Structure New","scope":"Facility: Tarrant","status":"Awaiting Client Reply","date":"2026-08-03","sources":[{"url":"https://aca-prod.accela.com/CFW/Cap/GlobalSearchResults.aspx?QueryText=PB26-11057","label":"aca-prod.accela.com"}],"parties":[],"groups":[],"attribution":"City of Fort Worth public permit records","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"789c3fa633d6a175","state":"TX","tracker":"permits","section":"air_permits","title":"ADC DFW03 (ALIGNED DATA CENTERS MANSFIELD PROPCO LLC)","summary":"Facility listing; a permit or issuance date may not be recorded.","scope":"Facility: Mansfield","status":"ACTIVE","date":"2025-08-12","sources":[{"url":"https://data.texas.gov/resource/t34q-qzi3.json","label":"data.texas.gov"},{"url":"https://data.texas.gov/d/t34q-qzi3","label":"data.texas.gov"}],"parties":[],"groups":[],"attribution":"Texas TCEQ air permit records","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"3ee0ec0060052ef4","state":"TX","tracker":"permits","section":"air_permits","title":"ADVANCED SOLUTIONS INC DATA OPERATIONS CENTER","summary":"Facility listing; a permit or issuance date may not be recorded.","scope":"Facility: Richardson","status":"Not recorded","date":null,"sources":[{"url":"https://echodata.epa.gov/echo/echo_rest_services.get_facility_info?output=JSON&p_fn=DATA%20CENTER&responseset=1000","label":"echodata.epa.gov"},{"url":"https://echo.epa.gov/detailed-facility-report?fid=110033529055","label":"echo.epa.gov"}],"parties":[],"groups":[],"attribution":"U.S. EPA ECHO","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"55f7392fd0e4bb11","state":"TX","tracker":"permits","section":"air_permits","title":"AIG DATA CENTER","summary":"Facility listing; a permit or issuance date may not be recorded.","scope":"Facility: Amarillo","status":"Not recorded","date":null,"sources":[{"url":"https://echodata.epa.gov/echo/echo_rest_services.get_facility_info?output=JSON&p_fn=DATA%20CENTER&responseset=1000","label":"echodata.epa.gov"},{"url":"https://echo.epa.gov/detailed-facility-report?fid=110037907432","label":"echo.epa.gov"}],"parties":[],"groups":[],"attribution":"U.S. EPA ECHO","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"722d7fa9be100c07","state":"TX","tracker":"permits","section":"air_permits","title":"AIG TECHNOLOGIES DATA CENTER","summary":"Facility listing; a permit or issuance date may not be recorded.","scope":"Facility: Fort Worth","status":"Not recorded","date":null,"sources":[{"url":"https://echodata.epa.gov/echo/echo_rest_services.get_facility_info?output=JSON&p_fn=DATA%20CENTER&responseset=1000","label":"echodata.epa.gov"},{"url":"https://echo.epa.gov/detailed-facility-report?fid=110033431935","label":"echo.epa.gov"}],"parties":[],"groups":[],"attribution":"U.S. EPA ECHO","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"7a6ae62613ad133a","state":"TX","tracker":"permits","section":"air_permits","title":"ALBORZ DATA CENTER","summary":"Facility listing; a permit or issuance date may not be recorded.","scope":"Facility: Happy","status":"Not recorded","date":null,"sources":[{"url":"https://echodata.epa.gov/echo/echo_rest_services.get_facility_info?output=JSON&p_fn=DATA%20CENTER&responseset=1000","label":"echodata.epa.gov"},{"url":"https://echo.epa.gov/detailed-facility-report?fid=110070949304","label":"echo.epa.gov"}],"parties":[],"groups":[],"attribution":"U.S. EPA ECHO","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"cd832f210fd36ac0","state":"TX","tracker":"permits","section":"air_permits","title":"ALIGNED DATA CENTER MEMORY TECH PHASE 1 ADDITION","summary":"Facility listing; a permit or issuance date may not be recorded.","scope":"Facility: Plano","status":"Not recorded","date":null,"sources":[{"url":"https://echodata.epa.gov/echo/echo_rest_services.get_facility_info?output=JSON&p_fn=DATA%20CENTER&responseset=1000","label":"echodata.epa.gov"},{"url":"https://echo.epa.gov/detailed-facility-report?fid=110071345231","label":"echo.epa.gov"}],"parties":[],"groups":[],"attribution":"U.S. EPA ECHO","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"1ea1a263a6fda00b","state":"TX","tracker":"permits","section":"air_permits","title":"ALIGNED PLANO DFW04","summary":"Facility listing; a permit or issuance date may not be recorded.","scope":"Facility: Plano","status":"Not recorded","date":null,"sources":[{"url":"https://echodata.epa.gov/echo/echo_rest_services.get_facility_info?output=JSON&p_sic=7374&responseset=1000","label":"echodata.epa.gov"},{"url":"https://echo.epa.gov/detailed-facility-report?fid=110071849069","label":"echo.epa.gov"}],"parties":[],"groups":[],"attribution":"U.S. EPA ECHO","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"3152159c88e3af9e","state":"TX","tracker":"permits","section":"air_permits","title":"ALIGNED PLANO DFW04 (ALIGNED DATA CENTERS PLANO PROPCO LLC)","summary":"Facility listing; a permit or issuance date may not be recorded.","scope":"Facility: Collin","status":"ACTIVE","date":"2024-09-18","sources":[{"url":"https://data.texas.gov/resource/t34q-qzi3.json","label":"data.texas.gov"},{"url":"https://data.texas.gov/d/t34q-qzi3","label":"data.texas.gov"}],"parties":[],"groups":[],"attribution":"Texas TCEQ air permit records","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"ef05e902a2047021","state":"TX","tracker":"permits","section":"air_permits","title":"AMAZON DATA CENTER SH 211","summary":"Facility listing; a permit or issuance date may not be recorded.","scope":"Facility: San Antonio","status":"Not recorded","date":null,"sources":[{"url":"https://echodata.epa.gov/echo/echo_rest_services.get_facility_info?output=JSON&p_fn=DATA%20CENTER&responseset=1000","label":"echodata.epa.gov"},{"url":"https://echo.epa.gov/detailed-facility-report?fid=110071065018","label":"echo.epa.gov"}],"parties":[],"groups":[],"attribution":"U.S. EPA ECHO","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"52b3a37e248735be","state":"TX","tracker":"permits","section":"air_permits","title":"AMAZON WEB SERVICE DATA CENTER","summary":"Facility listing; a permit or issuance date may not be recorded.","scope":"Facility: San Antonio","status":"Not recorded","date":null,"sources":[{"url":"https://echodata.epa.gov/echo/echo_rest_services.get_facility_info?output=JSON&p_fn=DATA%20CENTER&responseset=1000","label":"echodata.epa.gov"},{"url":"https://echo.epa.gov/detailed-facility-report?fid=110070930014","label":"echo.epa.gov"}],"parties":[],"groups":[],"attribution":"U.S. EPA ECHO","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"5b9442d1a508453b","state":"TX","tracker":"permits","section":"air_permits","title":"AREP LAS COLINAS DATA CENTER","summary":"Facility listing; a permit or issuance date may not be recorded.","scope":"Facility: Irving","status":"Not recorded","date":null,"sources":[{"url":"https://echodata.epa.gov/echo/echo_rest_services.get_facility_info?output=JSON&p_sic=7374&responseset=1000","label":"echodata.epa.gov"},{"url":"https://echo.epa.gov/detailed-facility-report?fid=110071898846","label":"echo.epa.gov"}],"parties":[],"groups":[],"attribution":"U.S. EPA ECHO","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"fe4e385f87634945","state":"TX","tracker":"permits","section":"air_permits","title":"ARGO DATA CENTER","summary":"Facility listing; a permit or issuance date may not be recorded.","scope":"Facility: Afton","status":"Not recorded","date":null,"sources":[{"url":"https://echodata.epa.gov/echo/echo_rest_services.get_facility_info?output=JSON&p_fn=DATA%20CENTER&responseset=1000","label":"echodata.epa.gov"},{"url":"https://echo.epa.gov/detailed-facility-report?fid=110071142021","label":"echo.epa.gov"}],"parties":[],"groups":[],"attribution":"U.S. EPA ECHO","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"c75594e81e99be85","state":"TX","tracker":"permits","section":"air_permits","title":"AUS02 DATA CENTER","summary":"Facility listing; a permit or issuance date may not be recorded.","scope":"Facility: Temple","status":"Not recorded","date":null,"sources":[{"url":"https://echodata.epa.gov/echo/echo_rest_services.get_facility_info?output=JSON&p_fn=DATA%20CENTER&responseset=1000","label":"echodata.epa.gov"},{"url":"https://echo.epa.gov/detailed-facility-report?fid=110072201355","label":"echo.epa.gov"}],"parties":[],"groups":[],"attribution":"U.S. EPA ECHO","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"ad291fa970ab9945","state":"TX","tracker":"permits","section":"air_permits","title":"AUS02 FACILITY (PRIME DATA CENTERS LLC)","summary":"Facility listing; a permit or issuance date may not be recorded.","scope":"Facility: Caldwell","status":"PENDING","date":"2026-08-06","sources":[{"url":"https://data.texas.gov/resource/msah-s2rv.json","label":"data.texas.gov"},{"url":"https://data.texas.gov/d/msah-s2rv","label":"data.texas.gov"}],"parties":[],"groups":[],"attribution":"Texas TCEQ air permit records","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"212c7e49fa33a9ae","state":"TX","tracker":"permits","section":"air_permits","title":"AUS04 DATA CENTER","summary":"Facility listing; a permit or issuance date may not be recorded.","scope":"Facility: Temple","status":"Not recorded","date":null,"sources":[{"url":"https://echodata.epa.gov/echo/echo_rest_services.get_facility_info?output=JSON&p_fn=DATA%20CENTER&responseset=1000","label":"echodata.epa.gov"},{"url":"https://echo.epa.gov/detailed-facility-report?fid=110072189269","label":"echo.epa.gov"}],"parties":[],"groups":[],"attribution":"U.S. EPA ECHO","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"bc761d2b268f785b","state":"TX","tracker":"permits","section":"air_permits","title":"AUSTIN DATA CENTER","summary":"Facility listing; a permit or issuance date may not be recorded.","scope":"Facility: Austin","status":"Not recorded","date":null,"sources":[{"url":"https://echodata.epa.gov/echo/echo_rest_services.get_facility_info?output=JSON&p_fn=DATA%20CENTER&responseset=1000","label":"echodata.epa.gov"},{"url":"https://echo.epa.gov/detailed-facility-report?fid=110033535057","label":"echo.epa.gov"}],"parties":[],"groups":[],"attribution":"U.S. EPA ECHO","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"b7eced91211c9046","state":"TX","tracker":"permits","section":"air_permits","title":"AUSTIN DATA CENTER 2","summary":"Facility listing; a permit or issuance date may not be recorded.","scope":"Facility: Pflugerville","status":"Not recorded","date":null,"sources":[{"url":"https://echodata.epa.gov/echo/echo_rest_services.get_facility_info?output=JSON&p_fn=DATA%20CENTER&responseset=1000","label":"echodata.epa.gov"},{"url":"https://echo.epa.gov/detailed-facility-report?fid=110071659424","label":"echo.epa.gov"}],"parties":[],"groups":[],"attribution":"U.S. EPA ECHO","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"f404945dae6e7861","state":"TX","tracker":"permits","section":"air_permits","title":"AWS ALE 64","summary":"Facility listing; a permit or issuance date may not be recorded.","scope":"Facility: San Antonio","status":"Not recorded","date":null,"sources":[{"url":"https://echodata.epa.gov/echo/echo_rest_services.get_facility_info?output=JSON&p_sic=7374&responseset=1000","label":"echodata.epa.gov"},{"url":"https://echo.epa.gov/detailed-facility-report?fid=110072247236","label":"echo.epa.gov"}],"parties":[],"groups":[],"attribution":"U.S. EPA ECHO","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"39c74eb1da4ade2a","state":"TX","tracker":"permits","section":"air_permits","title":"AWS-PROJECT EAGLE (AMAZON DATA SERVICES INC)","summary":"Facility listing; a permit or issuance date may not be recorded.","scope":"Facility: Wharton","status":"ACTIVE","date":"2026-07-31","sources":[{"url":"https://data.texas.gov/resource/tzyg-j7q4.json","label":"data.texas.gov"},{"url":"https://data.texas.gov/d/tzyg-j7q4","label":"data.texas.gov"}],"parties":[],"groups":[],"attribution":"Texas TCEQ air permit records","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"7d0575690b3e80d2","state":"TX","tracker":"permits","section":"air_permits","title":"BANK OF AMERICA - COIT DATA CENTER","summary":"Facility listing; a permit or issuance date may not be recorded.","scope":"Facility: Plano","status":"Not recorded","date":null,"sources":[{"url":"https://echodata.epa.gov/echo/echo_rest_services.get_facility_info?output=JSON&p_fn=DATA%20CENTER&responseset=1000","label":"echodata.epa.gov"},{"url":"https://echo.epa.gov/detailed-facility-report?fid=110062491744","label":"echo.epa.gov"}],"parties":[],"groups":[],"attribution":"U.S. EPA ECHO","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"7a1fb08ca9d6b442","state":"TX","tracker":"permits","section":"air_permits","title":"BARBER LAKE DATA CENTER PROJECT (CIPHER BARBER LAKE LLC)","summary":"Facility listing; a permit or issuance date may not be recorded.","scope":"Facility: Colorado City","status":"ACTIVE","date":"2025-08-27","sources":[{"url":"https://data.texas.gov/resource/5eqq-7nad.json","label":"data.texas.gov"},{"url":"https://data.texas.gov/d/5eqq-7nad","label":"data.texas.gov"}],"parties":[],"groups":[],"attribution":"Texas TCEQ air permit records","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"a25719c646f9e122","state":"TX","tracker":"permits","section":"air_permits","title":"BLUESTEM TECHNOLOGY PARK (BLUESTEM TECHNOLOGY PARK LLC)","summary":"Facility listing; a permit or issuance date may not be recorded.","scope":"Facility: Bell","status":"PENDING","date":"2026-08-12","sources":[{"url":"https://data.texas.gov/resource/msah-s2rv.json","label":"data.texas.gov"},{"url":"https://data.texas.gov/d/msah-s2rv","label":"data.texas.gov"}],"parties":[],"groups":[],"attribution":"Texas TCEQ air permit records","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"3776d51693e07ccb","state":"TX","tracker":"permits","section":"building_permits","title":"Bell County Appraisal District Parcels 7755, 24955, 106228, Temple, TX","summary":"Second and final reading of rezoning and binding site development plan FY-26-36-ZC, AG to PD LI on 316.13 acres; attachments are titled Project Lasso PD Conditions. The same agenda lists a development agreement with Rowan Lasso LLC for about 316 acres associated with Project Lasso (Phase 1B) of Rowan's Temple data center campus.","scope":"Facility:","status":"on agenda","date":"2026-09-17","sources":[{"url":"https://cityoftemple.primegov.com/Portal/Meeting?meetingTemplateId=13721","label":"cityoftemple.primegov.com"}],"parties":[{"role":"Applicant","name":"Rowan Lasso LLC"}],"groups":[],"attribution":"City of Temple, Texas","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"f25ac4d2ef6cfbb3","state":"TX","tracker":"permits","section":"air_permits","title":"CALDWELL VALLEY TECHNOLOGY PARK","summary":"Facility listing; a permit or issuance date may not be recorded.","scope":"Facility: Maxwell","status":"Not recorded","date":null,"sources":[{"url":"https://echodata.epa.gov/echo/echo_rest_services.get_facility_info?output=JSON&p_sic=7374&responseset=1000","label":"echodata.epa.gov"},{"url":"https://echo.epa.gov/detailed-facility-report?fid=TXR1574ZM","label":"echo.epa.gov"}],"parties":[],"groups":[],"attribution":"U.S. EPA ECHO","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"f3a14f6b0c575785","state":"TX","tracker":"permits","section":"air_permits","title":"CEMCO-348 CBP SWEETWATER 2 DATA CENTER (VAN EATON READY MIX INC)","summary":"Facility listing; a permit or issuance date may not be recorded.","scope":"Facility: Fisher","status":"PENDING","date":"2026-09-18","sources":[{"url":"https://data.texas.gov/resource/5eqq-7nad.json","label":"data.texas.gov"},{"url":"https://data.texas.gov/d/5eqq-7nad","label":"data.texas.gov"}],"parties":[],"groups":[],"attribution":"Texas TCEQ air permit records","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"449020c1c882fdf7","state":"TX","tracker":"permits","section":"air_permits","title":"CEMCO-403 & 365 CBP CLOCKTOWER DATA CENTER (VAN EATON READY MIX INC)","summary":"Facility listing; a permit or issuance date may not be recorded.","scope":"Facility: Hardeman","status":"ACTIVE","date":"2026-07-10","sources":[{"url":"https://data.texas.gov/resource/5eqq-7nad.json","label":"data.texas.gov"},{"url":"https://data.texas.gov/d/5eqq-7nad","label":"data.texas.gov"}],"parties":[],"groups":[],"attribution":"Texas TCEQ air permit records","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"a63a524ded0c2d55","state":"TX","tracker":"permits","section":"air_permits","title":"CINCO SITE (STREAMLINE UTILITY HOLDINGS LLC)","summary":"Facility listing; a permit or issuance date may not be recorded.","scope":"Facility: Medina","status":"ACTIVE","date":"2025-12-04","sources":[{"url":"https://data.texas.gov/resource/msah-s2rv.json","label":"data.texas.gov"},{"url":"https://data.texas.gov/d/msah-s2rv","label":"data.texas.gov"}],"parties":[],"groups":[],"attribution":"Texas TCEQ air permit records","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"e269ad1c3133897b","state":"TX","tracker":"permits","section":"air_permits","title":"CIRCE ENERGY DATA CENTERS E MONAHANS CAMPUS (CIRCE ENERGY LLC)","summary":"Facility listing; a permit or issuance date may not be recorded.","scope":"Facility: Ward","status":"ACTIVE","date":"2026-03-09","sources":[{"url":"https://data.texas.gov/resource/9iad-hrn8.json","label":"data.texas.gov"},{"url":"https://data.texas.gov/d/9iad-hrn8","label":"data.texas.gov"}],"parties":[],"groups":[],"attribution":"Texas TCEQ air permit records","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"c5992cfe6e3b0bba","state":"TX","tracker":"permits","section":"air_permits","title":"CIRCE PERMIAN DATA CENTER (CIRCE ENERGY LLC)","summary":"Facility listing; a permit or issuance date may not be recorded.","scope":"Facility: Ward","status":"ACTIVE","date":"2025-10-10","sources":[{"url":"https://data.texas.gov/resource/9iad-hrn8.json","label":"data.texas.gov"},{"url":"https://data.texas.gov/d/9iad-hrn8","label":"data.texas.gov"}],"parties":[],"groups":[],"attribution":"Texas TCEQ air permit records","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"85df0fbf033b2f5c","state":"TX","tracker":"permits","section":"air_permits","title":"CLOUDBURST DATA CENTERS (CLOUDBURST INC)","summary":"Facility listing; a permit or issuance date may not be recorded.","scope":"Facility: New Braunfels","status":"CANCELLED","date":"2025-10-22","sources":[{"url":"https://data.texas.gov/resource/msah-s2rv.json","label":"data.texas.gov"},{"url":"https://data.texas.gov/d/msah-s2rv","label":"data.texas.gov"}],"parties":[],"groups":[],"attribution":"Texas TCEQ air permit records","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"258fe1ab778545cd","state":"TX","tracker":"permits","section":"air_permits","title":"CLOUDBURST DATA CENTERS (EVOLVE HOLDINGS INC)","summary":"Facility listing; a permit or issuance date may not be recorded.","scope":"Facility: New Braunfels","status":"ACTIVE","date":"2025-10-22","sources":[{"url":"https://data.texas.gov/resource/msah-s2rv.json","label":"data.texas.gov"},{"url":"https://data.texas.gov/d/msah-s2rv","label":"data.texas.gov"}],"parties":[],"groups":[],"attribution":"Texas TCEQ air permit records","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"3d8243577936a745","state":"TX","tracker":"permits","section":"air_permits","title":"COLOVORE AUSTIN 1 (COLOVORE AUSTIN 1 LLC)","summary":"Facility listing; a permit or issuance date may not be recorded.","scope":"Facility: Hutto","status":"ACTIVE","date":"2025-12-22","sources":[{"url":"https://data.texas.gov/resource/msah-s2rv.json","label":"data.texas.gov"},{"url":"https://data.texas.gov/d/msah-s2rv","label":"data.texas.gov"}],"parties":[],"groups":[],"attribution":"Texas TCEQ air permit records","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"f84c4ffee02065f1","state":"TX","tracker":"permits","section":"building_permits","title":"COO-TEMPCOO26-38200706","summary":"SPC Microsoft-SAT15 Data Center Package1 Admin, COLO1 & 2","scope":"Facility:","status":"Inactive","date":"2026-08-17","sources":[{"url":"https://aca-prod.accela.com/COSA/Cap/GlobalSearchResults.aspx?QueryText=COO-TEMPCOO26-38200706","label":"aca-prod.accela.com"}],"parties":[],"groups":[],"attribution":"City of San Antonio public permit records","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"9e6f0077ade94e7a","state":"TX","tracker":"permits","section":"air_permits","title":"CyrusOne DFW20A DFW20B DFW20C","summary":"TCEQ completed a new permit by rule registration 184743 (30 TAC 106.511) for CyrusOne LLC at the DFW20A/B/C site on FM 488 south of FM 416 near Fairfield, received and completed 21 Jul 2026.","scope":"Facility: Fairfield","status":"Issued","date":"2026-07-21","sources":[{"url":"https://www2.tceq.texas.gov/airperm/index.cfm?fuseaction=airpermits.validate_search_criteria&proj_id=412304&proj_status_txt=ALL&program=NSR&out_form=web","label":"www2.tceq.texas.gov"}],"parties":[],"groups":[],"attribution":"Texas Commission on Environmental Quality","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"bc9ce76cb7c8b8d2","state":"TX","tracker":"permits","section":"air_permits","title":"DFW10 DFW11 DFW17A DFW17B DFW17C (CYRUSONE LLC)","summary":"Facility listing; a permit or issuance date may not be recorded.","scope":"Facility: Bosque","status":"ACTIVE","date":"2025-07-01","sources":[{"url":"https://data.texas.gov/resource/msah-s2rv.json","label":"data.texas.gov"},{"url":"https://data.texas.gov/d/msah-s2rv","label":"data.texas.gov"}],"parties":[],"groups":[],"attribution":"Texas TCEQ air permit records","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"767ee3b6d280e37b","state":"TX","tracker":"permits","section":"air_permits","title":"DFW6 (CYRUSONE LLC)","summary":"Facility listing; a permit or issuance date may not be recorded.","scope":"Facility: Richardson","status":"ACTIVE","date":"2024-06-12","sources":[{"url":"https://data.texas.gov/resource/t34q-qzi3.json","label":"data.texas.gov"},{"url":"https://data.texas.gov/d/t34q-qzi3","label":"data.texas.gov"}],"parties":[],"groups":[],"attribution":"Texas TCEQ air permit records","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"03a6e4c124186afb","state":"TX","tracker":"permits","section":"air_permits","title":"DFW7 DFW8 (CYRUSONE LLC)","summary":"Facility listing; a permit or issuance date may not be recorded.","scope":"Facility: Tarrant","status":"ACTIVE","date":"2024-10-15","sources":[{"url":"https://data.texas.gov/resource/t34q-qzi3.json","label":"data.texas.gov"},{"url":"https://data.texas.gov/d/t34q-qzi3","label":"data.texas.gov"}],"parties":[],"groups":[],"attribution":"Texas TCEQ air permit records","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"970e3442167349df","state":"TX","tracker":"permits","section":"air_permits","title":"DFW9 - DFW12 (DATABANK HOLDINGS LTD)","summary":"Facility listing; a permit or issuance date may not be recorded.","scope":"Facility: Ellis","status":"ACTIVE","date":"2024-12-19","sources":[{"url":"https://data.texas.gov/resource/t34q-qzi3.json","label":"data.texas.gov"},{"url":"https://data.texas.gov/d/t34q-qzi3","label":"data.texas.gov"}],"parties":[],"groups":[],"attribution":"Texas TCEQ air permit records","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"efeab6685e1a6a50","state":"TX","tracker":"permits","section":"air_permits","title":"DUNAMIS GAS (DUNAMIS BESS LLC)","summary":"Facility listing; a permit or issuance date may not be recorded.","scope":"Facility: Stockdale","status":"ACTIVE","date":"2026-04-21","sources":[{"url":"https://data.texas.gov/resource/msah-s2rv.json","label":"data.texas.gov"},{"url":"https://data.texas.gov/d/msah-s2rv","label":"data.texas.gov"}],"parties":[],"groups":[],"attribution":"Texas TCEQ air permit records","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"360ac9401e5f1f6f","state":"TX","tracker":"permits","section":"air_permits","title":"EL PASO 5MW DATA CENTER (CLOP EL PASO TX LLC)","summary":"Facility listing; a permit or issuance date may not be recorded.","scope":"Facility: El Paso","status":"ACTIVE","date":"2024-09-17","sources":[{"url":"https://data.texas.gov/resource/9iad-hrn8.json","label":"data.texas.gov"},{"url":"https://data.texas.gov/d/9iad-hrn8","label":"data.texas.gov"}],"parties":[],"groups":[],"attribution":"Texas TCEQ air permit records","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"f48c557e9f5fc7bb","state":"TX","tracker":"permits","section":"air_permits","title":"FERMI AMERICA PROJECT MATADOR (FERMI EQUIPMENT HOLDCO LLC)","summary":"Facility listing; a permit or issuance date may not be recorded.","scope":"Facility: Carson","status":"ACTIVE","date":"2025-08-01","sources":[{"url":"https://data.texas.gov/resource/5eqq-7nad.json","label":"data.texas.gov"},{"url":"https://data.texas.gov/d/5eqq-7nad","label":"data.texas.gov"}],"parties":[],"groups":[],"attribution":"Texas TCEQ air permit records","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"cd394a3563dda118","state":"TX","tracker":"permits","section":"building_permits","title":"FIR-FSP-APP26-22501987","summary":"ERRC - 5207 Rogers Road - Vantage Data Center TX-21 ERRCS","scope":"Facility:","status":"Additional Info Required","date":"2026-09-02","sources":[{"url":"https://aca-prod.accela.com/COSA/Cap/GlobalSearchResults.aspx?QueryText=FIR-FSP-APP26-22501987","label":"aca-prod.accela.com"}],"parties":[],"groups":[],"attribution":"City of San Antonio public permit records","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"0415f73e3872cfb4","state":"TX","tracker":"permits","section":"building_permits","title":"FIR-FSS-PMT26-22600856","summary":"$ - Vantage Data Center","scope":"Facility:","status":"Active","date":"2026-08-07","sources":[{"url":"https://aca-prod.accela.com/COSA/Cap/GlobalSearchResults.aspx?QueryText=FIR-FSS-PMT26-22600856","label":"aca-prod.accela.com"}],"parties":[],"groups":[],"attribution":"City of San Antonio public permit records","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"348e24837e59b16b","state":"TX","tracker":"permits","section":"substations","title":"From PD 1420 Planned Development for Specific Uses including data center with development standards","summary":"From PD 1420 Planned Development for Specific Uses including data center with development standards: Site plan required to Amend \"PD1420\" to add electrical substation, increase maximum building height to 70 feet, increase maximum building setback to 150 feet, data center to be parked at 1 per 4 employees;","scope":"Facility: Tarrant","status":"Not recorded","date":"2026-04-08","sources":[{"url":"https://aca-prod.accela.com/CFW/Cap/GlobalSearchResults.aspx?QueryText=ZC-26-041","label":"aca-prod.accela.com"}],"parties":[],"groups":[],"attribution":"City of Fort Worth public permit records","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"a785c9c82e156484","state":"TX","tracker":"permits","section":"air_permits","title":"GOLDENEYE (MONTERA INFRASTRUCTURE II LLC)","summary":"Facility listing; a permit or issuance date may not be recorded.","scope":"Facility: Harris","status":"ACTIVE","date":"2026-05-21","sources":[{"url":"https://data.texas.gov/resource/tzyg-j7q4.json","label":"data.texas.gov"},{"url":"https://data.texas.gov/d/tzyg-j7q4","label":"data.texas.gov"}],"parties":[],"groups":[],"attribution":"Texas TCEQ air permit records","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"2543a34b1d85bc2c","state":"TX","tracker":"permits","section":"air_permits","title":"GW RANCH ENERGY CENTER (PACIFICO GW LLC)","summary":"Facility listing; a permit or issuance date may not be recorded.","scope":"Facility: Pecos","status":"ACTIVE","date":"2025-08-04","sources":[{"url":"https://data.texas.gov/resource/9iad-hrn8.json","label":"data.texas.gov"},{"url":"https://data.texas.gov/d/9iad-hrn8","label":"data.texas.gov"}],"parties":[],"groups":[],"attribution":"Texas TCEQ air permit records","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"e198a4ab1f19304b","state":"TX","tracker":"permits","section":"air_permits","title":"HARVEY DFM (NYDIG DFM LLC)","summary":"Facility listing; a permit or issuance date may not be recorded.","scope":"Facility: Midland","status":"ACTIVE","date":"2026-03-05","sources":[{"url":"https://data.texas.gov/resource/9iad-hrn8.json","label":"data.texas.gov"},{"url":"https://data.texas.gov/d/9iad-hrn8","label":"data.texas.gov"}],"parties":[],"groups":[],"attribution":"Texas TCEQ air permit records","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"130f862ae453a6e6","state":"TX","tracker":"permits","section":"air_permits","title":"Hutto Data Center Campus, 4251 County Road 132","summary":"TCEQ completed a revision to permit by rule registration 174373 (30 TAC 106.511) for Hutto Data Center Campus LLC, received and completed 2 Jul 2026.","scope":"Facility: Hutto","status":"Issued","date":"2026-07-02","sources":[{"url":"https://www2.tceq.texas.gov/airperm/index.cfm?fuseaction=airpermits.validate_search_criteria&proj_id=411667&proj_status_txt=ALL&program=NSR&out_form=web","label":"www2.tceq.texas.gov"}],"parties":[],"groups":[],"attribution":"Texas Commission on Environmental Quality","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"b3c70654bd596642","state":"TX","tracker":"permits","section":"building_permits","title":"INV-COM-INV26-22703219","summary":"Vantage Data Center","scope":"Facility:","status":"Received","date":"2026-09-22","sources":[{"url":"https://aca-prod.accela.com/COSA/Cap/GlobalSearchResults.aspx?QueryText=INV-COM-INV26-22703219","label":"aca-prod.accela.com"}],"parties":[],"groups":[],"attribution":"City of San Antonio public permit records","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"f8f3e6369c008b04","state":"TX","tracker":"permits","section":"air_permits","title":"JAKE FACILITY (NYDIG DFM LLC)","summary":"Facility listing; a permit or issuance date may not be recorded.","scope":"Facility: Midland","status":"ACTIVE","date":"2026-05-13","sources":[{"url":"https://data.texas.gov/resource/9iad-hrn8.json","label":"data.texas.gov"},{"url":"https://data.texas.gov/d/9iad-hrn8","label":"data.texas.gov"}],"parties":[],"groups":[],"attribution":"Texas TCEQ air permit records","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"251c0e8dadafa910","state":"TX","tracker":"permits","section":"air_permits","title":"JOURNEY SITE (HOMEBOUND GROUP LLC)","summary":"Facility listing; a permit or issuance date may not be recorded.","scope":"Facility: Haskell","status":"ACTIVE","date":"2026-02-05","sources":[{"url":"https://data.texas.gov/resource/5eqq-7nad.json","label":"data.texas.gov"},{"url":"https://data.texas.gov/d/5eqq-7nad","label":"data.texas.gov"}],"parties":[],"groups":[],"attribution":"Texas TCEQ air permit records","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"0cea25b57adf12b5","state":"TX","tracker":"permits","section":"air_permits","title":"KLONDIKE PAD 1 (NYDIG DFM LLC)","summary":"Facility listing; a permit or issuance date may not be recorded.","scope":"Facility: Dawson","status":"ACTIVE","date":"2024-04-25","sources":[{"url":"https://data.texas.gov/resource/9iad-hrn8.json","label":"data.texas.gov"},{"url":"https://data.texas.gov/d/9iad-hrn8","label":"data.texas.gov"}],"parties":[],"groups":[],"attribution":"Texas TCEQ air permit records","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"ada6bd74c541feb5","state":"TX","tracker":"permits","section":"air_permits","title":"KMT AZURITE ENERGY (KMT AZURITE SOLAR LLC)","summary":"Facility listing; a permit or issuance date may not be recorded.","scope":"Facility: Pecos","status":"PENDING","date":"2026-07-23","sources":[{"url":"https://data.texas.gov/resource/9iad-hrn8.json","label":"data.texas.gov"},{"url":"https://data.texas.gov/d/9iad-hrn8","label":"data.texas.gov"}],"parties":[],"groups":[],"attribution":"Texas TCEQ air permit records","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"7a94485d477086b2","state":"TX","tracker":"permits","section":"air_permits","title":"LANCASTER DATA CENTER (LANCASTER DATA CENTER CAMPUS LP)","summary":"Facility listing; a permit or issuance date may not be recorded.","scope":"Facility: Lancaster","status":"ACTIVE","date":"2024-05-15","sources":[{"url":"https://data.texas.gov/resource/t34q-qzi3.json","label":"data.texas.gov"},{"url":"https://data.texas.gov/d/t34q-qzi3","label":"data.texas.gov"}],"parties":[],"groups":[],"attribution":"Texas TCEQ air permit records","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"6a38106156ec7dfb","state":"TX","tracker":"permits","section":"air_permits","title":"LBB120 HORIZON JUNCTION TECHNOLOGY PARK (AMAZON DATA SERVICES INC)","summary":"Facility listing; a permit or issuance date may not be recorded.","scope":"Facility: Floyd","status":"ACTIVE","date":"2026-06-10","sources":[{"url":"https://data.texas.gov/resource/5eqq-7nad.json","label":"data.texas.gov"},{"url":"https://data.texas.gov/d/5eqq-7nad","label":"data.texas.gov"}],"parties":[],"groups":[],"attribution":"Texas TCEQ air permit records","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"046155f86d0c8e59","state":"TX","tracker":"permits","section":"air_permits","title":"LONGHORN DATA CENTER","summary":"Facility listing; a permit or issuance date may not be recorded.","scope":"Facility: Abilene","status":"Operating","date":null,"sources":[{"url":"https://echodata.epa.gov/echo/echo_rest_services.get_facility_info?output=JSON&p_fn=DATA%20CENTER&responseset=1000","label":"echodata.epa.gov"},{"url":"https://echo.epa.gov/detailed-facility-report?fid=110072142010","label":"echo.epa.gov"}],"parties":[],"groups":[],"attribution":"U.S. EPA ECHO","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"b362e904b0f0554c","state":"TX","tracker":"permits","section":"air_permits","title":"LONGHORN DATA CENTER (ABILENE DATA CENTER CAMPUS MASTER ASSOCIATION)","summary":"Facility listing; a permit or issuance date may not be recorded.","scope":"Facility: Abilene","status":"ACTIVE","date":"2024-08-15","sources":[{"url":"https://data.texas.gov/resource/5eqq-7nad.json","label":"data.texas.gov"},{"url":"https://data.texas.gov/d/5eqq-7nad","label":"data.texas.gov"}],"parties":[],"groups":[],"attribution":"Texas TCEQ air permit records","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"c53cba0e1c0d979f","state":"TX","tracker":"permits","section":"air_permits","title":"LONGHORN DATA CENTER (CRUSOE TECHNOLOGIES LLC)","summary":"Facility listing; a permit or issuance date may not be recorded.","scope":"Facility: Abilene","status":"CANCELLED","date":"2024-08-15","sources":[{"url":"https://data.texas.gov/resource/5eqq-7nad.json","label":"data.texas.gov"},{"url":"https://data.texas.gov/d/5eqq-7nad","label":"data.texas.gov"}],"parties":[],"groups":[],"attribution":"Texas TCEQ air permit records","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"0f13f19e9ece7445","state":"TX","tracker":"permits","section":"air_permits","title":"LONGHORN DATA CENTER (ORACLE AMERICA INC)","summary":"Facility listing; a permit or issuance date may not be recorded.","scope":"Facility: Abilene","status":"ACTIVE","date":"2024-08-15","sources":[{"url":"https://data.texas.gov/resource/5eqq-7nad.json","label":"data.texas.gov"},{"url":"https://data.texas.gov/d/5eqq-7nad","label":"data.texas.gov"}],"parties":[],"groups":[],"attribution":"Texas TCEQ air permit records","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"2c0045b0cc1fefa2","state":"TX","tracker":"permits","section":"air_permits","title":"MEITNER ENERGY CENTER (FOUNDATIONAL SITE GROUP LLC)","summary":"Facility listing; a permit or issuance date may not be recorded.","scope":"Facility: Gray","status":"ACTIVE","date":"2026-05-01","sources":[{"url":"https://data.texas.gov/resource/5eqq-7nad.json","label":"data.texas.gov"},{"url":"https://data.texas.gov/d/5eqq-7nad","label":"data.texas.gov"}],"parties":[],"groups":[],"attribution":"Texas TCEQ air permit records","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"27ef798b15ab9aba","state":"TX","tracker":"permits","section":"air_permits","title":"MEITNER ENERGY CENTER (IP MEITNER GAS LLC)","summary":"Facility listing; a permit or issuance date may not be recorded.","scope":"Facility: Gray","status":"ACTIVE","date":"2026-05-01","sources":[{"url":"https://data.texas.gov/resource/5eqq-7nad.json","label":"data.texas.gov"},{"url":"https://data.texas.gov/d/5eqq-7nad","label":"data.texas.gov"}],"parties":[],"groups":[],"attribution":"Texas TCEQ air permit records","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"e2dcbc4dfaba5f0b","state":"TX","tracker":"permits","section":"air_permits","title":"MFE-A-KATI 2 DATA CENTER DEVELOPMENT","summary":"Facility listing; a permit or issuance date may not be recorded.","scope":"Facility: Lyford","status":"Not recorded","date":null,"sources":[{"url":"https://echodata.epa.gov/echo/echo_rest_services.get_facility_info?output=JSON&p_sic=7374&responseset=1000","label":"echodata.epa.gov"},{"url":"https://echo.epa.gov/detailed-facility-report?fid=TXR1513ZL","label":"echo.epa.gov"}],"parties":[],"groups":[],"attribution":"U.S. EPA ECHO","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"08d67d1a11b4cdbd","state":"TX","tracker":"permits","section":"air_permits","title":"MICROSOFT SAT 8990 DATA CENTER PROJECT SITE (LEMARTEC CORPORATION)","summary":"Facility listing; a permit or issuance date may not be recorded.","scope":"Facility: Medina","status":"ACTIVE","date":"2024-02-01","sources":[{"url":"https://data.texas.gov/resource/msah-s2rv.json","label":"data.texas.gov"},{"url":"https://data.texas.gov/d/msah-s2rv","label":"data.texas.gov"}],"parties":[],"groups":[],"attribution":"Texas TCEQ air permit records","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"6fb897fd034bd5c9","state":"TX","tracker":"permits","section":"air_permits","title":"MIDAS COMPUTE - BIG SPRING FACILITY (NDS VENTURES INC)","summary":"Facility listing; a permit or issuance date may not be recorded.","scope":"Facility: Big Spring","status":"PENDING","date":"2026-09-16","sources":[{"url":"https://data.texas.gov/resource/9iad-hrn8.json","label":"data.texas.gov"},{"url":"https://data.texas.gov/d/9iad-hrn8","label":"data.texas.gov"}],"parties":[],"groups":[],"attribution":"Texas TCEQ air permit records","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"e76adadc3fffdc81","state":"TX","tracker":"permits","section":"air_permits","title":"MILAM COUNTY DC (HAYS CITY CORPORATION)","summary":"Facility listing; a permit or issuance date may not be recorded.","scope":"Facility: Burlington","status":"ACTIVE","date":"2026-05-06","sources":[{"url":"https://data.texas.gov/resource/msah-s2rv.json","label":"data.texas.gov"},{"url":"https://data.texas.gov/d/msah-s2rv","label":"data.texas.gov"}],"parties":[],"groups":[],"attribution":"Texas TCEQ air permit records","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"5ba8ed932e5dbbec","state":"TX","tracker":"permits","section":"air_permits","title":"MISAE WILSON DC 500MW (MISAE GAS POWER LLC)","summary":"Facility listing; a permit or issuance date may not be recorded.","scope":"Facility: Stockdale","status":"ACTIVE","date":"2025-12-18","sources":[{"url":"https://data.texas.gov/resource/msah-s2rv.json","label":"data.texas.gov"},{"url":"https://data.texas.gov/d/msah-s2rv","label":"data.texas.gov"}],"parties":[],"groups":[],"attribution":"Texas TCEQ air permit records","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"e39d0b7706b1d7c4","state":"TX","tracker":"permits","section":"building_permits","title":"Maximo Moreno Survey, Abstract No. 14, Bell County, TX (Parcels 7755, 24955, 106228)","summary":"Second and final reading of voluntary annexation FY-26-4-ANX of 316.13 acres, the same parcels as the Project Lasso PD rezoning for Rowan's data center campus.","scope":"Facility:","status":"on agenda","date":"2026-09-17","sources":[{"url":"https://cityoftemple.primegov.com/Portal/Meeting?meetingTemplateId=13721","label":"cityoftemple.primegov.com"}],"parties":[],"groups":[],"attribution":"City of Temple, Texas","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"44c944a76583579a","state":"TX","tracker":"permits","section":"air_permits","title":"NEXUS DATA CENTER HUBBARD (NEXUS HUBBARD POWER LLC)","summary":"Facility listing; a permit or issuance date may not be recorded.","scope":"Facility: Hubbard","status":"ACTIVE","date":"2025-05-29","sources":[{"url":"https://data.texas.gov/resource/msah-s2rv.json","label":"data.texas.gov"},{"url":"https://data.texas.gov/d/msah-s2rv","label":"data.texas.gov"}],"parties":[],"groups":[],"attribution":"Texas TCEQ air permit records","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"9e3da2a61819a1cb","state":"TX","tracker":"permits","section":"air_permits","title":"NSCALE DATA CENTER - WARD COUNTY","summary":"Facility listing; a permit or issuance date may not be recorded.","scope":"Facility: Barstow","status":"Not recorded","date":null,"sources":[{"url":"https://echodata.epa.gov/echo/echo_rest_services.get_facility_info?output=JSON&p_sic=7374&responseset=1000","label":"echodata.epa.gov"},{"url":"https://echo.epa.gov/detailed-facility-report?fid=TXR1548ZO","label":"echo.epa.gov"}],"parties":[],"groups":[],"attribution":"U.S. EPA ECHO","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"d7791d82d48b8711","state":"TX","tracker":"permits","section":"air_permits","title":"Nscale Ward County II","summary":"TCEQ received a new standard permit registration (rule 6005, electric generating units) from Nscale Ward County II, LLC on 3 Aug 2026 for a power generation site near Barstow; pending.","scope":"Facility: Barstow","status":"Applied","date":null,"sources":[{"url":"https://www2.tceq.texas.gov/airperm/index.cfm?fuseaction=airpermits.validate_search_criteria&proj_id=412889&proj_status_txt=ALL&program=NSR&out_form=web","label":"www2.tceq.texas.gov"}],"parties":[],"groups":[],"attribution":"Texas Commission on Environmental Quality","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"ea96e3c34adecb31","state":"TX","tracker":"permits","section":"air_permits","title":"PCXAUS-11 Energy Center (Burr Computer Environments Properties LLC)","summary":"TCEQ registered standard permit 184208 (rule 6005) for Burr Computer Environments Properties LLC at the PCXAUS-11 Energy Center near Cedar Creek, received 28 May 2026 and completed 9 Jun 2026.","scope":"Facility: Cedar Creek","status":"Issued","date":null,"sources":[{"url":"https://www2.tceq.texas.gov/airperm/index.cfm?fuseaction=airpermits.validate_search_criteria&proj_id=410401&proj_status_txt=ALL&program=NSR&out_form=web","label":"www2.tceq.texas.gov"}],"parties":[],"groups":[],"attribution":"Texas Commission on Environmental Quality","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"e783a3a219097cda","state":"TX","tracker":"permits","section":"air_permits","title":"PLATON SITE (PLATON INVESTMENTS LLC)","summary":"Facility listing; a permit or issuance date may not be recorded.","scope":"Facility: Wilbarger","status":"ACTIVE","date":"2026-05-05","sources":[{"url":"https://data.texas.gov/resource/5eqq-7nad.json","label":"data.texas.gov"},{"url":"https://data.texas.gov/d/5eqq-7nad","label":"data.texas.gov"}],"parties":[],"groups":[],"attribution":"Texas TCEQ air permit records","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"f24b3e292df13c20","state":"TX","tracker":"permits","section":"air_permits","title":"POOLSIDE DATA CENTER PECOS COUNTY II (POOLSIDE LF PHASE 2 DC OPS LLC)","summary":"Facility listing; a permit or issuance date may not be recorded.","scope":"Facility: Pecos","status":"ACTIVE","date":"2026-03-09","sources":[{"url":"https://data.texas.gov/resource/9iad-hrn8.json","label":"data.texas.gov"},{"url":"https://data.texas.gov/d/9iad-hrn8","label":"data.texas.gov"}],"parties":[],"groups":[],"attribution":"Texas TCEQ air permit records","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"6a3721fca9cef5ce","state":"TX","tracker":"permits","section":"air_permits","title":"PROJECT LLANO (AGRILAND FS INC)","summary":"Facility listing; a permit or issuance date may not be recorded.","scope":"Facility: Claude","status":"PENDING","date":"2025-06-11","sources":[{"url":"https://data.texas.gov/resource/5eqq-7nad.json","label":"data.texas.gov"},{"url":"https://data.texas.gov/d/5eqq-7nad","label":"data.texas.gov"}],"parties":[],"groups":[],"attribution":"Texas TCEQ air permit records","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"ba8b18171ca535d8","state":"TX","tracker":"permits","section":"air_permits","title":"PROJECT LLANO (CRUSOE TECHNOLOGIES LLC)","summary":"Facility listing; a permit or issuance date may not be recorded.","scope":"Facility: Claude","status":"PENDING","date":"2025-06-11","sources":[{"url":"https://data.texas.gov/resource/5eqq-7nad.json","label":"data.texas.gov"},{"url":"https://data.texas.gov/d/5eqq-7nad","label":"data.texas.gov"}],"parties":[],"groups":[],"attribution":"Texas TCEQ air permit records","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"efd9ae36a5b9aa01","state":"TX","tracker":"permits","section":"air_permits","title":"PROJECT LLANO (ROBINSON CONSTRUCTION)","summary":"Facility listing; a permit or issuance date may not be recorded.","scope":"Facility: Claude","status":"ACTIVE","date":"2025-06-11","sources":[{"url":"https://data.texas.gov/resource/5eqq-7nad.json","label":"data.texas.gov"},{"url":"https://data.texas.gov/d/5eqq-7nad","label":"data.texas.gov"}],"parties":[],"groups":[],"attribution":"Texas TCEQ air permit records","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"6eaffc5fe5400ca0","state":"TX","tracker":"permits","section":"air_permits","title":"QUANTUM EXPEDITIONS SILSBEE FACILITY (QUANTUM EXPEDITIONS INC)","summary":"Facility listing; a permit or issuance date may not be recorded.","scope":"Facility: Hardin","status":"ACTIVE","date":"2025-06-20","sources":[{"url":"https://data.texas.gov/resource/tzyg-j7q4.json","label":"data.texas.gov"},{"url":"https://data.texas.gov/d/tzyg-j7q4","label":"data.texas.gov"}],"parties":[],"groups":[],"attribution":"Texas TCEQ air permit records","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"2872c7f4eb0f28f3","state":"TX","tracker":"permits","section":"air_permits","title":"ROYSE CITY DATA CENTER (BT GATEWAY DATA CENTER LLC)","summary":"Facility listing; a permit or issuance date may not be recorded.","scope":"Facility: Royse City","status":"PENDING","date":"2026-07-10","sources":[{"url":"https://data.texas.gov/resource/t34q-qzi3.json","label":"data.texas.gov"},{"url":"https://data.texas.gov/d/t34q-qzi3","label":"data.texas.gov"}],"parties":[],"groups":[],"attribution":"Texas TCEQ air permit records","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"2c84a0886a8e1eb5","state":"TX","tracker":"permits","section":"air_permits","title":"Roman Energy Center (Google LLC)","summary":"TCEQ received an initial NSR construction, PSD and GHG PSD application from Google LLC on 8 Sep 2026 for the Roman Energy Center near Hereford (RN112472139, a regulated entity TCEQ lists with NAICS 518210 data processing and hosting); the project is pending.","scope":"Facility: Hereford","status":"Applied","date":null,"sources":[{"url":"https://www2.tceq.texas.gov/airperm/index.cfm?fuseaction=airpermits.validate_search_criteria&proj_id=414637&proj_status_txt=ALL&program=NSR&out_form=web","label":"www2.tceq.texas.gov"}],"parties":[],"groups":[],"attribution":"Texas Commission on Environmental Quality","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"053de7a6cf873b88","state":"TX","tracker":"permits","section":"air_permits","title":"Roman Energy Center (IP Roman III Gas, LLC)","summary":"TCEQ received an initial NSR construction, PSD and GHG PSD application from IP Roman III Gas, LLC on 15 Jun 2026 for a power generation facility at the same Roman Energy Center site (RN112472139) where Google LLC filed its own application in September; pending.","scope":"Facility: Hereford","status":"Applied","date":null,"sources":[{"url":"https://www2.tceq.texas.gov/airperm/index.cfm?fuseaction=airpermits.validate_search_criteria&proj_id=411006&proj_status_txt=ALL&program=NSR&out_form=web","label":"www2.tceq.texas.gov"}],"parties":[],"groups":[],"attribution":"Texas Commission on Environmental Quality","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"348d49a53ea68c7a","state":"TX","tracker":"permits","section":"air_permits","title":"SAT14 (CYRUSONE LLC)","summary":"Facility listing; a permit or issuance date may not be recorded.","scope":"Facility: Medina","status":"ACTIVE","date":"2026-08-12","sources":[{"url":"https://data.texas.gov/resource/msah-s2rv.json","label":"data.texas.gov"},{"url":"https://data.texas.gov/d/msah-s2rv","label":"data.texas.gov"}],"parties":[],"groups":[],"attribution":"Texas TCEQ air permit records","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"2abf844a7dc14843","state":"TX","tracker":"permits","section":"air_permits","title":"SCHLACHTER REALTY (SCHLACHTER REALTY LTD)","summary":"Facility listing; a permit or issuance date may not be recorded.","scope":"Facility: Dallas","status":"PENDING","date":"2026-06-19","sources":[{"url":"https://data.texas.gov/resource/t34q-qzi3.json","label":"data.texas.gov"},{"url":"https://data.texas.gov/d/t34q-qzi3","label":"data.texas.gov"}],"parties":[],"groups":[],"attribution":"Texas TCEQ air permit records","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"8e2ce5f79c2ce854","state":"TX","tracker":"permits","section":"air_permits","title":"SDC DFW VIII (STREAM DATA CENTERS LP)","summary":"Facility listing; a permit or issuance date may not be recorded.","scope":"Facility: Wilmer","status":"ACTIVE","date":"2023-09-21","sources":[{"url":"https://data.texas.gov/resource/t34q-qzi3.json","label":"data.texas.gov"},{"url":"https://data.texas.gov/d/t34q-qzi3","label":"data.texas.gov"}],"parties":[],"groups":[],"attribution":"Texas TCEQ air permit records","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"b48356b37f9a3c89","state":"TX","tracker":"permits","section":"air_permits","title":"SDC DFWB CAMPUS (SDC DFW VIII LP)","summary":"Facility listing; a permit or issuance date may not be recorded.","scope":"Facility: Wilmer","status":"CANCELLED","date":"2024-10-15","sources":[{"url":"https://data.texas.gov/resource/t34q-qzi3.json","label":"data.texas.gov"},{"url":"https://data.texas.gov/d/t34q-qzi3","label":"data.texas.gov"}],"parties":[],"groups":[],"attribution":"Texas TCEQ air permit records","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"87fdd5997bed1298","state":"TX","tracker":"permits","section":"air_permits","title":"SI DFW02A (SI DFW02A LLC)","summary":"Facility listing; a permit or issuance date may not be recorded.","scope":"Facility: Dallas","status":"ACTIVE","date":"2025-10-10","sources":[{"url":"https://data.texas.gov/resource/t34q-qzi3.json","label":"data.texas.gov"},{"url":"https://data.texas.gov/d/t34q-qzi3","label":"data.texas.gov"}],"parties":[],"groups":[],"attribution":"Texas TCEQ air permit records","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"b7666bfb57fecb27","state":"TX","tracker":"permits","section":"air_permits","title":"STAMPEDE DATA CENTER (ROWAN STAMPEDE LLC)","summary":"Facility listing; a permit or issuance date may not be recorded.","scope":"Facility: Bell","status":"ACTIVE","date":"2026-06-15","sources":[{"url":"https://data.texas.gov/resource/msah-s2rv.json","label":"data.texas.gov"},{"url":"https://data.texas.gov/d/msah-s2rv","label":"data.texas.gov"}],"parties":[],"groups":[],"attribution":"Texas TCEQ air permit records","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"da88d0613a700f90","state":"TX","tracker":"permits","section":"air_permits","title":"STREAM SAT03 (SDC SA III LP)","summary":"Facility listing; a permit or issuance date may not be recorded.","scope":"Facility: San Antonio","status":"ACTIVE","date":"2023-10-24","sources":[{"url":"https://data.texas.gov/resource/msah-s2rv.json","label":"data.texas.gov"},{"url":"https://data.texas.gov/d/msah-s2rv","label":"data.texas.gov"}],"parties":[],"groups":[],"attribution":"Texas TCEQ air permit records","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"73d22d0f8db6dd2e","state":"TX","tracker":"permits","section":"air_permits","title":"TEMPLE 5MW DATA CENTER (CLOP TEMPLE TX LLC)","summary":"Facility listing; a permit or issuance date may not be recorded.","scope":"Facility: Temple","status":"ACTIVE","date":"2025-02-04","sources":[{"url":"https://data.texas.gov/resource/msah-s2rv.json","label":"data.texas.gov"},{"url":"https://data.texas.gov/d/msah-s2rv","label":"data.texas.gov"}],"parties":[],"groups":[],"attribution":"Texas TCEQ air permit records","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"a70338dbbe8509d3","state":"TX","tracker":"permits","section":"air_permits","title":"TEMPLE DATA CENTER (ROWAN TEMPLE LLC)","summary":"Facility listing; a permit or issuance date may not be recorded.","scope":"Facility: Bell","status":"ACTIVE","date":"2026-01-15","sources":[{"url":"https://data.texas.gov/resource/msah-s2rv.json","label":"data.texas.gov"},{"url":"https://data.texas.gov/d/msah-s2rv","label":"data.texas.gov"}],"parties":[],"groups":[],"attribution":"Texas TCEQ air permit records","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"2f5e9601171b5c05","state":"TX","tracker":"permits","section":"air_permits","title":"THELMA SITE (HOMEBOUND GROUP LLC)","summary":"Facility listing; a permit or issuance date may not be recorded.","scope":"Facility: Haskell","status":"ACTIVE","date":"2025-08-15","sources":[{"url":"https://data.texas.gov/resource/5eqq-7nad.json","label":"data.texas.gov"},{"url":"https://data.texas.gov/d/5eqq-7nad","label":"data.texas.gov"}],"parties":[],"groups":[],"attribution":"Texas TCEQ air permit records","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"4c370572a2b0d6c1","state":"TX","tracker":"permits","section":"air_permits","title":"VANTAGE DATA CENTER TX2","summary":"Facility listing; a permit or issuance date may not be recorded.","scope":"Facility: San Antonio","status":"Operating","date":null,"sources":[{"url":"https://echodata.epa.gov/echo/echo_rest_services.get_facility_info?output=JSON&p_fn=DATA%20CENTER&responseset=1000","label":"echodata.epa.gov"},{"url":"https://echo.epa.gov/detailed-facility-report?fid=110072155814","label":"echo.epa.gov"}],"parties":[],"groups":[],"attribution":"U.S. EPA ECHO","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"a32f92fad2d73927","state":"TX","tracker":"permits","section":"air_permits","title":"VANTAGE DATA CENTER TX2 (VANTAGE DATA CENTERS TX21 LLC)","summary":"Facility listing; a permit or issuance date may not be recorded.","scope":"Facility: San Antonio","status":"ACTIVE","date":"2024-02-29","sources":[{"url":"https://data.texas.gov/resource/msah-s2rv.json","label":"data.texas.gov"},{"url":"https://data.texas.gov/d/msah-s2rv","label":"data.texas.gov"}],"parties":[],"groups":[],"attribution":"Texas TCEQ air permit records","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"bf8e697d86fb857e","state":"TX","tracker":"permits","section":"air_permits","title":"VANTAGE DATA CENTERS TX3 (VANTAGE DATA CENTERS TX301 LLC)","summary":"Facility listing; a permit or issuance date may not be recorded.","scope":"Facility: Abilene","status":"ACTIVE","date":"2026-01-06","sources":[{"url":"https://data.texas.gov/resource/5eqq-7nad.json","label":"data.texas.gov"},{"url":"https://data.texas.gov/d/5eqq-7nad","label":"data.texas.gov"}],"parties":[],"groups":[],"attribution":"Texas TCEQ air permit records","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"194f263b23647929","state":"TX","tracker":"permits","section":"air_permits","title":"VANTAGE TX 11 (THE WHITING-TURNER CONTRACTING COMPANY)","summary":"Facility listing; a permit or issuance date may not be recorded.","scope":"Facility: San Antonio","status":"PENDING","date":"2023-11-28","sources":[{"url":"https://data.texas.gov/resource/msah-s2rv.json","label":"data.texas.gov"},{"url":"https://data.texas.gov/d/msah-s2rv","label":"data.texas.gov"}],"parties":[],"groups":[],"attribution":"Texas TCEQ air permit records","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"90b261e470744626","state":"TX","tracker":"permits","section":"air_permits","title":"VANTAGE TX 11 (VANTAGE DATA CENTERS TX11 LLC)","summary":"Facility listing; a permit or issuance date may not be recorded.","scope":"Facility: San Antonio","status":"ACTIVE","date":"2023-11-28","sources":[{"url":"https://data.texas.gov/resource/msah-s2rv.json","label":"data.texas.gov"},{"url":"https://data.texas.gov/d/msah-s2rv","label":"data.texas.gov"}],"parties":[],"groups":[],"attribution":"Texas TCEQ air permit records","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"3e2828b8a02d467c","state":"TX","tracker":"permits","section":"air_permits","title":"VKU SITE (PLATON INVESTMENTS LLC)","summary":"Facility listing; a permit or issuance date may not be recorded.","scope":"Facility: Wilbarger","status":"PENDING","date":"2026-09-14","sources":[{"url":"https://data.texas.gov/resource/5eqq-7nad.json","label":"data.texas.gov"},{"url":"https://data.texas.gov/d/5eqq-7nad","label":"data.texas.gov"}],"parties":[],"groups":[],"attribution":"Texas TCEQ air permit records","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"8bda46725c88ea5b","state":"TX","tracker":"permits","section":"air_permits","title":"VoltaGrid SAT-1 EGU, 14720 Omicron Dr","summary":"TCEQ completed a revision to VoltaGrid LLC standard permit registration 177637 (rule 6005) for the SAT-1 electric generating unit site in San Antonio, received 24 Jun 2026 and completed 24 Jul 2026; on 21 Sep 2026 environmental groups sued VoltaGrid and Vantage in federal court over the gas plants serving Vantage data centers on San Antonio's West Side (San Antonio Current).","scope":"Facility: San Antonio","status":"Issued","date":null,"sources":[{"url":"https://www2.tceq.texas.gov/airperm/index.cfm?fuseaction=airpermits.validate_search_criteria&proj_id=411374&proj_status_txt=ALL&program=NSR&out_form=web","label":"www2.tceq.texas.gov"}],"parties":[],"groups":[],"attribution":"Texas Commission on Environmental Quality","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"9416cedaa37ebf05","state":"TX","tracker":"permits","section":"air_permits","title":"VoltaGrid SAT-2 EGU, 5207 Rogers Rd","summary":"TCEQ registered VoltaGrid LLC standard permit 181707 (rule 6005) for the SAT-2 electric generating unit site in San Antonio, received 30 Sep 2025 and completed 3 Nov 2025; on 21 Sep 2026 environmental groups sued VoltaGrid and Vantage in federal court over the gas plants serving Vantage data centers on San Antonio's West Side (San Antonio Current).","scope":"Facility: San Antonio","status":"Issued","date":null,"sources":[{"url":"https://www2.tceq.texas.gov/airperm/index.cfm?fuseaction=airpermits.validate_search_criteria&proj_id=398729&proj_status_txt=ALL&program=NSR&out_form=web","label":"www2.tceq.texas.gov"}],"parties":[],"groups":[],"attribution":"Texas Commission on Environmental Quality","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"ffff2de5d9d988d1","state":"TX","tracker":"permits","section":"air_permits","title":"WESTLINE 2335 (WESTLINE TX HOLDINGS LLC)","summary":"Facility listing; a permit or issuance date may not be recorded.","scope":"Facility: Tom Green","status":"PENDING","date":"2026-06-12","sources":[{"url":"https://data.texas.gov/resource/5eqq-7nad.json","label":"data.texas.gov"},{"url":"https://data.texas.gov/d/5eqq-7nad","label":"data.texas.gov"}],"parties":[],"groups":[],"attribution":"Texas TCEQ air permit records","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"bfb2177ebb7db8be","state":"TX","tracker":"permits","section":"air_permits","title":"WOODROW DATA CENTER & POWER PLANT (NOLAN RANCH DC OWNER LLC)","summary":"Facility listing; a permit or issuance date may not be recorded.","scope":"Facility: Nolan","status":"ACTIVE","date":"2026-05-18","sources":[{"url":"https://data.texas.gov/resource/5eqq-7nad.json","label":"data.texas.gov"},{"url":"https://data.texas.gov/d/5eqq-7nad","label":"data.texas.gov"}],"parties":[],"groups":[],"attribution":"Texas TCEQ air permit records","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"c050b7ec6d7665a6","state":"TX","tracker":"permits","section":"air_permits","title":"WURLDWIDE (WURLDWIDE LLC)","summary":"Facility listing; a permit or issuance date may not be recorded.","scope":"Facility: El Paso","status":"ACTIVE","date":"2026-02-20","sources":[{"url":"https://data.texas.gov/resource/9iad-hrn8.json","label":"data.texas.gov"},{"url":"https://data.texas.gov/d/9iad-hrn8","label":"data.texas.gov"}],"parties":[],"groups":[],"attribution":"Texas TCEQ air permit records","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"68274dc80e1c6857","state":"TX","tracker":"permits","section":"substations","title":"X TEAM /// ACS Data Center Campus","summary":"X TEAM /// ACS Data Center Campus - Substation Retaining Wall X TEAM /// New retaining wall for the ACS Data Center substation.","scope":"Facility: Tarrant","status":"Awaiting Client Reply","date":"2026-07-01","sources":[{"url":"https://aca-prod.accela.com/CFW/Cap/GlobalSearchResults.aspx?QueryText=PB26-09476","label":"aca-prod.accela.com"}],"parties":[],"groups":[],"attribution":"City of Fort Worth public permit records","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"5810226deef73d9d","state":"TX","tracker":"permits","section":"air_permits","title":"XENERGY MONAHANS 1 (XENERGY PLUS INC)","summary":"Facility listing; a permit or issuance date may not be recorded.","scope":"Facility: Monahans","status":"ACTIVE","date":"2023-10-30","sources":[{"url":"https://data.texas.gov/resource/9iad-hrn8.json","label":"data.texas.gov"},{"url":"https://data.texas.gov/d/9iad-hrn8","label":"data.texas.gov"}],"parties":[],"groups":[],"attribution":"Texas TCEQ air permit records","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"6be6f422964160c7","state":"TX","tracker":"permits","section":"building_permits","title":"ZC25-26","summary":"Conduct a Public Hearing and consider approval of an Ordinance of the City Council of the City of Red Oak, Texas, granting a zoning change request from “PD”, Planned Development, 164 Revised 1 (PD, 164R1) to “PD”, Planned Development, 164 Revised 2 (PD, 164R2) for the development of a data center complex and associated infrastructure on approximately 212.8018 acres of land, generally located at the northeast corner of Stainback and Batchler Roads, north of Stainback Road, south of the Ellis County limit line, Property Identification No. 312905 in Ellis Appraisal District, City of Red Oak, Ellis County, Texas. (ZC25-26) Requested by Michael Landwehr (Ben Hartman)","scope":"Facility:","status":"on agenda","date":"2025-12-08","sources":[{"url":"https://redoaktx.portal.civicclerk.com/event/202/overview","label":"redoaktx.portal.civicclerk.com"}],"parties":[],"groups":[],"attribution":"City of Red Oak public permit records","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"f6f896825aa612fd","state":"TX","tracker":"permits","section":"building_permits","title":"ZC25-28","summary":"Conduct a public hearing and consider approval of an Ordinance approving a zoning change from “PD”, Planned Development, 66 Revised 6 (PD, 66R6) to “PD”, Planned Development, 66 Revised 7 (PD, 66R7), generally to allow for development of a Data Center Complex (and auxiliary structures) and to modify development standards and zoning regulations, located at the northwest corner of East Ovilla Road and State Highway 342, Property Identification Numbers 309734, 309735, 309737 and 191222, in Ellis Appraisal District, City of Red Oak, Ellis County, Texas. (ZC25-28) Requested by Alamo Mission LLC (Ben Hartman) Conduct a public hearing and consider a zoning change from “PD”, Planned Development, 66 Revised 6 (PD, 66R6) to “PD”, Planned Development, 66 Revised 7 (PD, 66R7), Generally to allow for development of a Data Center Complex (and auxiliary structures) and to modify development standards and zoning regulations, Located at the Northwest corner of East Ovilla Road and State Highway 342, Property Identification Numbers 309734, 309735, 309737, 191222 in Ellis County Appraisal District, City of Red Oak, Ellis County, Texas (ZC25-28). Requested by Alamo Mission LLC (Ben Hartman)","scope":"Facility:","status":"on agenda","date":"2026-02-09","sources":[{"url":"https://redoaktx.portal.civicclerk.com/event/67/overview","label":"redoaktx.portal.civicclerk.com"}],"parties":[],"groups":[],"attribution":"City of Red Oak public permit records","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"4df17ebdc897944e","state":"TX","tracker":"permits","section":"building_permits","title":"agenda item 3002","summary":"Conduct a public hearing and consider a zoning change from “PD”, Planned Development, 66 Revised 7 (PD, 66R 7) to “PD”, Planned Development, 66 Revised 8 (PD, 66R 8), For approval of a development plan to construct a Data Center Complex (and auxiliary structures), and to refine development standards, Located at the Northwest corner of East Ovilla Road and State Highway 342, Property Identification Numbers 309733, 309734, 309735, 309737, 191222 in Ellis County Appraisal District, City of Red Oak, Ellis County, Texas (ZC26, 15). Requested by Carlos Leal","scope":"Facility:","status":"on agenda","date":"2026-09-28","sources":[{"url":"https://redoaktx.portal.civicclerk.com/event/606/overview","label":"redoaktx.portal.civicclerk.com"}],"parties":[],"groups":[],"attribution":"City of Red Oak public permit records","provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"f4c280b4acf60e61","state":"TX","tracker":"water","section":"measures","title":"A mandatory survey that 83 percent of data centers ignored","summary":"Industries in Texas, data centers included, are required to complete an annual water use survey and submit it to the Texas Water Development Board. The board adopted its initial 2027 State Water Plan on July 23, 2026. The board surveyed 341 data centers for 2025 and 83 percent did not respond. Among the surveys that were returned, surface water accounted for nearly 90 percent of the water reported, groundwater for 8 percent, and 2 percent came from an unknown source. The 97-page initial plan uses the phrase data centers twice and AI facilities once, and the board attributed the thin treatment to limited data. The duty to report exists in law and has not produced a state total.","scope":"state: Texas","status":"enacted","date":"2026-07-23","sources":[{"url":"https://communityimpact.com/central-austin/texas-legislature/texas-includes-minimal-data-center-info-in-state-water-plan-citing-limited-data/","label":"communityimpact.com"}],"parties":[{"role":"Jurisdiction","name":"Texas"}],"groups":["water:disclosure:enacted"],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"617e27c4c491786f","state":"TX","tracker":"water","section":"measures","title":"An aquifer recharge zone ban weighed instead of a pause","summary":"Staff presented zoning changes that would confine data centers to industrial or commercial districts, keep a 500-foot setback from homes, schools, hospitals and assisted living facilities, and prohibit construction in the Edwards Aquifer Recharge Zone. The council also weighed a building permit moratorium of up to 180 days. Development Services recommended permanent changes to the development code over a temporary pause, and the director told the council that zoning and the code can set setbacks and locations but cannot regulate how much water a data center uses. Code changes were expected to reach a council vote by mid-October 2026. San Antonio sits over the Edwards Aquifer, so a recharge zone prohibition is a water measure about where water is drawn from rather than how much is drawn.","scope":"local: San Antonio, Texas","status":"proposed","date":"2026-08-25","sources":[{"url":"https://www.tpr.org/economy-and-labor/2026-08-25/san-antonio-will-consider-regulating-data-centers-its-unclear-if-that-involves-a-moratorium","label":"www.tpr.org"}],"parties":[{"role":"Jurisdiction","name":"San Antonio, Texas"}],"groups":["water:siting:proposed"],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"b41ba038f3b958e1","state":"TX","tracker":"water","section":"measures","title":"Closed-loop cooling required for new data centers on city water","summary":"Requires all new data centers in the Fort Worth Water Utility's service area to use closed-loop cooling systems and to obtain wastewater pretreatment permits as Non-Significant Industrial Users. City Council adopted the updated Installation Policy and Design Criteria on Aug 11, 2026, the same night it set aside a data center zoning ordinance with a similar cooling rule and started a moratorium process. The requirement comes through the water utility's design standards rather than zoning.","scope":"local: Fort Worth, Texas","status":"enacted","date":"2026-08-11","sources":[{"url":"https://www.fortworthtexas.gov/departments/city-manager/datacenters","label":"www.fortworthtexas.gov"}],"parties":[{"role":"Jurisdiction","name":"Fort Worth, Texas"}],"groups":["water:closed-loop:enacted"],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"a3bc163e4fc8a78f","state":"TX","tracker":"water","section":"measures","title":"Closed-loop mandate with a per-square-foot fill cap","summary":"Requires any data center to use a closed-loop cooling system, limits the initial water fill to no more than 8 gallons per square foot of gross building area, requires cooling water to be metered separately from other water use, and requires any approved or emergency exceedance to be reported in writing to the City Council within five business days. The most precisely drafted local water ordinance located to date. It regulates the three things that actually determine outcomes: the architecture, the fill volume, and the meter. Most ordinances regulate only the first.","scope":"local: San Angelo, Texas","status":"enacted","date":"2026-06-16","sources":[{"url":"https://sanangelolive.com/news/san-angelo/2026-06-16/san-angelo-city-council-adopts-water-use-regulations-data-centers","label":"sanangelolive.com"}],"parties":[{"role":"Jurisdiction","name":"San Angelo, Texas"}],"groups":["water:closed-loop:enacted"],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"ab5ef43c0bd56795","state":"TX","tracker":"water","section":"measures","title":"Data center audit covering water use and cooling","summary":"Directs the PUCT and ERCOT to audit every data center in ERCOT's interconnection process before more can advance, collecting projected water consumption, water sources, whether facilities bring and reuse their own water, and whether cooling is air-cooled, closed-loop or another water-efficient system. Projects that fail to complete the audit are to be denied interconnection. Governor Abbott issued the directive on August 3, 2026, citing data centers that did not answer the PUC's water and power survey under the General Appropriations Act. It predates the September 9 refresh but was not in the tracker; the September 14 and 21 letters build on it.","scope":"state: Texas","status":"enacted","date":"2026-08-03","sources":[{"url":"https://gov.texas.gov/news/post/governor-abbott-directs-comprehensive-data-center-audit","label":"gov.texas.gov"}],"parties":[{"role":"Jurisdiction","name":"Texas"}],"groups":["water:disclosure:enacted"],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"4fe0a4491af0e56e","state":"TX","tracker":"water","section":"measures","title":"Enforce water use survey reporting against data centers","summary":"Directs the Texas Water Development Board to compel major water users, including data centers, to complete the water use survey required by Texas Water Code 16.012(m), refer violations to county or district attorneys and notify TCEQ, since nonfilers are ineligible for Chapter 11 water permits. TWDB must also seek water consumption, supply source and cooling technology data through the ERCOT data center audit and report its enforcement progress to the Governor within 30 days. Governor Abbott sent the letter to TWDB Chairwoman L'Oreal Stepney and Executive Administrator Bryan McMath on September 14, 2026. Calendar Year 2025 survey responses were due March 1, 2026; no TWDB enforcement action had been published as of September 23.","scope":"state: Texas","status":"enacted","date":"2026-09-14","sources":[{"url":"https://gov.texas.gov/uploads/files/press/TWDB_Letter.pdf","label":"gov.texas.gov"}],"parties":[{"role":"Jurisdiction","name":"Texas"}],"groups":["water:disclosure:enacted"],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"ce0a82530ed2e6c2","state":"TX","tracker":"water","section":"measures","title":"Groundwater district request for authority to deny data center permits","summary":"The Blanco-Pedernales Groundwater Conservation District passed a resolution urging the Texas Legislature to grant it the legal authority to deny water permits to data centers. Groundwater conservation districts are the primary local groundwater regulators in Texas, and this one is saying its existing authority is not sufficient to refuse a large industrial permit.","scope":"state: Texas","status":"proposed","date":"2026-04-16","sources":[{"url":"https://thetexasdispatch.com/blanco-pedernales-water-district-data-center-resolution-2026/","label":"thetexasdispatch.com"}],"parties":[{"role":"Jurisdiction","name":"Texas"}],"groups":["water:siting:proposed"],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"18fff3b222f896e1","state":"TX","tracker":"water","section":"measures","title":"Investigation of data centers that skipped the TWDB water use survey","summary":"The Office of the Attorney General is investigating Texas data center developments that have not responded to the Texas Water Development Board's water use survey, which state law requires, and demands full survey responses from every data center in the state. Attorney General Ken Paxton announced the investigation on Sep 24, 2026, ten days after the Governor's letter directing TWDB to enforce the survey, saying his office was investigating hundreds of developments in counties including Harris, Travis, Dallas, Tarrant and Bexar. The release names no company, deadline or penalty.","scope":"state: Texas","status":"enacted","date":"2026-09-24","sources":[{"url":"https://www.texasattorneygeneral.gov/news/releases/attorney-general-paxton-launches-landmark-investigation-hundreds-data-center-developments-texas","label":"www.texasattorneygeneral.gov"}],"parties":[{"role":"Jurisdiction","name":"Texas"}],"groups":["water:disclosure:enacted"],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"0026ba717d68569a","state":"TX","tracker":"water","section":"measures","title":"Large data center water and cooling rules","summary":"Would require closed-loop, air or dry cooling or similar technology that minimizes continuous water use, and a water reservation fee for developers needing 100,000 gallons per day or more. The Planning and Zoning Commission held a special meeting on Sep 10, 2026 on staff-drafted rules after City Council passed a resolution earlier that week saying it would not consider large-scale data centers until regulations are adopted; a work session is set for Oct 1 and a commission vote for Nov 5.","scope":"local: Lubbock, Texas","status":"proposed","date":"2026-09-10","sources":[{"url":"https://www.kedt.org/texas-news/2026-09-11/planning-and-zoning-commission-wary-of-hindering-development-after-city-council-calls-for-data-center-regulations","label":"www.kedt.org"}],"parties":[{"role":"Jurisdiction","name":"Lubbock, Texas"}],"groups":["water:closed-loop:proposed"],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"97674740d6ace3d0","state":"TX","tracker":"water","section":"measures","title":"Legislative review of data center water demand","summary":"House Speaker Burrows and Lieutenant Governor Patrick placed data center water demand in the 2026 interim charges for five legislative panels, including House Natural Resources and the Senate Committee on Water, Agriculture and Rural Affairs, to draft recommendations ahead of the 90th Legislature. The Texas Water Development Board has acknowledged it has no way to track groundwater pumping by data centers in counties without a groundwater conservation district, which is the case in more than half of Texas counties. The Senate Committee on Water, Agriculture and Rural Affairs took up the charge on September 1, 2026; Chairman Charles Perry said he intends to carry a standalone bill prohibiting evaporative cooling systems, and the committee pressed for monthly rather than annual water use reporting, water source disclosure and drought contingency plans (Holland and Knight, September 2026).","scope":"state: Texas","status":"proposed","date":"2026-06-24","sources":[{"url":"https://www.kwtx.com/2026/06/24/lawmakers-demand-answers-texas-data-centers-water-use/","label":"www.kwtx.com"}],"parties":[{"role":"Jurisdiction","name":"Texas"}],"groups":["water:study:proposed"],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"23aaebd91e78f209","state":"TX","tracker":"water","section":"measures","title":"Pause on all TCEQ permits for data center projects","summary":"Directs TCEQ to pause issuing all permits related to data center projects until ERCOT completes its data center review, so that ERCOT and TWDB water use findings inform permitting. TCEQ must report its compliance to the Governor by October 19, 2026. Governor Abbott sent the letter to TCEQ Executive Director Kelly Keel on September 21, 2026, extending his August ERCOT audit and September 14 TWDB directive. The letter says data centers must not use water needed by local communities and must report electricity and water usage.","scope":"state: Texas","status":"enacted","date":"2026-09-21","sources":[{"url":"https://gov.texas.gov/uploads/files/press/TCEQ_Data_Center.pdf","label":"gov.texas.gov"}],"parties":[{"role":"Jurisdiction","name":"Texas"}],"groups":["water:moratorium:enacted"],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"0711b71f0ca0c23e","state":"TX","tracker":"water","section":"measures","title":"Proposed closed-loop cooling requirement","summary":"Would require data centers to be equipped with closed-loop cooling systems that recycle water and reduce evaporative loss, as part of a first-of-its-kind zoning and development ordinance for the city. On Aug 11, 2026 the City Council pulled the staff-drafted data center zoning and development rules from its agenda after the Zoning Commission voted 7 to 4 to deny them in July, and instead voted unanimously to start a 90-day moratorium process. Staff will study data center noise, impacts on local water supplies and long-term water availability. The closed-loop requirement in this zoning draft was not adopted; the same night the Council adopted a separate water utility policy that does require closed-loop cooling for new data centers on city water, listed as its own entry.","scope":"local: Fort Worth, Texas","status":"proposed","date":"2026-08-11","sources":[{"url":"https://fortworthreport.org/2026/08/12/data-center-moratorium-takes-first-steps-after-fort-worth-city-councils-unanimous-vote/","label":"fortworthreport.org"}],"parties":[{"role":"Jurisdiction","name":"Fort Worth, Texas"}],"groups":["water:closed-loop:proposed"],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"f512098faa3bf9c4","state":"TX","tracker":"water","section":"measures","title":"Smart meter records exception used to withhold data center water use","summary":"Information a government-operated utility collects through an advanced metering system for usage, services and billing is excepted from disclosure under the Public Information Act. The utility must release the data to the customer it belongs to, and to nobody else. Written to keep household smart meter readings away from payday lenders, not to cover industrial customers. San Antonio Water System invoked it in 2026 to deny a records request for three years of water use at 36 area data centers. The bill's author, Representative Diego Bernal, said the utility is not applying the law as he intended. This provision is the counterweight sitting underneath every Texas disclosure proposal on this page: a state can require reporting and still have the resulting numbers withheld.","scope":"state: Texas","status":"enacted","date":"2021-09-01","sources":[{"url":"https://www.ksat.com/news/ksat-investigates/2026/07/28/texas-law-shields-san-antonio-area-data-center-water-usage-from-public-records-requests/","label":"www.ksat.com"}],"parties":[{"role":"Jurisdiction","name":"Texas"}],"groups":["water:shield:enacted"],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."},{"id":"0d07fe0b0e4fa3bb","state":"TX","tracker":"water","section":"measures","title":"Zoning and water requirements written before the first hyperscale site","summary":"The City Council adopted Item 61 as amended on August 27, 2026, initiating amendments to City Code Title 25, the Land Development Code, to establish where data centers may operate, what development standards apply, and what permits they need. An amendment carried by the Mayor Pro Tem added a requirement that data centers develop an operations plan demonstrating on-site operations requirements, including water and reclaimed water use, energy use, noise generation and lighting impacts, before site plan approval is issued. Austin had no land use classification for data centers, which left the city little authority over one that was proposed. Austin Energy serves 10 data centers drawing between 1 and 20 megawatts, and no hyperscale facility has been proposed inside city limits. The vote was unanimous, and instead of waiting for the full framework in spring 2027 the council asked staff to return with a first set of rules by the end of 2026. Sponsors cited the low response rate to the state water survey as the reason to legislate locally. The measure requires a plan, not a metered volume.","scope":"local: Austin, Texas","status":"enacted","date":"2026-08-27","sources":[{"url":"https://cbsaustin.com/news/local/austin-city-council-unanimously-moves-forward-with-new-data-center-regulations","label":"cbsaustin.com"}],"parties":[{"role":"Jurisdiction","name":"Austin, Texas"}],"groups":["water:siting:enacted"],"attribution":null,"provenance":"Published SAVRN record; source status retained, not newly reverified here."}],"groups":{"policy:site-control":["170b3631ad48f5a9"],"policy:security":["1deb6f4ebbbba3d4"],"policy:curtailment":["56b017e8edee0f3b"],"policy:emissions":["e17cedb3112fd488"],"restriction:local:enacted":["cb4fae95f6ec62e9","226d9579a44729dd","8725a51570228ad5","9cd0e5a2740b6579","49d98f654070e13e","5a6631afcf14f245","1526c144af9c4197","bfaeb2b05925f9bf"],"restriction:local:proposed":["aa120245d3cde2b5","4bbd796802e5b2a9","29dbbc44e88a23f5","d4ddebe26453aec0","fd40bfb18bd582d1","e3d9ca006093dd8c","347c664b42d6867c","f141990e3f9ddb5c"],"restriction:local:failed":["4cf9e86df26cb47f","036f9e40cb83532e","8fbbd5e4d1430368","0148c0779dde3d94","c154399207131e2f"],"restriction:states:enacted":["35fcd20bf3d4a4e3","07b7360c48f3c46e","98ec338e6e03cba0"],"restriction:states:pause":["707703d5f96368d1","41c39b9ee7a58df2","9607cd1000488b0d"],"restriction:states:proposed":["8d85cc66b1113104"],"water:study:proposed":["97674740d6ace3d0"],"water:siting:proposed":["ce0a82530ed2e6c2","617e27c4c491786f"],"water:closed-loop:enacted":["a3bc163e4fc8a78f","b41ba038f3b958e1"],"water:closed-loop:proposed":["0711b71f0ca0c23e","0026ba717d68569a"],"water:shield:enacted":["f512098faa3bf9c4"],"water:siting:enacted":["0d07fe0b0e4fa3bb"],"water:disclosure:enacted":["f4c280b4acf60e61","4fe0a4491af0e56e","ab5ef43c0bd56795","18fff3b222f896e1"],"water:moratorium:enacted":["23aaebd91e78f209"],"delay:state_moratorium:withdrawn":["a8fe02f84bc4a666"],"delay:transformer_supply:delayed":["a60e9b00093891d5"],"delay:gas_pipeline_delay:delayed":["87485593349454ff"],"delay:corporate_realignment:withdrawn":["15ca382a6f880e9f"],"delay:financing:withdrawn":["15ca382a6f880e9f"],"delay:zoning_denial:cancelled":["9832792554ff4c9d","0b4408147f79994e","a1bb576b290d6353"],"delay:water_dispute:cancelled":["9832792554ff4c9d"],"delay:community_opposition:cancelled":["9832792554ff4c9d","0b4408147f79994e","a1bb576b290d6353"],"delay:water_dispute:withdrawn":["0581ab61da4d6697"],"delay:community_opposition:withdrawn":["0581ab61da4d6697","adfb727c5dd4e1cc"],"delay:litigation:litigation_active":["792ce5aec9329c29","109278a363838f96","f27cb758664748d7"],"delay:community_opposition:litigation_active":["792ce5aec9329c29","109278a363838f96"],"delay:corporate_realignment:delayed":["0120772c7188f042"],"delay:community_opposition:delayed":["168b4298a9ab289d","f7513e35f7c721c0","2e380fe2f7f014dc"],"delay:litigation:under_appeal":["f08287b22f91f244"],"delay:local_moratorium:litigation_active":["f27cb758664748d7"],"delay:zoning_denial:delayed":["2e380fe2f7f014dc"],"delay:interconnection_queue:halted":["d5e9430ff55efa0d"],"delay:zoning_denial:withdrawn":["adfb727c5dd4e1cc"],"utility:tariff:approved":["75dc99c20658fe92","aed4fabd0e2dc51c","9a879f558b598ed3"],"utility:rate case:pending":["3af74a147ed90618"],"utility:other:pending":["234c8b4fd863479c","b540667ef8b17e0f","0b11ccddef1877eb","99a349313213c782","87c2bcaca8770a64","ca36e7d667fd52d5","624c21796e30622a","6218dc8d9c2c19aa","a068f88c8918edb0"],"utility:special contract:pending":["85e644b149d44cc3"],"utility:tariff:pending":["179ce9c6749195ff","ecc5b89ff5cb7890"],"utility:statement:pending":["d04486225e3fbb69"],"utility:other:approved":["0b929d848501d87d"],"utility:certificate:approved":["f70bcf2339f86b49"],"utility:policy:rejected":["c7c2a7a3b4cd9ee5"],"utility:policy:effective":["ad4e34e0dfe00af1"]},"grid":[{"name":"ERCOT","key":"ERCOT","rules":[{"title":"Texas Senate Bill 6 ,  large-load interconnection, curtailment, and remote-disconnect standards","summary":"Applies to non-critical loads of 75 MW or greater in ERCOT. Requires remote-disconnect capability as a condition of interconnection for loads interconnecting after December 31, 2025, and authorizes utilities/ERCOT to disconnect eligible large loads during firm load shed events; creates a competitively procured voluntary curtailment/reliability service with a minimum 24-hour notice period. Also sets a $100,000 minimum interconnection study fee, mandatory disclosure of duplicative interconnection requests in Texas,…","status":"effective; PUCT implementation rulemakings ongoing through 2026","date":"2025-06-20","sources":[{"url":"https://www.utilitydive.com/news/texas-law-gives-grid-operator-power-to-disconnect-data-centers-during-crisi/751587/","label":"www.utilitydive.com"}]},{"title":"Batch Zero large-load interconnection framework (PGRR145 + NPRR1325)","summary":"Groups qualified large loads of 75 MW+ into a single batch study to allocate available grid capacity year-by-year (2028–2032) via Load Commissioning Plans, set financial commitments ($50,000/MW financial security), and produce an actionable transmission plan. Key milestones: developer submissions due July 10, 2026; TSP/DSP packages due July 24, 2026; ERCOT classification notices (Base Load / Studied Load) by August 7, 2026; study results April 9, 2027; interconnection agreements executed by June 8, 2027. ERCOT…","status":"approved/effective; classification and study timelines now partially suspended by the August 2026 audit pause","date":"2026-06-18","sources":[{"url":"https://www.ercot.com/news/release/06182026-puct-approves-ercots","label":"www.ercot.com"}]},{"title":"PUCT proposed rule 16 TAC §25.194 ,  large load interconnection standards (SB 6 implementation)","summary":"Would establish interconnection standards for new or expanded loads of 75 MW+ in ERCOT: minimum study fees of $100,000 (75–249 MW) and $300,000 (250 MW+), CPI-adjusted every five years from 2027; financial security of $50,000 per MW of requested peak demand at intermediate-agreement execution plus additional security for long-lead equipment; a non-refundable interconnection fee of $50,000 per MW of contracted peak demand after study completion; site-control and development-readiness showings before studies begin;…","status":"proposed / pending adoption (adoption expected later in 2026)","date":"2026-03-12","sources":[{"url":"https://www.dlapiper.com/en-us/insights/publications/2026/03/texas-proposes-new-interconnection-standards-for-large-electric-loads","label":"www.dlapiper.com"}]},{"title":"PUCT order in Docket 59220 ,  first SB 6 net-metering/co-location ruling, affirming curtailment authority over co-located data…","summary":"PUCT approved a net-metering arrangement for a Crusoe-developed AI data center co-located behind the ~265.5 MW Goodnight 1 wind farm (a 260 MW second facility at the campus), with conditions: the full campus load must curtail within 30 minutes during ERCOT grid emergencies, physical breaker disconnection authorized, ERCOT to give 60 minutes advance notice when practicable, and the project is barred from compensation for load reductions during grid emergencies. Establishes that emergency curtailment of co-located…","status":"approved with conditions (binding on the applicants; first precedent for SB 6 co-location cases)","date":"2026-07-23","sources":[{"url":"https://www.utilitydive.com/news/texas-approves-ai-data-center-co-location-next-to-wind-farm-with-curtailme/826617/","label":"www.utilitydive.com"}]},{"title":"Gov. Abbott directive ,  comprehensive verification and audit of data centers in the ERCOT queue; pause on new data center…","summary":"Directs PUCT and ERCOT to verify every data center project advancing through the interconnection process ,  power demand and sourcing, on-site generation progress, water use and cooling, state/local financial assistance, community protections, and ownership ,  before any additional data center is approved to advance. States that projects failing the verification and audit process 'must be denied' grid access. Binds ERCOT and the PUCT.","status":"effective; audit in progress, pause remains pending audit completion","date":"2026-08-03","sources":[{"url":"https://www.utilitydive.com/news/texas-hits-pause-data-center-interconnections/827046/","label":"www.utilitydive.com"}]},{"title":"ERCOT Market Notice M-A080326-01 ,  suspension of Batch Zero classification deadline","summary":"ERCOT announced it would not meet the August 7, 2026 deadline to notify service providers of Large Load classifications in the Batch Zero Interconnection Study, citing the Governor's directive to conduct a verification process before advancing any data center large loads. ERCOT committed to file a good cause exception request with the PUCT before the PUCT's August 20, 2026 open meeting, seeking modification of timelines in Planning Guide Sections 5 and 9.","status":"Effective","date":"2026-08-03","sources":[{"url":"https://www.ercot.com/services/comm/mkt_notices/M-A080326-01","label":"www.ercot.com"}]},{"title":"ERCOT good-cause-exception filing and PUCT approval; audit timeline set (RFIs now, reports due December 10, 2026)","summary":"ERCOT requested relief from the August 7 classification deadline, authority for large loads to participate in the August and November Quarterly Stability Assessments (6 projects for August, up to 17 for November), and an extension for dynamic-data deficiency notifications; the PUCT granted the exceptions on August 20. ERCOT's timeline: RFIs to developers via TSPs/DSPs from late August through September, information gathering October–November, and filing of the Batch Zero Eligibility Verification Report and…","status":"approved","date":"2026-08-10","sources":[{"url":"https://www.utilitydive.com/news/ercot-texas-puc-data-center-audit/828472/","label":"www.utilitydive.com"}]},{"title":"PUCT Project 58484 ,  evaluation of transmission cost recovery (4CP methodology) for large loads","summary":"Evaluates whether the four-coincident-peak (4CP) wholesale transmission cost allocation method appropriately assigns costs given large-load growth. Draft recommendations under comment include moving to more coincident peaks over longer intervals, eliminating interconnection cost allowances for large loads, requiring large loads to pay a share of system upgrade costs, and minimum demand charges based on contracted peak demand for 10–15 years.","status":"pending rulemaking (SB 6 requires amended rules no later than December 31, 2026)","date":"2025-08-01","sources":[{"url":"https://www.klgates.com/Request-for-Comments-on-Texas-PUCT-Draft-Report-Regarding-Transmission-Cost-Recovery-in-the-ERCOT-Region-3-30-2026","label":"www.klgates.com"}]},{"title":"SB 6 companion rulemakings: Project 58479 (co-location net metering), Project 58480 (large-load forecasting, ≥10 MW definition),…","summary":"58479 requires PUCT approval of net-metering arrangements between new 75 MW+ customers and stand-alone generators, allowing conditional approvals (callable capacity, behind-the-meter curtailment) ,  the framework applied in Docket 59220. 58480 defines a large load customer as 10 MW+ at a single site for forecasting and sets documentation/milestones for inclusion in ERCOT forecasts. 58482 creates the SB 6 voluntary demand-reduction/reliability program for large loads.","status":"pending as of the December 23, 2025 source; mid-2026 adoption status not independently confirmed (see flags)","date":"2026-01","sources":[{"url":"https://www.ashurstperkinscoie.com/en/insights/sb-6-implementation-shaping-data-center-future-in-texas/","label":"www.ashurstperkinscoie.com"}]},{"title":"ERCOT market notice M-A013126-02: Results of Final Ad Hoc Interim VRT Assessment for Large Loads","summary":"ERCOT issued market notice M-A013126-02, Results of Final Ad Hoc Interim VRT Assessment for Large Loads, on Jun 26, 2026.","status":"Market notice","date":"2026-06-26","sources":[{"url":"https://www.ercot.com/services/comm/mkt_notices/M-A013126-02","label":"www.ercot.com"}]},{"title":"ERCOT market notice M-A052026-02: Impact Analysis - Incorrect consideration of ECRS Ramp Rate Telemetry for Non-Controllable Load Resources","summary":"ERCOT issued market notice M-A052026-02, Impact Analysis - Incorrect consideration of ECRS Ramp Rate Telemetry for Non-Controllable Load Resources, on Jul 31, 2026.","status":"Market notice","date":"2026-07-31","sources":[{"url":"https://www.ercot.com/services/comm/mkt_notices/M-A052026-02","label":"www.ercot.com"}]},{"title":"ERCOT market notice M-A080326-02: PUC Approval of Good Cause Exceptions Relating To Batch Zero Process","summary":"ERCOT issued market notice M-A080326-02, PUC Approval of Good Cause Exceptions Relating To Batch Zero Process, on Aug 21, 2026.","status":"Market notice","date":"2026-08-21","sources":[{"url":"https://www.ercot.com/services/comm/mkt_notices/M-A080326-02","label":"www.ercot.com"}]},{"title":"ERCOT market notice M-A080326-03: Delayed Issuance of Batch Zero Conditional Classifications","summary":"ERCOT issued market notice M-A080326-03, Delayed Issuance of Batch Zero Conditional Classifications, on Aug 31, 2026.","status":"Market notice","date":"2026-08-31","sources":[{"url":"https://www.ercot.com/services/comm/mkt_notices/M-A080326-03","label":"www.ercot.com"}]},{"title":"ERCOT market notice M-A080326-04: Batch Zero Conditional Classification issued to Transmission and/or Distribution Service Providers","summary":"ERCOT issued market notice M-A080326-04, Batch Zero Conditional Classification issued to Transmission and/or Distribution Service Providers, on Sep 3, 2026.","status":"Market notice","date":"2026-09-03","sources":[{"url":"https://www.ercot.com/services/comm/mkt_notices/M-A080326-04","label":"www.ercot.com"}]},{"title":"ERCOT market notice M-A090226-01: Workshop to share proposed operational framework for implementing SB6-related Large Load curtailments, including registration requirements","summary":"ERCOT issued market notice M-A090226-01, Workshop to share proposed operational framework for implementing SB6-related Large Load curtailments, including registration requirements, on Sep 2, 2026.","status":"Market notice","date":"2026-09-02","sources":[{"url":"https://www.ercot.com/services/comm/mkt_notices/M-A090226-01","label":"www.ercot.com"}]},{"title":"ERCOT market notice M-A090926-01: Issuance of Batch Zero Verification Requests for Information","summary":"ERCOT issued market notice M-A090926-01, Issuance of Batch Zero Verification Requests for Information, on Sep 9, 2026.","status":"Market notice","date":"2026-09-09","sources":[{"url":"https://www.ercot.com/services/comm/mkt_notices/M-A090926-01","label":"www.ercot.com"}]},{"title":"ERCOT market notice M-B062326-01: Implementation of the Batch Zero Process (PGRR145/NPRR1325)","summary":"ERCOT issued market notice M-B062326-01, Implementation of the Batch Zero Process (PGRR145/NPRR1325), on Jun 23, 2026.","status":"Market notice","date":"2026-06-23","sources":[{"url":"https://www.ercot.com/services/comm/mkt_notices/M-B062326-01","label":"www.ercot.com"}]},{"title":"ERCOT market notice M-B062326-02: Batch Zero follow-up for WLPUN/BYOG","summary":"ERCOT issued market notice M-B062326-02, Batch Zero follow-up for WLPUN/BYOG, on Jun 26, 2026.","status":"Market notice","date":"2026-06-26","sources":[{"url":"https://www.ercot.com/services/comm/mkt_notices/M-B062326-02","label":"www.ercot.com"}]},{"title":"ERCOT market notice M-B062326-03: Large Load Prerequisites for the Quarterly Stability Assessment with a Prerequisite Deadline of August 1, 2026","summary":"ERCOT issued market notice M-B062326-03, Large Load Prerequisites for the Quarterly Stability Assessment with a Prerequisite Deadline of August 1, 2026, on Jul 8, 2026.","status":"Market notice","date":"2026-07-08","sources":[{"url":"https://www.ercot.com/services/comm/mkt_notices/M-B062326-03","label":"www.ercot.com"}]},{"title":"ERCOT market notice M-B062326-04: Details for ending the Large Load Interconnection Study process under PGRR115 and submission deadlines for PGRR145 (Batch Zero) on July 10, 2026","summary":"ERCOT issued market notice M-B062326-04, Details for ending the Large Load Interconnection Study process under PGRR115 and submission deadlines for PGRR145 (Batch Zero) on July 10, 2026, on Jul 8, 2026.","status":"Market notice","date":"2026-07-08","sources":[{"url":"https://www.ercot.com/services/comm/mkt_notices/M-B062326-04","label":"www.ercot.com"}]},{"title":"ERCOT market notice M-B062326-05: Batch Zero submissions of Dynamic Model files to ERCOT for July 10, 2026 deadline","summary":"ERCOT issued market notice M-B062326-05, Batch Zero submissions of Dynamic Model files to ERCOT for July 10, 2026 deadline, on Jul 10, 2026.","status":"Market notice","date":"2026-07-10","sources":[{"url":"https://www.ercot.com/services/comm/mkt_notices/M-B062326-05","label":"www.ercot.com"}]},{"title":"ERCOT market notice M-B062326-06: Batch Zero Eligibility Submissions and Good Cause Exception Process for PGRR145","summary":"ERCOT issued market notice M-B062326-06, Batch Zero Eligibility Submissions and Good Cause Exception Process for PGRR145, on Jul 23, 2026.","status":"Market notice","date":"2026-07-23","sources":[{"url":"https://www.ercot.com/services/comm/mkt_notices/M-B062326-06","label":"www.ercot.com"}]},{"title":"ERCOT market notice M-B063026-01: Partial Implementation Details of PGRR145/NPRR1325, Batch Zero Process for Large Load Interconnections","summary":"ERCOT issued market notice M-B063026-01, Partial Implementation Details of PGRR145/NPRR1325, Batch Zero Process for Large Load Interconnections, on Jun 30, 2026.","status":"Market notice","date":"2026-06-30","sources":[{"url":"https://www.ercot.com/services/comm/mkt_notices/M-B063026-01","label":"www.ercot.com"}]},{"title":"ERCOT market notice M-F073126-01: Revised Notice of Proposed Net Metering Arrangement Form relating to Net Metering Arrangements Involving a Large Load Customer Co-Located with an Existing Generation Resource","summary":"ERCOT issued market notice M-F073126-01, Revised Notice of Proposed Net Metering Arrangement Form relating to Net Metering Arrangements Involving a Large Load Customer Co-Located with an Existing Generation Resource, on Jul 31, 2026.","status":"Market notice","date":"2026-07-31","sources":[{"url":"https://www.ercot.com/services/comm/mkt_notices/M-F073126-01","label":"www.ercot.com"}]},{"title":"ERCOT news release: PUCT Approves ERCOT's Batch Zero Process for Connecting Large Electricity Users While Protecting System Reliability for Texans","summary":"ERCOT published the news release PUCT Approves ERCOT's Batch Zero Process for Connecting Large Electricity Users While Protecting System Reliability for Texans on Jun 18, 2026.","status":"News release","date":"2026-06-18","sources":[{"url":"https://www.ercot.com/news/release/06182026-puct-approves-ercots","label":"www.ercot.com"}]},{"title":"PUCT Project 58481: Request for Control Number","summary":"PUC RULES & PROJECTS filed Request for Control Number in PUCT Project 58481 on Jul 31, 2025.","status":"PUC RULES & PROJECTS","date":"2025-07-31","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=1","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: Staff Memo and Questions for Comment w/Oct. 10 Comment Deadline","summary":"PUC RULES & PROJECTS filed Staff Memo and Questions for Comment w/Oct. 10 Comment Deadline in PUCT Project 58481 on Sep 12, 2025.","status":"PUC RULES & PROJECTS","date":"2025-09-12","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=2","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: OPUC NOTICE OF PARTICIPATION LETTER","summary":"OPUC filed OPUC NOTICE OF PARTICIPATION LETTER in PUCT Project 58481 on Sep 24, 2025.","status":"OPUC","date":"2025-09-24","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=3","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59142: ERCOT LARGE LOAD BATCH STUDY PROCESS UPDATE","summary":"ERCOT filed ERCOT LARGE LOAD BATCH STUDY PROCESS UPDATE in PUCT Project 59142 on Feb 5, 2026.","status":"ERCOT","date":"2026-02-05","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59142&itemNumber=11","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59142: TBC ERCOT Large Load Interconnection Batch Study Comments","summary":"TEXAS BLOCKCHAIN COUNCIL filed TBC ERCOT Large Load Interconnection Batch Study Comments in PUCT Project 59142 on Feb 6, 2026.","status":"TEXAS BLOCKCHAIN COUNCIL","date":"2026-02-06","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59142&itemNumber=12","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59142: ERCOT LARGE LOAD BATCH STUDY UPDATE","summary":"ERCOT filed ERCOT LARGE LOAD BATCH STUDY UPDATE in PUCT Project 59142 on Feb 13, 2026.","status":"ERCOT","date":"2026-02-13","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59142&itemNumber=13","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59142: ERCOT LARGE LOAD BATCH STUDY UPDATE","summary":"ERCOT filed ERCOT LARGE LOAD BATCH STUDY UPDATE in PUCT Project 59142 on Mar 5, 2026.","status":"ERCOT","date":"2026-03-05","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59142&itemNumber=14","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59142: PUC PROJECT NO. 59142 - BATCH STUDY CONSIDERATIONS AND PGRR145","summary":"SCHAPER ENERGY CONSULTING LLC filed PUC PROJECT NO. 59142 - BATCH STUDY CONSIDERATIONS AND PGRR145 in PUCT Project 59142 on Mar 9, 2026.","status":"SCHAPER ENERGY CONSULTING LLC","date":"2026-03-09","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59142&itemNumber=15","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59142: Vistra Corp.'s Comments on Planning Guide Revision Request 145 for Project 59142","summary":"VISTRA CORP. filed Vistra Corp.'s Comments on Planning Guide Revision Request 145 for Project 59142 in PUCT Project 59142 on Mar 20, 2026.","status":"VISTRA CORP.","date":"2026-03-20","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59142&itemNumber=16","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59142: ERCOT LARGE LOAD BATCH STUDY UPDATE","summary":"ERCOT filed ERCOT LARGE LOAD BATCH STUDY UPDATE in PUCT Project 59142 on Mar 30, 2026.","status":"ERCOT","date":"2026-03-30","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59142&itemNumber=17","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59142: Vistra Corp.'s Comments on Planning Guide Revision Request 145 for Project 59142","summary":"VISTRA CORP. filed Vistra Corp.'s Comments on Planning Guide Revision Request 145 for Project 59142 in PUCT Project 59142 on Apr 9, 2026.","status":"VISTRA CORP.","date":"2026-04-09","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59142&itemNumber=18","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59142: ONCOR ELECTRIC DELIVERY COMPANY LLC’S COMMENTS ON ERCOT’S PGRR 145","summary":"ONCOR ELECTRIC DELIVERY COMPANY LLC filed ONCOR ELECTRIC DELIVERY COMPANY LLC’S COMMENTS ON ERCOT’S PGRR 145 in PUCT Project 59142 on Apr 10, 2026.","status":"ONCOR ELECTRIC DELIVERY COMPANY LLC","date":"2026-04-10","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59142&itemNumber=19","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59142: CONTROL NUMBER REQUEST","summary":"PUC EXECUTIVE DIRECTOR filed CONTROL NUMBER REQUEST in PUCT Project 59142 on Dec 17, 2025.","status":"PUC EXECUTIVE DIRECTOR","date":"2025-12-17","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59142&itemNumber=1","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59142: ERCOT LARGE LOAD BATCH STUDY UPDATE","summary":"ERCOT filed ERCOT LARGE LOAD BATCH STUDY UPDATE in PUCT Project 59142 on Apr 10, 2026.","status":"ERCOT","date":"2026-04-10","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59142&itemNumber=20","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59142: PGRR145 & ERCOT BATCH ZERO CRITERIA CONSIDERATION","summary":"SCHAPER ENERGY CONSULTING LLC filed PGRR145 & ERCOT BATCH ZERO CRITERIA CONSIDERATION in PUCT Project 59142 on Apr 11, 2026.","status":"SCHAPER ENERGY CONSULTING LLC","date":"2026-04-11","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59142&itemNumber=21","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59142: Staff Memo","summary":"PUC RULES & PROJECTS filed Staff Memo in PUCT Project 59142 on Apr 13, 2026.","status":"PUC RULES & PROJECTS","date":"2026-04-13","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59142&itemNumber=22","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59142: Joint Comments of Google LLC, Lancium LLC, and Eolic Development LLC","summary":"Google LLC, Lancium LLC, Eolic Development LLC filed Joint Comments of Google LLC, Lancium LLC, and Eolic Development LLC in PUCT Project 59142 on Apr 16, 2026.","status":"Google LLC, Lancium LLC, Eolic Development LLC","date":"2026-04-16","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59142&itemNumber=24","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59142: TRACT HOLDING COMPANY I, LLC’S COMMENTS ON THE COMMISSION’S STAFF MEMO DATED APRIL 12, 2026","summary":"Tract Holding Company I, LLC filed TRACT HOLDING COMPANY I, LLC’S COMMENTS ON THE COMMISSION’S STAFF MEMO DATED APRIL 12, 2026 in PUCT Project 59142 on Apr 16, 2026.","status":"Tract Holding Company I, LLC","date":"2026-04-16","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59142&itemNumber=25","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59142: Comments in Response to Staff Memo","summary":"Engine No. 1 filed Comments in Response to Staff Memo in PUCT Project 59142 on Apr 16, 2026.","status":"Engine No. 1","date":"2026-04-16","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59142&itemNumber=27","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59142: CyrusOne Project No. 59142 Batch Study Considerations and PGRR145","summary":"CyrusOne, LP filed CyrusOne Project No. 59142 Batch Study Considerations and PGRR145 in PUCT Project 59142 on Apr 17, 2026.","status":"CyrusOne, LP","date":"2026-04-17","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59142&itemNumber=29","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59142: Joint Comments of Google LLC and Lancium LLC as it pertains to ERCOT's Large Load Process Reforms","summary":"GOOGLE LLC, LANCIUM LLC filed Joint Comments of Google LLC and Lancium LLC as it pertains to ERCOT's Large Load Process Reforms in PUCT Project 59142 on Dec 18, 2025.","status":"GOOGLE LLC, LANCIUM LLC","date":"2025-12-18","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59142&itemNumber=2","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59142: Staff's April 29, 2026 comments on PGRR 145","summary":"PUC DEPUTY EXECUTIVE DIRECTOR filed Staff's April 29, 2026 comments on PGRR 145 in PUCT Project 59142 on Apr 29, 2026.","status":"PUC DEPUTY EXECUTIVE DIRECTOR","date":"2026-04-29","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59142&itemNumber=30","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59142: TRACT HOLDING COMPANY I, LLC’S COMMENTS ON THE COMMISSION’S STAFF MEMO DATED APRIL 12, 2026","summary":"Tract Holding Company I, LLC filed TRACT HOLDING COMPANY I, LLC’S COMMENTS ON THE COMMISSION’S STAFF MEMO DATED APRIL 12, 2026 in PUCT Project 59142 on May 4, 2026.","status":"Tract Holding Company I, LLC","date":"2026-05-04","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59142&itemNumber=31","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59142: ERCOT LARGE LOAD BATCH STUDY UPDATE","summary":"ERCOT filed ERCOT LARGE LOAD BATCH STUDY UPDATE in PUCT Project 59142 on May 5, 2026.","status":"ERCOT","date":"2026-05-05","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59142&itemNumber=32","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59142: Staff memo on Batch 0 entry criteria","summary":"PUC DEPUTY EXECUTIVE DIRECTOR filed Staff memo on Batch 0 entry criteria in PUCT Project 59142 on May 6, 2026.","status":"PUC DEPUTY EXECUTIVE DIRECTOR","date":"2026-05-06","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59142&itemNumber=33","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59142: DCC Comments on Net Metering Arrangements in Batch Zero","summary":"Data Center Coalition (DCC) filed DCC Comments on Net Metering Arrangements in Batch Zero in PUCT Project 59142 on May 14, 2026.","status":"Data Center Coalition (DCC)","date":"2026-05-14","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59142&itemNumber=34","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59142: Comments on May 6th Staff Memorandum","summary":"Nightpeak Energy LLC filed Comments on May 6th Staff Memorandum in PUCT Project 59142 on May 26, 2026.","status":"Nightpeak Energy LLC","date":"2026-05-26","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59142&itemNumber=36","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59142: Crusoe Technologies, LLC Comments on Recommended Approval of PGRR 145 by the ERCOT Board of Directors","summary":"Crusoe Technologies, LLC filed Crusoe Technologies, LLC Comments on Recommended Approval of PGRR 145 by the ERCOT Board of Directors in PUCT Project 59142 on Jun 12, 2026.","status":"Crusoe Technologies, LLC","date":"2026-06-12","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59142&itemNumber=37","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59142: First Ammonia LLC's Comments on Commission Consideration of PGRR 145, Batch Zero Process for Large Load Interconnections","summary":"First Ammonia LLC filed First Ammonia LLC's Comments on Commission Consideration of PGRR 145, Batch Zero Process for Large Load Interconnections in PUCT Project 59142 on Jun 17, 2026.","status":"First Ammonia LLC","date":"2026-06-17","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59142&itemNumber=39","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59142: Project Trailblazer - Request for Legacy and/or batch zero Interconnection Process Consideration","summary":"Trailblazer Infrastructure LLC filed Project Trailblazer - Request for Legacy and/or batch zero Interconnection Process Consideration in PUCT Project 59142 on Jul 10, 2026.","status":"Trailblazer Infrastructure LLC","date":"2026-07-10","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59142&itemNumber=40","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59142: Notice of Withdrawal - This filing formally withdraws Trailblazer Infrastructure LLC's previously submitted Informational Memorandum in PUCT Project No. 59142. The notice advises the Commission that, due to ongoing discussions among the relevant parties.","summary":"Trailblazer Infrastrructure LLC. filed Notice of Withdrawal - This filing formally withdraws Trailblazer Infrastructure LLC's previously submitted Informational Memorandum in PUCT Project No. 59142. The notice advises the Commission that, due to ongoing discussions among the relevant parties. in PUCT Project 59142 on Jul 13, 2026.","status":"Trailblazer Infrastrructure LLC.","date":"2026-07-13","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59142&itemNumber=41","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59142: ELECTRIC RELIABILITY COUNCIL OF TEXAS, INC.’S REQUESTS FOR GOOD CAUSE EXCEPTIONS RELATING TO BATCH ZERO DEADLINES AND STATUS UPDATE ON ADDITIONAL MATTERS INCLUDING THE LONG-TERM LOAD FORECAST","summary":"ERCOT filed ELECTRIC RELIABILITY COUNCIL OF TEXAS, INC.’S REQUESTS FOR GOOD CAUSE EXCEPTIONS RELATING TO BATCH ZERO DEADLINES AND STATUS UPDATE ON ADDITIONAL MATTERS INCLUDING THE LONG-TERM LOAD FORECAST in PUCT Project 59142 on Aug 10, 2026.","status":"ERCOT","date":"2026-08-10","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59142&itemNumber=42","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59142: Letter regarding ERCOT's Requests for Exceptions Relating to Batch Zero Deadlines","summary":"First Ammonia LLC filed Letter regarding ERCOT's Requests for Exceptions Relating to Batch Zero Deadlines in PUCT Project 59142 on Aug 13, 2026.","status":"First Ammonia LLC","date":"2026-08-13","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59142&itemNumber=44","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59142: Octa's Comments on ERCOT's August 10, 2026 Status Update","summary":"Octa Data Center Development Company LLC filed Octa's Comments on ERCOT's August 10, 2026 Status Update in PUCT Project 59142 on Aug 13, 2026.","status":"Octa Data Center Development Company LLC","date":"2026-08-13","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59142&itemNumber=45","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59142: Public Comment - Audit Standards Required Under Governor’s Directive","summary":"Sandra Gail Gilbreath Wright filed Public Comment - Audit Standards Required Under Governor’s Directive in PUCT Project 59142 on Aug 16, 2026.","status":"Sandra Gail Gilbreath Wright","date":"2026-08-16","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59142&itemNumber=46","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59142: Ionic Digital Inc.'s Comments Regarding ERCOT's Requests for Good Cause Exceptions Relating to Batch Zero Deadlines","summary":"Ionic Digital Inc. filed Ionic Digital Inc.'s Comments Regarding ERCOT's Requests for Good Cause Exceptions Relating to Batch Zero Deadlines in PUCT Project 59142 on Aug 19, 2026.","status":"Ionic Digital Inc.","date":"2026-08-19","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59142&itemNumber=48","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59142: Request for Commission Action on Batch Zero Eligibility (CloudPeak BZ-259 & BZ-180)","summary":"PowerHouse CloudPeak Venture Alpha LLC and PowerHouse CloudPeak Venture C LLC filed Request for Commission Action on Batch Zero Eligibility (CloudPeak BZ-259 & BZ-180) in PUCT Project 59142 on Aug 19, 2026.","status":"PowerHouse CloudPeak Venture Alpha LLC and PowerHouse CloudPeak Venture C LLC","date":"2026-08-19","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59142&itemNumber=49","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59142: LETTER RE ERCOT LARGE LOAD BATCH STUDY PROCESS UPDATE","summary":"ERCOT filed LETTER RE ERCOT LARGE LOAD BATCH STUDY PROCESS UPDATE in PUCT Project 59142 on Jan 12, 2026.","status":"ERCOT","date":"2026-01-12","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59142&itemNumber=4","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59142: ERCOT UPDATES - GOOD CAUSE EXCEPTIONS FOR PGRR 145, BATCH ZERO VERIFICATION AND AUDIT PROCESS, AND COMMUNITY IMPACT REVIEW PROCESS","summary":"ERCOT filed ERCOT UPDATES - GOOD CAUSE EXCEPTIONS FOR PGRR 145, BATCH ZERO VERIFICATION AND AUDIT PROCESS, AND COMMUNITY IMPACT REVIEW PROCESS in PUCT Project 59142 on Aug 20, 2026.","status":"ERCOT","date":"2026-08-20","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59142&itemNumber=52","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59142: ORDER GRANTING GOOD CAUSE EXCEPTIONS","summary":"PUC OPDM filed ORDER GRANTING GOOD CAUSE EXCEPTIONS in PUCT Project 59142 on Aug 20, 2026.","status":"PUC OPDM","date":"2026-08-20","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59142&itemNumber=53","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59142: SCHAPER ENERGY CONSULTING PROPOSED APPROACH TO PUBLIC BENEFIT DISCLOSURE IN THE COMMUNITY IMPACT COMPONENT OF THE LARGE LOAD AUDIT","summary":"SCHAPER ENERGY CONSULTING LLC filed SCHAPER ENERGY CONSULTING PROPOSED APPROACH TO PUBLIC BENEFIT DISCLOSURE IN THE COMMUNITY IMPACT COMPONENT OF THE LARGE LOAD AUDIT in PUCT Project 59142 on Aug 20, 2026.","status":"SCHAPER ENERGY CONSULTING LLC","date":"2026-08-20","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59142&itemNumber=54","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59142: ERCOT UPDATE FOR SEPTEMBER 11, 2026 OPEN MEETING - BATCH ZERO AND STATE AND COMMUNITY IMPACT RFI PROCESS","summary":"ERCOT filed ERCOT UPDATE FOR SEPTEMBER 11, 2026 OPEN MEETING - BATCH ZERO AND STATE AND COMMUNITY IMPACT RFI PROCESS in PUCT Project 59142 on Sep 11, 2026.","status":"ERCOT","date":"2026-09-11","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59142&itemNumber=55","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59142: Request for Audit for Project Raptor","summary":"Laura Lindemann filed Request for Audit for Project Raptor in PUCT Project 59142 on Sep 11, 2026.","status":"Laura Lindemann","date":"2026-09-11","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59142&itemNumber=56","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59142: Synergen's Request for Good Cause Exception Relating To Batch Zero Eligibility Deadlines","summary":"Synergen Green Energy, Inc. filed Synergen's Request for Good Cause Exception Relating To Batch Zero Eligibility Deadlines in PUCT Project 59142 on Sep 11, 2026.","status":"Synergen Green Energy, Inc.","date":"2026-09-11","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59142&itemNumber=57","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59142: LETTER RE FEBRUARY 3 2026 BATCH STUDY WORKSHOP","summary":"ERCOT filed LETTER RE FEBRUARY 3 2026 BATCH STUDY WORKSHOP in PUCT Project 59142 on Jan 16, 2026.","status":"ERCOT","date":"2026-01-16","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59142&itemNumber=5","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59142: LETTER RE ERCOT LARGE LOAD BATCH STUDY PROCESS UPDATE","summary":"ERCOT filed LETTER RE ERCOT LARGE LOAD BATCH STUDY PROCESS UPDATE in PUCT Project 59142 on Jan 26, 2026.","status":"ERCOT","date":"2026-01-26","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59142&itemNumber=6","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59142: OPEN LETTER TO THE COMMISSION REGARDING ERCOT'S INTERCONNECTION PROCESS FOR LARGE LOADS","summary":"Rose City Partners, Schaper Energy Consulting, Crusoe Energy Systems, Outlaw Ventures, Solomon Data Systems, Eolic Development Partners, Zero Emission Grid, Juvo Energy, Belisari, and V-Wire filed OPEN LETTER TO THE COMMISSION REGARDING ERCOT'S INTERCONNECTION PROCESS FOR LARGE LOADS in PUCT Project 59142 on Jan 29, 2026.","status":"Rose City Partners, Schaper Energy Consulting, Crusoe Energy Systems, Outlaw Ventures, Solomon Data Systems, Eolic Development Partners, Zero Emission Grid, Juvo Energy, Belisari, and V-Wire","date":"2026-01-29","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59142&itemNumber=7","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59142: ERCOT LARGE LOAD BATCH STUDY PROCESS DRAFT FRAMEWORK PRESENTATIONS","summary":"ERCOT filed ERCOT LARGE LOAD BATCH STUDY PROCESS DRAFT FRAMEWORK PRESENTATIONS in PUCT Project 59142 on Jan 30, 2026.","status":"ERCOT","date":"2026-01-30","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59142&itemNumber=8","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59142: OPUC NOTICE OF PARTICIPATION LETTER","summary":"OPUC filed OPUC NOTICE OF PARTICIPATION LETTER in PUCT Project 59142 on Feb 2, 2026.","status":"OPUC","date":"2026-02-02","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59142&itemNumber=9","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: VOID SEE ITEM 205","summary":"PUC RULES & PROJECTS filed VOID SEE ITEM 205 in PUCT Project 58481 on Aug 24, 2026.","status":"PUC RULES & PROJECTS","date":"2026-08-24","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=204","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: Memo Requesting CR Void Item No. 204","summary":"PUC RULES & PROJECTS filed Memo Requesting CR Void Item No. 204 in PUCT Project 58481 on Aug 24, 2026.","status":"PUC RULES & PROJECTS","date":"2026-08-24","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=205","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: Staff Memo w/Draft Recommended Changes to Proposed Rule","summary":"PUC RULES & PROJECTS filed Staff Memo w/Draft Recommended Changes to Proposed Rule in PUCT Project 58481 on Aug 24, 2026.","status":"PUC RULES & PROJECTS","date":"2026-08-24","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=206","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58796: SOAH ORDER NO. 10 - EXTENDING BRIEFING DEADLINES","summary":"SOAH filed SOAH ORDER NO. 10 - EXTENDING BRIEFING DEADLINES in PUCT Project 58796 on Aug 27, 2026.","status":"SOAH","date":"2026-08-27","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58796&itemNumber=99","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59948: EPE's Proof of Notice","summary":"EL PASO ELECTRIC COMPANY filed EPE's Proof of Notice in PUCT Project 59948 on Aug 27, 2026.","status":"EL PASO ELECTRIC COMPANY","date":"2026-08-27","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59948&itemNumber=11","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: Comments of CenterPoint Energy Houston Electric, LLC","summary":"CENTERPOINT ENERGY HOUSTON ELECTRIC filed Comments of CenterPoint Energy Houston Electric, LLC in PUCT Project 58481 on Oct 10, 2025.","status":"CENTERPOINT ENERGY HOUSTON ELECTRIC","date":"2025-10-10","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=10","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: ONCOR'S RESPONSE TO COMMISSION STAFF’S FIRST SET OF QUESTIONS FOR COMMENTS","summary":"ONCOR ELECTRIC DELIVERY COMPANY LLC filed ONCOR'S RESPONSE TO COMMISSION STAFF’S FIRST SET OF QUESTIONS FOR COMMENTS in PUCT Project 58481 on Oct 10, 2025.","status":"ONCOR ELECTRIC DELIVERY COMPANY LLC","date":"2025-10-10","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=11","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: RESPONSE TO QUESTIONS FOR COMMENT","summary":"LCRA TRANSMISSION SERVICE CORPORATION filed RESPONSE TO QUESTIONS FOR COMMENT in PUCT Project 58481 on Oct 10, 2025.","status":"LCRA TRANSMISSION SERVICE CORPORATION","date":"2025-10-10","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=12","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: DCC Comments on Project 58481, Rulemaking to Implement Large Load Interconnection Standards","summary":"Data Center Coalition filed DCC Comments on Project 58481, Rulemaking to Implement Large Load Interconnection Standards in PUCT Project 58481 on Oct 10, 2025.","status":"Data Center Coalition","date":"2025-10-10","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=13","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: Responses of Texas Electric Cooperatives, Inc.","summary":"Texas Electric Cooperatives, Inc. filed Responses of Texas Electric Cooperatives, Inc. in PUCT Project 58481 on Oct 10, 2025.","status":"Texas Electric Cooperatives, Inc.","date":"2025-10-10","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=15","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: Sharyland Utilities, L.L.C's Comments to Commission Staff's Questions for Comments","summary":"SHARYLAND UTILITIES, L.L.C. filed Sharyland Utilities, L.L.C's Comments to Commission Staff's Questions for Comments in PUCT Project 58481 on Oct 10, 2025.","status":"SHARYLAND UTILITIES, L.L.C.","date":"2025-10-10","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=16","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: Eneus Response to Staff Questions on Project No. 58481","summary":"Eneus Energy filed Eneus Response to Staff Questions on Project No. 58481 in PUCT Project 58481 on Oct 10, 2025.","status":"Eneus Energy","date":"2025-10-10","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=19","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: OPUC’S RESPONSES TO QUESTIONS FOR PUBLIC COMMENT RELATED TO THE IMPLEMENTATION OF PURA § 37.0561","summary":"OPUC filed OPUC’S RESPONSES TO QUESTIONS FOR PUBLIC COMMENT RELATED TO THE IMPLEMENTATION OF PURA § 37.0561 in PUCT Project 58481 on Oct 10, 2025.","status":"OPUC","date":"2025-10-10","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=20","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: ELECTRIC RELIABILITY COUNCIL OF TEXAS, INC.’S RESPONSES TO STAFF QUESTIONS","summary":"ERCOT filed ELECTRIC RELIABILITY COUNCIL OF TEXAS, INC.’S RESPONSES TO STAFF QUESTIONS in PUCT Project 58481 on Oct 10, 2025.","status":"ERCOT","date":"2025-10-10","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=21","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: AEP Texas Responses to Questions for Public Comment","summary":"AEP TEXAS INC. filed AEP Texas Responses to Questions for Public Comment in PUCT Project 58481 on Oct 10, 2025.","status":"AEP TEXAS INC.","date":"2025-10-10","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=22","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: TEBA Responses to Staff Questions on Project 58481","summary":"TEXAS ENERGY BUYERS ALLIANCE filed TEBA Responses to Staff Questions on Project 58481 in PUCT Project 58481 on Oct 10, 2025.","status":"TEXAS ENERGY BUYERS ALLIANCE","date":"2025-10-10","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=24","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: Texas-New Mexico Power Company's Comments to Commission Staff's Questions for Comment","summary":"TEXAS-NEW MEXICO POWER COMPANY filed Texas-New Mexico Power Company's Comments to Commission Staff's Questions for Comment in PUCT Project 58481 on Oct 10, 2025.","status":"TEXAS-NEW MEXICO POWER COMPANY","date":"2025-10-10","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=27","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: Lancium Comments on Project No. 58481","summary":"LANCIUM, LLC filed Lancium Comments on Project No. 58481 in PUCT Project 58481 on Oct 10, 2025.","status":"LANCIUM, LLC","date":"2025-10-10","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=28","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: Enchanted Rock, LLC's Responses to Commission Staff's Questions for Comment","summary":"ENCHANTED ROCK, LLC filed Enchanted Rock, LLC's Responses to Commission Staff's Questions for Comment in PUCT Project 58481 on Oct 14, 2025.","status":"ENCHANTED ROCK, LLC","date":"2025-10-14","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=30","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: Discussion Draft w/12.19 Comment Deadline","summary":"PUC RULES & PROJECTS filed Discussion Draft w/12.19 Comment Deadline in PUCT Project 58481 on Dec 1, 2025.","status":"PUC RULES & PROJECTS","date":"2025-12-01","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=31","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: SCHAPER ENERGY CONSULTING LLC RESPONSE TO PROJECT NO. 58481, COMMENTS TO STAFF’s QUESTIONS AND DRAFT 16 TAC §25.194","summary":"Schaper Energy Consulting LLC filed SCHAPER ENERGY CONSULTING LLC RESPONSE TO PROJECT NO. 58481, COMMENTS TO STAFF’s QUESTIONS AND DRAFT 16 TAC §25.194 in PUCT Project 58481 on Dec 8, 2025.","status":"Schaper Energy Consulting LLC","date":"2025-12-08","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=32","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: Notice of January 9 Workshop","summary":"PUC RULES & PROJECTS filed Notice of January 9 Workshop in PUCT Project 58481 on Dec 16, 2025.","status":"PUC RULES & PROJECTS","date":"2025-12-16","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=33","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: Cholla Comments on Draft Rule","summary":"Cholla Petroleum, Inc. filed Cholla Comments on Draft Rule in PUCT Project 58481 on Dec 16, 2025.","status":"Cholla Petroleum, Inc.","date":"2025-12-16","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=34","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: Cholla Comments on Draft Rule Amended","summary":"Cholla Petroleum, Inc. filed Cholla Comments on Draft Rule Amended in PUCT Project 58481 on Dec 17, 2025.","status":"Cholla Petroleum, Inc.","date":"2025-12-17","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=35","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: Comments on proposed staff draft on large load interconnection standards.","summary":"SIERRA CLUB filed Comments on proposed staff draft on large load interconnection standards. in PUCT Project 58481 on Dec 18, 2025.","status":"SIERRA CLUB","date":"2025-12-18","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=36","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: Joint Comments of Google LLC and Lancium LLC to 58481 Large Load Interconnection Standards","summary":"GOOGLE LLC, LANCIUM LLC filed Joint Comments of Google LLC and Lancium LLC to 58481 Large Load Interconnection Standards in PUCT Project 58481 on Dec 18, 2025.","status":"GOOGLE LLC, LANCIUM LLC","date":"2025-12-18","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=40","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: TCPA Comments on Staff Questions & Discussion Draft","summary":"TCPA filed TCPA Comments on Staff Questions & Discussion Draft in PUCT Project 58481 on Dec 19, 2025.","status":"TCPA","date":"2025-12-19","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=42","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: Comments of Texas Electric Cooperatives, Inc.","summary":"Texas Electric Cooperatives, Inc. filed Comments of Texas Electric Cooperatives, Inc. in PUCT Project 58481 on Dec 19, 2025.","status":"Texas Electric Cooperatives, Inc.","date":"2025-12-19","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=48","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: Comments of CenterPoint Energy Houston Electric, LLC","summary":"CENTERPOINT ENERGY HOUSTON ELECTRIC, LLC filed Comments of CenterPoint Energy Houston Electric, LLC in PUCT Project 58481 on Dec 19, 2025.","status":"CENTERPOINT ENERGY HOUSTON ELECTRIC, LLC","date":"2025-12-19","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=49","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: SCHAPER ENERGY CONSULTING LLC RESPONSE TO STAFF’s QUESTIONS ON PROJECT NO. 58481; RULEMAKING TO IMPLEMENT LARGE LOAD INTERCONNECTION STANDARDS UNDER PURA §37.0561","summary":"Schaper Energy Consulting LLC filed SCHAPER ENERGY CONSULTING LLC RESPONSE TO STAFF’s QUESTIONS ON PROJECT NO. 58481; RULEMAKING TO IMPLEMENT LARGE LOAD INTERCONNECTION STANDARDS UNDER PURA §37.0561 in PUCT Project 58481 on Sep 30, 2025.","status":"Schaper Energy Consulting LLC","date":"2025-09-30","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=4","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: NRG Energy, Inc.'s Comments on Staff's Discussion Draft","summary":"NRG ENERGY, INC. filed NRG Energy, Inc.'s Comments on Staff's Discussion Draft in PUCT Project 58481 on Dec 19, 2025.","status":"NRG ENERGY, INC.","date":"2025-12-19","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=50","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: BASF Comments on Rule Project 58481","summary":"BASF filed BASF Comments on Rule Project 58481 in PUCT Project 58481 on Dec 19, 2025.","status":"BASF","date":"2025-12-19","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=52","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: RESPONSE TO QUESTIONS FOR COMMENT AND DRAFT NEW 16 TAC § 25.194","summary":"LCRA TRANSMISSION SERVICES CORPORATION filed RESPONSE TO QUESTIONS FOR COMMENT AND DRAFT NEW 16 TAC § 25.194 in PUCT Project 58481 on Dec 19, 2025.","status":"LCRA TRANSMISSION SERVICES CORPORATION","date":"2025-12-19","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=53","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: Comments on Staff new Draft 16 TAC §25.194","summary":"Aperture filed Comments on Staff new Draft 16 TAC §25.194 in PUCT Project 58481 on Dec 19, 2025.","status":"Aperture","date":"2025-12-19","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=55","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: ERCOT Steel Mills' Comments on Staff's Discussion Draft for Project No. 58481","summary":"ERCOT STEEL MILLS filed ERCOT Steel Mills' Comments on Staff's Discussion Draft for Project No. 58481 in PUCT Project 58481 on Dec 19, 2025.","status":"ERCOT STEEL MILLS","date":"2025-12-19","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=57","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: Cholla, Inc. Response to Staff Questions on Project No. 58481; Large Load Interconnection Framework Recommendations","summary":"Cholla, Inc. filed Cholla, Inc. Response to Staff Questions on Project No. 58481; Large Load Interconnection Framework Recommendations in PUCT Project 58481 on Oct 9, 2025.","status":"Cholla, Inc.","date":"2025-10-09","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=5","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: ONCOR ELECTRIC DELIVERY'S COMMENTS ON COMMISSION STAFF'S RULE 25.194 DISCUSSION DRAFT","summary":"ONCOR ELECTRIC DELIVERY COMPANY LLC filed ONCOR ELECTRIC DELIVERY'S COMMENTS ON COMMISSION STAFF'S RULE 25.194 DISCUSSION DRAFT in PUCT Project 58481 on Dec 19, 2025.","status":"ONCOR ELECTRIC DELIVERY COMPANY LLC","date":"2025-12-19","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=61","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: Provident Inc. comments on staff discussion draft","summary":"Provident Inc. filed Provident Inc. comments on staff discussion draft in PUCT Project 58481 on Dec 19, 2025.","status":"Provident Inc.","date":"2025-12-19","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=62","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: OFFICE OF PUBLIC UTILITY COUNSEL’S COMMENTS ON DISCUSSION DRAFT AND QUESTIONS FOR PUBLIC COMMENTS RELATED TO NEW 16 TAC § 25.194","summary":"OPUC filed OFFICE OF PUBLIC UTILITY COUNSEL’S COMMENTS ON DISCUSSION DRAFT AND QUESTIONS FOR PUBLIC COMMENTS RELATED TO NEW 16 TAC § 25.194 in PUCT Project 58481 on Dec 19, 2025.","status":"OPUC","date":"2025-12-19","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=64","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: DCC's Comments on the Discussion Draft (Project 58481)","summary":"Data Center Coalition filed DCC's Comments on the Discussion Draft (Project 58481) in PUCT Project 58481 on Dec 19, 2025.","status":"Data Center Coalition","date":"2025-12-19","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=66","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: SPLIGHT COMMENTS ON STAFF'S DRAFT DISCUSSION RULE § 25.194","summary":"Splight Inc. filed SPLIGHT COMMENTS ON STAFF'S DRAFT DISCUSSION RULE § 25.194 in PUCT Project 58481 on Dec 19, 2025.","status":"Splight Inc.","date":"2025-12-19","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=69","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: TCPA Response to Staff Questions","summary":"TCPA filed TCPA Response to Staff Questions in PUCT Project 58481 on Oct 10, 2025.","status":"TCPA","date":"2025-10-10","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=6","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: AEP TEXAS INC.’S COMMENTS ON STAFF DISCUSSION DRAFT","summary":"AEP TEXAS INC. filed AEP TEXAS INC.’S COMMENTS ON STAFF DISCUSSION DRAFT in PUCT Project 58481 on Dec 19, 2025.","status":"AEP TEXAS INC.","date":"2025-12-19","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=71","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: Targa Resources LLC's Comments in Response to Commission Staff's Discussion Draft","summary":"Targa Resources LLC filed Targa Resources LLC's Comments in Response to Commission Staff's Discussion Draft in PUCT Project 58481 on Dec 19, 2025.","status":"Targa Resources LLC","date":"2025-12-19","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=72","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: Texas-New Mexico Power Company’s Comments To Commission Staff’s Questions For Comment On Draft New 16 Tac § 25.194","summary":"TEXAS-NEW MEXICO POWER COMPANY filed Texas-New Mexico Power Company’s Comments To Commission Staff’s Questions For Comment On Draft New 16 Tac § 25.194 in PUCT Project 58481 on Dec 19, 2025.","status":"TEXAS-NEW MEXICO POWER COMPANY","date":"2025-12-19","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=73","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: CRUSOE ENERGY SYSTEMS LLC’S COMMENTS ON STAFF’S DRAFT DISCUSSION RULE 16 TAC § 25.194","summary":"CRUSOE ENERGY SYSTEMS LLC filed CRUSOE ENERGY SYSTEMS LLC’S COMMENTS ON STAFF’S DRAFT DISCUSSION RULE 16 TAC § 25.194 in PUCT Project 58481 on Dec 19, 2025.","status":"CRUSOE ENERGY SYSTEMS LLC","date":"2025-12-19","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=75","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: ELECTRIC RELIABILITY COUNCIL OF TEXAS, INC.’S COMMENTS ON DISCUSSION DRAFT","summary":"ERCOT filed ELECTRIC RELIABILITY COUNCIL OF TEXAS, INC.’S COMMENTS ON DISCUSSION DRAFT in PUCT Project 58481 on Dec 19, 2025.","status":"ERCOT","date":"2025-12-19","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=76","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: TEBA's Comments on Commission Staff's Questions and Discussion Draft","summary":"TEXAS ENERGY BUYERS ALLIANCE filed TEBA's Comments on Commission Staff's Questions and Discussion Draft in PUCT Project 58481 on Dec 19, 2025.","status":"TEXAS ENERGY BUYERS ALLIANCE","date":"2025-12-19","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=78","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: EDGECONNEX RESPONSE TO STAFF’S QUESTIONS ON PROJECT NO. 58481; RULEMAKING TO IMPLEMENT LARGE LOAD INTERCONNECTION STANDARDS UNDER PURA §37.0561","summary":"EdgeConneX filed EDGECONNEX RESPONSE TO STAFF’S QUESTIONS ON PROJECT NO. 58481; RULEMAKING TO IMPLEMENT LARGE LOAD INTERCONNECTION STANDARDS UNDER PURA §37.0561 in PUCT Project 58481 on Oct 10, 2025.","status":"EdgeConneX","date":"2025-10-10","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=7","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: SOLUNA DIGITAL’S SUPPORTIVE COMMENTS FOR COMMENTS SUBMITTED BY SATOSHI ENERGY ON STAFF'S DISCUSSION DRAFT NEW 16 TAC §25.194","summary":"Soluna Digital filed SOLUNA DIGITAL’S SUPPORTIVE COMMENTS FOR COMMENTS SUBMITTED BY SATOSHI ENERGY ON STAFF'S DISCUSSION DRAFT NEW 16 TAC §25.194 in PUCT Project 58481 on Dec 19, 2025.","status":"Soluna Digital","date":"2025-12-19","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=81","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: Staff Memo and January 9 Workshop Agenda w/Attachments","summary":"PUC RULES & PROJECTS filed Staff Memo and January 9 Workshop Agenda w/Attachments in PUCT Project 58481 on Jan 2, 2026.","status":"PUC RULES & PROJECTS","date":"2026-01-02","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=82","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: SATOSHI ENERGY COMMENTS ON STAFF'S SECOND DISCUSSION DRAFT ON PROJECT NO. 58481, RULEMAKING TO IMPLEMENT LARGE LOAD INTERCONNECTION STANDARDS UNDER PURA §37.0561","summary":"SATOSHI ENERGY CORP. filed SATOSHI ENERGY COMMENTS ON STAFF'S SECOND DISCUSSION DRAFT ON PROJECT NO. 58481, RULEMAKING TO IMPLEMENT LARGE LOAD INTERCONNECTION STANDARDS UNDER PURA §37.0561 in PUCT Project 58481 on Jan 16, 2026.","status":"SATOSHI ENERGY CORP.","date":"2026-01-16","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=83","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: CRUSOE ENERGY SYSTEMS LLC’S COMMENTS ON STAFF’S SECOND DRAFT DISCUSSION RULE 16 TAC § 25.194","summary":"CRUSOE ENERGY SYSTEMS LLC filed CRUSOE ENERGY SYSTEMS LLC’S COMMENTS ON STAFF’S SECOND DRAFT DISCUSSION RULE 16 TAC § 25.194 in PUCT Project 58481 on Jan 16, 2026.","status":"CRUSOE ENERGY SYSTEMS LLC","date":"2026-01-16","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=84","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: Google and Lancium Joint Comments to STaff Questions and 2nd Discussion Draft","summary":"GOOGLE LLC, LANCIUM LLC filed Google and Lancium Joint Comments to STaff Questions and 2nd Discussion Draft in PUCT Project 58481 on Jan 16, 2026.","status":"GOOGLE LLC, LANCIUM LLC","date":"2026-01-16","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=87","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: NRG Energy, Inc.'s Comments on PUCT Staff's Questions","summary":"NRG ENERGY, INC. filed NRG Energy, Inc.'s Comments on PUCT Staff's Questions in PUCT Project 58481 on Oct 10, 2025.","status":"NRG ENERGY, INC.","date":"2025-10-10","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=8","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: Texas Public Power Association (TPPA) Response to Questions for Comment","summary":"TPPA filed Texas Public Power Association (TPPA) Response to Questions for Comment in PUCT Project 58481 on Oct 10, 2025.","status":"TPPA","date":"2025-10-10","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=9","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59142: Request of audit for Project Raptor","summary":"Ray Baggett filed Request of audit for Project Raptor in PUCT Project 59142 on Sep 13, 2026.","status":"Ray Baggett","date":"2026-09-13","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59142&itemNumber=58","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59142: Audit Request- Project Raptor","summary":"Megan Atchison filed Audit Request- Project Raptor in PUCT Project 59142 on Sep 13, 2026.","status":"Megan Atchison","date":"2026-09-13","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59142&itemNumber=59","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59142: Audit Request- Project Raptor","summary":"Andrew Atchison filed Audit Request- Project Raptor in PUCT Project 59142 on Sep 13, 2026.","status":"Andrew Atchison","date":"2026-09-13","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59142&itemNumber=60","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59142: Audit Request- Project Raptor","summary":"Merri Dawn Bolton filed Audit Request- Project Raptor in PUCT Project 59142 on Sep 13, 2026.","status":"Merri Dawn Bolton","date":"2026-09-13","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59142&itemNumber=61","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59142: Audit Request- Project Raptor","summary":"Brad Bolton filed Audit Request- Project Raptor in PUCT Project 59142 on Sep 13, 2026.","status":"Brad Bolton","date":"2026-09-13","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59142&itemNumber=62","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59142: Audit Request- Project Raptor","summary":"Mark Steel filed Audit Request- Project Raptor in PUCT Project 59142 on Sep 13, 2026.","status":"Mark Steel","date":"2026-09-13","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59142&itemNumber=63","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59142: Audit Request- Project Raptor","summary":"Holly Steel filed Audit Request- Project Raptor in PUCT Project 59142 on Sep 13, 2026.","status":"Holly Steel","date":"2026-09-13","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59142&itemNumber=64","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59142: Request for audit -Project Raptor","summary":"Adam Lindemann filed Request for audit -Project Raptor in PUCT Project 59142 on Sep 14, 2026.","status":"Adam Lindemann","date":"2026-09-14","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59142&itemNumber=65","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59142: Request for audit - Project Raptor","summary":"Katrina Farmer filed Request for audit - Project Raptor in PUCT Project 59142 on Sep 14, 2026.","status":"Katrina Farmer","date":"2026-09-14","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59142&itemNumber=66","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: OM Item No. 24 - (Staff Recommendation) Order Adopting New §25.194","summary":"PUC RULES & PROJECTS filed OM Item No. 24 - (Staff Recommendation) Order Adopting New §25.194 in PUCT Project 58481 on Sep 3, 2026.","status":"PUC RULES & PROJECTS","date":"2026-09-03","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=208","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: Vistra's Comments on Project 58481 Recommended Adoption Order","summary":"VISTRA CORPORATE SERVICES COMPANY filed Vistra's Comments on Project 58481 Recommended Adoption Order in PUCT Project 58481 on Sep 8, 2026.","status":"VISTRA CORPORATE SERVICES COMPANY","date":"2026-09-08","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=211","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58482: OFFICE OF PUBLIC UTILITY COUNSEL’S COMMENTS REGARDING THE PROPOSAL FOR PUBLICATION OF NEW 16 TAC §25.521","summary":"OPUC filed OFFICE OF PUBLIC UTILITY COUNSEL’S COMMENTS REGARDING THE PROPOSAL FOR PUBLICATION OF NEW 16 TAC §25.521 in PUCT Project 58482 on Sep 3, 2026.","status":"OPUC","date":"2026-09-03","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58482&itemNumber=36","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58482: TAEBA'S COMMENTS ON PROPOSAL FOR PUBLICATION OF NEW 16 TAC §25.521","summary":"TEXAS ADVANCED ENERGY BUSINESS ALLIANCE filed TAEBA'S COMMENTS ON PROPOSAL FOR PUBLICATION OF NEW 16 TAC §25.521 in PUCT Project 58482 on Sep 4, 2026.","status":"TEXAS ADVANCED ENERGY BUSINESS ALLIANCE","date":"2026-09-04","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58482&itemNumber=38","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58482: ERCOT Steel Mills Comments Project 58482_Proposal for Publication","summary":"ERCOT STEEL MILLS filed ERCOT Steel Mills Comments Project 58482_Proposal for Publication in PUCT Project 58482 on Sep 4, 2026.","status":"ERCOT STEEL MILLS","date":"2026-09-04","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58482&itemNumber=39","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58482: GOOGLE COMMENTS FOR THE 58482 PROPOSAL FOR PUBLICATION","summary":"GOOGLE LLC filed GOOGLE COMMENTS FOR THE 58482 PROPOSAL FOR PUBLICATION in PUCT Project 58482 on Sep 4, 2026.","status":"GOOGLE LLC","date":"2026-09-04","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58482&itemNumber=40","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58482: Comments of Texas Electric Cooperatives, Inc.","summary":"TEXAS ELECTRIC COOPERATIVES, INC. filed Comments of Texas Electric Cooperatives, Inc. in PUCT Project 58482 on Sep 4, 2026.","status":"TEXAS ELECTRIC COOPERATIVES, INC.","date":"2026-09-04","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58482&itemNumber=41","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58482: Data Center Coalition's Comment on Proposal for Publication (Project 58482)","summary":"DATA CENTER COALITION filed Data Center Coalition's Comment on Proposal for Publication (Project 58482) in PUCT Project 58482 on Sep 4, 2026.","status":"DATA CENTER COALITION","date":"2026-09-04","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58482&itemNumber=45","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58482: ENGIE North America Inc. Comments on Proposal for Publication","summary":"ENGIE NORTH AMERICA INC. filed ENGIE North America Inc. Comments on Proposal for Publication in PUCT Project 58482 on Sep 4, 2026.","status":"ENGIE NORTH AMERICA INC.","date":"2026-09-04","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58482&itemNumber=46","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58482: COMMENTS OF AEP TEXAS INC. ON COMMISSION STAFF’S PROPOSAL FOR PUBLICATION","summary":"AEP TEXAS INC. filed COMMENTS OF AEP TEXAS INC. ON COMMISSION STAFF’S PROPOSAL FOR PUBLICATION in PUCT Project 58482 on Sep 4, 2026.","status":"AEP TEXAS INC.","date":"2026-09-04","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58482&itemNumber=47","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58482: COMMENTS OF CENTERPOINT ENERGY HOUSTON ELECTRIC, LLC","summary":"CENTERPOINT ENERGY HOUSTON ELECTRIC, LLC filed COMMENTS OF CENTERPOINT ENERGY HOUSTON ELECTRIC, LLC in PUCT Project 58482 on Sep 4, 2026.","status":"CENTERPOINT ENERGY HOUSTON ELECTRIC, LLC","date":"2026-09-04","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58482&itemNumber=48","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58482: TCPA'S COMMENTS ON PROPOSAL FOR PUBLICATION OF NEW §25.521","summary":"TCPA filed TCPA'S COMMENTS ON PROPOSAL FOR PUBLICATION OF NEW §25.521 in PUCT Project 58482 on Sep 4, 2026.","status":"TCPA","date":"2026-09-04","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58482&itemNumber=49","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58482: COMMENTS ON THE PROPOSAL FOR PUBLICATION OF NEW §25.521","summary":"LOWER COLORADO RIVER AUTHORITY filed COMMENTS ON THE PROPOSAL FOR PUBLICATION OF NEW §25.521 in PUCT Project 58482 on Sep 4, 2026.","status":"LOWER COLORADO RIVER AUTHORITY","date":"2026-09-04","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58482&itemNumber=52","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58482: ONCOR ELECTRIC DELIVERY COMPANY'S COMMENTS ON THE PROPOSAL FOR PUBLICATION OF NEW 16 TAC § 25.521","summary":"ONCOR ELECTRIC DELIVERY COMPANY LLC filed ONCOR ELECTRIC DELIVERY COMPANY'S COMMENTS ON THE PROPOSAL FOR PUBLICATION OF NEW 16 TAC § 25.521 in PUCT Project 58482 on Sep 4, 2026.","status":"ONCOR ELECTRIC DELIVERY COMPANY LLC","date":"2026-09-04","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58482&itemNumber=53","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58482: NRG Comments on Proposed Rule","summary":"NRG ENERGY, INC. filed NRG Comments on Proposed Rule in PUCT Project 58482 on Sep 4, 2026.","status":"NRG ENERGY, INC.","date":"2026-09-04","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58482&itemNumber=54","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58482: Vistra Corporate Services Company's Comments on the Proposal for Publication of new 16 TAC § 25.521","summary":"VISTRA CORPORATE SERVICES COMPANY filed Vistra Corporate Services Company's Comments on the Proposal for Publication of new 16 TAC § 25.521 in PUCT Project 58482 on Sep 4, 2026.","status":"VISTRA CORPORATE SERVICES COMPANY","date":"2026-09-04","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58482&itemNumber=55","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58482: The Steering Committee of Cities Served by Oncor and Texas Coalition for Affordable Power's Comments on Proposal for Publication of New 16 TAC § 25.521","summary":"STEERING COMMITTEE OF CITIES SERVED BY ONCOR AND TEXAS COALITION FOR AFFORDABLE POWER filed The Steering Committee of Cities Served by Oncor and Texas Coalition for Affordable Power's Comments on Proposal for Publication of New 16 TAC § 25.521 in PUCT Project 58482 on Sep 4, 2026.","status":"STEERING COMMITTEE OF CITIES SERVED BY ONCOR AND TEXAS COALITION FOR AFFORDABLE POWER","date":"2026-09-04","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58482&itemNumber=58","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58482: TNMP'S COMMENTS ON PROPOSAL FOR PUBLICATION OF NEW §25.521","summary":"TEXAS NEW MEXICO POWER COMPANY filed TNMP'S COMMENTS ON PROPOSAL FOR PUBLICATION OF NEW §25.521 in PUCT Project 58482 on Sep 4, 2026.","status":"TEXAS NEW MEXICO POWER COMPANY","date":"2026-09-04","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58482&itemNumber=59","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58482: TEBA Comments on Proposal for Publication for Project No. 58482","summary":"TEXAS ENERGY BUYERS ALLIANCE filed TEBA Comments on Proposal for Publication for Project No. 58482 in PUCT Project 58482 on Sep 4, 2026.","status":"TEXAS ENERGY BUYERS ALLIANCE","date":"2026-09-04","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58482&itemNumber=60","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58482: ELECTRIC RELIABILITY COUNCIL OF TEXAS, INC.’S COMMENTS ON THE PROPOSAL FOR PUBLICATION","summary":"ERCOT filed ELECTRIC RELIABILITY COUNCIL OF TEXAS, INC.’S COMMENTS ON THE PROPOSAL FOR PUBLICATION in PUCT Project 58482 on Sep 4, 2026.","status":"ERCOT","date":"2026-09-04","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58482&itemNumber=62","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58796: SOAH ORDER NO. 11- GRANTING MOTION TO ABATE","summary":"SOAH filed SOAH ORDER NO. 11- GRANTING MOTION TO ABATE in PUCT Project 58796 on Sep 3, 2026.","status":"SOAH","date":"2026-09-03","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58796&itemNumber=101","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: OPUC’S COMMENTS ON STAFF’S SECOND SET OF QUESTIONS FOR PUBLIC COMMENT AND SECOND DISCUSSION DRAFT RELATED TO NEW 16 TAC § 25.194","summary":"OPUC filed OPUC’S COMMENTS ON STAFF’S SECOND SET OF QUESTIONS FOR PUBLIC COMMENT AND SECOND DISCUSSION DRAFT RELATED TO NEW 16 TAC § 25.194 in PUCT Project 58481 on Jan 16, 2026.","status":"OPUC","date":"2026-01-16","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=100","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: Tract Post-Workshop Comments on Staff's Second Discussion Draft","summary":"Tract filed Tract Post-Workshop Comments on Staff's Second Discussion Draft in PUCT Project 58481 on Jan 17, 2026.","status":"Tract","date":"2026-01-17","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=104","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: Comments of Texas-New Mexico Power Company","summary":"TEXAS-NEW MEXICO POWER COMPANY filed Comments of Texas-New Mexico Power Company in PUCT Project 58481 on Jan 20, 2026.","status":"TEXAS-NEW MEXICO POWER COMPANY","date":"2026-01-20","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=105","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: OM Item No. 27 - Staff Memo & PFP w/March 27 Comment Deadline","summary":"PUC RULES & PROJECTS filed OM Item No. 27 - Staff Memo & PFP w/March 27 Comment Deadline in PUCT Project 58481 on Feb 13, 2026.","status":"PUC RULES & PROJECTS","date":"2026-02-13","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=107","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: Comments regarding Fee recommendation by Staff","summary":"Cholla, Inc. filed Comments regarding Fee recommendation by Staff in PUCT Project 58481 on Feb 17, 2026.","status":"Cholla, Inc.","date":"2026-02-17","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=108","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: SCHAPER ENERGY ENERGY CONSULTING COMMENTS TO STAFF DISCUSSION DRAFT 16 (TAC) §25.194 DATED FEBRUARY 13, 2026","summary":"SCHAPER ENERGY CONSULTING LLC filed SCHAPER ENERGY ENERGY CONSULTING COMMENTS TO STAFF DISCUSSION DRAFT 16 (TAC) §25.194 DATED FEBRUARY 13, 2026 in PUCT Project 58481 on Feb 18, 2026.","status":"SCHAPER ENERGY CONSULTING LLC","date":"2026-02-18","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=109","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: Google and Lancium Joint Comments to Proposed PFP","summary":"Google LLC, Lancium LLC filed Google and Lancium Joint Comments to Proposed PFP in PUCT Project 58481 on Feb 19, 2026.","status":"Google LLC, Lancium LLC","date":"2026-02-19","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=110","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: Speed to Power Concept Paper for ERCOT Large Load Batch Study Proceedings","summary":"Luminary Strategies,LLC filed Speed to Power Concept Paper for ERCOT Large Load Batch Study Proceedings in PUCT Project 58481 on Feb 26, 2026.","status":"Luminary Strategies,LLC","date":"2026-02-26","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=111","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: Monarch Energy Comments on Proposal for Publication","summary":"Monarch Energy Development LLC filed Monarch Energy Comments on Proposal for Publication in PUCT Project 58481 on Mar 4, 2026.","status":"Monarch Energy Development LLC","date":"2026-03-04","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=113","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: Provident, Inc. Comments on Proposed Proposal for Publication","summary":"Provident, Inc. filed Provident, Inc. Comments on Proposed Proposal for Publication in PUCT Project 58481 on Mar 4, 2026.","status":"Provident, Inc.","date":"2026-03-04","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=114","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: JOINT REDLINES FOR THE PROPOSED PROPOSAL FOR PUBLICATION","summary":"GOOGLE LLC, LANCIUM LLC filed JOINT REDLINES FOR THE PROPOSED PROPOSAL FOR PUBLICATION in PUCT Project 58481 on Mar 10, 2026.","status":"GOOGLE LLC, LANCIUM LLC","date":"2026-03-10","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=115","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: CIPHER DIGITAL INC. COMMENTS TO STAFF PROPOSED PROPOSAL FOR PUBLICATION","summary":"Cipher Digital filed CIPHER DIGITAL INC. COMMENTS TO STAFF PROPOSED PROPOSAL FOR PUBLICATION in PUCT Project 58481 on Mar 11, 2026.","status":"Cipher Digital","date":"2026-03-11","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=116","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: EDGECONNEX COMMENTS TO STAFF'S PROPOSED PROPOSAL FOR PUBLICATION","summary":"EdgeConnex filed EDGECONNEX COMMENTS TO STAFF'S PROPOSED PROPOSAL FOR PUBLICATION in PUCT Project 58481 on Mar 11, 2026.","status":"EdgeConnex","date":"2026-03-11","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=117","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: CHAIRMAN GLEESON MEMORANDUM","summary":"PUC OPDM filed CHAIRMAN GLEESON MEMORANDUM in PUCT Project 58481 on Mar 11, 2026.","status":"PUC OPDM","date":"2026-03-11","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=118","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: Engine 1's Comments on PUCT Staff's Proposal for Publication","summary":"Engine 1 filed Engine 1's Comments on PUCT Staff's Proposal for Publication in PUCT Project 58481 on Mar 11, 2026.","status":"Engine 1","date":"2026-03-11","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=119","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: Hut 8 Comments on Staff's Proposal for Publication","summary":"Hut 8 Corp filed Hut 8 Comments on Staff's Proposal for Publication in PUCT Project 58481 on Mar 11, 2026.","status":"Hut 8 Corp","date":"2026-03-11","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=120","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: Nightpeak Energy Comments on Staff's Proposal for Publication","summary":"Nightpeak Energy filed Nightpeak Energy Comments on Staff's Proposal for Publication in PUCT Project 58481 on Mar 11, 2026.","status":"Nightpeak Energy","date":"2026-03-11","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=121","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: PROPOSAL FOR PUBLICATION OF NEW 16 TAC §25.194","summary":"PUC OPDM filed PROPOSAL FOR PUBLICATION OF NEW 16 TAC §25.194 in PUCT Project 58481 on Mar 12, 2026.","status":"PUC OPDM","date":"2026-03-12","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=122","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: Texas Register Acknowledgement of Receipt - Comments Due 04/17/2026","summary":"PUC RULES & PROJECTS filed Texas Register Acknowledgement of Receipt - Comments Due 04/17/2026 in PUCT Project 58481 on Mar 12, 2026.","status":"PUC RULES & PROJECTS","date":"2026-03-12","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=123","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: Staff Memo w/MS Word Version of PFP","summary":"PUC RULES & PROJECTS filed Staff Memo w/MS Word Version of PFP in PUCT Project 58481 on Mar 16, 2026.","status":"PUC RULES & PROJECTS","date":"2026-03-16","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=124","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: Monarch Energy Additional Comments on Proposal for Publication","summary":"MONARCH ENERGY filed Monarch Energy Additional Comments on Proposal for Publication in PUCT Project 58481 on Mar 19, 2026.","status":"MONARCH ENERGY","date":"2026-03-19","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=125","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: Vistra Corp.'s Comments on Planning Guide Revision Request 145 for Project 58481","summary":"VISTRA CORP. filed Vistra Corp.'s Comments on Planning Guide Revision Request 145 for Project 58481 in PUCT Project 58481 on Mar 20, 2026.","status":"VISTRA CORP.","date":"2026-03-20","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=127","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: PUC Project No. 58481 - Interconnection Agreement Standards Applicability to Batch Zero","summary":"SCHAPER ENERGY CONSULTING LLC filed PUC Project No. 58481 - Interconnection Agreement Standards Applicability to Batch Zero in PUCT Project 58481 on Mar 29, 2026.","status":"SCHAPER ENERGY CONSULTING LLC","date":"2026-03-29","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=129","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: Comments on Proposal for Publication of 16 TAC §25.194 - Project No. 58481","summary":"Jason Buster filed Comments on Proposal for Publication of 16 TAC §25.194 - Project No. 58481 in PUCT Project 58481 on Mar 30, 2026.","status":"Jason Buster","date":"2026-03-30","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=130","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: CPV Comments on Proposal for Publication of 16 TAC §25.194","summary":"Competitive Power Ventures filed CPV Comments on Proposal for Publication of 16 TAC §25.194 in PUCT Project 58481 on Apr 6, 2026.","status":"Competitive Power Ventures","date":"2026-04-06","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=132","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: Cholla comments on Proposal for Publication","summary":"Cholla, Inc. filed Cholla comments on Proposal for Publication in PUCT Project 58481 on Apr 7, 2026.","status":"Cholla, Inc.","date":"2026-04-07","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=133","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: Vistra Corp.'s Additional Comments on Planning Guide Revision Request 145 for Project 58481","summary":"VISTRA CORP. filed Vistra Corp.'s Additional Comments on Planning Guide Revision Request 145 for Project 58481 in PUCT Project 58481 on Apr 9, 2026.","status":"VISTRA CORP.","date":"2026-04-09","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=134","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: AEP COMPANIES’ COMMENTS ON COMMISSION’S PROPOSAL FOR PUBLICATION","summary":"AEP COMPANIES filed AEP COMPANIES’ COMMENTS ON COMMISSION’S PROPOSAL FOR PUBLICATION in PUCT Project 58481 on Apr 13, 2026.","status":"AEP COMPANIES","date":"2026-04-13","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=139","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: CCNG Comments and Redlines for the Proposal for Publication in Project 58481","summary":"CCNG, Inc. filed CCNG Comments and Redlines for the Proposal for Publication in Project 58481 in PUCT Project 58481 on Apr 13, 2026.","status":"CCNG, Inc.","date":"2026-04-13","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=140","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: TRACT HOLDING COMPANY I, LLC’S COMMENTS ON THE COMMISSION’S PROPOSAL FOR PUBLICATION TO IMPLEMENT LARGE LOAD INTERCONNECTION STANDARDS (“STANDARDS”)","summary":"Tract Holding Company I, LLC filed TRACT HOLDING COMPANY I, LLC’S COMMENTS ON THE COMMISSION’S PROPOSAL FOR PUBLICATION TO IMPLEMENT LARGE LOAD INTERCONNECTION STANDARDS (“STANDARDS”) in PUCT Project 58481 on Apr 13, 2026.","status":"Tract Holding Company I, LLC","date":"2026-04-13","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=141","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: Project# Rule 25.194 The people demand full and extensive transparency on all water and gas studies, usage records and future plans pertaining to industrial use especially for large scale data centers in bell county","summary":"SARAH DUNHAM filed Project# Rule 25.194 The people demand full and extensive transparency on all water and gas studies, usage records and future plans pertaining to industrial use especially for large scale data centers in bell county in PUCT Project 58481 on Apr 14, 2026.","status":"SARAH DUNHAM","date":"2026-04-14","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=142","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: HUT 8 COMMENTS ON PUC PROPOSAL FOR PUBLICATION","summary":"HUT 8 CORP filed HUT 8 COMMENTS ON PUC PROPOSAL FOR PUBLICATION in PUCT Project 58481 on Apr 14, 2026.","status":"HUT 8 CORP","date":"2026-04-14","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=144","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: Suplement filing to comment XYAWFICE - Updated analytic methodology attribution of SVI/TRI addition to research","summary":"Zack Butler | EnerShield AI filed Suplement filing to comment XYAWFICE - Updated analytic methodology attribution of SVI/TRI addition to research in PUCT Project 58481 on Apr 15, 2026.","status":"Zack Butler | EnerShield AI","date":"2026-04-15","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=146","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: COMMENTS ON THE PROPOSAL FOR PUBLICATION","summary":"LOWER COLORADO RIVER AUTHORITY AND LCRA TRANSMISSION SERVICES CORPORATION filed COMMENTS ON THE PROPOSAL FOR PUBLICATION in PUCT Project 58481 on Apr 15, 2026.","status":"LOWER COLORADO RIVER AUTHORITY AND LCRA TRANSMISSION SERVICES CORPORATION","date":"2026-04-15","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=147","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: COMMENTS OF CENTERPOINT ENERGY HOUSTON ELECTRIC, LLC","summary":"CENTERPOINT ENERGY HOUSTON ELECTRIC, LLC filed COMMENTS OF CENTERPOINT ENERGY HOUSTON ELECTRIC, LLC in PUCT Project 58481 on Apr 15, 2026.","status":"CENTERPOINT ENERGY HOUSTON ELECTRIC, LLC","date":"2026-04-15","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=148","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: STACK INFRASTRUCTURE COMMENTS TO PROPOSAL FOR PUBLICATION IN PROJECT NO. 58481","summary":"STACK Infrastructure filed STACK INFRASTRUCTURE COMMENTS TO PROPOSAL FOR PUBLICATION IN PROJECT NO. 58481 in PUCT Project 58481 on Apr 15, 2026.","status":"STACK Infrastructure","date":"2026-04-15","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=151","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: SATOSHI ENERGY COMMENTS ON STAFF'S PROPOSAL FOR PUBLICATION ON PROJECT NO. 58481, RULEMAKING TO IMPLEMENT LARGE LOAD INTERCONNECTION STANDARDS UNDER PURA §37.0561","summary":"SATOSHI ENERGY CORP. filed SATOSHI ENERGY COMMENTS ON STAFF'S PROPOSAL FOR PUBLICATION ON PROJECT NO. 58481, RULEMAKING TO IMPLEMENT LARGE LOAD INTERCONNECTION STANDARDS UNDER PURA §37.0561 in PUCT Project 58481 on Apr 16, 2026.","status":"SATOSHI ENERGY CORP.","date":"2026-04-16","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=156","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: INFINIUM'S COMMENTS ON LARGE LOAD INTERCONNECTION STANDARDS PROPOSAL FOR PUBLICATION","summary":"INFINIUM OPERATIONS, LLC filed INFINIUM'S COMMENTS ON LARGE LOAD INTERCONNECTION STANDARDS PROPOSAL FOR PUBLICATION in PUCT Project 58481 on Apr 16, 2026.","status":"INFINIUM OPERATIONS, LLC","date":"2026-04-16","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=159","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: TCPA Comments on Large Load Interconnection PfP & Issues","summary":"TCPA filed TCPA Comments on Large Load Interconnection PfP & Issues in PUCT Project 58481 on Apr 16, 2026.","status":"TCPA","date":"2026-04-16","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=162","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: HUNT ENERGY NETWORK'S COMMENTS ON COMMISSION’S PROPOSAL FOR PUBLICATION","summary":"HUNT ENERGY NETWORK L.L.C. filed HUNT ENERGY NETWORK'S COMMENTS ON COMMISSION’S PROPOSAL FOR PUBLICATION in PUCT Project 58481 on Apr 16, 2026.","status":"HUNT ENERGY NETWORK L.L.C.","date":"2026-04-16","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=164","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: Joint Comments of Google LLC, Lancium LLC, and TotalEnergies Renewables USA","summary":"GOOGLE LLC, LANCIUM LLC, TOTALENERGIES RENEWABLES USA filed Joint Comments of Google LLC, Lancium LLC, and TotalEnergies Renewables USA in PUCT Project 58481 on Apr 16, 2026.","status":"GOOGLE LLC, LANCIUM LLC, TOTALENERGIES RENEWABLES USA","date":"2026-04-16","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=165","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: TEBA's Comments on Commission Staff's Proposal for Publication","summary":"TEXAS ENERGY BUYERS ALLIANCE filed TEBA's Comments on Commission Staff's Proposal for Publication in PUCT Project 58481 on Apr 16, 2026.","status":"TEXAS ENERGY BUYERS ALLIANCE","date":"2026-04-16","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=166","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: Trammell Crow Company's Comments on Proposal for Publication of 16 TAC§ 25.194","summary":"Trammell Crow Company filed Trammell Crow Company's Comments on Proposal for Publication of 16 TAC§ 25.194 in PUCT Project 58481 on Apr 17, 2026.","status":"Trammell Crow Company","date":"2026-04-17","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=169","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: PUCT 58481 Large Load Interconnection Standards PfP - NRG Comments - FINAL","summary":"NRG ENERGY INC filed PUCT 58481 Large Load Interconnection Standards PfP - NRG Comments - FINAL in PUCT Project 58481 on Apr 17, 2026.","status":"NRG ENERGY INC","date":"2026-04-17","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=173","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: Targa Resources LLC's Comments and Proposed Redlines in Response to Proposal for Publication of 16 TAC § 25.194","summary":"Targa Resources LLC filed Targa Resources LLC's Comments and Proposed Redlines in Response to Proposal for Publication of 16 TAC § 25.194 in PUCT Project 58481 on Apr 17, 2026.","status":"Targa Resources LLC","date":"2026-04-17","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=175","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: Permian Basin Petroleum Association's Comments in Response to Proposal for Publication of 16 TAC § 25.194","summary":"Permian Basin Petroleum Association filed Permian Basin Petroleum Association's Comments in Response to Proposal for Publication of 16 TAC § 25.194 in PUCT Project 58481 on Apr 17, 2026.","status":"Permian Basin Petroleum Association","date":"2026-04-17","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=176","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: BLACK MOUNTAIN POWER COMMENTS ON PROJECT NO. 58481 PROPOSAL FOR PUBLICATION","summary":"BLACK MOUNTAIN POWER filed BLACK MOUNTAIN POWER COMMENTS ON PROJECT NO. 58481 PROPOSAL FOR PUBLICATION in PUCT Project 58481 on Apr 17, 2026.","status":"BLACK MOUNTAIN POWER","date":"2026-04-17","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=177","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: CONSTELLATION ENERGY GENERATION, LLC’S COMMENTS ON COMMISSION STAFF’S PROPOSAL FOR PUBLICATION OF NEW 16 TAC § 25.194","summary":"CONSTELLATION ENERGY GENERATION, LLC filed CONSTELLATION ENERGY GENERATION, LLC’S COMMENTS ON COMMISSION STAFF’S PROPOSAL FOR PUBLICATION OF NEW 16 TAC § 25.194 in PUCT Project 58481 on Apr 17, 2026.","status":"CONSTELLATION ENERGY GENERATION, LLC","date":"2026-04-17","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=178","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: POST-WORKSHOP COMMENTS OF TEXAS ELECTRIC COOPERATIVES, INC.","summary":"TEXAS ELECTRIC COOPERATIVES, INC. filed POST-WORKSHOP COMMENTS OF TEXAS ELECTRIC COOPERATIVES, INC. in PUCT Project 58481 on Jan 16, 2026.","status":"TEXAS ELECTRIC COOPERATIVES, INC.","date":"2026-01-16","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=88","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: Comments of CenterPoint Energy Houston Electric, LLC","summary":"CENTERPOINT ENERGY HOUSTON ELECTRIC filed Comments of CenterPoint Energy Houston Electric, LLC in PUCT Project 58481 on Jan 16, 2026.","status":"CENTERPOINT ENERGY HOUSTON ELECTRIC","date":"2026-01-16","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=90","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: ETT’S COMMENTS ON STAFF’S 2ND DISCUSSION DRAFT","summary":"ELECTRIC TRANSMISSION TEXAS, LLC filed ETT’S COMMENTS ON STAFF’S 2ND DISCUSSION DRAFT in PUCT Project 58481 on Jan 16, 2026.","status":"ELECTRIC TRANSMISSION TEXAS, LLC","date":"2026-01-16","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=92","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: CPS Energy's Response to Questions for Comment","summary":"CPS ENERGY filed CPS Energy's Response to Questions for Comment in PUCT Project 58481 on Jan 16, 2026.","status":"CPS ENERGY","date":"2026-01-16","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=93","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: Comments on Staff's Second Draft Discussion Rule in 16 TAC 25.194","summary":"ROWAN DIGITAL INFRASTRUCTURE LLC filed Comments on Staff's Second Draft Discussion Rule in 16 TAC 25.194 in PUCT Project 58481 on Jan 16, 2026.","status":"ROWAN DIGITAL INFRASTRUCTURE LLC","date":"2026-01-16","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=94","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: ONCOR ELECTRIC DELIVERY’S COMMENTS ON COMMISSION STAFF’S SECOND RULE 25.194 DISCUSSION DRAFT","summary":"ONCOR ELECTRIC DELIVERY COMPANY LLC filed ONCOR ELECTRIC DELIVERY’S COMMENTS ON COMMISSION STAFF’S SECOND RULE 25.194 DISCUSSION DRAFT in PUCT Project 58481 on Jan 16, 2026.","status":"ONCOR ELECTRIC DELIVERY COMPANY LLC","date":"2026-01-16","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=95","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: AEP TEXAS' COMMENTS ON STAFF’S SECOND DISCUSSION DRAFT","summary":"AEP TEXAS INC. filed AEP TEXAS' COMMENTS ON STAFF’S SECOND DISCUSSION DRAFT in PUCT Project 58481 on Jan 16, 2026.","status":"AEP TEXAS INC.","date":"2026-01-16","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=97","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: Additional Comment's on Second Discussion Draft","summary":"Data Center Coalition filed Additional Comment's on Second Discussion Draft in PUCT Project 58481 on Jan 16, 2026.","status":"Data Center Coalition","date":"2026-01-16","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=98","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59142: My name is Chad Peysen and I live at 1116 Three Way Rd, Wichita Falls, TX 76310. The 1000 MW request sits 1200 ft from my home. I would like the audit applied to Project Raptor specifically.","summary":"Chad Peysen filed My name is Chad Peysen and I live at 1116 Three Way Rd, Wichita Falls, TX 76310. The 1000 MW request sits 1200 ft from my home. I would like the audit applied to Project Raptor specifically. in PUCT Project 59142 on Sep 14, 2026.","status":"Chad Peysen","date":"2026-09-14","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59142&itemNumber=69","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59142: My name is Heather Peysen and I live at 1116 Three Way Rd, Wichita Falls, TX 76310. The 1000 MW request sits 1200 ft from my home. I would like the audit applied to Project Raptor specifically.","summary":"Heather Peysen filed My name is Heather Peysen and I live at 1116 Three Way Rd, Wichita Falls, TX 76310. The 1000 MW request sits 1200 ft from my home. I would like the audit applied to Project Raptor specifically. in PUCT Project 59142 on Sep 14, 2026.","status":"Heather Peysen","date":"2026-09-14","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59142&itemNumber=70","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59142: My name is John Peysen and I live at 433 Mahler Rd, Wichita Falls, TX 76310. The 1000 MW request sits 1 road over from my home. I would like the audit applied to Project Raptor specifically.","summary":"John Peysen filed My name is John Peysen and I live at 433 Mahler Rd, Wichita Falls, TX 76310. The 1000 MW request sits 1 road over from my home. I would like the audit applied to Project Raptor specifically. in PUCT Project 59142 on Sep 14, 2026.","status":"John Peysen","date":"2026-09-14","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59142&itemNumber=71","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59142: My name is Rhonda Peysen and I live at 433 Mahler Rd, Wichita Falls, TX 76310. The 1000 MW request sits 1 road over from my home. I would like the audit applied to Project Raptor specifically.","summary":"Rhonda Peysen filed My name is Rhonda Peysen and I live at 433 Mahler Rd, Wichita Falls, TX 76310. The 1000 MW request sits 1 road over from my home. I would like the audit applied to Project Raptor specifically. in PUCT Project 59142 on Sep 14, 2026.","status":"Rhonda Peysen","date":"2026-09-14","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59142&itemNumber=72","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: SOLUNA HOLDINGS, INC. COMMENTS TO PROPOSAL FOR ADOPTION OF NEW 16 TAC § 25.194","summary":"Soluna Holdings filed SOLUNA HOLDINGS, INC. COMMENTS TO PROPOSAL FOR ADOPTION OF NEW 16 TAC § 25.194 in PUCT Project 58481 on Sep 9, 2026.","status":"Soluna Holdings","date":"2026-09-09","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=212","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: GOOD COMPANY ASSOOCIATES COMMENTS ON THE COMMISSION’S PROPOSAL FOR ADOPTION (PFA)","summary":"Good Company Associates filed GOOD COMPANY ASSOOCIATES COMMENTS ON THE COMMISSION’S PROPOSAL FOR ADOPTION (PFA) in PUCT Project 58481 on Sep 9, 2026.","status":"Good Company Associates","date":"2026-09-09","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=213","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: SATOSHI ENERGY COMMENTS ON STAFF'S RECOMMENDED ADOPTION ORDER ON PROJECT NO. 58481, RULEMAKING TO IMPLEMENT LARGE LOAD INTERCONNECTION STANDARDS UNDER PURA §37.0561","summary":"SATOSHI ENERGY CORP. filed SATOSHI ENERGY COMMENTS ON STAFF'S RECOMMENDED ADOPTION ORDER ON PROJECT NO. 58481, RULEMAKING TO IMPLEMENT LARGE LOAD INTERCONNECTION STANDARDS UNDER PURA §37.0561 in PUCT Project 58481 on Sep 9, 2026.","status":"SATOSHI ENERGY CORP.","date":"2026-09-09","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=214","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: Comments of Lancium LLC on Project 58481 Recommended Adoption Order","summary":"Lancium LLC filed Comments of Lancium LLC on Project 58481 Recommended Adoption Order in PUCT Project 58481 on Sep 9, 2026.","status":"Lancium LLC","date":"2026-09-09","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=215","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58796: Joint Status Report","summary":"SOUTHWESTERN ELECTRIC POWER COMPANY filed Joint Status Report in PUCT Project 58796 on Sep 9, 2026.","status":"SOUTHWESTERN ELECTRIC POWER COMPANY","date":"2026-09-09","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58796&itemNumber=102","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59948: PROTECTIVE ORDER CERTIFICATIONS","summary":"PUC LEGAL filed PROTECTIVE ORDER CERTIFICATIONS in PUCT Project 59948 on Sep 14, 2026.","status":"PUC LEGAL","date":"2026-09-14","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59948&itemNumber=12","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59948: COMMISSION STAFF’S RECOMMENDATION ON FINAL DISPOSITION","summary":"PUC LEGAL filed COMMISSION STAFF’S RECOMMENDATION ON FINAL DISPOSITION in PUCT Project 59948 on Sep 15, 2026.","status":"PUC LEGAL","date":"2026-09-15","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59948&itemNumber=13","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 54445: NOTICE OF RECOMMENDED APPROVAL OF REVISION REQUESTS BY ERCOT BOARD OF DIRECTORS","summary":"ERCOT filed NOTICE OF RECOMMENDED APPROVAL OF REVISION REQUESTS BY ERCOT BOARD OF DIRECTORS in PUCT Project 54445 on Jun 26, 2025.","status":"ERCOT","date":"2025-06-26","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=54445&itemNumber=112","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 54445: Staff Memo and Proposed Order","summary":"PUC MARKET ANALYSIS filed Staff Memo and Proposed Order in PUCT Project 54445 on Jul 24, 2025.","status":"PUC MARKET ANALYSIS","date":"2025-07-24","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=54445&itemNumber=113","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 54445: ORDER APPROVING ERCOT REVISION REQUESTS","summary":"PUC OPDM filed ORDER APPROVING ERCOT REVISION REQUESTS in PUCT Project 54445 on Jul 31, 2025.","status":"PUC OPDM","date":"2025-07-31","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=54445&itemNumber=114","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 54445: NOTICE OF RECOMMENDED APPROVAL OF REVISION REQUESTS BY ERCOT BOARD OF DIRECTORS","summary":"ERCOT filed NOTICE OF RECOMMENDED APPROVAL OF REVISION REQUESTS BY ERCOT BOARD OF DIRECTORS in PUCT Project 54445 on Sep 29, 2025.","status":"ERCOT","date":"2025-09-29","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=54445&itemNumber=115","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 54445: ERCOT Request for Approval of 2026 Ancillary Service Methodology","summary":"ERCOT filed ERCOT Request for Approval of 2026 Ancillary Service Methodology in PUCT Project 54445 on Oct 6, 2025.","status":"ERCOT","date":"2025-10-06","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=54445&itemNumber=116","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 54445: Staff Memo and Proposed Order_1 (revision requests only)","summary":"PUC MARKET ANALYSIS filed Staff Memo and Proposed Order_1 (revision requests only) in PUCT Project 54445 on Oct 30, 2025.","status":"PUC MARKET ANALYSIS","date":"2025-10-30","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=54445&itemNumber=117","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 54445: Staff Memo and Proposed Order_2 (2026 AS Methodology)","summary":"PUC MARKET ANALYSIS filed Staff Memo and Proposed Order_2 (2026 AS Methodology) in PUCT Project 54445 on Oct 30, 2025.","status":"PUC MARKET ANALYSIS","date":"2025-10-30","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=54445&itemNumber=118","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 54445: ORDER APPROVING ERCOT REVISION REQUESTS","summary":"PUC OPDM filed ORDER APPROVING ERCOT REVISION REQUESTS in PUCT Project 54445 on Nov 6, 2025.","status":"PUC OPDM","date":"2025-11-06","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=54445&itemNumber=119","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 54445: ORDER APPROVING 2026 ERCOT METHODOLOGIES FOR DETERMINING MINIMUM ANCILLARY SERVICE REQUIREMENTS","summary":"PUC OPDM filed ORDER APPROVING 2026 ERCOT METHODOLOGIES FOR DETERMINING MINIMUM ANCILLARY SERVICE REQUIREMENTS in PUCT Project 54445 on Nov 6, 2025.","status":"PUC OPDM","date":"2025-11-06","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=54445&itemNumber=120","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 54445: Staff memo regarding ERCOT revision requests approval timelines","summary":"PUC MARKET ANALYSIS filed Staff memo regarding ERCOT revision requests approval timelines in PUCT Project 54445 on Nov 19, 2025.","status":"PUC MARKET ANALYSIS","date":"2025-11-19","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=54445&itemNumber=121","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 54445: NOTICE OF RECOMMENDED APPROVAL OF REVISION REQUESTS BY ERCOT BOARD OF DIRECTORS","summary":"ERCOT filed NOTICE OF RECOMMENDED APPROVAL OF REVISION REQUESTS BY ERCOT BOARD OF DIRECTORS in PUCT Project 54445 on Dec 15, 2025.","status":"ERCOT","date":"2025-12-15","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=54445&itemNumber=122","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 54445: Staff Memo and Proposed Order","summary":"PUC MARKET ANALYSIS filed Staff Memo and Proposed Order in PUCT Project 54445 on Jan 8, 2026.","status":"PUC MARKET ANALYSIS","date":"2026-01-08","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=54445&itemNumber=123","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 54445: ORDER APPROVING ERCOT REVISION REQUESTS","summary":"PUC OPDM filed ORDER APPROVING ERCOT REVISION REQUESTS in PUCT Project 54445 on Jan 15, 2026.","status":"PUC OPDM","date":"2026-01-15","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=54445&itemNumber=124","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 54445: NOTICE OF RECOMMENDED APPROVAL OF REVISION REQUESTS BY ERCOT BOARD OF DIRECTORS","summary":"ERCOT filed NOTICE OF RECOMMENDED APPROVAL OF REVISION REQUESTS BY ERCOT BOARD OF DIRECTORS in PUCT Project 54445 on Feb 13, 2026.","status":"ERCOT","date":"2026-02-13","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=54445&itemNumber=125","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 54445: Staff Memo and Proposed Order","summary":"PUC MARKET ANALYSIS filed Staff Memo and Proposed Order in PUCT Project 54445 on Mar 19, 2026.","status":"PUC MARKET ANALYSIS","date":"2026-03-19","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=54445&itemNumber=126","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 54445: ORDER APPROVING ERCOT REVISION REQUESTS","summary":"PUC OPDM filed ORDER APPROVING ERCOT REVISION REQUESTS in PUCT Project 54445 on Mar 26, 2026.","status":"PUC OPDM","date":"2026-03-26","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=54445&itemNumber=127","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 54445: NOTICE OF RECOMMENDED APPROVAL OF REVISION REQUESTS BY ERCOT BOARD OF DIRECTORS","summary":"ERCOT filed NOTICE OF RECOMMENDED APPROVAL OF REVISION REQUESTS BY ERCOT BOARD OF DIRECTORS in PUCT Project 54445 on Apr 28, 2026.","status":"ERCOT","date":"2026-04-28","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=54445&itemNumber=128","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 54445: Staff Memo and Proposed Order","summary":"PUC MARKET ANALYSIS filed Staff Memo and Proposed Order in PUCT Project 54445 on May 21, 2026.","status":"PUC MARKET ANALYSIS","date":"2026-05-21","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=54445&itemNumber=129","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 54445: PROPOSED ORDER APPROVING ERCOT REVISION REQUESTS","summary":"PUC OPDM filed PROPOSED ORDER APPROVING ERCOT REVISION REQUESTS in PUCT Project 54445 on May 29, 2026.","status":"PUC OPDM","date":"2026-05-29","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=54445&itemNumber=130","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 54445: NOTICE OF RECOMMENDED APPROVAL OF REVISION REQUESTS BY ERCOT BOARD OF DIRECTORS","summary":"ERCOT filed NOTICE OF RECOMMENDED APPROVAL OF REVISION REQUESTS BY ERCOT BOARD OF DIRECTORS in PUCT Project 54445 on Jun 2, 2026.","status":"ERCOT","date":"2026-06-02","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=54445&itemNumber=131","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 54445: Commission Staff's Memo Regarding NOGRR282","summary":"PUC MARKET ANALYSIS filed Commission Staff's Memo Regarding NOGRR282 in PUCT Project 54445 on Jun 3, 2026.","status":"PUC MARKET ANALYSIS","date":"2026-06-03","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=54445&itemNumber=132","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 54445: NOTICE OF RECOMMENDED APPROVAL OF REVISION REQUESTS BY ERCOT BOARD OF DIRECTORS","summary":"ERCOT filed NOTICE OF RECOMMENDED APPROVAL OF REVISION REQUESTS BY ERCOT BOARD OF DIRECTORS in PUCT Project 54445 on Jun 8, 2026.","status":"ERCOT","date":"2026-06-08","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=54445&itemNumber=133","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 54445: Skybox Datacenters, LLC's Comments regarding Planning Guide Revision Request (\"PGRR\") 145 and Site Control Requirements for Batch Zero Large Load Interconnections","summary":"SKYBOX DATACENTERS, LLC filed Skybox Datacenters, LLC's Comments regarding Planning Guide Revision Request (\"PGRR\") 145 and Site Control Requirements for Batch Zero Large Load Interconnections in PUCT Project 54445 on Jun 10, 2026.","status":"SKYBOX DATACENTERS, LLC","date":"2026-06-10","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=54445&itemNumber=134","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 54445: Staff Memo and Proposed Order for PGRR 145 and NPRR 1325","summary":"PUC MARKET ANALYSIS filed Staff Memo and Proposed Order for PGRR 145 and NPRR 1325 in PUCT Project 54445 on Jun 11, 2026.","status":"PUC MARKET ANALYSIS","date":"2026-06-11","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=54445&itemNumber=138","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 54445: COMMENTS OF TEXAS ELECTRIC COOPERATIVES, INC. REGARDING NOGRR 282","summary":"TEXAS ELECTRIC COOPERATIVES, INC. filed COMMENTS OF TEXAS ELECTRIC COOPERATIVES, INC. REGARDING NOGRR 282 in PUCT Project 54445 on Jun 12, 2026.","status":"TEXAS ELECTRIC COOPERATIVES, INC.","date":"2026-06-12","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=54445&itemNumber=142","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 54445: DCC Comments on NOGRR282 Large Computational Load Ride-Through Requirements","summary":"DATA CENTER COALITION filed DCC Comments on NOGRR282 Large Computational Load Ride-Through Requirements in PUCT Project 54445 on Jun 12, 2026.","status":"DATA CENTER COALITION","date":"2026-06-12","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=54445&itemNumber=148","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 54445: Crusoe Technologies, LLC Comments on Recommended Approval of PGRR 145 by the ERCOT Board of Directors","summary":"Crusoe Technologies, LLC filed Crusoe Technologies, LLC Comments on Recommended Approval of PGRR 145 by the ERCOT Board of Directors in PUCT Project 54445 on Jun 12, 2026.","status":"Crusoe Technologies, LLC","date":"2026-06-12","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=54445&itemNumber=149","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 54445: ELECTRIC RELIABILITY COUNCIL OF TEXAS, INC.’S COMMENTS REGARDING NODAL OPERATING GUIDE REVISION REQUEST 282","summary":"ERCOT filed ELECTRIC RELIABILITY COUNCIL OF TEXAS, INC.’S COMMENTS REGARDING NODAL OPERATING GUIDE REVISION REQUEST 282 in PUCT Project 54445 on Jun 12, 2026.","status":"ERCOT","date":"2026-06-12","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=54445&itemNumber=150","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 54445: Data Center Coalition's Comments Regarding PGRR 145","summary":"Data Center Coalition (DCC) filed Data Center Coalition's Comments Regarding PGRR 145 in PUCT Project 54445 on Jun 16, 2026.","status":"Data Center Coalition (DCC)","date":"2026-06-16","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=54445&itemNumber=154","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 54445: ERCOT LETTER REGARDING PGRR145","summary":"ERCOT filed ERCOT LETTER REGARDING PGRR145 in PUCT Project 54445 on Jun 16, 2026.","status":"ERCOT","date":"2026-06-16","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=54445&itemNumber=155","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 54445: First Ammonia LLC's Comments on Commission Consideration of PGRR 145, Batch Zero Process for Large Load Interconnections","summary":"First Ammonia LLC filed First Ammonia LLC's Comments on Commission Consideration of PGRR 145, Batch Zero Process for Large Load Interconnections in PUCT Project 54445 on Jun 17, 2026.","status":"First Ammonia LLC","date":"2026-06-17","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=54445&itemNumber=157","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 54445: ORDER APPROVING ERCOT REVISION REQUESTS","summary":"PUC OPDM filed ORDER APPROVING ERCOT REVISION REQUESTS in PUCT Project 54445 on Jun 18, 2026.","status":"PUC OPDM","date":"2026-06-18","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=54445&itemNumber=158","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 54445: Staff Memos and Proposed Order","summary":"PUC MARKET ANALYSIS filed Staff Memos and Proposed Order in PUCT Project 54445 on Jul 2, 2026.","status":"PUC MARKET ANALYSIS","date":"2026-07-02","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=54445&itemNumber=160","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 54445: PROPOSED ORDER APPROVING ERCOT REVISION REQUESTS","summary":"PUC OPDM filed PROPOSED ORDER APPROVING ERCOT REVISION REQUESTS in PUCT Project 54445 on Jul 9, 2026.","status":"PUC OPDM","date":"2026-07-09","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=54445&itemNumber=162","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: ROWAN DIGITAL INFRASTRUCTURE LLC COMMENTS ON PROPOSAL FOR PUBLICATION OF NEW 16 TAC § 25.194","summary":"ROWAN DIGITAL INFRASTRUCTURE LLC filed ROWAN DIGITAL INFRASTRUCTURE LLC COMMENTS ON PROPOSAL FOR PUBLICATION OF NEW 16 TAC § 25.194 in PUCT Project 58481 on Apr 17, 2026.","status":"ROWAN DIGITAL INFRASTRUCTURE LLC","date":"2026-04-17","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=179","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: Comments on Proposal for Publication on Proposed New 16 TAC §25.194","summary":"Data Center Coalition (DCC) filed Comments on Proposal for Publication on Proposed New 16 TAC §25.194 in PUCT Project 58481 on Apr 17, 2026.","status":"Data Center Coalition (DCC)","date":"2026-04-17","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=180","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: Comments of Texas Electric Cooperatives, Inc.","summary":"TEXAS ELECTRIC COOPERATIVES, INC. filed Comments of Texas Electric Cooperatives, Inc. in PUCT Project 58481 on Apr 17, 2026.","status":"TEXAS ELECTRIC COOPERATIVES, INC.","date":"2026-04-17","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=182","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: The Steering Committee of Cities Served by Oncor and Texas Coalition for Affordable Power's Comments on Proposal for Publication of New 16 TAC § 25.194","summary":"STEERING COMMITTEE OF CITIES SERVED BY ONCOR AND TEXAS COALITION FOR AFFORDABLE POWER filed The Steering Committee of Cities Served by Oncor and Texas Coalition for Affordable Power's Comments on Proposal for Publication of New 16 TAC § 25.194 in PUCT Project 58481 on Apr 17, 2026.","status":"STEERING COMMITTEE OF CITIES SERVED BY ONCOR AND TEXAS COALITION FOR AFFORDABLE POWER","date":"2026-04-17","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=183","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: ONCOR ELECTRIC DELIVERY'S COMMENTS ON THE PROPOSAL FOR PUBLICATION OF NEW 16 TAC §25.194","summary":"ONCOR ELECTRIC DELIVERY COMPANY LLC filed ONCOR ELECTRIC DELIVERY'S COMMENTS ON THE PROPOSAL FOR PUBLICATION OF NEW 16 TAC §25.194 in PUCT Project 58481 on Apr 17, 2026.","status":"ONCOR ELECTRIC DELIVERY COMPANY LLC","date":"2026-04-17","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=184","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: ERCOT Steel Mills Comments on Proposal for Publication of New Rule 16 TAC §25.194","summary":"ERCOT STEEL MILLS filed ERCOT Steel Mills Comments on Proposal for Publication of New Rule 16 TAC §25.194 in PUCT Project 58481 on Apr 17, 2026.","status":"ERCOT STEEL MILLS","date":"2026-04-17","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=185","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: TXOGA Comments on Proposal for Publication on Proposed New 16 TAC §25.194","summary":"TEXAS OIL & GAS ASSOCIATION filed TXOGA Comments on Proposal for Publication on Proposed New 16 TAC §25.194 in PUCT Project 58481 on Apr 17, 2026.","status":"TEXAS OIL & GAS ASSOCIATION","date":"2026-04-17","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=188","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: GVEC's Comments on Proposal for Publication","summary":"GUADALUPE VALLEY ELECTRIC COOPERATIVE, INC filed GVEC's Comments on Proposal for Publication in PUCT Project 58481 on Apr 17, 2026.","status":"GUADALUPE VALLEY ELECTRIC COOPERATIVE, INC","date":"2026-04-17","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=189","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: Thor Equities’ Comments on PUCT Staff’s Proposal for Publication","summary":"Thor Equities LLC filed Thor Equities’ Comments on PUCT Staff’s Proposal for Publication in PUCT Project 58481 on Apr 17, 2026.","status":"Thor Equities LLC","date":"2026-04-17","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=191","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: Tesla, Inc. Comments on Proposal for Publication on Proposed New 16 TAC §25.194","summary":"TESLA filed Tesla, Inc. Comments on Proposal for Publication on Proposed New 16 TAC §25.194 in PUCT Project 58481 on Apr 17, 2026.","status":"TESLA","date":"2026-04-17","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=192","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: TEXAS INDUSTRIAL ENERGY CONSUMERS’ PROPOSED COMMENTS TO PROPOSAL FOR PUBLICATION OF NEW 16 TAC § 25.194","summary":"TIEC filed TEXAS INDUSTRIAL ENERGY CONSUMERS’ PROPOSED COMMENTS TO PROPOSAL FOR PUBLICATION OF NEW 16 TAC § 25.194 in PUCT Project 58481 on Apr 17, 2026.","status":"TIEC","date":"2026-04-17","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=193","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: Joint TSPs’ Comments on Proposal for Publication","summary":"WIND ENERGY TRANSMISSION TEXAS, LLC filed Joint TSPs’ Comments on Proposal for Publication in PUCT Project 58481 on Apr 17, 2026.","status":"WIND ENERGY TRANSMISSION TEXAS, LLC","date":"2026-04-17","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=194","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: OPUC’S COMMENTS REGARDING THE PROPOSAL FOR PUBLICATION OF NEW 16 TAC §25.194","summary":"OPUC filed OPUC’S COMMENTS REGARDING THE PROPOSAL FOR PUBLICATION OF NEW 16 TAC §25.194 in PUCT Project 58481 on Apr 17, 2026.","status":"OPUC","date":"2026-04-17","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=195","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: TNMP’s Comments To Proposal For Publication Of New 16 TAC § 25.194","summary":"TEXAS-NEW MEXICO POWER COMPANY filed TNMP’s Comments To Proposal For Publication Of New 16 TAC § 25.194 in PUCT Project 58481 on Apr 17, 2026.","status":"TEXAS-NEW MEXICO POWER COMPANY","date":"2026-04-17","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=197","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: CRUSOE TECHNOLOGIES LLC’S COMMENTS ON STAFF’S PROPOSAL FOR PUBLICATION OF NEW 16 TAC § 25.194","summary":"Crusoe Technologies LLC filed CRUSOE TECHNOLOGIES LLC’S COMMENTS ON STAFF’S PROPOSAL FOR PUBLICATION OF NEW 16 TAC § 25.194 in PUCT Project 58481 on Apr 17, 2026.","status":"Crusoe Technologies LLC","date":"2026-04-17","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=199","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: Vistra's Comments - Project 58481","summary":"VISTRA CORPORATE SERVICES COMPANY filed Vistra's Comments - Project 58481 in PUCT Project 58481 on Apr 17, 2026.","status":"VISTRA CORPORATE SERVICES COMPANY","date":"2026-04-17","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=200","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: Cormint Data Systems Comments on Staff PforP in 58481","summary":"Cormint Data Systems filed Cormint Data Systems Comments on Staff PforP in 58481 in PUCT Project 58481 on Apr 20, 2026.","status":"Cormint Data Systems","date":"2026-04-20","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=203","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 54445: Staff memo regarding ERCOT revision requests approval timelines","summary":"PUC MARKET ANALYSIS filed Staff memo regarding ERCOT revision requests approval timelines in PUCT Project 54445 on Aug 11, 2026.","status":"PUC MARKET ANALYSIS","date":"2026-08-11","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=54445&itemNumber=163","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58317: Request for control number","summary":"PUC RULES AND PROJECTS filed Request for control number in PUCT Project 58317 on Jun 30, 2025.","status":"PUC RULES AND PROJECTS","date":"2025-06-30","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58317&itemNumber=1","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58317: Notice of July 21 Workshop","summary":"PUC RULES AND PROJECTS filed Notice of July 21 Workshop in PUCT Project 58317 on Jul 8, 2025.","status":"PUC RULES AND PROJECTS","date":"2025-07-08","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58317&itemNumber=2","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58317: July 21 Workshop Agenda","summary":"PUC RULES AND PROJECTS filed July 21 Workshop Agenda in PUCT Project 58317 on Jul 14, 2025.","status":"PUC RULES AND PROJECTS","date":"2025-07-14","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58317&itemNumber=3","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58317: Response to Commission Request for Information Regarding Net Metering Arrangements Under PURA § 39.169","summary":"PUC RULES & PROJECTS filed Response to Commission Request for Information Regarding Net Metering Arrangements Under PURA § 39.169 in PUCT Project 58317 on Jul 24, 2025.","status":"PUC RULES & PROJECTS","date":"2025-07-24","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58317&itemNumber=4","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58317: Staff Memo and Roadmap","summary":"PUC RULES & PROJECTS filed Staff Memo and Roadmap in PUCT Project 58317 on Aug 1, 2025.","status":"PUC RULES & PROJECTS","date":"2025-08-01","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58317&itemNumber=5","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59220: ORDER NO. 3- GRANTING MOTIONS TO INTERVENE","summary":"PUC OPDM filed ORDER NO. 3- GRANTING MOTIONS TO INTERVENE in PUCT Project 59220 on Feb 9, 2026.","status":"PUC OPDM","date":"2026-02-09","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59220&itemNumber=10","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59220: AMENDED APPLICATION FOR NET METERING APPROVAL BY FGE GOODNIGHT I, LLC (GOODNIGHT WIND) AND CRUSOE ENERGY SYSTEMS LLC, AND ENSIGN INFRASTRUCTURE LLC","summary":"CRUSOE ENERGY SYSTEMS LLC filed AMENDED APPLICATION FOR NET METERING APPROVAL BY FGE GOODNIGHT I, LLC (GOODNIGHT WIND) AND CRUSOE ENERGY SYSTEMS LLC, AND ENSIGN INFRASTRUCTURE LLC in PUCT Project 59220 on Mar 26, 2026.","status":"CRUSOE ENERGY SYSTEMS LLC","date":"2026-03-26","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59220&itemNumber=11","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59220: SUPPLEMENT TO AMENDED APPLICATION FOR NET METERING APPROVAL BY FGE GOODNIGHT I, LLC (GOODNIGHT WIND) AND CRUSOE ENERGY SYSTEMS LLC, AND ENSIGN INFRASTRUCTURE LLC","summary":"CRUSOE ENERGY SYSTEMS LLC filed SUPPLEMENT TO AMENDED APPLICATION FOR NET METERING APPROVAL BY FGE GOODNIGHT I, LLC (GOODNIGHT WIND) AND CRUSOE ENERGY SYSTEMS LLC, AND ENSIGN INFRASTRUCTURE LLC in PUCT Project 59220 on Mar 26, 2026.","status":"CRUSOE ENERGY SYSTEMS LLC","date":"2026-03-26","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59220&itemNumber=12","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59220: ORDER NO. 4 - RESTYLING DOCKET","summary":"PUC OPDM filed ORDER NO. 4 - RESTYLING DOCKET in PUCT Project 59220 on Apr 8, 2026.","status":"PUC OPDM","date":"2026-04-08","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59220&itemNumber=13","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59220: PROTECTIVE ORDER CERTIFICATIONS","summary":"PUC LEGAL filed PROTECTIVE ORDER CERTIFICATIONS in PUCT Project 59220 on May 12, 2026.","status":"PUC LEGAL","date":"2026-05-12","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59220&itemNumber=14","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59220: ERCOT NOTICE OF INTENT TO FILE STUDY RESULTS AND RECOMMENDATIONS","summary":"ERCOT filed ERCOT NOTICE OF INTENT TO FILE STUDY RESULTS AND RECOMMENDATIONS in PUCT Project 59220 on May 19, 2026.","status":"ERCOT","date":"2026-05-19","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59220&itemNumber=15","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59220: ELECTRIC RELIABILITY COUNCIL OF TEXAS, INC.’S FILING OF STUDY RESULTS AND RECOMMENDATIONS","summary":"ERCOT filed ELECTRIC RELIABILITY COUNCIL OF TEXAS, INC.’S FILING OF STUDY RESULTS AND RECOMMENDATIONS in PUCT Project 59220 on May 29, 2026.","status":"ERCOT","date":"2026-05-29","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59220&itemNumber=16","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59220: CONFIDENTIAL - ELECTRIC RELIABILITY COUNCIL OF TEXAS, INC.’S FILING OF STUDY RESULTS AND RECOMMENDATIONS","summary":"ERCOT filed CONFIDENTIAL - ELECTRIC RELIABILITY COUNCIL OF TEXAS, INC.’S FILING OF STUDY RESULTS AND RECOMMENDATIONS in PUCT Project 59220 on May 29, 2026.","status":"ERCOT","date":"2026-05-29","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59220&itemNumber=17","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59220: ORDER NO. 5 - ESTABLISHING PROCEDURAL SCHEDULE","summary":"PUC OPDM filed ORDER NO. 5 - ESTABLISHING PROCEDURAL SCHEDULE in PUCT Project 59220 on May 29, 2026.","status":"PUC OPDM","date":"2026-05-29","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59220&itemNumber=18","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59220: ENSIGN INFRASTRUCTURE LLC’S NOTICE OF FILING PROTECTIVE ORDER CERTIFICATIONS","summary":"ENSIGN INFRASTRUCTURE LLC filed ENSIGN INFRASTRUCTURE LLC’S NOTICE OF FILING PROTECTIVE ORDER CERTIFICATIONS in PUCT Project 59220 on May 30, 2026.","status":"ENSIGN INFRASTRUCTURE LLC","date":"2026-05-30","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59220&itemNumber=19","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59220: JOINT APPLICATION FOR NET METERING APPROVAL BY FGE GOODNIGHT I, LLC AND CRUSOE ENERGY SYSTEMS LLC","summary":"FGE Goodnight I, LLC and Crusoe Energy Systems LLC filed JOINT APPLICATION FOR NET METERING APPROVAL BY FGE GOODNIGHT I, LLC AND CRUSOE ENERGY SYSTEMS LLC in PUCT Project 59220 on Jan 9, 2026.","status":"FGE Goodnight I, LLC and Crusoe Energy Systems LLC","date":"2026-01-09","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59220&itemNumber=1","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59220: Direct Testimony of Bharath Kumar Ravulapati","summary":"CRUSOE ENERGY SYSTEMS filed Direct Testimony of Bharath Kumar Ravulapati in PUCT Project 59220 on Jun 3, 2026.","status":"CRUSOE ENERGY SYSTEMS","date":"2026-06-03","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59220&itemNumber=22","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59220: ELECTRIC RELIABILITY COUNCIL OF TEXAS, INC.’S STATEMENT OF POSITION IN RESPONSE TO ORDER NO. 5","summary":"ERCOT filed ELECTRIC RELIABILITY COUNCIL OF TEXAS, INC.’S STATEMENT OF POSITION IN RESPONSE TO ORDER NO. 5 in PUCT Project 59220 on Jun 8, 2026.","status":"ERCOT","date":"2026-06-08","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59220&itemNumber=23","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59220: Staff's Recommendation on Administrative Completeness and Sufficiency of Notice","summary":"PUC MARKET ANALYSIS filed Staff's Recommendation on Administrative Completeness and Sufficiency of Notice in PUCT Project 59220 on Jun 8, 2026.","status":"PUC MARKET ANALYSIS","date":"2026-06-08","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59220&itemNumber=24","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59220: ENSIGN INFRASTRUCTURE, LLC’S AND CRUSOE ENERGY SYSTEMS LLC’S NOTICE OF HEARING AND NOTICE OF INTENT TO REQUEST COURT REPORTER","summary":"ENSIGN INFRASTRUCTURE LLC filed ENSIGN INFRASTRUCTURE, LLC’S AND CRUSOE ENERGY SYSTEMS LLC’S NOTICE OF HEARING AND NOTICE OF INTENT TO REQUEST COURT REPORTER in PUCT Project 59220 on Jun 8, 2026.","status":"ENSIGN INFRASTRUCTURE LLC","date":"2026-06-08","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59220&itemNumber=25","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59220: ORDER NO. 6 - FINDING APPLICATION ADMINISTRATIVELY COMPLETE AND NOTICE SUFFICIENT, REQUIRING CORRECTED NOTICE OF HEARING, PROVIDING NOTICE OF PREHEARING CONFERENCE, AND REVISING PROCEDURAL SCHEDULE","summary":"PUC OPDM filed ORDER NO. 6 - FINDING APPLICATION ADMINISTRATIVELY COMPLETE AND NOTICE SUFFICIENT, REQUIRING CORRECTED NOTICE OF HEARING, PROVIDING NOTICE OF PREHEARING CONFERENCE, AND REVISING PROCEDURAL SCHEDULE in PUCT Project 59220 on Jun 9, 2026.","status":"PUC OPDM","date":"2026-06-09","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59220&itemNumber=28","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59220: ORDER NO. 7- CLARIFYING DEADLINE FOR APPLICANTS TO FILE CORRECTED NOTICE OF HEARING","summary":"PUC OPDM filed ORDER NO. 7- CLARIFYING DEADLINE FOR APPLICANTS TO FILE CORRECTED NOTICE OF HEARING in PUCT Project 59220 on Jun 10, 2026.","status":"PUC OPDM","date":"2026-06-10","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59220&itemNumber=29","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59220: Correction to the Joint Application for Net Metering Approval","summary":"CRUSOE ENERGY SYSTEMS LLC filed Correction to the Joint Application for Net Metering Approval in PUCT Project 59220 on Jan 12, 2026.","status":"CRUSOE ENERGY SYSTEMS LLC","date":"2026-01-12","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59220&itemNumber=2","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59220: ELECTRIC RELIABILITY COUNCIL OF TEXAS, INC.’S RESPONSE TO OTHER PARTIES’ FILINGS","summary":"ERCOT filed ELECTRIC RELIABILITY COUNCIL OF TEXAS, INC.’S RESPONSE TO OTHER PARTIES’ FILINGS in PUCT Project 59220 on Jun 15, 2026.","status":"ERCOT","date":"2026-06-15","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59220&itemNumber=32","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59220: Commission Staff's Statement of Position and Recommendations","summary":"PUC MARKET ANALYSIS filed Commission Staff's Statement of Position and Recommendations in PUCT Project 59220 on Jun 17, 2026.","status":"PUC MARKET ANALYSIS","date":"2026-06-17","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59220&itemNumber=33","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59220: Commission Staff's Objections and Motion to Strike","summary":"PUC MARKET ANALYSIS filed Commission Staff's Objections and Motion to Strike in PUCT Project 59220 on Jun 18, 2026.","status":"PUC MARKET ANALYSIS","date":"2026-06-18","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59220&itemNumber=34","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59220: ORDER NO. 8- DENYING REQUEST FOR A VIRTUAL PREHEARING CONFERENCE","summary":"PUC OPDM filed ORDER NO. 8- DENYING REQUEST FOR A VIRTUAL PREHEARING CONFERENCE in PUCT Project 59220 on Jun 18, 2026.","status":"PUC OPDM","date":"2026-06-18","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59220&itemNumber=36","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59220: ENSIGN INFRASTRUCTURE, LLC RESPONSE TO COMMISSION STAFF’S MOTION TO STRIKE","summary":"ENSIGN INFRASTRUCTURE LLC filed ENSIGN INFRASTRUCTURE, LLC RESPONSE TO COMMISSION STAFF’S MOTION TO STRIKE in PUCT Project 59220 on Jun 19, 2026.","status":"ENSIGN INFRASTRUCTURE LLC","date":"2026-06-19","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59220&itemNumber=37","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59220: ELECTRIC RELIABILITY COUNCIL OF TEXAS, INC.’S RESPONSE TO ENSIGN INFRASTRUCTURE, LLC’S INFORMAL FIRST SET OF REQUESTS FOR INFORMATION","summary":"ERCOT filed ELECTRIC RELIABILITY COUNCIL OF TEXAS, INC.’S RESPONSE TO ENSIGN INFRASTRUCTURE, LLC’S INFORMAL FIRST SET OF REQUESTS FOR INFORMATION in PUCT Project 59220 on Jun 19, 2026.","status":"ERCOT","date":"2026-06-19","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59220&itemNumber=38","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59220: Notice of Protective Order Certifications","summary":"Greenbelt Electric Cooperative, Inc. and Golden Spread Electric Cooperative, Inc. filed Notice of Protective Order Certifications in PUCT Project 59220 on Jun 19, 2026.","status":"Greenbelt Electric Cooperative, Inc. and Golden Spread Electric Cooperative, Inc.","date":"2026-06-19","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59220&itemNumber=39","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59220: ORDER NO. 1 - ESTABLISHING PROCEDURAL REQUIREMENTS AND ENTERING PROTECTIVE ORDER","summary":"PUC OPDM filed ORDER NO. 1 - ESTABLISHING PROCEDURAL REQUIREMENTS AND ENTERING PROTECTIVE ORDER in PUCT Project 59220 on Jan 13, 2026.","status":"PUC OPDM","date":"2026-01-13","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59220&itemNumber=3","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59220: ORDER NO. 9 - MEMORIALIZING PREHEARING CONFERENCE, CANCELING HEARING ON THE MERITS, AND ADOPTING REVISED PROCEDURAL SCHEDULE","summary":"PUC OPDM filed ORDER NO. 9 - MEMORIALIZING PREHEARING CONFERENCE, CANCELING HEARING ON THE MERITS, AND ADOPTING REVISED PROCEDURAL SCHEDULE in PUCT Project 59220 on Jun 19, 2026.","status":"PUC OPDM","date":"2026-06-19","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59220&itemNumber=40","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59220: CRUSOE ENERGY SYSTEMS LLC EXHIBIT LIST AND EXHIBIT","summary":"CRUSOE ENERGY SYSTEMS LLC filed CRUSOE ENERGY SYSTEMS LLC EXHIBIT LIST AND EXHIBIT in PUCT Project 59220 on Jun 22, 2026.","status":"CRUSOE ENERGY SYSTEMS LLC","date":"2026-06-22","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59220&itemNumber=41","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59220: ELECTRIC RELIABILITY COUNCIL OF TEXAS, INC.’S EXHIBIT LIST","summary":"ERCOT filed ELECTRIC RELIABILITY COUNCIL OF TEXAS, INC.’S EXHIBIT LIST in PUCT Project 59220 on Jun 22, 2026.","status":"ERCOT","date":"2026-06-22","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59220&itemNumber=44","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59220: ELECTRIC RELIABILITY COUNCIL OF TEXAS, INC.’S NITIAL BRIEF","summary":"ERCOT filed ELECTRIC RELIABILITY COUNCIL OF TEXAS, INC.’S NITIAL BRIEF in PUCT Project 59220 on Jun 26, 2026.","status":"ERCOT","date":"2026-06-26","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59220&itemNumber=45","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59220: Commission Staff's Initial Brief","summary":"PUC MARKET ANALYSIS filed Commission Staff's Initial Brief in PUCT Project 59220 on Jun 26, 2026.","status":"PUC MARKET ANALYSIS","date":"2026-06-26","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59220&itemNumber=47","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59220: ONCOR ELECTRIC DELIVERY COMPANY LLC'S MOTION TO INTERVENE","summary":"ONCOR ELECTRIC DELIVERY COMPANY LLC filed ONCOR ELECTRIC DELIVERY COMPANY LLC'S MOTION TO INTERVENE in PUCT Project 59220 on Jan 21, 2026.","status":"ONCOR ELECTRIC DELIVERY COMPANY LLC","date":"2026-01-21","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59220&itemNumber=4","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59220: ELECTRIC RELIABILITY COUNCIL OF TEXAS, INC.’S REPLY BRIEF","summary":"ERCOT filed ELECTRIC RELIABILITY COUNCIL OF TEXAS, INC.’S REPLY BRIEF in PUCT Project 59220 on Jul 2, 2026.","status":"ERCOT","date":"2026-07-02","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59220&itemNumber=51","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59220: ELECTRIC RELIABILITY COUNCIL OF TEXAS, INC.’S AND COMMISSION STAFF’S JOINT PROPOSED FINDINGS OF FACT AND CONCLUSIONS OF LAW","summary":"ERCOT filed ELECTRIC RELIABILITY COUNCIL OF TEXAS, INC.’S AND COMMISSION STAFF’S JOINT PROPOSED FINDINGS OF FACT AND CONCLUSIONS OF LAW in PUCT Project 59220 on Jul 2, 2026.","status":"ERCOT","date":"2026-07-02","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59220&itemNumber=52","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59220: Commission Staff's Reply Brief","summary":"PUC MARKET ANALYSIS filed Commission Staff's Reply Brief in PUCT Project 59220 on Jul 2, 2026.","status":"PUC MARKET ANALYSIS","date":"2026-07-02","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59220&itemNumber=54","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59220: JOINT PROPOSED ORDER","summary":"ENSIGN INFRASTRUCTURE LLC filed JOINT PROPOSED ORDER in PUCT Project 59220 on Jul 2, 2026.","status":"ENSIGN INFRASTRUCTURE LLC","date":"2026-07-02","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59220&itemNumber=56","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59220: Commission Staff's Change of Counsel","summary":"PUC MARKET ANALYSIS filed Commission Staff's Change of Counsel in PUCT Project 59220 on Jul 8, 2026.","status":"PUC MARKET ANALYSIS","date":"2026-07-08","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59220&itemNumber=59","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59220: NOTICE OF APPEARANCE OF COUNSEL ON BEHALF OF ELECTRIC RELIABILITY COUNCIL OF TEXAS, INC.","summary":"ERCOT filed NOTICE OF APPEARANCE OF COUNSEL ON BEHALF OF ELECTRIC RELIABILITY COUNCIL OF TEXAS, INC. in PUCT Project 59220 on Jan 29, 2026.","status":"ERCOT","date":"2026-01-29","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59220&itemNumber=5","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59220: PROPOSED ORDER WITH MEMORANDUM","summary":"PUC OPDM filed PROPOSED ORDER WITH MEMORANDUM in PUCT Project 59220 on Jul 9, 2026.","status":"PUC OPDM","date":"2026-07-09","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59220&itemNumber=60","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59220: ENSIGN INFRASTRUCTURE, LLC’S AND CRUSOE ENERGY SYSTEMS LLC’S CORRECTIONS AND EXCEPTIONS TO PROPOSED ORDER","summary":"ENSIGN INFRASTRUCTURE LLC filed ENSIGN INFRASTRUCTURE, LLC’S AND CRUSOE ENERGY SYSTEMS LLC’S CORRECTIONS AND EXCEPTIONS TO PROPOSED ORDER in PUCT Project 59220 on Jul 14, 2026.","status":"ENSIGN INFRASTRUCTURE LLC","date":"2026-07-14","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59220&itemNumber=61","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59220: FGE Goodnight I, LLC's Corrections and Exceptions to the Proposed Order","summary":"FGE Goodnight I, LLC filed FGE Goodnight I, LLC's Corrections and Exceptions to the Proposed Order in PUCT Project 59220 on Jul 14, 2026.","status":"FGE Goodnight I, LLC","date":"2026-07-14","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59220&itemNumber=62","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59220: NOTICE MEMORANDUM","summary":"PUC OPDM filed NOTICE MEMORANDUM in PUCT Project 59220 on Jul 15, 2026.","status":"PUC OPDM","date":"2026-07-15","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59220&itemNumber=63","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59220: PROPOSED ORDER MEMORANDUM","summary":"PUC OPDM filed PROPOSED ORDER MEMORANDUM in PUCT Project 59220 on Jul 16, 2026.","status":"PUC OPDM","date":"2026-07-16","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59220&itemNumber=64","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59220: Amicus Brief","summary":"TEXAS COMPETITIVE POWER ADVOCATES filed Amicus Brief in PUCT Project 59220 on Jul 16, 2026.","status":"TEXAS COMPETITIVE POWER ADVOCATES","date":"2026-07-16","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59220&itemNumber=65","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59220: Commission Staff's Motion to Strike Amicus Briefs","summary":"PUC MARKET ANALYSIS filed Commission Staff's Motion to Strike Amicus Briefs in PUCT Project 59220 on Jul 17, 2026.","status":"PUC MARKET ANALYSIS","date":"2026-07-17","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59220&itemNumber=67","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59220: CHAIRMAN GLEESON MEMORANDUM","summary":"PUC OPDM filed CHAIRMAN GLEESON MEMORANDUM in PUCT Project 59220 on Jul 23, 2026.","status":"PUC OPDM","date":"2026-07-23","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59220&itemNumber=68","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59220: ORDER","summary":"PUC OPDM filed ORDER in PUCT Project 59220 on Jul 24, 2026.","status":"PUC OPDM","date":"2026-07-24","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59220&itemNumber=69","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59220: Protective Order Certifications for Crusoe Energy Systems and FGE Goodnight I, LLC (Goodnight Wind)","summary":"Crusoe Energy Systems and FGE Goodnight I, LLC filed Protective Order Certifications for Crusoe Energy Systems and FGE Goodnight I, LLC (Goodnight Wind) in PUCT Project 59220 on Jan 29, 2026.","status":"Crusoe Energy Systems and FGE Goodnight I, LLC","date":"2026-01-29","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59220&itemNumber=6","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59220: OUTGOING COMMISSION-SIGNED ORDER MAIL LOG","summary":"PUC OPDM filed OUTGOING COMMISSION-SIGNED ORDER MAIL LOG in PUCT Project 59220 on Jul 24, 2026.","status":"PUC OPDM","date":"2026-07-24","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59220&itemNumber=70","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59220: VOID SEE ITEM 72","summary":"ERCOT filed VOID SEE ITEM 72 in PUCT Project 59220 on Jul 24, 2026.","status":"ERCOT","date":"2026-07-24","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59220&itemNumber=71","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59220: VOID LETTER","summary":"ERCOT filed VOID LETTER in PUCT Project 59220 on Jul 24, 2026.","status":"ERCOT","date":"2026-07-24","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59220&itemNumber=72","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59220: BALLOT MEMORANDUM","summary":"PUC OPDM filed BALLOT MEMORANDUM in PUCT Project 59220 on Aug 31, 2026.","status":"PUC OPDM","date":"2026-08-31","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59220&itemNumber=74","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59220: ELECTRIC RELIABILITY COUNCIL OF TEXAS, INC.’S NOTICE OF COMMENCEMENT OF STUDY","summary":"ERCOT filed ELECTRIC RELIABILITY COUNCIL OF TEXAS, INC.’S NOTICE OF COMMENCEMENT OF STUDY in PUCT Project 59220 on Jan 29, 2026.","status":"ERCOT","date":"2026-01-29","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59220&itemNumber=7","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59220: ORDER NO. 2 - GRANTING MOTION TO INTERVENE","summary":"PUC OPDM filed ORDER NO. 2 - GRANTING MOTION TO INTERVENE in PUCT Project 59220 on Feb 2, 2026.","status":"PUC OPDM","date":"2026-02-02","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59220&itemNumber=9","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58317: OPUC NOTICE OF PARTICIPATION LETTER","summary":"OPUC filed OPUC NOTICE OF PARTICIPATION LETTER in PUCT Project 58317 on Sep 24, 2025.","status":"OPUC","date":"2025-09-24","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58317&itemNumber=10","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58317: Joint Comments of Google LLC and Lancium LLC on SB6 Implementation","summary":"GOOGLE LLC, LANCIUM LLC filed Joint Comments of Google LLC and Lancium LLC on SB6 Implementation in PUCT Project 58317 on Dec 18, 2025.","status":"GOOGLE LLC, LANCIUM LLC","date":"2025-12-18","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58317&itemNumber=11","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58317: OM Item No. 46 - Staff Memo and Updated Roadmap","summary":"PUC RULES & PROJECTS filed OM Item No. 46 - Staff Memo and Updated Roadmap in PUCT Project 58317 on Jan 30, 2026.","status":"PUC RULES & PROJECTS","date":"2026-01-30","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58317&itemNumber=12","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58317: Staff Memo_New Rulemaking Project","summary":"PUC RULES & PROJECTS filed Staff Memo_New Rulemaking Project in PUCT Project 58317 on May 27, 2026.","status":"PUC RULES & PROJECTS","date":"2026-05-27","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58317&itemNumber=14","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58317: Staff Memo and Updated Roadmap","summary":"PUC RULES & PROJECTS filed Staff Memo and Updated Roadmap in PUCT Project 58317 on May 27, 2026.","status":"PUC RULES & PROJECTS","date":"2026-05-27","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58317&itemNumber=15","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58317: Governor Abbott's June 10, 2026 letter to PUCT and ERCOT re: Data Center Infrastructure Costs","summary":"PUC DEPUTY EXECUTIVE DIRECTOR filed Governor Abbott's June 10, 2026 letter to PUCT and ERCOT re: Data Center Infrastructure Costs in PUCT Project 58317 on Jun 22, 2026.","status":"PUC DEPUTY EXECUTIVE DIRECTOR","date":"2026-06-22","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58317&itemNumber=16","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58317: Response to Governor Abbott's June 10, 2026 letter","summary":"PUC DEPUTY EXECUTIVE DIRECTOR filed Response to Governor Abbott's June 10, 2026 letter in PUCT Project 58317 on Jul 20, 2026.","status":"PUC DEPUTY EXECUTIVE DIRECTOR","date":"2026-07-20","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58317&itemNumber=18","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58317: SB6 Implementation Roadmap Updated July 2026","summary":"PUC RULES & PROJECTS filed SB6 Implementation Roadmap Updated July 2026 in PUCT Project 58317 on Jul 21, 2026.","status":"PUC RULES & PROJECTS","date":"2026-07-21","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58317&itemNumber=19","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58317: CHAIRMAN GLEESON MEMORANDUM","summary":"PUC OPDM filed CHAIRMAN GLEESON MEMORANDUM in PUCT Project 58317 on Aug 6, 2026.","status":"PUC OPDM","date":"2026-08-06","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58317&itemNumber=25","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58317: Governor Abbott's August 3, 2026 letter to PUCT and ERCOT re: Verification of Data Center Information","summary":"PUC DEPUTY EXECUTIVE DIRECTOR filed Governor Abbott's August 3, 2026 letter to PUCT and ERCOT re: Verification of Data Center Information in PUCT Project 58317 on Aug 6, 2026.","status":"PUC DEPUTY EXECUTIVE DIRECTOR","date":"2026-08-06","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58317&itemNumber=26","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58317: ERCOT LETTER REGARDING PROJECT NO. 59142 FILING","summary":"ERCOT filed ERCOT LETTER REGARDING PROJECT NO. 59142 FILING in PUCT Project 58317 on Aug 10, 2026.","status":"ERCOT","date":"2026-08-10","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58317&itemNumber=27","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58317: SENATE BILL 6 IMPLEMENTATION WORKSHOP PROJECT NO. 58317 MONDAY, JULY 21, 2025","summary":"KENNEDY REPORTING SERVICE filed SENATE BILL 6 IMPLEMENTATION WORKSHOP PROJECT NO. 58317 MONDAY, JULY 21, 2025 in PUCT Project 58317 on Aug 5, 2025.","status":"KENNEDY REPORTING SERVICE","date":"2025-08-05","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58317&itemNumber=6","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58317: ERCOT LETTER RE NET METERING STUDY DETAILS","summary":"ERCOT filed ERCOT LETTER RE NET METERING STUDY DETAILS in PUCT Project 58317 on Sep 2, 2025.","status":"ERCOT","date":"2025-09-02","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58317&itemNumber=7","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58317: ERCOT LETTER RE STAND-ALONE GENERATION RESOURCE LIST UPDATE","summary":"ERCOT filed ERCOT LETTER RE STAND-ALONE GENERATION RESOURCE LIST UPDATE in PUCT Project 58317 on Sep 19, 2025.","status":"ERCOT","date":"2025-09-19","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58317&itemNumber=9","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58480: EDF comments on large load forecast proposed rule","summary":"ENVIRONMENTAL DEFENSE FUND INC filed EDF comments on large load forecast proposed rule in PUCT Project 58480 on Oct 17, 2025.","status":"ENVIRONMENTAL DEFENSE FUND INC","date":"2025-10-17","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58480&itemNumber=14","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58480: ERCOT STEEL MILLS’ COMMENTS ON PROJECT NO. 58480 - ERCOT LARGE LOAD FORECASTING CRITERIA","summary":"ERCOT STEEL MILLS filed ERCOT STEEL MILLS’ COMMENTS ON PROJECT NO. 58480 - ERCOT LARGE LOAD FORECASTING CRITERIA in PUCT Project 58480 on Oct 17, 2025.","status":"ERCOT STEEL MILLS","date":"2025-10-17","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58480&itemNumber=15","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58480: Targa Resources LLC's Comments to Staff Recommendation for Proposal for Publication of New 16 TAC §25.370","summary":"Targa Resources LLC filed Targa Resources LLC's Comments to Staff Recommendation for Proposal for Publication of New 16 TAC §25.370 in PUCT Project 58480 on Oct 17, 2025.","status":"Targa Resources LLC","date":"2025-10-17","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58480&itemNumber=16","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58480: NRG Energy, Inc.'s Comments on the Proposed Rule","summary":"NRG ENERGY, INC. filed NRG Energy, Inc.'s Comments on the Proposed Rule in PUCT Project 58480 on Oct 17, 2025.","status":"NRG ENERGY, INC.","date":"2025-10-17","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58480&itemNumber=17","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58480: Texas Public Policy Foundation Comments on Proposal for Publication of New 16 TAC §25.370","summary":"Texas Public Policy Foundation filed Texas Public Policy Foundation Comments on Proposal for Publication of New 16 TAC §25.370 in PUCT Project 58480 on Oct 17, 2025.","status":"Texas Public Policy Foundation","date":"2025-10-17","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58480&itemNumber=18","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58480: Request for Control Number","summary":"PUC RULES & PROJECTS filed Request for Control Number in PUCT Project 58480 on Jul 31, 2025.","status":"PUC RULES & PROJECTS","date":"2025-07-31","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58480&itemNumber=1","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58480: OCSC and TCAP's Comments on Proposed Large Load Forecasting Criteria","summary":"THE STEERING COMMITTEE OF CITIES SERVED BY ONCOR (CITIES) filed OCSC and TCAP's Comments on Proposed Large Load Forecasting Criteria in PUCT Project 58480 on Oct 17, 2025.","status":"THE STEERING COMMITTEE OF CITIES SERVED BY ONCOR (CITIES)","date":"2025-10-17","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58480&itemNumber=20","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58480: SCHAPER ENERGY CONSULTING LLC SUPPLEMENTAL RESPONSE TO STAFF’s QUESTIONS ON PROJECT NO. 58480; ERCOT LARGE LOAD FORECASTING CRITERIA UNDER PROPOSED 16 TAC §25.370","summary":"Schaper Energy Consulting LLC filed SCHAPER ENERGY CONSULTING LLC SUPPLEMENTAL RESPONSE TO STAFF’s QUESTIONS ON PROJECT NO. 58480; ERCOT LARGE LOAD FORECASTING CRITERIA UNDER PROPOSED 16 TAC §25.370 in PUCT Project 58480 on Oct 17, 2025.","status":"Schaper Energy Consulting LLC","date":"2025-10-17","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58480&itemNumber=21","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58480: TCPA Comments and Recommendations on PfP","summary":"TCPA filed TCPA Comments and Recommendations on PfP in PUCT Project 58480 on Oct 17, 2025.","status":"TCPA","date":"2025-10-17","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58480&itemNumber=22","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58480: TEXAS INDUSTRIAL ENERGY CONSUMERS’ PROPOSED COMMENTS TO DRAFT RULE 25.504","summary":"TIEC filed TEXAS INDUSTRIAL ENERGY CONSUMERS’ PROPOSED COMMENTS TO DRAFT RULE 25.504 in PUCT Project 58480 on Oct 17, 2025.","status":"TIEC","date":"2025-10-17","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58480&itemNumber=23","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58480: OFFICE OF PUBLIC UTILITY COUNSEL’S COMMENTS ON PROPOSAL FOR PUBLICATION OF NEW 16 TAC § 25.370","summary":"OPUC filed OFFICE OF PUBLIC UTILITY COUNSEL’S COMMENTS ON PROPOSAL FOR PUBLICATION OF NEW 16 TAC § 25.370 in PUCT Project 58480 on Oct 17, 2025.","status":"OPUC","date":"2025-10-17","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58480&itemNumber=24","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58480: TEBA's Comments on Project No. 58480 Proposal for Publication","summary":"TEXAS ENERGY BUYERS ALLIANCE filed TEBA's Comments on Project No. 58480 Proposal for Publication in PUCT Project 58480 on Oct 17, 2025.","status":"TEXAS ENERGY BUYERS ALLIANCE","date":"2025-10-17","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58480&itemNumber=25","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58480: ONCOR ELECTRIC DELIVERY’S COMMENTS ON THE PROPOSAL FOR PUBLICATION OF NEW 16 TAC §25.370","summary":"ONCOR ELECTRIC DELIVERY COMPANY LLC filed ONCOR ELECTRIC DELIVERY’S COMMENTS ON THE PROPOSAL FOR PUBLICATION OF NEW 16 TAC §25.370 in PUCT Project 58480 on Oct 17, 2025.","status":"ONCOR ELECTRIC DELIVERY COMPANY LLC","date":"2025-10-17","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58480&itemNumber=26","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58480: CenterPoint Energy Houston Electric Comments","summary":"CENTERPOINT ENERGY HOUSTON ELECTRIC filed CenterPoint Energy Houston Electric Comments in PUCT Project 58480 on Oct 17, 2025.","status":"CENTERPOINT ENERGY HOUSTON ELECTRIC","date":"2025-10-17","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58480&itemNumber=27","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58480: Comments of Texas Electric Cooperatives, Inc.","summary":"Texas Electric Cooperatives, Inc. filed Comments of Texas Electric Cooperatives, Inc. in PUCT Project 58480 on Oct 17, 2025.","status":"Texas Electric Cooperatives, Inc.","date":"2025-10-17","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58480&itemNumber=28","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58480: AEP TEXAS’ COMMENTS ON PROPOSAL FOR PUBLICATION","summary":"AEP TEXAS INC. filed AEP TEXAS’ COMMENTS ON PROPOSAL FOR PUBLICATION in PUCT Project 58480 on Oct 17, 2025.","status":"AEP TEXAS INC.","date":"2025-10-17","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58480&itemNumber=29","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58480: OPUC NOTICE OF PARTICIPATION LETTER","summary":"OPUC filed OPUC NOTICE OF PARTICIPATION LETTER in PUCT Project 58480 on Aug 11, 2025.","status":"OPUC","date":"2025-08-11","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58480&itemNumber=2","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58480: LCRA AND LCRA TSC COMMENTS","summary":"LOWER COLORADO RIVER AUTHORITY AND LCRA TRANSMISSION SERVICES CORPORATION filed LCRA AND LCRA TSC COMMENTS in PUCT Project 58480 on Oct 17, 2025.","status":"LOWER COLORADO RIVER AUTHORITY AND LCRA TRANSMISSION SERVICES CORPORATION","date":"2025-10-17","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58480&itemNumber=30","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58480: Comments from the City of Red Oak on SB6 Rule Making Project 58480","summary":"CITY OF RED OAK filed Comments from the City of Red Oak on SB6 Rule Making Project 58480 in PUCT Project 58480 on Oct 17, 2025.","status":"CITY OF RED OAK","date":"2025-10-17","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58480&itemNumber=31","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58480: ELECTRIC RELIABILITY COUNCIL OF TEXAS, INC.’S COMMENTS REGARDING PROPOSED 16 TAC § 25.370","summary":"ERCOT filed ELECTRIC RELIABILITY COUNCIL OF TEXAS, INC.’S COMMENTS REGARDING PROPOSED 16 TAC § 25.370 in PUCT Project 58480 on Oct 17, 2025.","status":"ERCOT","date":"2025-10-17","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58480&itemNumber=32","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58480: Texas-New Mexico Power Company’s Public Comments Regarding Staff’s Proposal for Publication of New 16 TAC § 25.370","summary":"TEXAS- NEW MEXICO POWER COMPANY filed Texas-New Mexico Power Company’s Public Comments Regarding Staff’s Proposal for Publication of New 16 TAC § 25.370 in PUCT Project 58480 on Oct 17, 2025.","status":"TEXAS- NEW MEXICO POWER COMPANY","date":"2025-10-17","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58480&itemNumber=33","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58480: Data Center Coalition's Comments","summary":"Data Center Coalition filed Data Center Coalition's Comments in PUCT Project 58480 on Oct 17, 2025.","status":"Data Center Coalition","date":"2025-10-17","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58480&itemNumber=35","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58480: Sharyland Utilities, L.L.C.'s Initial Comments on the Proposal for Publication of New 16 TAC § 25.370","summary":"SHARYLAND UTILITIES, L.L.C. filed Sharyland Utilities, L.L.C.'s Initial Comments on the Proposal for Publication of New 16 TAC § 25.370 in PUCT Project 58480 on Oct 17, 2025.","status":"SHARYLAND UTILITIES, L.L.C.","date":"2025-10-17","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58480&itemNumber=36","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58480: REPLY COMMENTS","summary":"AEP TEXAS INC. filed REPLY COMMENTS in PUCT Project 58480 on Oct 30, 2025.","status":"AEP TEXAS INC.","date":"2025-10-30","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58480&itemNumber=38","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58480: REPLY COMMENTS","summary":"CENTERPOINT ENERGY HOUSTON ELECTRIC, LLC filed REPLY COMMENTS in PUCT Project 58480 on Oct 31, 2025.","status":"CENTERPOINT ENERGY HOUSTON ELECTRIC, LLC","date":"2025-10-31","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58480&itemNumber=39","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58480: Staff Memo and Notice of 9/2 Workshop","summary":"PUC RULES & PROJECTS filed Staff Memo and Notice of 9/2 Workshop in PUCT Project 58480 on Aug 15, 2025.","status":"PUC RULES & PROJECTS","date":"2025-08-15","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58480&itemNumber=3","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58480: ONCOR ELECTRIC DELIVERY’S REPLY COMMENTS ON THE PROPOSAL FOR PUBLICATION OF NEW 16 TAC §25.370","summary":"ONCOR ELECTRIC DELIVERY COMPANY LLC filed ONCOR ELECTRIC DELIVERY’S REPLY COMMENTS ON THE PROPOSAL FOR PUBLICATION OF NEW 16 TAC §25.370 in PUCT Project 58480 on Oct 31, 2025.","status":"ONCOR ELECTRIC DELIVERY COMPANY LLC","date":"2025-10-31","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58480&itemNumber=40","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58480: TCPA REPLY COMMENTS TO THE PFP REGARDING LARGE LOAD FORECASTING CRITERIA","summary":"TCPA filed TCPA REPLY COMMENTS TO THE PFP REGARDING LARGE LOAD FORECASTING CRITERIA in PUCT Project 58480 on Oct 31, 2025.","status":"TCPA","date":"2025-10-31","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58480&itemNumber=42","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58480: Joint Reply Comments of Wind Energy Transmission Texas, LLC; Cross Texas Transmission, LLC; and Lone Start Transmission, LLC on the Proposal for Publication of New 16 TAC § 25.370","summary":"WIND ENERGY TRANSMISSION LLC filed Joint Reply Comments of Wind Energy Transmission Texas, LLC; Cross Texas Transmission, LLC; and Lone Start Transmission, LLC on the Proposal for Publication of New 16 TAC § 25.370 in PUCT Project 58480 on Oct 31, 2025.","status":"WIND ENERGY TRANSMISSION LLC","date":"2025-10-31","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58480&itemNumber=43","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58480: OCSC and TCAP's Reply Comments","summary":"STEERING COMMITTEE OF CITIES SERVED BY ONCOR AND TEXAS COALITION FOR AFFORDABLE POWER filed OCSC and TCAP's Reply Comments in PUCT Project 58480 on Oct 31, 2025.","status":"STEERING COMMITTEE OF CITIES SERVED BY ONCOR AND TEXAS COALITION FOR AFFORDABLE POWER","date":"2025-10-31","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58480&itemNumber=44","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58480: REPLY COMMENTS","summary":"LOWER COLORADO RIVER AUTHORITY AND LCRA TRANSMISSION SERVICES CORPORATION filed REPLY COMMENTS in PUCT Project 58480 on Oct 31, 2025.","status":"LOWER COLORADO RIVER AUTHORITY AND LCRA TRANSMISSION SERVICES CORPORATION","date":"2025-10-31","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58480&itemNumber=45","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58480: OPUC’S REPLY COMMENTS ON THE PROPOSAL FOR PUBLICATION OF NEW 16 TAC § 25.370","summary":"OPUC filed OPUC’S REPLY COMMENTS ON THE PROPOSAL FOR PUBLICATION OF NEW 16 TAC § 25.370 in PUCT Project 58480 on Oct 31, 2025.","status":"OPUC","date":"2025-10-31","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58480&itemNumber=48","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58480: CRUSOE ENERGY SYSTEMS LLC REPLY COMMENTS","summary":"CRUSOE ENERGY SYSTEMS LLC filed CRUSOE ENERGY SYSTEMS LLC REPLY COMMENTS in PUCT Project 58480 on Oct 31, 2025.","status":"CRUSOE ENERGY SYSTEMS LLC","date":"2025-10-31","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58480&itemNumber=49","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58480: Staff memo, workshop agenda, and discussion draft","summary":"PUC RULES & PROJECTS filed Staff memo, workshop agenda, and discussion draft in PUCT Project 58480 on Aug 25, 2025.","status":"PUC RULES & PROJECTS","date":"2025-08-25","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58480&itemNumber=4","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58480: ELECTRIC RELIABILITY COUNCIL OF TEXAS, INC.’S REPLY COMMENTS REGARDING PROPOSED 16 TAC § 25.370","summary":"ERCOT filed ELECTRIC RELIABILITY COUNCIL OF TEXAS, INC.’S REPLY COMMENTS REGARDING PROPOSED 16 TAC § 25.370 in PUCT Project 58480 on Oct 31, 2025.","status":"ERCOT","date":"2025-10-31","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58480&itemNumber=50","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58480: Eolian L.P.'s Reply Comments on Proposal for Publication","summary":"EOLIAN, L.P. filed Eolian L.P.'s Reply Comments on Proposal for Publication in PUCT Project 58480 on Oct 31, 2025.","status":"EOLIAN, L.P.","date":"2025-10-31","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58480&itemNumber=51","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58480: Data Center Coalition's Reply Comments","summary":"Data Center Coalition (DCC) filed Data Center Coalition's Reply Comments in PUCT Project 58480 on Oct 31, 2025.","status":"Data Center Coalition (DCC)","date":"2025-10-31","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58480&itemNumber=52","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58480: OM Item No. 10 - (Staff Recommendation) Order Adopting New §25.370","summary":"PUC RULES & PROJECTS filed OM Item No. 10 - (Staff Recommendation) Order Adopting New §25.370 in PUCT Project 58480 on Jan 22, 2026.","status":"PUC RULES & PROJECTS","date":"2026-01-22","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58480&itemNumber=53","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58480: ERCOT’S PROPOSED COMPLIANCE PLAN FOR INCLUDING LARGE LOADS IN THE LOAD FORECAST FOR THE 2026 REGIONAL TRANSMISSION PLAN","summary":"ERCOT filed ERCOT’S PROPOSED COMPLIANCE PLAN FOR INCLUDING LARGE LOADS IN THE LOAD FORECAST FOR THE 2026 REGIONAL TRANSMISSION PLAN in PUCT Project 58480 on Jan 22, 2026.","status":"ERCOT","date":"2026-01-22","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58480&itemNumber=54","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58480: COMMISSIONER HJALTMAN MEMORANDUM","summary":"PUC OPDM filed COMMISSIONER HJALTMAN MEMORANDUM in PUCT Project 58480 on Jan 28, 2026.","status":"PUC OPDM","date":"2026-01-28","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58480&itemNumber=56","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58480: OM Item No. 33 - Staff Memo with Proposed Redline Changes","summary":"PUC RULES & PROJECTS filed OM Item No. 33 - Staff Memo with Proposed Redline Changes in PUCT Project 58480 on Feb 4, 2026.","status":"PUC RULES & PROJECTS","date":"2026-02-04","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58480&itemNumber=57","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58480: ERCOT PRESENTATION ON SB 6 LOAD FORECASTING PROCESSES","summary":"ERCOT filed ERCOT PRESENTATION ON SB 6 LOAD FORECASTING PROCESSES in PUCT Project 58480 on Sep 2, 2025.","status":"ERCOT","date":"2025-09-02","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58480&itemNumber=5","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58480: OPUC’S INITIAL COMMENTS ON DISCUSSION DRAFT ATTACHMENT B TO COMMISSION STAFF’S MEMORANDUM ON RULEMAKING TO ESTABLISH LARGE LOAD FORECASTING CRITERIA","summary":"OPUC filed OPUC’S INITIAL COMMENTS ON DISCUSSION DRAFT ATTACHMENT B TO COMMISSION STAFF’S MEMORANDUM ON RULEMAKING TO ESTABLISH LARGE LOAD FORECASTING CRITERIA in PUCT Project 58480 on Sep 3, 2025.","status":"OPUC","date":"2025-09-03","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58480&itemNumber=6","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58480: OM Item No. 10 - Staff Memo & PFP w/Oct. 17 Comment Deadline","summary":"PUC RULES & PROJECTS filed OM Item No. 10 - Staff Memo & PFP w/Oct. 17 Comment Deadline in PUCT Project 58480 on Sep 12, 2025.","status":"PUC RULES & PROJECTS","date":"2025-09-12","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58480&itemNumber=7","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58480: PROPOSAL FOR PUBLICATION OF NEW 16 TAC §25.370","summary":"PUC OPDM filed PROPOSAL FOR PUBLICATION OF NEW 16 TAC §25.370 in PUCT Project 58480 on Sep 18, 2025.","status":"PUC OPDM","date":"2025-09-18","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58480&itemNumber=8","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58481: ORDER ADOPTING NEW 16 TAC §25.194","summary":"PUC OPDM filed ORDER ADOPTING NEW 16 TAC §25.194 in PUCT Project 58481 on Sep 18, 2026.","status":"PUC OPDM","date":"2026-09-18","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58481&itemNumber=218","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58479: SATOSHI ENERGY COMMENTS ON STAFF’S DRAFT DISCUSSION RULE § 25.205","summary":"SATOSHI ENERGY CORP. filed SATOSHI ENERGY COMMENTS ON STAFF’S DRAFT DISCUSSION RULE § 25.205 in PUCT Project 58479 on Sep 10, 2025.","status":"SATOSHI ENERGY CORP.","date":"2025-09-10","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58479&itemNumber=10","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58479: OM Item No. 9 - Staff Memo & PFP w/Oct. 17 Comment Deadline","summary":"PUC RULES & PROJECTS filed OM Item No. 9 - Staff Memo & PFP w/Oct. 17 Comment Deadline in PUCT Project 58479 on Sep 12, 2025.","status":"PUC RULES & PROJECTS","date":"2025-09-12","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58479&itemNumber=11","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58479: LETTER & PRESENTATION REGARDING ERCOT STUDIES OF PROPOSED NET METERING ARRANGEMENTS","summary":"ERCOT filed LETTER & PRESENTATION REGARDING ERCOT STUDIES OF PROPOSED NET METERING ARRANGEMENTS in PUCT Project 58479 on Sep 18, 2025.","status":"ERCOT","date":"2025-09-18","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58479&itemNumber=12","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58479: PROPOSAL FOR PUBLICATION OF NEW 16 TAC §25.205","summary":"PUC OPDM filed PROPOSAL FOR PUBLICATION OF NEW 16 TAC §25.205 in PUCT Project 58479 on Sep 18, 2025.","status":"PUC OPDM","date":"2025-09-18","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58479&itemNumber=13","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58479: ERCOT LETTER RE STAND-ALONE GENERATION RESOURCE LIST UPDATE","summary":"ERCOT filed ERCOT LETTER RE STAND-ALONE GENERATION RESOURCE LIST UPDATE in PUCT Project 58479 on Sep 19, 2025.","status":"ERCOT","date":"2025-09-19","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58479&itemNumber=15","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58479: SPLIGHT COMMENTS ON STAFF'S DRAFT DISCUSSION RULE § 25.205","summary":"Splight Inc. filed SPLIGHT COMMENTS ON STAFF'S DRAFT DISCUSSION RULE § 25.205 in PUCT Project 58479 on Oct 17, 2025.","status":"Splight Inc.","date":"2025-10-17","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58479&itemNumber=17","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58479: Request for Control Number","summary":"PUC RULES AND PROJECTS filed Request for Control Number in PUCT Project 58479 on Jul 31, 2025.","status":"PUC RULES AND PROJECTS","date":"2025-07-31","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58479&itemNumber=1","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58479: VOID SEE ITEM 35","summary":"TCPA filed VOID SEE ITEM 35 in PUCT Project 58479 on Oct 17, 2025.","status":"TCPA","date":"2025-10-17","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58479&itemNumber=20","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58479: Initial Comments of the Texas Advanced Energy Business Alliance on Commission Staff's Draft Rule §25.205","summary":"TEXAS ADVANCED ENERGY BUSINESS ALLIANCE filed Initial Comments of the Texas Advanced Energy Business Alliance on Commission Staff's Draft Rule §25.205 in PUCT Project 58479 on Oct 17, 2025.","status":"TEXAS ADVANCED ENERGY BUSINESS ALLIANCE","date":"2025-10-17","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58479&itemNumber=21","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58479: TEXAS INDUSTRIAL ENERGY CONSUMERS’ PROPOSED COMMENTS TO DRAFT RULE 25.504","summary":"TIEC filed TEXAS INDUSTRIAL ENERGY CONSUMERS’ PROPOSED COMMENTS TO DRAFT RULE 25.504 in PUCT Project 58479 on Oct 17, 2025.","status":"TIEC","date":"2025-10-17","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58479&itemNumber=22","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58479: SATOSHI'S COMMENTS ON STAFF'S PROPOSAL FOR PUBLICATION","summary":"SATOSHI ENERGY CORP. filed SATOSHI'S COMMENTS ON STAFF'S PROPOSAL FOR PUBLICATION in PUCT Project 58479 on Oct 17, 2025.","status":"SATOSHI ENERGY CORP.","date":"2025-10-17","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58479&itemNumber=23","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58479: EDGECONNEX COMMENTS ON COMMISSION STAFF'S DRAFT RULE 16 TAC § 25.205","summary":"EdgeConneX filed EDGECONNEX COMMENTS ON COMMISSION STAFF'S DRAFT RULE 16 TAC § 25.205 in PUCT Project 58479 on Oct 17, 2025.","status":"EdgeConneX","date":"2025-10-17","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58479&itemNumber=24","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58479: CALPINE CORPORATION’S COMMENTS ON COMMISSION STAFF’S PROPOSAL FOR PUBLICATION OF NEW 16 TAC § 25.205","summary":"CALPINE CORPORATION filed CALPINE CORPORATION’S COMMENTS ON COMMISSION STAFF’S PROPOSAL FOR PUBLICATION OF NEW 16 TAC § 25.205 in PUCT Project 58479 on Oct 17, 2025.","status":"CALPINE CORPORATION","date":"2025-10-17","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58479&itemNumber=25","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58479: ONCOR ELECTRIC DELIVERY’S COMMENTS ON THE PROPOSAL FOR PUBLICATION OF NEW 16 TAC §25.205 AND ACCOMPANYING QUESTIONS","summary":"ONCOR ELECTRIC DELIVERY COMPANY LLC filed ONCOR ELECTRIC DELIVERY’S COMMENTS ON THE PROPOSAL FOR PUBLICATION OF NEW 16 TAC §25.205 AND ACCOMPANYING QUESTIONS in PUCT Project 58479 on Oct 17, 2025.","status":"ONCOR ELECTRIC DELIVERY COMPANY LLC","date":"2025-10-17","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58479&itemNumber=26","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58479: OFFICE OF PUBLIC UTILITY COUNSEL’S INITIAL COMMENTS ON PROPOSAL FOR PUBLICATION OF NEW 16 TAC §25.205","summary":"OPUC filed OFFICE OF PUBLIC UTILITY COUNSEL’S INITIAL COMMENTS ON PROPOSAL FOR PUBLICATION OF NEW 16 TAC §25.205 in PUCT Project 58479 on Oct 17, 2025.","status":"OPUC","date":"2025-10-17","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58479&itemNumber=27","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58479: Comments of Texas Electric Cooperatives, Inc.","summary":"Texas Electric Cooperatives, Inc. filed Comments of Texas Electric Cooperatives, Inc. in PUCT Project 58479 on Oct 17, 2025.","status":"Texas Electric Cooperatives, Inc.","date":"2025-10-17","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58479&itemNumber=28","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58479: LCRA RESPONSE TO PFP","summary":"LOWER COLORADO RIVER AUTHORITY AND LCRA TRANSMISSION SERVICES CORPORATION filed LCRA RESPONSE TO PFP in PUCT Project 58479 on Oct 17, 2025.","status":"LOWER COLORADO RIVER AUTHORITY AND LCRA TRANSMISSION SERVICES CORPORATION","date":"2025-10-17","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58479&itemNumber=29","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58479: OPUC NOTICE OF PARTICIPATION LETTER","summary":"OPUC filed OPUC NOTICE OF PARTICIPATION LETTER in PUCT Project 58479 on Aug 8, 2025.","status":"OPUC","date":"2025-08-08","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58479&itemNumber=2","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58479: Vistra Corp.'s Comments","summary":"VISTRA CORP. filed Vistra Corp.'s Comments in PUCT Project 58479 on Oct 17, 2025.","status":"VISTRA CORP.","date":"2025-10-17","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58479&itemNumber=30","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58479: CORRECTION: RESPONSE TO STAFF QUESTIONS & RECOMMENDATIONS FOR PFP","summary":"TCPA filed CORRECTION: RESPONSE TO STAFF QUESTIONS & RECOMMENDATIONS FOR PFP in PUCT Project 58479 on Oct 17, 2025.","status":"TCPA","date":"2025-10-17","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58479&itemNumber=31","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58479: COMMENTS ON PROPOSAL FOR PUBLICATION OF NEW 16 TAC § 25.505","summary":"ELECTRIC TRANSMISSION TEXAS, LLC filed COMMENTS ON PROPOSAL FOR PUBLICATION OF NEW 16 TAC § 25.505 in PUCT Project 58479 on Oct 17, 2025.","status":"ELECTRIC TRANSMISSION TEXAS, LLC","date":"2025-10-17","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58479&itemNumber=32","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58479: COMMENTS OF CENTERPOINT ENERGY HOUSTON ELECTRIC, LLC","summary":"CENTERPOINT ENERGY HOUSTON ELECTRIC filed COMMENTS OF CENTERPOINT ENERGY HOUSTON ELECTRIC, LLC in PUCT Project 58479 on Oct 17, 2025.","status":"CENTERPOINT ENERGY HOUSTON ELECTRIC","date":"2025-10-17","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58479&itemNumber=33","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58479: AEP TEXAS’ COMMENTS ON PROPOSAL FOR PUBLICATION","summary":"AEP TEXAS INC. filed AEP TEXAS’ COMMENTS ON PROPOSAL FOR PUBLICATION in PUCT Project 58479 on Oct 17, 2025.","status":"AEP TEXAS INC.","date":"2025-10-17","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58479&itemNumber=34","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58479: REQUEST TO VOID ITEM 20, FILED IN ERROR","summary":"TCPA filed REQUEST TO VOID ITEM 20, FILED IN ERROR in PUCT Project 58479 on Oct 17, 2025.","status":"TCPA","date":"2025-10-17","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58479&itemNumber=35","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58479: ELECTRIC RELIABILITY COUNCIL OF TEXAS, INC.’S RESPONSES TO COMMISSION QUESTIONS AND COMMENTS REGARDING PROPOSED 16 TAC § 25.205","summary":"ERCOT filed ELECTRIC RELIABILITY COUNCIL OF TEXAS, INC.’S RESPONSES TO COMMISSION QUESTIONS AND COMMENTS REGARDING PROPOSED 16 TAC § 25.205 in PUCT Project 58479 on Oct 17, 2025.","status":"ERCOT","date":"2025-10-17","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58479&itemNumber=36","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58479: Eolian, L.P.'s Comments on the Proposal for Publication and Request for Hearing","summary":"EOLIAN, L.P. filed Eolian, L.P.'s Comments on the Proposal for Publication and Request for Hearing in PUCT Project 58479 on Oct 17, 2025.","status":"EOLIAN, L.P.","date":"2025-10-17","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58479&itemNumber=37","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58479: Data Center Coalition's Comments","summary":"Data Center Coalition filed Data Center Coalition's Comments in PUCT Project 58479 on Oct 17, 2025.","status":"Data Center Coalition","date":"2025-10-17","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58479&itemNumber=38","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58479: Texas-New Mexico Power Company’s Comments to Commission Staff’s Questions and Comments on Proposal For Publication","summary":"TEXAS- NEW MEXICO POWER COMPANY filed Texas-New Mexico Power Company’s Comments to Commission Staff’s Questions and Comments on Proposal For Publication in PUCT Project 58479 on Oct 17, 2025.","status":"TEXAS- NEW MEXICO POWER COMPANY","date":"2025-10-17","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58479&itemNumber=39","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58479: Staff Memo and Notice of 9/2 Workshop","summary":"PUC RULES & PROJECTS filed Staff Memo and Notice of 9/2 Workshop in PUCT Project 58479 on Aug 15, 2025.","status":"PUC RULES & PROJECTS","date":"2025-08-15","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58479&itemNumber=3","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58479: TCPA Reply Comments","summary":"TCPA filed TCPA Reply Comments in PUCT Project 58479 on Oct 31, 2025.","status":"TCPA","date":"2025-10-31","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58479&itemNumber=42","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58479: REPLY COMMENTS OF CENTERPOINT ENERGY HOUSTON ELECTRIC, LLC","summary":"CENTERPOINT ENERGY HOUSTON ELECTRIC filed REPLY COMMENTS OF CENTERPOINT ENERGY HOUSTON ELECTRIC, LLC in PUCT Project 58479 on Oct 31, 2025.","status":"CENTERPOINT ENERGY HOUSTON ELECTRIC","date":"2025-10-31","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58479&itemNumber=45","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58479: ONCOR ELECTRIC DELIVERY’S REPLY COMMENTS ON THE PROPOSAL FOR PUBLICATION OF NEW 16 TAC §25.205 AND ACCOMPANYING QUESTIONS","summary":"ONCOR ELECTRIC DELIVERY COMPANY LLC filed ONCOR ELECTRIC DELIVERY’S REPLY COMMENTS ON THE PROPOSAL FOR PUBLICATION OF NEW 16 TAC §25.205 AND ACCOMPANYING QUESTIONS in PUCT Project 58479 on Oct 31, 2025.","status":"ONCOR ELECTRIC DELIVERY COMPANY LLC","date":"2025-10-31","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58479&itemNumber=46","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58479: Vistra Reply Comments","summary":"VISTRA CORP. filed Vistra Reply Comments in PUCT Project 58479 on Oct 31, 2025.","status":"VISTRA CORP.","date":"2025-10-31","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58479&itemNumber=47","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58479: Comments of Texas Electric Cooperatives, Inc.","summary":"TEXAS ELECTRIC COOPERATIVES, INC. filed Comments of Texas Electric Cooperatives, Inc. in PUCT Project 58479 on Oct 31, 2025.","status":"TEXAS ELECTRIC COOPERATIVES, INC.","date":"2025-10-31","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58479&itemNumber=49","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58479: Staff memo, workshop agenda, and discussion draft","summary":"PUC RULES & PROJECTS filed Staff memo, workshop agenda, and discussion draft in PUCT Project 58479 on Aug 25, 2025.","status":"PUC RULES & PROJECTS","date":"2025-08-25","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58479&itemNumber=4","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58479: CALPINE CORPORATION’S REPLY COMMENTS ON COMMISSION STAFF’S PROPOSAL FOR PUBLICATION OF NEW 16 TAC § 25.205","summary":"CALPINE CORPORATION filed CALPINE CORPORATION’S REPLY COMMENTS ON COMMISSION STAFF’S PROPOSAL FOR PUBLICATION OF NEW 16 TAC § 25.205 in PUCT Project 58479 on Oct 31, 2025.","status":"CALPINE CORPORATION","date":"2025-10-31","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58479&itemNumber=52","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58479: CRUSOE ENERGY SYSTEMS LLC REPLY COMMENTS","summary":"CRUSOE ENERGY SYSTEMS LLC filed CRUSOE ENERGY SYSTEMS LLC REPLY COMMENTS in PUCT Project 58479 on Oct 31, 2025.","status":"CRUSOE ENERGY SYSTEMS LLC","date":"2025-10-31","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58479&itemNumber=54","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58479: ELECTRIC RELIABILITY COUNCIL OF TEXAS, INC.’S REPLY COMMENTS REGARDING PROPOSED 16 TAC § 25.205","summary":"ERCOT filed ELECTRIC RELIABILITY COUNCIL OF TEXAS, INC.’S REPLY COMMENTS REGARDING PROPOSED 16 TAC § 25.205 in PUCT Project 58479 on Oct 31, 2025.","status":"ERCOT","date":"2025-10-31","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58479&itemNumber=55","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58479: Texas-New Mexico Power Company’s Reply Comments Regarding Proposal for Publication","summary":"TEXAS NEW MEXICO POWER COMPANY filed Texas-New Mexico Power Company’s Reply Comments Regarding Proposal for Publication in PUCT Project 58479 on Oct 31, 2025.","status":"TEXAS NEW MEXICO POWER COMPANY","date":"2025-10-31","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58479&itemNumber=56","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58479: OPUC’S REPLY COMMENTS ON PROPOSAL FOR PUBLICATION OF NEW 16 TAC §25.205","summary":"OPUC filed OPUC’S REPLY COMMENTS ON PROPOSAL FOR PUBLICATION OF NEW 16 TAC §25.205 in PUCT Project 58479 on Oct 31, 2025.","status":"OPUC","date":"2025-10-31","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58479&itemNumber=57","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58479: ENCHANTED ROCK, LLC REPLY COMMENTS ON PROPOSAL FOR PUBLICATION OF NEW 16 TAC §25.205","summary":"ENCHANTED ROCK, LLC filed ENCHANTED ROCK, LLC REPLY COMMENTS ON PROPOSAL FOR PUBLICATION OF NEW 16 TAC §25.205 in PUCT Project 58479 on Oct 31, 2025.","status":"ENCHANTED ROCK, LLC","date":"2025-10-31","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58479&itemNumber=58","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58479: Eolian's Reply Comments on Proposal for Publication","summary":"EOLIAN, L.P. filed Eolian's Reply Comments on Proposal for Publication in PUCT Project 58479 on Oct 31, 2025.","status":"EOLIAN, L.P.","date":"2025-10-31","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58479&itemNumber=59","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58479: ERCOT LETTER RE NET METERING STUDY DETAILS","summary":"ERCOT filed ERCOT LETTER RE NET METERING STUDY DETAILS in PUCT Project 58479 on Sep 2, 2025.","status":"ERCOT","date":"2025-09-02","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58479&itemNumber=5","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58479: Data Center Coalition's Reply Comments","summary":"Data Center Coalition (DCC) filed Data Center Coalition's Reply Comments in PUCT Project 58479 on Oct 31, 2025.","status":"Data Center Coalition (DCC)","date":"2025-10-31","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58479&itemNumber=60","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58479: OM Item No. 26 - (Staff Recommendation) Order Adopting New §25.205","summary":"PUC RULES & PROJECTS filed OM Item No. 26 - (Staff Recommendation) Order Adopting New §25.205 in PUCT Project 58479 on Feb 13, 2026.","status":"PUC RULES & PROJECTS","date":"2026-02-13","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58479&itemNumber=62","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58479: OM Item No. 43 - Staff Memo with Proposed Redline Changes","summary":"PUC RULES & PROJECTS filed OM Item No. 43 - Staff Memo with Proposed Redline Changes in PUCT Project 58479 on Mar 5, 2026.","status":"PUC RULES & PROJECTS","date":"2026-03-05","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58479&itemNumber=63","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58479: CHAIRMAN GLEESON MEMORANDUM","summary":"PUC OPDM filed CHAIRMAN GLEESON MEMORANDUM in PUCT Project 58479 on Mar 11, 2026.","status":"PUC OPDM","date":"2026-03-11","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58479&itemNumber=64","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58479: Vistra Corp.'s Comments on Planning Guide Revision Request 145","summary":"VISTRA CORP. filed Vistra Corp.'s Comments on Planning Guide Revision Request 145 in PUCT Project 58479 on Mar 20, 2026.","status":"VISTRA CORP.","date":"2026-03-20","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58479&itemNumber=65","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58479: ORDER ADOPTING NEW 16 TAC §25.205","summary":"PUC OPDM filed ORDER ADOPTING NEW 16 TAC §25.205 in PUCT Project 58479 on Mar 26, 2026.","status":"PUC OPDM","date":"2026-03-26","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58479&itemNumber=66","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58479: Texas Register Acknowledgement of Receipt-Proposal for Adoption","summary":"RULES & PROJECTS filed Texas Register Acknowledgement of Receipt-Proposal for Adoption in PUCT Project 58479 on Mar 26, 2026.","status":"RULES & PROJECTS","date":"2026-03-26","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58479&itemNumber=67","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58479: ERCOT PRESENTATION ON SB6 NET METERING ARRANGEMENT REVIEW PROCESS","summary":"ERCOT filed ERCOT PRESENTATION ON SB6 NET METERING ARRANGEMENT REVIEW PROCESS in PUCT Project 58479 on Sep 2, 2025.","status":"ERCOT","date":"2025-09-02","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58479&itemNumber=6","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58479: ONCOR'S COMMENTS ON STRANDED/UNDERUTILIZED ASSET COST TREATMENT","summary":"ONCOR ELECTRIC DELIVERY COMPANY LLC filed ONCOR'S COMMENTS ON STRANDED/UNDERUTILIZED ASSET COST TREATMENT in PUCT Project 58479 on Sep 4, 2025.","status":"ONCOR ELECTRIC DELIVERY COMPANY LLC","date":"2025-09-04","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58479&itemNumber=7","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58479: OPUC’S INITIAL COMMENTS ON DISCUSSION DRAFT ATTACHMENT B TO COMMISSION STAFF’S MEMORANDUM ON RULEMAKING FOR NET METERING ARRANGEMENTS INVOLVING A LARGE LOAD CO-LOCATED WITH AN EXISTING GENERATION RESOURCE","summary":"OPUC filed OPUC’S INITIAL COMMENTS ON DISCUSSION DRAFT ATTACHMENT B TO COMMISSION STAFF’S MEMORANDUM ON RULEMAKING FOR NET METERING ARRANGEMENTS INVOLVING A LARGE LOAD CO-LOCATED WITH AN EXISTING GENERATION RESOURCE in PUCT Project 58479 on Sep 4, 2025.","status":"OPUC","date":"2025-09-04","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58479&itemNumber=8","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58479: Crusoe's Comments on Staff's Draft Discussion Rule § 25.205","summary":"Crusoe Energy Systems, Inc. filed Crusoe's Comments on Staff's Draft Discussion Rule § 25.205 in PUCT Project 58479 on Sep 5, 2025.","status":"Crusoe Energy Systems, Inc.","date":"2025-09-05","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58479&itemNumber=9","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58480: ORDER ADOPTING NEW 16 TAC § 25.370","summary":"PUC OPDM filed ORDER ADOPTING NEW 16 TAC § 25.370 in PUCT Project 58480 on Feb 6, 2026.","status":"PUC OPDM","date":"2026-02-06","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58480&itemNumber=58","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58480: Texas Register Acknowledgement of Receipt-Proposal for Adoption","summary":"PUC RULES & PROJECTS filed Texas Register Acknowledgement of Receipt-Proposal for Adoption in PUCT Project 58480 on Feb 9, 2026.","status":"PUC RULES & PROJECTS","date":"2026-02-09","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58480&itemNumber=59","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58482: Request for Control Number","summary":"PUC RULES AND PROJECTS filed Request for Control Number in PUCT Project 58482 on Aug 1, 2025.","status":"PUC RULES AND PROJECTS","date":"2025-08-01","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58482&itemNumber=1","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58482: Staff Memo_Restyle Request","summary":"PUC RULES & PROJECTS filed Staff Memo_Restyle Request in PUCT Project 58482 on Mar 23, 2026.","status":"PUC RULES & PROJECTS","date":"2026-03-23","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58482&itemNumber=2","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58482: Staff Memo and Questions for Comment w/April 8 Deadline","summary":"PUC RULES & PROJECTS filed Staff Memo and Questions for Comment w/April 8 Deadline in PUCT Project 58482 on Mar 23, 2026.","status":"PUC RULES & PROJECTS","date":"2026-03-23","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58482&itemNumber=3","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58482: OPUC NOTICE OF PARTICIPATION LETTER","summary":"OPUC filed OPUC NOTICE OF PARTICIPATION LETTER in PUCT Project 58482 on Mar 24, 2026.","status":"OPUC","date":"2026-03-24","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58482&itemNumber=4","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58482: DCC Comments Regarding the Large Load Demand Management Service","summary":"Data Center Coalition filed DCC Comments Regarding the Large Load Demand Management Service in PUCT Project 58482 on Apr 8, 2026.","status":"Data Center Coalition","date":"2026-04-08","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58482&itemNumber=10","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58482: RESPONSE TO QUESTIONS FOR COMMENT","summary":"LOWER COLORADO RIVER AUTHORITY filed RESPONSE TO QUESTIONS FOR COMMENT in PUCT Project 58482 on Apr 8, 2026.","status":"LOWER COLORADO RIVER AUTHORITY","date":"2026-04-08","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58482&itemNumber=11","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58482: RESPONSES OF TEXAS ELECTRIC COOPERATIVES, INC.","summary":"TEXAS ELECTRIC COOPERATIVES, INC. filed RESPONSES OF TEXAS ELECTRIC COOPERATIVES, INC. in PUCT Project 58482 on Apr 8, 2026.","status":"TEXAS ELECTRIC COOPERATIVES, INC.","date":"2026-04-08","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58482&itemNumber=13","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58482: NRG Energy, Inc.'s Comments in Response to Staff's Questions","summary":"NRG ENERGY, INC. filed NRG Energy, Inc.'s Comments in Response to Staff's Questions in PUCT Project 58482 on Apr 8, 2026.","status":"NRG ENERGY, INC.","date":"2026-04-08","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58482&itemNumber=14","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58482: VOLTUS RESPONSE TO PUCT STAFF'S QUESTIONS ON PROPOSED LARGE LOAD DEMAND MANAGEMENT SERVICE","summary":"Voltus Inc. filed VOLTUS RESPONSE TO PUCT STAFF'S QUESTIONS ON PROPOSED LARGE LOAD DEMAND MANAGEMENT SERVICE in PUCT Project 58482 on Apr 8, 2026.","status":"Voltus Inc.","date":"2026-04-08","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58482&itemNumber=15","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58482: Texas Energy Buyers Alliance Response to Commission Staff Questions","summary":"TEXAS ENERGY BUYERS ALLIANCE filed Texas Energy Buyers Alliance Response to Commission Staff Questions in PUCT Project 58482 on Apr 8, 2026.","status":"TEXAS ENERGY BUYERS ALLIANCE","date":"2026-04-08","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58482&itemNumber=16","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58482: ONCOR ELECTRIC DELIVERY’S RESPONSE TO COMMISSION STAFF’S FIRST SET OF QUESTIONS FOR COMMENTS","summary":"ONCOR ELECTRIC DELIVERY COMPANY LLC filed ONCOR ELECTRIC DELIVERY’S RESPONSE TO COMMISSION STAFF’S FIRST SET OF QUESTIONS FOR COMMENTS in PUCT Project 58482 on Apr 8, 2026.","status":"ONCOR ELECTRIC DELIVERY COMPANY LLC","date":"2026-04-08","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58482&itemNumber=18","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58482: Enchanted Rock, LLC's Comments to Commission Staff's March 23 Memo and Questions for Comment","summary":"ENCHANTED ROCK, LLC filed Enchanted Rock, LLC's Comments to Commission Staff's March 23 Memo and Questions for Comment in PUCT Project 58482 on Apr 8, 2026.","status":"ENCHANTED ROCK, LLC","date":"2026-04-08","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58482&itemNumber=20","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58482: AEP Texas Inc.’s Responses to Commission Staff’s Memo and Questions for Comment","summary":"AEP TEXAS INC. filed AEP Texas Inc.’s Responses to Commission Staff’s Memo and Questions for Comment in PUCT Project 58482 on Apr 8, 2026.","status":"AEP TEXAS INC.","date":"2026-04-08","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58482&itemNumber=21","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58482: ELECTRIC RELIABILITY COUNCIL OF TEXAS, INC.’S RESPONSE TO COMMISSION STAFF’S LIST OF QUESTIONS","summary":"ERCOT filed ELECTRIC RELIABILITY COUNCIL OF TEXAS, INC.’S RESPONSE TO COMMISSION STAFF’S LIST OF QUESTIONS in PUCT Project 58482 on Apr 8, 2026.","status":"ERCOT","date":"2026-04-08","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58482&itemNumber=22","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58482: Vistra Corporate Services Company's Comments in Response to Commission Staff's Questions","summary":"VISTRA CORPORATE SERVICES COMPANY filed Vistra Corporate Services Company's Comments in Response to Commission Staff's Questions in PUCT Project 58482 on Apr 8, 2026.","status":"VISTRA CORPORATE SERVICES COMPANY","date":"2026-04-08","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58482&itemNumber=23","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58482: EOLIAN, L.P.'s Comments to Commission Staff's March 23, 2026 Memo and Questions for Comment","summary":"EOLIAN, L.P. filed EOLIAN, L.P.'s Comments to Commission Staff's March 23, 2026 Memo and Questions for Comment in PUCT Project 58482 on Apr 8, 2026.","status":"EOLIAN, L.P.","date":"2026-04-08","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58482&itemNumber=24","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58482: CyrusOne, LP Comments in Response to Commission Staff's Questions","summary":"CyrusOne, LP filed CyrusOne, LP Comments in Response to Commission Staff's Questions in PUCT Project 58482 on Apr 8, 2026.","status":"CyrusOne, LP","date":"2026-04-08","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58482&itemNumber=25","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58482: Public Comments in Response to Staff's Questions for Comment - Project No. 58482","summary":"Fedor Mikheev | Texas A&M University Energy Institute filed Public Comments in Response to Staff's Questions for Comment - Project No. 58482 in PUCT Project 58482 on Jul 16, 2026.","status":"Fedor Mikheev | Texas A&M University Energy Institute","date":"2026-07-16","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58482&itemNumber=28","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58482: OM Item No. 29 - Staff Memo & PFP w/Sept. 4 Comment Deadline","summary":"PUC RULES & PROJECTS filed OM Item No. 29 - Staff Memo & PFP w/Sept. 4 Comment Deadline in PUCT Project 58482 on Jul 24, 2026.","status":"PUC RULES & PROJECTS","date":"2026-07-24","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58482&itemNumber=29","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58482: PROPOSAL FOR PUBLICATION NEW §25.521","summary":"PUC OPDM filed PROPOSAL FOR PUBLICATION NEW §25.521 in PUCT Project 58482 on Jul 30, 2026.","status":"PUC OPDM","date":"2026-07-30","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58482&itemNumber=30","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58482: Texas Register Acknowledgement of Receipt - Comment Deadline 09/04/2026","summary":"RULES & PROJECTS filed Texas Register Acknowledgement of Receipt - Comment Deadline 09/04/2026 in PUCT Project 58482 on Jul 30, 2026.","status":"RULES & PROJECTS","date":"2026-07-30","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58482&itemNumber=31","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58482: Objection to rule change","summary":"Helen Bryant filed Objection to rule change in PUCT Project 58482 on Aug 3, 2026.","status":"Helen Bryant","date":"2026-08-03","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58482&itemNumber=33","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58482: ERCOT Steel Mills Comments_Project 58482_4.8.2026","summary":"ERCOT STEEL MILLS filed ERCOT Steel Mills Comments_Project 58482_4.8.2026 in PUCT Project 58482 on Apr 8, 2026.","status":"ERCOT STEEL MILLS","date":"2026-04-08","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58482&itemNumber=6","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58482: TCPA’S RESPONSES TO STAFF’S QUESTIONS REGARDING THE LARGE LOAD DEMAND MANAGEMENT SERVICE","summary":"TCPA filed TCPA’S RESPONSES TO STAFF’S QUESTIONS REGARDING THE LARGE LOAD DEMAND MANAGEMENT SERVICE in PUCT Project 58482 on Apr 8, 2026.","status":"TCPA","date":"2026-04-08","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58482&itemNumber=7","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58482: Texas Public Power Association (TPPA) Response to Questions for Comment","summary":"TPPA filed Texas Public Power Association (TPPA) Response to Questions for Comment in PUCT Project 58482 on Apr 8, 2026.","status":"TPPA","date":"2026-04-08","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58482&itemNumber=9","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58484: CPS Energy's Response to Questions for Comment","summary":"CPS ENERGY filed CPS Energy's Response to Questions for Comment in PUCT Project 58484 on Sep 9, 2025.","status":"CPS ENERGY","date":"2025-09-09","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58484&itemNumber=10","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58484: TCPA Response to Staff Questions","summary":"TCPA filed TCPA Response to Staff Questions in PUCT Project 58484 on Sep 9, 2025.","status":"TCPA","date":"2025-09-09","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58484&itemNumber=11","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58484: Texas Public Policy Foundation's Response to PUC Staff Questions for Comment","summary":"Texas Public Policy Foundation filed Texas Public Policy Foundation's Response to PUC Staff Questions for Comment in PUCT Project 58484 on Sep 9, 2025.","status":"Texas Public Policy Foundation","date":"2025-09-09","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58484&itemNumber=12","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58484: Sharyland Utilities LLC's Initial Comments to Commission Staff's Questions for Comment","summary":"SHARYLAND UTILITIES LLC filed Sharyland Utilities LLC's Initial Comments to Commission Staff's Questions for Comment in PUCT Project 58484 on Sep 9, 2025.","status":"SHARYLAND UTILITIES LLC","date":"2025-09-09","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58484&itemNumber=13","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58484: Comments of NRG Energy, Inc. in Response to Staff's August 5, 2025, Questions","summary":"NRG ENERGY, INC. filed Comments of NRG Energy, Inc. in Response to Staff's August 5, 2025, Questions in PUCT Project 58484 on Sep 9, 2025.","status":"NRG ENERGY, INC.","date":"2025-09-09","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58484&itemNumber=14","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58484: TEXAS ADVANCED ENERGY BUSINESS ALLIANCE RESPONSES TO COMMISSION STAFF QUESTIONS AUG. 5 2025","summary":"TEXAS ADVANCED ENERGY BUSINESS ALLIANCE filed TEXAS ADVANCED ENERGY BUSINESS ALLIANCE RESPONSES TO COMMISSION STAFF QUESTIONS AUG. 5 2025 in PUCT Project 58484 on Sep 9, 2025.","status":"TEXAS ADVANCED ENERGY BUSINESS ALLIANCE","date":"2025-09-09","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58484&itemNumber=17","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58484: Texas Public Power Association (TPPA) Comments on Transmission Cost Recovery Questions for Comment","summary":"TPPA filed Texas Public Power Association (TPPA) Comments on Transmission Cost Recovery Questions for Comment in PUCT Project 58484 on Sep 9, 2025.","status":"TPPA","date":"2025-09-09","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58484&itemNumber=18","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58484: LCRA AND LCRA TRANSMISSION SERVICES CORPORATION'S RESPONSE TO QUESTIONS FOR COMMENT","summary":"LCRA AND LCRA TRANSMISSION SERVICES CORPORATION filed LCRA AND LCRA TRANSMISSION SERVICES CORPORATION'S RESPONSE TO QUESTIONS FOR COMMENT in PUCT Project 58484 on Sep 9, 2025.","status":"LCRA AND LCRA TRANSMISSION SERVICES CORPORATION","date":"2025-09-09","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58484&itemNumber=19","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58484: Request for Control Number","summary":"PUC RULES & PROJECTS filed Request for Control Number in PUCT Project 58484 on Aug 1, 2025.","status":"PUC RULES & PROJECTS","date":"2025-08-01","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58484&itemNumber=1","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58484: Joint Comments of Wind Energy Transmission Texas, LLC; Lone Star Transmission Texas, LLC; and Cross Texas Transmission, LLC in Response to Commission Staff’s Request for Comments","summary":"Wind Energy Transmission Texas, LLC; Lone Star Transmission Texas, LLC; and Cross Texas Transmission, LLC filed Joint Comments of Wind Energy Transmission Texas, LLC; Lone Star Transmission Texas, LLC; and Cross Texas Transmission, LLC in Response to Commission Staff’s Request for Comments in PUCT Project 58484 on Sep 9, 2025.","status":"Wind Energy Transmission Texas, LLC; Lone Star Transmission Texas, LLC; and Cross Texas Transmission, LLC","date":"2025-09-09","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58484&itemNumber=20","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58484: AEP COMPANIES’ COMMENTS ON QUESTIONS FOR PUBLIC COMMENT","summary":"AEP COMPANIES filed AEP COMPANIES’ COMMENTS ON QUESTIONS FOR PUBLIC COMMENT in PUCT Project 58484 on Sep 9, 2025.","status":"AEP COMPANIES","date":"2025-09-09","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58484&itemNumber=21","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58484: OPUC’S INITIAL COMMENTS ON QUESTIONS FOR PUBLIC COMMENT RELATING TO THE EVALUATION OF TRANSMISSION COST RECOVERY","summary":"OPUC filed OPUC’S INITIAL COMMENTS ON QUESTIONS FOR PUBLIC COMMENT RELATING TO THE EVALUATION OF TRANSMISSION COST RECOVERY in PUCT Project 58484 on Sep 9, 2025.","status":"OPUC","date":"2025-09-09","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58484&itemNumber=23","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58484: ELECTRIC RELIABILITY COUNCIL OF TEXAS, INC.’S RESPONSES TO STAFF QUESTIONS","summary":"ERCOT filed ELECTRIC RELIABILITY COUNCIL OF TEXAS, INC.’S RESPONSES TO STAFF QUESTIONS in PUCT Project 58484 on Sep 9, 2025.","status":"ERCOT","date":"2025-09-09","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58484&itemNumber=24","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58484: CenterPoint Energy Houston Electric, LLC’s Responses to Commission Staff’s Request for Comments","summary":"CENTERPOINT ENERGY HOUSTON ELECTRIC filed CenterPoint Energy Houston Electric, LLC’s Responses to Commission Staff’s Request for Comments in PUCT Project 58484 on Sep 9, 2025.","status":"CENTERPOINT ENERGY HOUSTON ELECTRIC","date":"2025-09-09","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58484&itemNumber=26","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58484: Staff Memo and First Set of Questions for Comment","summary":"PUC RULES & PROJECTS filed Staff Memo and First Set of Questions for Comment in PUCT Project 58484 on Aug 5, 2025.","status":"PUC RULES & PROJECTS","date":"2025-08-05","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58484&itemNumber=2","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58484: OPUC NOTICE OF PARTICIPATION LETTER","summary":"OPUC filed OPUC NOTICE OF PARTICIPATION LETTER in PUCT Project 58484 on Aug 8, 2025.","status":"OPUC","date":"2025-08-08","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58484&itemNumber=3","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58484: ONCOR ELECTRIC DELIVERY'S RESPONSE TO COMMISSION STAFF'S FIRST SET OF QUESTIONS FOR COMMENTS","summary":"ONCOR ELECTRIC DELIVERY COMPANY LLC filed ONCOR ELECTRIC DELIVERY'S RESPONSE TO COMMISSION STAFF'S FIRST SET OF QUESTIONS FOR COMMENTS in PUCT Project 58484 on Sep 9, 2025.","status":"ONCOR ELECTRIC DELIVERY COMPANY LLC","date":"2025-09-09","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58484&itemNumber=5","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58484: ERCOT Steel Mills' Response to PUC Staff's Initial Request for Comments on Transmission Cost Recovery","summary":"ERCOT STEEL MILLS filed ERCOT Steel Mills' Response to PUC Staff's Initial Request for Comments on Transmission Cost Recovery in PUCT Project 58484 on Sep 9, 2025.","status":"ERCOT STEEL MILLS","date":"2025-09-09","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58484&itemNumber=6","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58484: RESPONSES OF TEXAS ELECTRIC COOPERATIVES, INC.","summary":"TEXAS ELECTRIC COOPERATIVES, INC. filed RESPONSES OF TEXAS ELECTRIC COOPERATIVES, INC. in PUCT Project 58484 on Sep 9, 2025.","status":"TEXAS ELECTRIC COOPERATIVES, INC.","date":"2025-09-09","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58484&itemNumber=7","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58484: Joint Responses to Staff Questions of H-E-B and STEC","summary":"H-E-B, LP and South Texas Electric Cooperative, Inc. filed Joint Responses to Staff Questions of H-E-B and STEC in PUCT Project 58484 on Sep 9, 2025.","status":"H-E-B, LP and South Texas Electric Cooperative, Inc.","date":"2025-09-09","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58484&itemNumber=8","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58484: Steering Committee of Cities Served by Oncor and Texas Coalition for Affordable Power's Responses to Commission Staff's First Set of Questions for Comment","summary":"STEERING COMMITTEE OF CITIES SERVED BY ONCOR AND TEXAS COALITION FOR AFFORDABLE POWER filed Steering Committee of Cities Served by Oncor and Texas Coalition for Affordable Power's Responses to Commission Staff's First Set of Questions for Comment in PUCT Project 58484 on Sep 9, 2025.","status":"STEERING COMMITTEE OF CITIES SERVED BY ONCOR AND TEXAS COALITION FOR AFFORDABLE POWER","date":"2025-09-09","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58484&itemNumber=9","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 54445: NOTICE OF RECOMMENDED APPROVAL OF REVISION REQUESTS BY ERCOT BOARD OF DIRECTORS","summary":"ERCOT filed NOTICE OF RECOMMENDED APPROVAL OF REVISION REQUESTS BY ERCOT BOARD OF DIRECTORS in PUCT Project 54445 on Sep 21, 2026.","status":"ERCOT","date":"2026-09-21","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=54445&itemNumber=164","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58484: Texas REP Coalition Response to PUC Staff Request for Comments","summary":"TEXAS REP COALITION filed Texas REP Coalition Response to PUC Staff Request for Comments in PUCT Project 58484 on Apr 13, 2026.","status":"TEXAS REP COALITION","date":"2026-04-13","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58484&itemNumber=100","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58484: RWE Americas, LLC's Comments to Commission Staff's Draft Recommendations","summary":"RWE Americas, LLC filed RWE Americas, LLC's Comments to Commission Staff's Draft Recommendations in PUCT Project 58484 on Apr 13, 2026.","status":"RWE Americas, LLC","date":"2026-04-13","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58484&itemNumber=102","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58484: Vistra's Third Set of Comments in Response to Staff's Second Set of Questions","summary":"VISTRA CORPORATE SERVICES COMPANY filed Vistra's Third Set of Comments in Response to Staff's Second Set of Questions in PUCT Project 58484 on Apr 13, 2026.","status":"VISTRA CORPORATE SERVICES COMPANY","date":"2026-04-13","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58484&itemNumber=103","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58484: ONCOR ELECTRIC DELIVERY'S COMMENTS ON COMMISSION STAFF'S DRAFT SET OF RECOMMENDATIONS","summary":"ONCOR ELECTRIC DELIVERY COMPANY LLC filed ONCOR ELECTRIC DELIVERY'S COMMENTS ON COMMISSION STAFF'S DRAFT SET OF RECOMMENDATIONS in PUCT Project 58484 on Apr 13, 2026.","status":"ONCOR ELECTRIC DELIVERY COMPANY LLC","date":"2026-04-13","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58484&itemNumber=105","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58484: CENTERPOINT ENERGY HOUSTON ELECTRIC, LLC’S RESPONSES TO COMMISSON STAFF’S REQUEST FOR COMMENTS","summary":"CENTERPOINT ENERGY HOUSTON ELECTRIC, LLC filed CENTERPOINT ENERGY HOUSTON ELECTRIC, LLC’S RESPONSES TO COMMISSON STAFF’S REQUEST FOR COMMENTS in PUCT Project 58484 on Apr 13, 2026.","status":"CENTERPOINT ENERGY HOUSTON ELECTRIC, LLC","date":"2026-04-13","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58484&itemNumber=106","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58484: VOID SEE ITEM 114","summary":"OPUC filed VOID SEE ITEM 114 in PUCT Project 58484 on Apr 13, 2026.","status":"OPUC","date":"2026-04-13","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58484&itemNumber=107","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58484: AEP COMPANIES’ RESPONSE TO COMMISSION STAFF’S DRAFT REPORT","summary":"AEP COMPANIES filed AEP COMPANIES’ RESPONSE TO COMMISSION STAFF’S DRAFT REPORT in PUCT Project 58484 on Apr 13, 2026.","status":"AEP COMPANIES","date":"2026-04-13","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58484&itemNumber=108","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58484: Crusoe Technologies LLC's Responses to Staff's Request for Comments on Draft Recommendations","summary":"Crusoe Technologies LLC filed Crusoe Technologies LLC's Responses to Staff's Request for Comments on Draft Recommendations in PUCT Project 58484 on Apr 13, 2026.","status":"Crusoe Technologies LLC","date":"2026-04-13","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58484&itemNumber=110","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58484: TEBA Comments on Commission Staff's Draft Recommendations","summary":"TEXAS ENERGY BUYERS ALLIANCE filed TEBA Comments on Commission Staff's Draft Recommendations in PUCT Project 58484 on Apr 13, 2026.","status":"TEXAS ENERGY BUYERS ALLIANCE","date":"2026-04-13","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58484&itemNumber=111","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58484: Eolian, L.P.'s Response to Commission Staff's Recommendations","summary":"EOLIAN, L.P. filed Eolian, L.P.'s Response to Commission Staff's Recommendations in PUCT Project 58484 on Apr 13, 2026.","status":"EOLIAN, L.P.","date":"2026-04-13","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58484&itemNumber=112","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58484: Joint Comments of Google LLC and Lancium LLC to PUC Staff Memo and Draft Report in 58484","summary":"GOOGLE LLC, LANCIUM LLC filed Joint Comments of Google LLC and Lancium LLC to PUC Staff Memo and Draft Report in 58484 in PUCT Project 58484 on Apr 13, 2026.","status":"GOOGLE LLC, LANCIUM LLC","date":"2026-04-13","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58484&itemNumber=113","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58484: PEC Responses to Commission Staff’s Request for Comments","summary":"PEDERNALES ELECTRIC COOPERATIVE, INC filed PEC Responses to Commission Staff’s Request for Comments in PUCT Project 58484 on Sep 9, 2025.","status":"PEDERNALES ELECTRIC COOPERATIVE, INC","date":"2025-09-09","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58484&itemNumber=27","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58484: Vistra Comments","summary":"VISTRA CORPORATE SERVICES COMPANY LLC filed Vistra Comments in PUCT Project 58484 on Sep 9, 2025.","status":"VISTRA CORPORATE SERVICES COMPANY LLC","date":"2025-09-09","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58484&itemNumber=29","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58484: Staff's Request for Information to TDUs w/11.14 Response Deadline","summary":"PUC RULES & PROJECTS filed Staff's Request for Information to TDUs w/11.14 Response Deadline in PUCT Project 58484 on Oct 17, 2025.","status":"PUC RULES & PROJECTS","date":"2025-10-17","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58484&itemNumber=35","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58484: Staff Memo & Notice of 11/10 Workshop","summary":"PUC RULES & PROJECTS filed Staff Memo & Notice of 11/10 Workshop in PUCT Project 58484 on Oct 21, 2025.","status":"PUC RULES & PROJECTS","date":"2025-10-21","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58484&itemNumber=36","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58484: Staff Memo & Nov. 10 Workshop Agenda w/Nov. 21 Written Comment Deadline","summary":"PUC RULES & PROJECTS filed Staff Memo & Nov. 10 Workshop Agenda w/Nov. 21 Written Comment Deadline in PUCT Project 58484 on Oct 28, 2025.","status":"PUC RULES & PROJECTS","date":"2025-10-28","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58484&itemNumber=37","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58484: Staff Memo Extending Comment Deadline to 11/25","summary":"PUC RULES & PROJECTS filed Staff Memo Extending Comment Deadline to 11/25 in PUCT Project 58484 on Oct 31, 2025.","status":"PUC RULES & PROJECTS","date":"2025-10-31","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58484&itemNumber=38","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58484: RESPONSE TO COMMISSION STAFF’S REQUEST FOR INFORMATION ISSUED ON OCTOBER 17, 2025 RELATED TO WHOLESALE TRANSMISSION SERVICE CHARGES","summary":"AEP TEXAS INC. filed RESPONSE TO COMMISSION STAFF’S REQUEST FOR INFORMATION ISSUED ON OCTOBER 17, 2025 RELATED TO WHOLESALE TRANSMISSION SERVICE CHARGES in PUCT Project 58484 on Nov 12, 2025.","status":"AEP TEXAS INC.","date":"2025-11-12","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58484&itemNumber=39","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58484: TNMP Response to Staff Request for Information","summary":"TEXAS-NEW MEXICO POWER COMPANY filed TNMP Response to Staff Request for Information in PUCT Project 58484 on Nov 13, 2025.","status":"TEXAS-NEW MEXICO POWER COMPANY","date":"2025-11-13","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58484&itemNumber=40","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58484: VOID SEE ITEM 44","summary":"CENTERPOINT ENERGY HOUSTON ELECTRIC, LLC filed VOID SEE ITEM 44 in PUCT Project 58484 on Nov 14, 2025.","status":"CENTERPOINT ENERGY HOUSTON ELECTRIC, LLC","date":"2025-11-14","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58484&itemNumber=41","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58484: ONCOR'S RESPONSE TO STAFF'S REQUEST FOR INFORMATION RELATED TO WHOLESALE TRANSMISSION SERVICE CHARGES","summary":"ONCOR ELECTRIC DELIVERY COMPANY LLC filed ONCOR'S RESPONSE TO STAFF'S REQUEST FOR INFORMATION RELATED TO WHOLESALE TRANSMISSION SERVICE CHARGES in PUCT Project 58484 on Nov 14, 2025.","status":"ONCOR ELECTRIC DELIVERY COMPANY LLC","date":"2025-11-14","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58484&itemNumber=42","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58484: SUPPLEMENTAL RESPONSE TO COMMISSION STAFF’S REQUEST FOR INFORMATION ISSUED ON OCTOBER 17, 2025 RELATED TO WHOLESALE TRANSMISSION SERVICE CHARGES","summary":"AEP TEXAS INC. filed SUPPLEMENTAL RESPONSE TO COMMISSION STAFF’S REQUEST FOR INFORMATION ISSUED ON OCTOBER 17, 2025 RELATED TO WHOLESALE TRANSMISSION SERVICE CHARGES in PUCT Project 58484 on Nov 17, 2025.","status":"AEP TEXAS INC.","date":"2025-11-17","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58484&itemNumber=43","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58484: Letter to Void Item #41","summary":"CENTERPOINT ENERGY HOUSTON ELECTRIC filed Letter to Void Item #41 in PUCT Project 58484 on Nov 20, 2025.","status":"CENTERPOINT ENERGY HOUSTON ELECTRIC","date":"2025-11-20","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58484&itemNumber=44","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58484: CEHE’s Updated Response to Commission Staff’s Request for Information Issued October 17, 2025, Regarding Wholesale Transmission Service Charges","summary":"CENTERPOINT ENERGY HOUSTON ELECTRIC filed CEHE’s Updated Response to Commission Staff’s Request for Information Issued October 17, 2025, Regarding Wholesale Transmission Service Charges in PUCT Project 58484 on Nov 20, 2025.","status":"CENTERPOINT ENERGY HOUSTON ELECTRIC","date":"2025-11-20","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58484&itemNumber=45","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58484: Comments and answers to staff questions","summary":"Sierra Club filed Comments and answers to staff questions in PUCT Project 58484 on Nov 25, 2025.","status":"Sierra Club","date":"2025-11-25","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58484&itemNumber=50","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58484: ONCOR'S RESPONSE TO COMMISSION STAFF’S SECOND SET OF QUESTIONS FOR COMMENTS","summary":"ONCOR ELECTRIC DELIVERY COMPANY LLC filed ONCOR'S RESPONSE TO COMMISSION STAFF’S SECOND SET OF QUESTIONS FOR COMMENTS in PUCT Project 58484 on Nov 25, 2025.","status":"ONCOR ELECTRIC DELIVERY COMPANY LLC","date":"2025-11-25","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58484&itemNumber=52","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58484: LCRA AND LCRA TSC'S RESPONSE TO COMMISSION STAFF'S SECOND SET OF QUESTIONS FOR COMMENT","summary":"LOWER COLORADO RIVER AUTHORITY AND LCRA TRANSMISSION SERVICES CORPORATION filed LCRA AND LCRA TSC'S RESPONSE TO COMMISSION STAFF'S SECOND SET OF QUESTIONS FOR COMMENT in PUCT Project 58484 on Nov 25, 2025.","status":"LOWER COLORADO RIVER AUTHORITY AND LCRA TRANSMISSION SERVICES CORPORATION","date":"2025-11-25","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58484&itemNumber=53","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58484: Joint Responses to Staff Questions of H-E-B, LP and South Texas Electric Cooperative, Inc.","summary":"H-E-B LP and South Texas Electric Cooperative, Inc. filed Joint Responses to Staff Questions of H-E-B, LP and South Texas Electric Cooperative, Inc. in PUCT Project 58484 on Nov 25, 2025.","status":"H-E-B LP and South Texas Electric Cooperative, Inc.","date":"2025-11-25","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58484&itemNumber=54","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58484: Comments of NRG Energy, Inc. in Response to Staff's Second Set of Questions on Transmission Cost Recovery","summary":"NRG ENERGY, INC. filed Comments of NRG Energy, Inc. in Response to Staff's Second Set of Questions on Transmission Cost Recovery in PUCT Project 58484 on Nov 25, 2025.","status":"NRG ENERGY, INC.","date":"2025-11-25","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58484&itemNumber=55","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58484: Responses of Texas Electric Cooperatives, Inc.","summary":"Texas Electric Cooperatives, Inc. filed Responses of Texas Electric Cooperatives, Inc. in PUCT Project 58484 on Nov 25, 2025.","status":"Texas Electric Cooperatives, Inc.","date":"2025-11-25","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58484&itemNumber=57","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58484: DCC's Comments in Response to Staff's Second Set of Questions","summary":"Data Center Coalition filed DCC's Comments in Response to Staff's Second Set of Questions in PUCT Project 58484 on Nov 25, 2025.","status":"Data Center Coalition","date":"2025-11-25","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58484&itemNumber=59","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58484: TCA Comments on Staff Questions","summary":"TEXAS CONSUMER ASSOCIATION filed TCA Comments on Staff Questions in PUCT Project 58484 on Nov 25, 2025.","status":"TEXAS CONSUMER ASSOCIATION","date":"2025-11-25","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58484&itemNumber=60","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58484: Texas Energy Association for Marketers' Response to Questions for Comment","summary":"TEXAS ENERGY ASSOCIATION FOR MARKETERS filed Texas Energy Association for Marketers' Response to Questions for Comment in PUCT Project 58484 on Nov 25, 2025.","status":"TEXAS ENERGY ASSOCIATION FOR MARKETERS","date":"2025-11-25","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58484&itemNumber=61","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58484: Vistra's Comments in Response to Staff's Second Set of Questions","summary":"VISTRA CORPORATE SERVICES COMPANY LLC filed Vistra's Comments in Response to Staff's Second Set of Questions in PUCT Project 58484 on Nov 25, 2025.","status":"VISTRA CORPORATE SERVICES COMPANY LLC","date":"2025-11-25","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58484&itemNumber=63","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58484: CPS Energy's Comments in Response to Second Set of Questions.","summary":"CPS ENERGY filed CPS Energy's Comments in Response to Second Set of Questions. in PUCT Project 58484 on Nov 25, 2025.","status":"CPS ENERGY","date":"2025-11-25","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58484&itemNumber=64","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58484: ELECTRIC RELIABILITY COUNCIL OF TEXAS, INC.’S RESPONSE TO STAFF QUESTIONS","summary":"ERCOT filed ELECTRIC RELIABILITY COUNCIL OF TEXAS, INC.’S RESPONSE TO STAFF QUESTIONS in PUCT Project 58484 on Nov 25, 2025.","status":"ERCOT","date":"2025-11-25","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58484&itemNumber=65","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58484: TAEBA Response to Staff's Second Set of Questions Proj. No. 58484","summary":"TEXAS ADVANCED ENERGY BUSINESS ALLIANCE filed TAEBA Response to Staff's Second Set of Questions Proj. No. 58484 in PUCT Project 58484 on Nov 25, 2025.","status":"TEXAS ADVANCED ENERGY BUSINESS ALLIANCE","date":"2025-11-25","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58484&itemNumber=67","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58484: CENTERPOINT ENERGY HOUSTON ELECTRIC, LLC’S RESPONSES TO COMMISSON STAFF’S REQUEST FOR COMMENTS","summary":"CENTERPOINT ENERGY HOUSTON ELECTRIC filed CENTERPOINT ENERGY HOUSTON ELECTRIC, LLC’S RESPONSES TO COMMISSON STAFF’S REQUEST FOR COMMENTS in PUCT Project 58484 on Nov 25, 2025.","status":"CENTERPOINT ENERGY HOUSTON ELECTRIC","date":"2025-11-25","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58484&itemNumber=68","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58484: RESPONSES TO COMMISSION STAFF’S SECOND SET OF QUESTIONS FOR COMMENTS","summary":"AEP TEXAS INC. filed RESPONSES TO COMMISSION STAFF’S SECOND SET OF QUESTIONS FOR COMMENTS in PUCT Project 58484 on Nov 25, 2025.","status":"AEP TEXAS INC.","date":"2025-11-25","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58484&itemNumber=69","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58484: OPUC’S COMMENTS ON THE SECOND SET OF QUESTIONS FOR PUBLIC COMMENT TO ATTACHMENTS A AND B RELATING TO THE EVALUATION OF TRANSMISSION COST RECOVERY","summary":"OPUC filed OPUC’S COMMENTS ON THE SECOND SET OF QUESTIONS FOR PUBLIC COMMENT TO ATTACHMENTS A AND B RELATING TO THE EVALUATION OF TRANSMISSION COST RECOVERY in PUCT Project 58484 on Nov 25, 2025.","status":"OPUC","date":"2025-11-25","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58484&itemNumber=70","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58484: ERCOT Steel Mills' Comments on Commission Staff Questions and Draft Report Outline for Project No. 58484 - Evaluation of Transmission Cost Recovery","summary":"ERCOT STEEL MILLS filed ERCOT Steel Mills' Comments on Commission Staff Questions and Draft Report Outline for Project No. 58484 - Evaluation of Transmission Cost Recovery in PUCT Project 58484 on Nov 25, 2025.","status":"ERCOT STEEL MILLS","date":"2025-11-25","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58484&itemNumber=71","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58484: CenterPoint Energy Houston Electric Second Updated Response to Commission Staff’s Request for Comments","summary":"CENTERPOINT ENERGY HOUSTON ELECTRIC filed CenterPoint Energy Houston Electric Second Updated Response to Commission Staff’s Request for Comments in PUCT Project 58484 on Jan 14, 2026.","status":"CENTERPOINT ENERGY HOUSTON ELECTRIC","date":"2026-01-14","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58484&itemNumber=76","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58484: Staff Memo and Draft Report w/April 13 Comment Deadline","summary":"PUC RULES & PROJECTS filed Staff Memo and Draft Report w/April 13 Comment Deadline in PUCT Project 58484 on Mar 16, 2026.","status":"PUC RULES & PROJECTS","date":"2026-03-16","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58484&itemNumber=77","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58484: Vitol Inc. comments in response Commission Staff's Draft Evaluation of Transmission Cost Recovery","summary":"VITOL INC. filed Vitol Inc. comments in response Commission Staff's Draft Evaluation of Transmission Cost Recovery in PUCT Project 58484 on Apr 12, 2026.","status":"VITOL INC.","date":"2026-04-12","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58484&itemNumber=80","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58484: Comments on Commission Staff Report Filed Jointly by Base Power Company, Octopus Energy, Rhythm Energy, and Tesla Energy Ventures, LLC","summary":"Retail Electric Providers for Affordable, Innovative Rates filed Comments on Commission Staff Report Filed Jointly by Base Power Company, Octopus Energy, Rhythm Energy, and Tesla Energy Ventures, LLC in PUCT Project 58484 on Apr 13, 2026.","status":"Retail Electric Providers for Affordable, Innovative Rates","date":"2026-04-13","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58484&itemNumber=82","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58484: Texas Public Power Association (TPPA) Comments on Draft Report and Recommendations","summary":"TPPA filed Texas Public Power Association (TPPA) Comments on Draft Report and Recommendations in PUCT Project 58484 on Apr 13, 2026.","status":"TPPA","date":"2026-04-13","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58484&itemNumber=84","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58484: H-E-B and South Texas Electric Cooperative, Inc.'s Joint Comments on Staff's Memorandum and Draft Report","summary":"H-E-B, LP AND SOUTH TEXAS ELECTRIC COOPERATIVE, INC. filed H-E-B and South Texas Electric Cooperative, Inc.'s Joint Comments on Staff's Memorandum and Draft Report in PUCT Project 58484 on Apr 13, 2026.","status":"H-E-B, LP AND SOUTH TEXAS ELECTRIC COOPERATIVE, INC.","date":"2026-04-13","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58484&itemNumber=87","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58484: Comments of NRG Energy, Inc. in Response to Staff Memo and Draft Report on Transmission Cost Recovery","summary":"NRG ENERGY, INC. filed Comments of NRG Energy, Inc. in Response to Staff Memo and Draft Report on Transmission Cost Recovery in PUCT Project 58484 on Apr 13, 2026.","status":"NRG ENERGY, INC.","date":"2026-04-13","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58484&itemNumber=88","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58484: Comments on Staff's Report and Recommendations","summary":"Data Center Coalition (DCC) filed Comments on Staff's Report and Recommendations in PUCT Project 58484 on Apr 13, 2026.","status":"Data Center Coalition (DCC)","date":"2026-04-13","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58484&itemNumber=89","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58484: COMMENTS OF TEXAS ELECTRIC COOPERATIVES, INC.","summary":"TEXAS ELECTRIC COOPERATIVES, INC. filed COMMENTS OF TEXAS ELECTRIC COOPERATIVES, INC. in PUCT Project 58484 on Apr 13, 2026.","status":"TEXAS ELECTRIC COOPERATIVES, INC.","date":"2026-04-13","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58484&itemNumber=90","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58484: Steering Committee of Cities Served by Oncor and Texas Coalition for Affordable Power's Comments on Commission Staff’s Draft Report on Transmission Cost Recovery","summary":"STEERING COMMITTEE OF CITIES SERVED BY ONCOR AND TEXAS COALITION FOR AFFORDABLE POWER filed Steering Committee of Cities Served by Oncor and Texas Coalition for Affordable Power's Comments on Commission Staff’s Draft Report on Transmission Cost Recovery in PUCT Project 58484 on Apr 13, 2026.","status":"STEERING COMMITTEE OF CITIES SERVED BY ONCOR AND TEXAS COALITION FOR AFFORDABLE POWER","date":"2026-04-13","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58484&itemNumber=91","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58484: LCRA'S COMMENTS ON COMMISSION STAFF'S DRAFT RECOMMENDATIONS FOR TRANSMISSION COST RECOVERY","summary":"LOWER COLORADO RIVER AUTHORITY filed LCRA'S COMMENTS ON COMMISSION STAFF'S DRAFT RECOMMENDATIONS FOR TRANSMISSION COST RECOVERY in PUCT Project 58484 on Apr 13, 2026.","status":"LOWER COLORADO RIVER AUTHORITY","date":"2026-04-13","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58484&itemNumber=92","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58484: ERCOT Steel Mills Comments on PUCT Staff's Draft Report_Project 58484","summary":"ERCOT STEEL MILLS filed ERCOT Steel Mills Comments on PUCT Staff's Draft Report_Project 58484 in PUCT Project 58484 on Apr 13, 2026.","status":"ERCOT STEEL MILLS","date":"2026-04-13","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58484&itemNumber=93","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58484: CPS Energy's Response to Staff's Draft Recommendations","summary":"CPS ENERGY filed CPS Energy's Response to Staff's Draft Recommendations in PUCT Project 58484 on Apr 13, 2026.","status":"CPS ENERGY","date":"2026-04-13","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58484&itemNumber=95","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58484: TCPA Comments on Staff Draft Report on Evaluation of Transmission Cost Allocation","summary":"TCPA filed TCPA Comments on Staff Draft Report on Evaluation of Transmission Cost Allocation in PUCT Project 58484 on Apr 13, 2026.","status":"TCPA","date":"2026-04-13","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58484&itemNumber=96","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58484: TCA Comments on Draft Report for Transmission Cost Recovery","summary":"TEXAS CONSUMER ASSOCIATION filed TCA Comments on Draft Report for Transmission Cost Recovery in PUCT Project 58484 on Apr 13, 2026.","status":"TEXAS CONSUMER ASSOCIATION","date":"2026-04-13","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58484&itemNumber=97","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58484: Texas-New Mexico Power Company's Comments to Commission Staff's March 16, 2026 Request for Public Comment","summary":"TEXAS-NEW MEXICO POWER COMPANY filed Texas-New Mexico Power Company's Comments to Commission Staff's March 16, 2026 Request for Public Comment in PUCT Project 58484 on Apr 13, 2026.","status":"TEXAS-NEW MEXICO POWER COMPANY","date":"2026-04-13","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58484&itemNumber=98","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58484: GVEC's Comments Regarding Staff's Memo & Draft Report","summary":"GUADALUPE VALLEY ELECTRIC COOPERATIVE, INC filed GVEC's Comments Regarding Staff's Memo & Draft Report in PUCT Project 58484 on Apr 13, 2026.","status":"GUADALUPE VALLEY ELECTRIC COOPERATIVE, INC","date":"2026-04-13","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58484&itemNumber=99","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59142: ERCOT UPDATE - BATCH ZERO ELIGIBILITY VERIFICATION AND STATE AND COMMUNITY IMPACT RFI PROCESS","summary":"ERCOT filed ERCOT UPDATE - BATCH ZERO ELIGIBILITY VERIFICATION AND STATE AND COMMUNITY IMPACT RFI PROCESS in PUCT Project 59142 on Sep 21, 2026.","status":"ERCOT","date":"2026-09-21","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59142&itemNumber=73","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58317: SB6 Implementation Roadmap Updated September 2026","summary":"PUC RULES & PROJECTS filed SB6 Implementation Roadmap Updated September 2026 in PUCT Project 58317 on Sep 22, 2026.","status":"PUC RULES & PROJECTS","date":"2026-09-22","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58317&itemNumber=69","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58317: Governor’s audit","summary":"Mary Balmain filed Governor’s audit in PUCT Project 58317 on Sep 22, 2026.","status":"Mary Balmain","date":"2026-09-22","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58317&itemNumber=71","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58317: Public comments on data centers. 765kV Governor's audit","summary":"Toni Williams filed Public comments on data centers. 765kV Governor's audit in PUCT Project 58317 on Sep 22, 2026.","status":"Toni Williams","date":"2026-09-22","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58317&itemNumber=74","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58484: OPUC'S LETTER TO CENTRAL RECORDS- REQUEST TO VOID ITEM NO. 107","summary":"OPUC filed OPUC'S LETTER TO CENTRAL RECORDS- REQUEST TO VOID ITEM NO. 107 in PUCT Project 58484 on Apr 14, 2026.","status":"OPUC","date":"2026-04-14","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58484&itemNumber=114","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58484: OPUC’S INITIAL COMMENTS ON STAFF OF THE PUBLIC UTILITY COMMISSION OF TEXAS’S MEMORANDUM AND DRAFT EVALUATION OF TRANSMISSION COST RECOVERY","summary":"OPUC filed OPUC’S INITIAL COMMENTS ON STAFF OF THE PUBLIC UTILITY COMMISSION OF TEXAS’S MEMORANDUM AND DRAFT EVALUATION OF TRANSMISSION COST RECOVERY in PUCT Project 58484 on Apr 14, 2026.","status":"OPUC","date":"2026-04-14","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58484&itemNumber=115","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58484: Staff Memo and Draft Report","summary":"PUC RULES & PROJECTS filed Staff Memo and Draft Report in PUCT Project 58484 on May 4, 2026.","status":"PUC RULES & PROJECTS","date":"2026-05-04","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58484&itemNumber=117","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58484: Staff Memo_New Rulemaking Project","summary":"PUC RULES & PROJECTS filed Staff Memo_New Rulemaking Project in PUCT Project 58484 on May 27, 2026.","status":"PUC RULES & PROJECTS","date":"2026-05-27","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58484&itemNumber=118","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58484: LETTER REGARDING EVALUATION OF TRANSMISSION COST RECOVERY","summary":"CHAIRMAN DREW DARBY filed LETTER REGARDING EVALUATION OF TRANSMISSION COST RECOVERY in PUCT Project 58484 on Jun 30, 2026.","status":"CHAIRMAN DREW DARBY","date":"2026-06-30","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58484&itemNumber=119","label":"interchange.puc.texas.gov"}]},{"title":"ERCOT market notice M-C092126-01: Batch Zero Verification and Community Impact RFIs: RIOO RFI Tool Update to Restrict Visibility of Other Respondents' Submissions, and Posting of Question Reference Guides on the ERCOT Website","summary":"ERCOT issued market notice M-C092126-01, Batch Zero Verification and Community Impact RFIs: RIOO RFI Tool Update to Restrict Visibility of Other Respondents' Submissions, and Posting of Question Reference Guides on the ERCOT Website, on Sep 21, 2026.","status":"Market notice","date":"2026-09-21","sources":[{"url":"https://www.ercot.com/services/comm/mkt_notices/M-C092126-01","label":"www.ercot.com"}]},{"title":"PUCT Project 59948: Joint Motion to Admit Evidence and Parties' Proposed Finding of Fact, Conclusions of Law, and Ordering Paragraphs","summary":"EL PASO ELECTRIC COMPANY filed Joint Motion to Admit Evidence and Parties' Proposed Finding of Fact, Conclusions of Law, and Ordering Paragraphs in PUCT Project 59948 on Sep 22, 2026.","status":"EL PASO ELECTRIC COMPANY","date":"2026-09-22","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59948&itemNumber=14","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58317: Public comments on data centers, 765 kV, and the Governor’s audit","summary":"Tim Morin filed Public comments on data centers, 765 kV, and the Governor’s audit in PUCT Project 58317 on Sep 23, 2026.","status":"Tim Morin","date":"2026-09-23","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58317&itemNumber=80","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58317: data centers, 765 kV, and the Governor's audit. I’m Very concerned and upset to find out that 8,300 acres has been purchased for a proposed DATA CENTER JIM HOGG. Co Property is surrounded by farms, wildlife and historic sites. Drought has been declared.","summary":"Lynda Soliz filed data centers, 765 kV, and the Governor's audit. I’m Very concerned and upset to find out that 8,300 acres has been purchased for a proposed DATA CENTER JIM HOGG. Co Property is surrounded by farms, wildlife and historic sites. Drought has been declared. in PUCT Project 58317 on Sep 23, 2026.","status":"Lynda Soliz","date":"2026-09-23","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58317&itemNumber=81","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58317: Overwhelming the state with data centers. 765 kV, governors audit. 520 acres of data center near atmos gas line. Drought. Farm land/agriculture, wildlife and historical sites.","summary":"Ashly Sanchez filed Overwhelming the state with data centers. 765 kV, governors audit. 520 acres of data center near atmos gas line. Drought. Farm land/agriculture, wildlife and historical sites. in PUCT Project 58317 on Sep 24, 2026.","status":"Ashly Sanchez","date":"2026-09-24","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58317&itemNumber=83","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58796: OPUC'S NOTICE OF CHANGE OF COUNSEL","summary":"OPUC filed OPUC'S NOTICE OF CHANGE OF COUNSEL in PUCT Project 58796 on Sep 24, 2026.","status":"OPUC","date":"2026-09-24","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58796&itemNumber=105","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59948: ORDER NO. 5- FINDING NOTICE SUFFICIENT","summary":"PUC OPDM filed ORDER NO. 5- FINDING NOTICE SUFFICIENT in PUCT Project 59948 on Sep 24, 2026.","status":"PUC OPDM","date":"2026-09-24","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59948&itemNumber=15","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59142: Request for Audit for Project Raptor","summary":"Douglas Lindemann filed Request for Audit for Project Raptor in PUCT Project 59142 on Sep 25, 2026.","status":"Douglas Lindemann","date":"2026-09-25","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59142&itemNumber=74","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59142: Request for Audit for Project Raptor","summary":"Jennifer Lindemann filed Request for Audit for Project Raptor in PUCT Project 59142 on Sep 25, 2026.","status":"Jennifer Lindemann","date":"2026-09-25","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59142&itemNumber=75","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59142: Request for Audit for Project Raptor","summary":"Bob Lindemann filed Request for Audit for Project Raptor in PUCT Project 59142 on Sep 25, 2026.","status":"Bob Lindemann","date":"2026-09-25","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59142&itemNumber=76","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 59142: Request for Audit for Project Raptor","summary":"Becky Lindemann filed Request for Audit for Project Raptor in PUCT Project 59142 on Sep 25, 2026.","status":"Becky Lindemann","date":"2026-09-25","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=59142&itemNumber=77","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58317: I oppose the data centers, 765 kV, and I have no faith in the Governor’s audit. We moved to rural area to avoid what you are bringin here. I will not pay for these data centers to ruin our state!","summary":"Leslie Wiltse filed I oppose the data centers, 765 kV, and I have no faith in the Governor’s audit. We moved to rural area to avoid what you are bringin here. I will not pay for these data centers to ruin our state! in PUCT Project 58317 on Sep 26, 2026.","status":"Leslie Wiltse","date":"2026-09-26","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58317&itemNumber=87","label":"interchange.puc.texas.gov"}]},{"title":"PUCT Project 58317: Public comments on data centers, 765 KV and Governors audit","summary":"Kimberly Weiland filed Public comments on data centers, 765 KV and Governors audit in PUCT Project 58317 on Oct 2, 2026.","status":"Kimberly Weiland","date":"2026-10-02","sources":[{"url":"https://interchange.puc.texas.gov/search/documents/?controlNumber=58317&itemNumber=101","label":"interchange.puc.texas.gov"}]}]},{"name":"MISO","key":"MISO","rules":[{"title":"FERC Order to Show Cause on large-load integration (MISO)","summary":"FPA Section 206 order preliminarily finding the MISO tariff unjust and unreasonable because it lacks a consistent, transparent framework for large-load application, study, cost-transparency, co-location, and operational requirements. Defines 'Large Load' as a new commercial or industrial customer at a single site with peak load of 50 MW or greater, interconnecting above 69 kV, not part of a co-location arrangement. Required a generation-adequacy informational report by July 20, 2026 and a show-cause response by…","status":"Pending ,  held in abeyance (see abeyance entry)","date":"2026-06-18","sources":[{"url":"https://www.akingump.com/en/insights/blogs/speaking-energy/ferc-issues-show-cause-order-to-midcontinent-independent-system-operator-inc","label":"www.akingump.com"}]},{"title":"MISO generation-adequacy informational report (EL26-70)","summary":"Report required by the June 18 order on how MISO will ensure adequate generation for existing and new large loads. It acknowledged that concentrated, fast-moving large-load demand requires new tools and previewed two filings: a Zero-Injection GIA (then targeted on or about July 31, 2026) and a Large Load Parallel Study Process (targeted on or about end of September 2026). It stated the region is currently resource adequate.","status":"Filed","date":"2026-07-20","sources":[{"url":"https://www.climatesolutionslaw.com/2026/07/rtos-and-isos-answer-a-national-preview-of-how-all-six-grid-operators-plan-to-respond-to-the-large-load-surge/","label":"www.climatesolutionslaw.com"}]},{"title":"MISO abeyance motion and FERC grant ,  show-cause response deadline moved to November 16, 2026","summary":"MISO (like every RTO/ISO) moved on August 3, 2026 to hold the show-cause proceeding in abeyance for up to 90 days to develop Section 205 filings; American Municipal Power opposed. Per a docket tracker updated August 23, 2026, FERC granted full abeyance on August 14, 2026, resetting MISO's response to November 16, 2026 with answers due December 16, 2026. Consequence: MISO did NOT file a substantive show-cause response on August 17, 2026.","status":"Granted ,  proceeding in full abeyance; response due November 16, 2026, answers due December 16, 2026","date":"2026-08-03","sources":[{"url":"https://www.pranavaraparla.com/FERC-Orders-June-2026/","label":"www.pranavaraparla.com"}]},{"title":"Zero-Injection Generator Interconnection Agreement (ZGIA) tariff filing","summary":"Section 205(d) filing creating a fast-track interconnection path for generation co-located with large loads behind the same point of interconnection that will not inject power onto the transmission system (injection prevented beyond transient tolerance windows; POIs on the same voltage side of the same substation treated as electrically equivalent). Per the June 29, 2026 LLWG: ZGIA generators must register as market resources; associated loads are classified as firm NITS loads paying transmission on a gross…","status":"Filed ,  pending at FERC","date":"2026-08-18","sources":[{"url":"https://www.govinfo.gov/content/pkg/FR-2026-08-24/html/2026-17246.htm","label":"www.govinfo.gov"}]},{"title":"Large Load Parallel Study Process (planned tariff filing)","summary":"A new, expedited study process for large loads conducted outside MISO's regular interconnection queue, allowing concurrent rather than sequential study of new large loads and their associated ('devoted') generation. MISO also said it intends to develop a non-firm transmission service option for large loads. Developed through the Large Load Working Group, with meetings scheduled through November 2026.","status":"Proposed ,  pre-filing; announced in MISO's July 20, 2026 informational report","date":"2026-09","sources":[{"url":"https://www.climatesolutionslaw.com/2026/07/rtos-and-isos-answer-a-national-preview-of-how-all-six-grid-operators-plan-to-respond-to-the-large-load-surge/","label":"www.climatesolutionslaw.com"}]},{"title":"Large Load Interconnection Reliability Requirements (LLWG-2026-3) tariff package","summary":"MISO-wide reliability requirements for large loads: hourly 168-hour forecasts updated hourly plus 5-minute forecasts covering 6 hours; real-time SCADA/ICCP telemetry (MW, MVAR, voltage, breaker status); PMUs at each point of withdrawal streaming IEEE C37.118 data; ramp-rate limits, voltage/frequency ride-through, and remote-disconnect capability; new tariff definitions for computational load, large load customer, and points of withdrawal. Generation over 20 MVA behind the same POI needs individual, un-netted…","status":"Tariff language drafted; filing not independently confirmed","date":"2026-06-29","sources":[{"url":"https://cdn.misoenergy.org/20260716%20LLWG%20Item%2001c%20Minutes%2020260629769037.pdf","label":"cdn.misoenergy.org"}]},{"title":"Expedited Resource Addition Study (ERAS) ,  generation fast lane","summary":"Expedited interconnection track for shovel-ready generation addressing resource adequacy, including generation serving large-load growth; MISO began its first ERAS review with 6.1 GW of projects, about 70% gas. A third-party tracker lists ERAS as sunsetting August 31, 2027 or at a 68-project cap. MISO's large-load page pairs ERAS with Expedited Project Review (EPR) for accelerating transmission solutions.","status":"Approved/operating; first cycle reviewing 6.1 GW (~70% gas)","date":"2025-06","sources":[{"url":"https://www.utilitydive.com/news/miso-eras-fast-track-interconnection-study-gas/806747/","label":"www.utilitydive.com"}]},{"title":"Attachment GGG (Merchant HVDC Connection Procedures) and Improvements (PAC-2024-6)","summary":"Attachment GGG is MISO's connection-only procedure for merchant HVDC ties: it establishes safe physical interconnection while separating physical connection from injection rights and transmission service. MISO targeted a tariff/BPM filing in Q2-Q3 2026 with FERC action and implementation expected Q4 2026. The connection-only construct has been referenced in MISO's large-load interconnection policy discussions (January 21, 2026 PAC), making it a template of interest for load-only connections.","status":"Active ,  'FERC' phase on MISO dashboard (last modified August 12, 2026)","date":"2026-05-12","sources":[{"url":"https://www.misoenergy.org/engage/MISO-Dashboard/attachment-ggg-improvements/","label":"www.misoenergy.org"}]},{"title":"2026/27 Planning Resource Auction results","summary":"Annualized capacity prices fell ~42% to $116-126/MW-day across MISO's zones (from $212-217/MW-day for 2025/26). Summer-season prices cleared at $424.30/MW-day in North/Central, $384.10 in Arkansas/Mississippi, $412.10 in Louisiana/Texas (down from $666.50 footprint-wide). Driven by a 4% increase in offered capacity including 12.2 GW of accredited solar (up 59%).","status":"Final ,  all zones cleared, no shortfalls","date":"2026-04-28","sources":[{"url":"https://www.misoenergy.org/meet-miso/media-center/2026---news-releases/misos-planning-resource-auction-shows-sufficient-capacity-for-coming-year","label":"www.misoenergy.org"}]},{"title":"2026 OMS-MISO Resource Adequacy Survey","summary":"Members plan record additions averaging ~15 GW/year of new accredited summer capacity over five years (~100 GW of new supply by 2032; ~60% wind/solar/storage, ~40% gas), against 5.1%/year load growth. Projected surpluses above the planning reserve margin: summer 2028 +11.5 GW, summer 2031 up to +39 GW (November-forecast basis); the April-forecast basis shows materially lower margins. Record 99.5% survey participation.","status":"Published","date":"2026-06-03","sources":[{"url":"https://www.utilitydive.com/news/oms-miso-survey-resource-outlook-generation/821973/","label":"www.utilitydive.com"}]},{"title":"State commissions' complaint against LRTP Tranche 2.1 benefits/cost allocation","summary":"Utility commissions from Arkansas, Louisiana, Mississippi, Montana and North Dakota asked FERC to undo the Tranche 2.1 Multi-Value Project designation, alleging MISO's modeling overstated benefits. MISO, six other state commissions, multiple utilities, the Data Center Coalition, and the governor of Iowa opposed the complaint and sought dismissal. Outcome directly affects cost allocation for the 765 kV backbone that would serve large-load growth.","status":"Pending ,  no FERC merits ruling found as of 2026-08-24","date":"2025-07-30","sources":[{"url":"https://www.utilitydive.com/news/ferc-complaint-mvp-multi-value-project-transmission/756411/","label":"www.utilitydive.com"}]},{"title":"FERC rulemaking: Interconnection of Large Loads to the Interstate Transmission System","summary":"The Secretary of Energy initiated a rulemaking in October 2025 to facilitate timely large-load interconnection ('speed to power'). FERC's June 18, 2026 response was six tailored show cause orders (including EL26-70 for MISO) rather than a single national rule, while keeping the RM26-4 docket open. Binds all six RTO/ISO regions' reform schedules.","status":"Open rulemaking docket; FERC chose targeted Section 206 show-cause orders over an immediate generic rule","date":"2026-06-18","sources":[{"url":"https://www.ferc.gov/rm26-4","label":"www.ferc.gov"}]}]},{"name":"SPP","key":"SPP","rules":[{"title":"High Impact Large Load (HILL) study process, HILLGA, and Load Limited Resource Interconnection Service (LLRIS)","summary":"Creates a HILL load category ,  new or increased commercial/industrial load of 10 MW+ at ≤69 kV or 50 MW+ at >69 kV at a single site (electric storage excluded) ,  with a 90-day study-and-approval path to interconnection agreements for loads paired with new or existing generation. HILLs must provide real-time telemetry, give the transmission operator remote-disconnect capability, hold ramp rates to no more than 20 MW/minute unless otherwise directed, install a PMU at customer expense, and meet ride-through…","status":"approved / effective (unanimous; Commissioner Rosner concurrence; compliance filing due within 30 days)","date":"2025-10-24","sources":[{"url":"https://spp.org/documents/76996/20260618_show%20cause%20order%20on%20large%20and%20co-located%20loads_el26-68-000.pdf","label":"spp.org"}]},{"title":"Conditional High Impact Large Load Service (CHILLS) ,  non-firm bridge transmission service","summary":"Adds a new as-available, non-firm transmission service letting customers serving HILLs take energy transfers to designated delivery points, subject to curtailment and interruption when the system is constrained or during emergency conditions, until designated resources and/or network upgrades supporting long-term firm service are in place. Maximum term is seven years, intended to push customers to complete firm-service arrangements through existing tariff processes. FERC found CHILLS just and reasonable given…","status":"approved / effective","date":"2026-02-10","sources":[{"url":"https://spp.org/documents/76880/20260605_order%20-%20revisions%20to%20add%20the%20conditional%20high%20impact%20large%20load%20service_er26-1323.pdf","label":"spp.org"}]},{"title":"Expedited Resource Adequacy Study (ERAS) ,  one-time fast-track generation interconnection process","summary":"One-time expedited interconnection framework for generation needed for member resource adequacy, adopted in response to queue backlogs and projected capacity deficits. As of SPP's July 2026 informational reports, 36 active requests totaling ~13.3 GW are in the process, with Generator Interconnection Agreement negotiation/execution expected in September 2026. Thermal resources lead the ERAS mix, followed by hybrid projects.","status":"approved / in execution (36 requests ~13.3 GW; GIAs anticipated September 2026)","date":"2025-07-21","sources":[{"url":"https://www.spp.org/documents/74369/20250721_order%20accepting%20tariff%20revisions%20subject%20to%20condition%20-%20expediated%20resource%20adequacy%20study_er25-2296-000.pdf","label":"www.spp.org"}]},{"title":"FERC Section 206 show cause order on large and co-located loads (one of six issued to all RTOs/ISOs)","summary":"FERC preliminarily found SPP's OATT appears unjust, unreasonable, or unduly discriminatory and directed SPP and 22 named transmission owners to either show cause or propose remedies on four gaps: (a) no requirement to evaluate alternative transmission technologies (GETs) or memorialize ongoing operational requirements in a transmission service agreement; (b) transparency on network upgrade costs, a pro forma cost recovery agreement, and a crediting mechanism to prevent cost shifting; (c) rates/terms for…","status":"pending (SPP filed its 30-day informational report July 20, 2026; the 60-day show-cause response deadline passed Aug 17, 2026 ,  contents not yet…","date":"2026-06-18","sources":[{"url":"https://spp.org/documents/76996/20260618_show%20cause%20order%20on%20large%20and%20co-located%20loads_el26-68-000.pdf","label":"spp.org"}]},{"title":"SPP informational report on resource adequacy for large loads (EL26-68 compliance)","summary":"SPP argued its existing framework ,  ERAS, Provisional Load Process (Attachment AX), HILL/HILLGA, CHILLS, Peak Demand Assessment, and the Consolidated Planning Process ,  collectively addresses resource adequacy for new large loads and that no immediate tariff overhaul is required. Reported all 65 Load Responsible Entities met summer 2026 resource adequacy requirements, with the East Balancing Authority Area holding a 17.1% reserve margin (~5,752 MW excess capacity).","status":"Filed","date":"2026-07-20","sources":[{"url":"https://www.climatesolutionslaw.com/2026/07/rtos-and-isos-answer-a-national-preview-of-how-all-six-grid-operators-plan-to-respond-to-the-large-load-surge/","label":"www.climatesolutionslaw.com"}]},{"title":"Price Adaptive Load / Price Adaptive Load Service (PAL/PALS) market participation model","summary":"A new market participation model and non-firm transmission service for flexible, price-responsive large loads willing to curtail, developed partly in response to the EL26-68 show cause order's directive on flexible-load services. A draft Schedule 16 would assign PALS the lowest non-firm curtailment priority ,  curtailed before other non-firm customers and well before firm service. Target FERC filing on or before November 16, 2026.","status":"proposed / in stakeholder development","date":"2026","sources":[{"url":"https://www.climatesolutionslaw.com/2026/07/rtos-and-isos-answer-a-national-preview-of-how-all-six-grid-operators-plan-to-respond-to-the-large-load-surge/","label":"www.climatesolutionslaw.com"}]},{"title":"Seasonal planning reserve margins ,  36% winter / 16% summer","summary":"Load Responsible Entities must hold capacity of at least 36% above winter peak (first separately defined winter PRM) and 16% above summer peak, up from the prior 15% requirement in effect since 2023. The summer PRM is scheduled to rise to 17% in 2029. These requirements bind the capacity that must back any new large load served by an LRE.","status":"approved / effective","date":"2026","sources":[{"url":"https://www.spp.org/news-list/spp-board-approves-new-planning-reserve-margins-to-protect-against-high-winter-summer-use/","label":"www.spp.org"}]},{"title":"Consolidated Planning Process (CPP) ,  merged transmission/interconnection/load planning","summary":"Consolidates SPP's transmission planning, generator interconnection, and (large) load processes into a single planning framework, adopted in response to historic load growth, queue backlogs, escalating network-upgrade costs, and project withdrawals. First Interconnection Cluster Study queue window opened 30 days after the effective date; initial GRID-C rate publication expected by end of 2026.","status":"approved / effective; first CPP planning cycle concludes 2028","date":"2026-03-13","sources":[{"url":"https://www.hklaw.com/en/insights/publications/2026/03/ferc-approves-spps-consolidated-planning-process","label":"www.hklaw.com"}]},{"title":"CHILLS refinement revision requests RR767 / RR768","summary":"RR767 clarifies how CHILL-related curtailment commitments must be defined, sequenced, and made operationally feasible; RR768 accommodates planned outages of generators supporting a CHILL while preserving SPP's ability to curtail for reliability. SPP is also developing refinements on resource commitment sequencing and minimum curtailment ramp rates.","status":"Proposed","date":"2026","sources":[{"url":"https://epeconsulting.com/epe-intelligence/news/accelerating-project-opportunity-new-chills-tariff-revisions-in-spp-provide-critical-flexibility","label":"epeconsulting.com"}]}]}],"grid_note":"ERCOT ~90% of state load (ERCOT profile); Panhandle/South Plains (Xcel-SPS) and a NE corner in SPP; southeast TX (Entergy Texas) in MISO; El Paso Electric in WECC, non-RTO.","grid_operators":["ERCOT","SPP","MISO","NON-RTO"],"counts":{"policy":4,"moratorium":28,"water":14,"delay":83,"atlas":135,"permits":127},"record_count":391},"states":[{"id":"AL","name":"Alabama","groups":{"restriction:local:enacted":["b754e99ab4330e15","decd6891258f47ef","f0af2bd58075bd01","acf788f0940c151f","5d2b5e02877a6db1","86b6b59a0f9f25d6","c4e0ec1c77b375f6","f54b7627480545ea","e01160ee3d027689","a5568f503c16796e","672a4451f57ed71f","130f0e56bf60745e","4985760687f3ce84","03643fb450f0e606","e03f681545f8685d","7e09fb347db9cc56","3eaa5dec8cc4f32e"],"restriction:local:failed":["c8b4ae70216bc13d"],"restriction:states:proposed":["e7f13067c265e602"],"water:moratorium:enacted":["fe369e5b2f828936"],"delay:litigation:active_litigation":["588eb0c7ad945e8c"],"delay:zoning_approval_challenge:active_litigation":["588eb0c7ad945e8c"],"delay:litigation:zoning_request_paused_active_litigation":["1b2abff9a622f18f"],"delay:council_agenda_removal:zoning_request_paused_active_litigation":["1b2abff9a622f18f"],"delay:environmental_concerns:zoning_request_paused_active_litigation":["1b2abff9a622f18f"],"utility:statement:pending":["11c4e5e5098ce897"],"utility:special contract:pending":["6d50a85ed575ad70","ea51d9bfa3f2aef7"]},"grid_operators":["NON-RTO"],"counts":{"moratorium":19,"water":1,"delay":17,"atlas":28,"permits":3},"record_count":68},{"id":"AK","name":"Alaska","groups":{"restriction:local:enacted":["a3bdbc7a2f903071"],"restriction:local:proposed":["1b1fd599ecf09004"],"restriction:local:failed":["14fcd2107dd36027"],"restriction:states:failed":["70bf8b65e5240449"],"delay:interconnection:cancelled":["cbda12242cdda058"],"delay:community_opposition:cancelled":["cbda12242cdda058"],"delay:financing:cancelled":["cbda12242cdda058"]},"grid_operators":["NON-RTO"],"counts":{"moratorium":4,"delay":2,"atlas":1},"record_count":7},{"id":"AZ","name":"Arizona","groups":{"restriction:local:enacted":["efe1b1646b346c07","a90bced96e18e77a","a6281e2e804f5a60","1d398d0ae1a21d5b","641d11706e6d4289"],"restriction:local:proposed":["543df422425e5d64"],"restriction:states:enacted":["341f659a40d6be88","8c611b34dae73c14","1e866041a2d45903"],"restriction:states:proposed":["add216a01080fe60","226daa2040f1d307"],"restriction:states:failed":["1b22a852fb3cd3d6","6300ce595ef5d0af","fe22b44843f73aaa"],"water:closed-loop:enacted":["869ef8ac67db8830"],"water:siting:enacted":["e4c543ec417de650","bf9111175cdcc2be"],"water:study:enacted":["c002da5fb08b6601"],"water:moratorium:enacted":["5706e495e387c218"],"delay:zoning_denial:cancelled":["3a372b9b02a89621","717671bd9cdc167f"],"delay:water_dispute:cancelled":["3a372b9b02a89621"],"delay:community_opposition:cancelled":["3a372b9b02a89621"],"delay:community_opposition:litigation_active":["b1a04c91d82be6c4"],"delay:water_dispute:delayed":["f0fd3f3d4688462e"],"delay:community_opposition:delayed":["f0fd3f3d4688462e"],"delay:zoning_denial:under_appeal":["cb82a5cd61fb9cec"],"delay:tax_incentive_change:under_appeal":["cb82a5cd61fb9cec"],"delay:zoning_denial:withdrawn":["5567ed106330c2df"],"delay:community_opposition:withdrawn":["5567ed106330c2df"],"utility:other:pending":["5d17a79f01d2eb63"],"utility:tariff:pending":["1da26df1fe5c13a0"],"utility:rate case:pending":["5b45806c6fb887c7","d2b222dc47567225"],"utility:special contract:approved":["d3d18ed766abfecd","44611b67548fe3db"],"utility:tariff:approved":["f2a114901b242afc"],"utility:special contract:pending":["aa4d78d10d987248"],"utility:statement:pending":["0dcfef71df5fb811"],"utility:other:approved":["03326890e794e215"]},"grid_operators":["NON-RTO","SPP"],"counts":{"moratorium":14,"water":5,"delay":29,"atlas":21,"permits":63},"record_count":132},{"id":"AR","name":"Arkansas","groups":{"restriction:local:enacted":["ccd17d0cc78e8f6b","24be15d78831b997","2976edbd642bc5ee","165be2cac366e40a","c321161246656575","11b2b2b4357c9b9a","f1fcd0a91c9b364f","cc8edc44497c00b0"],"restriction:local:failed":["7a3c89981993bc87","f0d3a1dde3ddedd3"],"restriction:states:proposed":["24cb87919949138b"],"restriction:states:failed":["669f43bd9db94313","4cd8f4567d93ecf7"],"water:disclosure:failed":["b599e881f9e16713","460013ff73ea7911"],"water:siting:enacted":["d25f62e8d2b28025"],"water:disclosure:vetoed":["34510ed612779eb7"],"delay:litigation:active_litigation_temporary_block":["038ee7f241ea0405"],"delay:state_law_ownership_ban:active_litigation_temporary_block":["038ee7f241ea0405"],"delay:quorum_court_rejection:moratorium_exemption_rejected":["31e41baa9c0feb7f"],"delay:county_moratorium_dispute:moratorium_exemption_rejected":["31e41baa9c0feb7f"],"delay:litigation:active_litigation_records_dispute":["a103b1f5c7cb3114"],"delay:public_records_dispute:active_litigation_records_dispute":["a103b1f5c7cb3114"],"utility:statement:approved":["36a2338551fca4bf"],"utility:tariff:approved":["f43b05ef42c2b01e"]},"grid_operators":["MISO","SPP"],"counts":{"moratorium":13,"water":4,"delay":17,"atlas":10,"permits":2},"record_count":46},{"id":"CA","name":"California","groups":{"restriction:local:enacted":["a25de67269df0ed1","5709c4b5b56bdcb7","2a076a8efdfced43","09ce6bf92df9e75f","846b44fb44875a68","c8bffaf8e914e126","d3f536e572c853c0","e6f878bf8f23af8a","0bc1904215c57133","91ff35645c472dbe","188c7c4f44c8536f","2e31d9e1a9cca3fe","c6bb03e1b77debf9","1df245d5ecbbe1dd","106240b9c12fa638","71e0bfc997caca17","e8632d627b1772a4","7c6238e16f306088","055c2fca846ffbb0","4db95272d4d0b3b9","c0ec3d7f70d99734","9749538c1593f5cd","396ad9209089e80b","8aa7be7faae30500","dbd84a0fba7823d9","4297fa613aade787","1ed97d6ba694c7ec"],"restriction:local:proposed":["ea295658dff6c100","4d8d1ffdf12217a7","0552f5d218785acb","566895b8839e5229","558caf6ac46fd86a","aafdf3f00fd02036","1447a768a8032ada","8f8c47d0520b6675","07dc420f28cea720","cc095341ed505538","96c02fe3f2b69d63"],"restriction:local:failed":["4c7a6aab7028e4cf","6c0f45a31c38dd96","60a1fd085fb7faa2"],"restriction:local:pause":["9441b074827051cd"],"restriction:states:enacted":["b138c8f25c6a1df9","6cd48a1a9e3b6e42","e04ce361015d10b8","997e47cb2efa0fb1","a99eee6a8346d803","f8de3ea100d5a73c","36821d2782e3a288","b175ffb656ec4e09"],"restriction:states:failed":["9a181689208d061f"],"water:disclosure:proposed":["6018757e291cf1cf"],"water:disclosure:enacted":["f1363de6a8051f4c","0542c8536ced8e81","d192c59c767e1959"],"water:moratorium:enacted":["1cc46a341cdc3ef8","455741d01ef09906","490cb87c459dd8d3","b85c5b51cdf4ca84","2d55ff4b663fe464"],"water:moratorium:proposed":["7dd1832dd7f10e5b","d430cf80aec173de"],"water:incentive:enacted":["4a4855c312ff4655"],"water:siting:enacted":["0f9ba6aedeacc0f2"],"delay:litigation:litigation_active":["df264e03425ec97a"],"delay:permit_denial:litigation_active":["df264e03425ec97a"],"delay:local_moratorium:delayed":["81e21ec7e868a8a0"],"delay:water_dispute:delayed":["81e21ec7e868a8a0"],"delay:community_opposition:delayed":["81e21ec7e868a8a0","14833b21d81cfae2"],"delay:litigation:delayed":["8f4ba499ed265bb0"],"delay:permit_denial:delayed":["8f4ba499ed265bb0"],"delay:local_moratorium:cancelled":["e6ef57967971f34b"],"delay:community_opposition:cancelled":["e6ef57967971f34b","60ad802b8bf4ce26"],"delay:community_opposition:withdrawn":["dabaa0d9ca40c829"],"utility:other:pending":["2331af1293597280","65708bfad2e82891"],"utility:tariff:pending":["9365b7af7942c436","345f48017f0b0304"],"utility:statement:pending":["686efa78facdadc1","c9e2f082eb03806e"],"utility:tariff:contested":["d8dc8b595b9287b9"],"utility:IRP:pending":["2c217c66f5f9e73f"],"utility:special contract:approved":["e9224e475fe0078d"],"utility:special contract:pending":["a93460236987d2aa"],"utility:tariff:approved":["77fc87a9cbbc5266"]},"grid_operators":["CAISO","NON-RTO"],"counts":{"moratorium":51,"water":13,"delay":52,"atlas":42,"permits":18},"record_count":176},{"id":"CO","name":"Colorado","groups":{"restriction:local:enacted":["d20e86908dbdc520","7e23b2c472790666","b680584b86f47325","27892c65296bbedd","4057677a34555f38","611f35a83bc2affd","079b59e4fdf63d21","a78ac9d55cc5b6e7","72aaf79dce28835b","8c94de22f0407e5e","fafd70f2e092776b","b7f34202c64479ce","68d895f0c2ab0e74","9ef574abef591c91","73177d5333c4eddd","025c6d645640e09f","2c25069cf664aaf3"],"restriction:local:proposed":["180c78e281f128cd","e516a7d3e6cb6124"],"restriction:local:failed":["1224f46eadf9763d"],"restriction:states:failed":["804810ef9bbbcba8","8bb8b6f98d15d82f"],"water:siting:enacted":["1a50144d2155e77c","b03afdefabd7d0fe"],"water:moratorium:enacted":["da5550e87bcd99b9"],"delay:local_moratorium:halted":["9cef3b22115f1c92"],"delay:community_opposition:delayed":["a38043d281f78904"],"delay:litigation:delayed":["a38043d281f78904"],"delay:tax_incentive_change:litigation_active":["75f9d2abb9fb3326"],"delay:local_moratorium:delayed":["346f7ed881ecaa83"],"utility:tariff:pending":["959a6c65c1b74f30","59050cc9ea65018e","7d2e982178725742"],"utility:IRP:approved":["c4287797ac10652c"],"utility:tariff:denied":["c0672975e176ca01"]},"grid_operators":["NON-RTO","SPP"],"counts":{"moratorium":22,"water":3,"delay":27,"atlas":26,"permits":35},"record_count":113},{"id":"CT","name":"Connecticut","groups":{"restriction:local:enacted":["6e1a2316302287f7","576ae2d483109634","f7bc5e6a64694fc6","afa7c0bb25faeb00","0642f9a9d449638b"],"restriction:states:failed":["717698e42ef6e901","e135ad979d2fc395"],"water:disclosure:proposed":["7a7d2e991305affc"]},"grid_operators":["ISO-NE"],"counts":{"moratorium":7,"water":1,"delay":4,"atlas":5,"permits":1},"record_count":18},{"id":"DE","name":"Delaware","groups":{"restriction:local:proposed":["d3ed82824472253c"],"restriction:local:enacted":["20667d2af7bb1915","349d8f4e1160a386","e6b800970826b7ff"],"restriction:states:enacted":["f79088b84dfb570b","f797bd58db306835","00d385fc78b43d3c"],"restriction:states:failed":["8e1aedf35862eb28"],"delay:zoning_denial:halted":["5fef84a0dc8a6ea7"],"delay:community_opposition:halted":["5fef84a0dc8a6ea7"],"utility:tariff:pending":["5c2aae85d73c5722","7d3ea4d67fa68520","db8fb22803e36edc","5b6e0fabe7643de5","a3ef5c98705ce81a"],"utility:tariff:contested":["17240088860f9cd6"],"utility:policy:effective":["c3275bc79925ea23"]},"grid_operators":["PJM"],"counts":{"moratorium":8,"delay":14,"atlas":4,"permits":3},"record_count":29},{"id":"FL","name":"Florida","groups":{"restriction:local:proposed":["3c6d8b831356d465","e8b089b79a0f9026","7425d7591ce9c05a","e1b9861a123c1037","eff63eaba9c47d23","5b481baefebc87d9","a5e933035ad808b1","fac9127296bbb451","81e7440dc92c2b86","92a8872884499683"],"restriction:local:enacted":["a5503fc35c328f46","23c7119619365d48","8b07f1ffc26fabaf","3d8300137881558a","73505e05af5a93eb","f81b18c1e2c17955","930a54e75fe30dbf","a6dde620b7e76c37","55f91fe7e81d73f9","256ea0475a8abfbc","3d3d3059a4680f72","d7dcf42909108795","81d807032f719371","e068dd6b5ef9a080","2309ccbc3d286709","6056ac6cc19512a9","7143529782427cf5","089c1610e25cae54","6519ee70858d723f","10e7ec4ad55643e8","9d86ef4ad5bda00b","664c54df9091c973","05af516c4516ea5a","f5948f47a6af75c6","983f2c993373327d","06dc3cba02451c3d","c1218a13301328fe","b404521e586a3d39"],"restriction:local:failed":["3cabceedb3599796","cea30c117def2cca","3eec78ad6ec41fba","b3455f9b6eb27513"],"restriction:states:enacted":["bd1baf5ebba563ea","0481f85a9e1d5f2a"],"restriction:states:failed":["8cb4a715971a72e5","3ba747e753788cc7","04d2addc80c5d977"],"water:reclaimed:enacted":["41fb56a04133f262"],"water:moratorium:proposed":["edf34b85cb944f74","1cd10774835a9376","ad733fa464deef93"],"water:moratorium:enacted":["2940ba1eefc2e616","9b3a0316ced968a7","209a4247fb52b5dd"],"delay:community_opposition:cancelled":["8e40e6f05855c417"],"delay:water_dispute:cancelled":["8e40e6f05855c417"],"delay:zoning_denial:cancelled":["8e40e6f05855c417"],"delay:permit_denial:denied_without_prejudice":["a96919e42e70568c"],"delay:community_opposition:denied_without_prejudice":["a96919e42e70568c"],"delay:county_moratorium:moratorium_in_force":["a80ab26a0223aab0"],"delay:community_opposition:under_construction_amid_opposition":["30167fbd092c1632"],"delay:transparency_concerns:under_construction_amid_opposition":["30167fbd092c1632"],"delay:community_opposition:rumored_no_application_filed":["f2412c254c9be527"],"delay:meeting_postponed:rumored_no_application_filed":["f2412c254c9be527"],"utility:tariff:pending":["8decf641f8a25d7d","a3c4a2035b1bbdae"],"utility:tariff:approved":["e302a349f266e980","6e774dbc7dc0ad70"],"utility:other:pending":["49d867567171c0f6"]},"grid_operators":["NON-RTO"],"counts":{"moratorium":47,"water":7,"delay":35,"atlas":45,"permits":3},"record_count":137},{"id":"GA","name":"Georgia","groups":{"policy:cost-allocation":["8dcc4b156d460b66"],"policy:minimum-payment":["90114ff524521a31"],"restriction:local:enacted":["83b7e8e76b5ee0bc","c702f3e21493eb78","f01b7f9bb899e3d6","f7d299ad7a92bf12","3bbce17db7406e29","d82372162bbd6160","85de3463c47701a1","7086dae6422907ad","754cf92f96c529a3","c7572839bf1e65ec","0f457e9b1f07b13c","cde0de75b390a38c","190ca6042402e496","b7df742790192976","18d1622ef7bf1615","91cb94f80ea44672","8b31abcd9fbd53f1","25670f673645fec9","a263b272f78d0c97","c968b3ce64dc6e50","94471cc36a302f4d","d8321a4a32d96fe5","d6fd85ec434dbb95","e92bfd601e97e81a","b442425bf5306c01","0a299b6f3e4f8a71","97f3ce24746ab390","75bf8ea8521c54fa","0a88eeaf1510a872","b85fe594520520c1","90a000efae4eb640","c5f545916c737149","7718b91252a0926a","dea0bc58f5667b0f","31c097aea2e6b922","e07ddb442cda946c","8e0052e65c172653","8c1646131950febb","05cc6246e1b41c7f","f7dbcf4c51bf6858","a0256947e3545780","8a2dd9e2691ff06f","9f541b9254ba4673"],"restriction:local:failed":["0abc00ddccf55a33","2bc57eb4e3e90e1f","701836b773fb0b9f","69a87b66a5ff3dc2","c86da04ebcb107b1","496e8e5d89e48f9e","e1f3ad4472027620","6e2cdff1c98b89c0"],"restriction:local:proposed":["c2f04f5b50afc543","0fb52176825fcefa","cb9ce96499427440"],"restriction:states:proposed":["8f9aa89848bde366"],"restriction:states:failed":["e9f083814e55fed7","9c1953c2716db6dd","40cfc9d1ff50d003","6a4a691d7908a952","1f42995802ab1e14","1b3fd31a366bf4bd","a9baa8b690070329","30d8a643dc1032e6","35836125f8f5c6e9"],"water:disclosure:proposed":["763ca1cd9c5aab65"],"water:siting:enacted":["dfcc4d38d0110edd","e2e353fc1545946a"],"water:siting:proposed":["1054015276abc18b"],"water:closed-loop:enacted":["de00fb52546e6f23"],"water:disclosure:enacted":["2ad2d7c1dd2cabd0"],"delay:permit_denial:permit_denied":["1f36ddedf54f3fd4"],"delay:community_opposition:permit_denied":["1f36ddedf54f3fd4"],"delay:county_moratorium:permit_denied":["1f36ddedf54f3fd4"],"delay:county_moratorium:approved_active_litigation":["d0f8256ac51fab90"],"delay:litigation:approved_active_litigation":["d0f8256ac51fab90"],"delay:community_opposition:approved_active_litigation":["d0f8256ac51fab90"],"delay:county_moratorium:delayed_amid_moratorium":["4b90e184c8781b68"],"delay:community_opposition:delayed_amid_moratorium":["4b90e184c8781b68"],"delay:county_moratorium:moratorium_in_force":["dc2902692d6491a1"],"delay:public_outcry:tax_incentive_withdrawn":["79abe857d504f0de"],"delay:tax_break_withdrawal:tax_incentive_withdrawn":["79abe857d504f0de"],"delay:community_opposition:cancelled":["2a4ab4968e918d44"],"delay:interconnection:cancelled":["1de43b4a847f9aa8"],"delay:financing:cancelled":["1de43b4a847f9aa8"],"delay:interconnection:denied":["2661c3858a5d582c"],"delay:zoning_denial:halted":["07d5ce26e3298956"],"delay:community_opposition:halted":["07d5ce26e3298956"],"utility:tariff:approved":["51165aeea3b5c521"],"utility:rate case:approved":["858fc088c06ae5c6"],"utility:other:pending":["7eacf8103d2cde93","725643f3b4745c90"],"utility:statement:pending":["83d8f442e8f028cc","613ee18634340b67"]},"grid_operators":["NON-RTO"],"counts":{"policy":2,"moratorium":64,"water":6,"delay":70,"atlas":70,"permits":91},"record_count":303},{"id":"HI","name":"Hawaii","groups":{"restriction:local:proposed":["28597eb2f2e2356b"]},"grid_operators":["NON-RTO"],"counts":{"moratorium":1},"record_count":1},{"id":"ID","name":"Idaho","groups":{"restriction:local:enacted":["95089721b56ee774","fe1a183a87096ad9","cfe65746b5a0f7e3"],"restriction:local:failed":["93f06396ad555ba2"],"restriction:states:enacted":["276f9be7f349fc75"],"restriction:states:proposed":["cefda14587a887e9","f7f09ea72ca4e50b"],"restriction:states:failed":["9c8a456a09d32f23","89b3c3ec88bdbc77","46828f9c28d595d2"],"water:siting:enacted":["d9479381dd39426b"],"delay:litigation:under_appeal":["6c2c455020d0272b"],"delay:corporate_realignment:delayed":["7e9cb32e4e8d817f"],"utility:other:pending":["7cf4e8e8f3a38458"],"utility:tariff:approved":["e898000ea6ecc3d6"]},"grid_operators":["NON-RTO"],"counts":{"moratorium":10,"water":1,"delay":9,"atlas":3,"permits":1},"record_count":24},{"id":"IL","name":"Illinois","groups":{"restriction:local:failed":["1688237928438d39"],"restriction:local:enacted":["ca8eaa4fae2c852a","6f07a6763fa734a0","09ae1486502886e8","5bd418f017328c7c","06b72d07cd1c49ac","0c47dab15c0d2f8b","0af9b2178b92e9d5","a63897e78f332f95","9c11e0fbe25fcdd9","dff4c418b6ff66a4","4dbd1742ac88cba6","98cdcd339817f68e","95fb3d3156498f12","15e7d96176c192b0","4ada4d4ff9e7b794","9f441a6e33f21096","91816e044ae91d73","606804a7751c5741"],"restriction:local:proposed":["c658effcd8a8404b","e742ed625e62ce6f","a952290a81b198a4","5b9ee8080b2a9ab7"],"restriction:states:pause":["d15586bf00803a21"],"restriction:states:proposed":["2de67be693a93ad7"],"restriction:states:failed":["6456aa7bb0b23688"],"water:disclosure:proposed":["8a7dc5bdfec701e7"],"water:moratorium:enacted":["080dab59c19bd690","2a07c1558296be02","e635d05e2074a570"],"water:disclosure:enacted":["dc2475a676fa62ca"],"delay:litigation:litigation_active":["fea0362f66d7ce4d"],"delay:community_opposition:litigation_active":["fea0362f66d7ce4d"],"delay:zoning_denial:litigation_active":["fea0362f66d7ce4d"],"delay:litigation:active_litigation":["9e23d3ec3c2afc8f","73e7e2b4984b632d","180053263745dfcc"],"delay:wetlands_permit_suspended:active_litigation":["9e23d3ec3c2afc8f"],"delay:community_opposition:opposed_pending_council_vote":["e132605bfcfb961d"],"delay:community_opposition:opposed_effectively_stalled":["0cd52f874d37722a"],"delay:petition_campaign:opposed_effectively_stalled":["0cd52f874d37722a"],"delay:city_moratorium:moratorium_in_force":["58cf33c3ebe468f0"],"delay:public_notice_violation_alleged:active_litigation":["73e7e2b4984b632d","180053263745dfcc"],"delay:rezoning_denial:withdrawn":["035003b98053fc06"],"delay:no_secured_tenant:withdrawn":["035003b98053fc06"],"delay:council_opposition:withdrawn":["035003b98053fc06"],"delay:water:cancelled":["46efd12bf3ea6dcb"],"delay:financing:cancelled":["46efd12bf3ea6dcb"],"utility:rate case:approved":["37ab93fd8b57c77e"],"utility:tariff:approved":["1543e61fc24998f6"]},"grid_operators":["PJM","MISO"],"counts":{"moratorium":26,"water":5,"delay":42,"atlas":40,"permits":60},"record_count":173},{"id":"IN","name":"Indiana","groups":{"policy:minimum-payment":["bf784d50ec22157b"],"policy:departure":["03586139e9d09948"],"policy:security":["19c77af74e853a13"],"policy:regulator-reporting":["dde07ed35b93f0c9"],"restriction:local:enacted":["963b8c0256246b3b","8eac5106889da9ac","183f5e5fde8b2c9e","a7e5ebb04d58be95","f4c86ae66329b23b","a3e5e35d93d700fd","a444b64740435e08","3a39e47da83f24be","c7133c46e29c6d69","5e41da92046a9bcb","ff803a94b802fe31","7db5ead22195b986","998bd34f448ab467","9e2594c01650c7f4","837d5ad2452c9a6c","42d0a19e60e69b3f","7a052f9efca8b303","5be45e17d6ec7513","c1be058ee36c4738","a86775303cb769f2","bba265c36e34c00f","ee5f8620c8465f3d","736410e487973794","faaee5c934ec1ecb","ee6a98915d4cd96d","678dfff8b193d0a3","0e6064d1c5503319"],"restriction:local:proposed":["e66e435a43f67c04","7467dd109abc68e3","fed5ec0ec8852137","c73095088bd90160","b24ea3f72d09cb82"],"restriction:local:failed":["845faec2de5f43fc"],"restriction:local:pause":["4d96d9bb18ac4024"],"restriction:states:enacted":["227139621030dba6"],"restriction:states:failed":["eea922145c00d1a8"],"water:moratorium:enacted":["2e6ca318ecd03dd0"],"water:siting:failed":["b35eb608d2415382"],"delay:community_opposition:cancelled":["bb2ed0971e6302ac"],"delay:zoning_denial:cancelled":["bb2ed0971e6302ac"],"delay:litigation:litigation_active":["6f356448fc4e65f9"],"delay:community_opposition:litigation_active":["6f356448fc4e65f9"],"delay:community_opposition:approved_but_citywide_moratorium_pending":["e034c083058251a3","72ffc530ecd5fd9a","3e312e13c51a83a6"],"delay:proposed_moratorium:approved_but_citywide_moratorium_pending":["e034c083058251a3","72ffc530ecd5fd9a","3e312e13c51a83a6"],"delay:community_opposition:withdrawn":["1729a8c1f14a58a4"],"delay:rezoning_denial_or_withdrawal:withdrawn":["1729a8c1f14a58a4"],"delay:rezoning_denial:rezoning_denied":["d11979032cadd398","569435ce3fe609dd"],"delay:community_opposition:rezoning_denied":["d11979032cadd398"],"delay:litigation:active_litigation":["c5e676669917e797"],"delay:permit_challenge:active_litigation":["c5e676669917e797"],"delay:community_opposition:approved_amid_opposition":["6d8bec92336deeb0"],"delay:missed_milestones:development_agreement_expired":["27c39d9347a1192e"],"delay:financing_delay:development_agreement_expired":["27c39d9347a1192e"],"delay:unresolved_commitments:rezoning_denied":["569435ce3fe609dd"],"delay:county_moratorium:moratorium_in_force":["33af90259cf95dde"],"delay:county_moratorium:moratorium_extended":["6e309bb5ef6dcc2b"],"utility:tariff:approved":["4b48c2fabeec119f","fa98544ba5e059ad","6b0503ca135ba204"],"utility:special contract:pending":["113a466c8203c668"]},"grid_operators":["MISO","PJM"],"counts":{"policy":4,"moratorium":36,"water":2,"delay":51,"atlas":50,"permits":12},"record_count":155},{"id":"IA","name":"Iowa","groups":{"restriction:local:enacted":["6ec7f0571c9f0b36","b997268fd2bd8a07","a3d89d9d748c79e5","ece6aca21720a05a","b53022fa847d859d","2265266858f1808d","d2821404eb9b773b","e429297830c5c85e","2c27ac27b47a53de","8ce23138e1f0ecbd","0e74326bb2038903","245488a7b0f0baed","4ec7c3f119f63571","5d574b2e962d112d","57926d8a3b16421b","6873275732caceab","6572038f8fb6515a","09dabb3487e83177","fc20843db6b3c777","ab4c1a0e46a2c211","f73ca7c24ea9ea51","48355f233539620f","e170f696214b321f","8f8fd51101db1cc6","c5304dad0e04e811","75a122be02ae0d9d"],"restriction:local:failed":["0fa0b840766c8a19","c263db1bebb5e27f","a131c04ede50c5f6"],"restriction:states:enacted":["9e83b550b15760aa"],"restriction:states:proposed":["639d23fdd3311f98","262084f7a02f3ad2","e2e155d413c48eda"],"water:disclosure:failed":["304d0cab55c6bd68","e3e82ac6f5792d65"],"water:rate:failed":["42f37d1bced6be18"],"water:closed-loop:failed":["b47e084956bfc26a"],"water:closed-loop:proposed":["24ce35cf4b42f743"],"delay:multi_year_construction_delay:delayed_extension_requested":["4ce223b15edc681a"],"delay:design_changes:delayed_extension_requested":["4ce223b15edc681a"],"delay:county_moratorium:moratorium_in_force":["679ae4b13385d757"],"delay:county_moratorium_neighboring:early_stage_amid_county_moratoriums":["12e1cb598a859683"],"delay:zoning_denial:delayed":["8e0bc83eff50a9de"],"delay:community_opposition:delayed":["8e0bc83eff50a9de"],"utility:tariff:approved":["a9a9512892558d03"],"utility:other:approved":["3046845ad149fe7d"],"utility:special contract:approved":["e59432224488c63a"],"utility:special contract:pending":["48182dc47986bf11"]},"grid_operators":["MISO","SPP"],"counts":{"moratorium":33,"water":5,"delay":37,"atlas":22,"permits":21},"record_count":118},{"id":"KS","name":"Kansas","groups":{"restriction:local:enacted":["092e69a7498ed6f4","c5d6b2d241f5cc17","5d6e924e754d82a1","d65aa07eb73bb390","2b56b5bc78d3d2c2","779bf14e695b30f3","46ebfe654cb98769","6b3d06b7e6d5546b","3e6f9643e146e802","a03f8a97d54da728","88a8f8a97b3eb631","5c9d3499ff80e6d7","61d91d35faaab6ce","49d229995410fd72","4654c90eb016ce15"],"restriction:local:proposed":["3989c573db251ea1","c49b85a22488877d"],"restriction:local:failed":["50ea4020ea582738"],"restriction:states:enacted":["2ee674af511b50f4"],"restriction:states:failed":["f13da72ca930c823","b3815616ed614981","c1154548fbef7c6e","8db95808ba8ac8e5","69b27b03dc718361"],"water:closed-loop:failed":["4eb2bfa0c2e15d57"],"delay:community_opposition:approved_expanded_amid_opposition":["947909f4a6543759"],"delay:noise_regulation_review:approved_expanded_amid_opposition":["947909f4a6543759"],"delay:water:cancelled":["70833cef331617f1"],"delay:community_opposition:cancelled":["7d838f4833d1b349"],"delay:financing:cancelled":["7d838f4833d1b349"],"utility:tariff:approved":["f77ece2de2ac70fa","3ba852096f736178","1dface436cf210c2"],"utility:tariff:pending":["3e89a8aa0948bcc5"],"utility:other:pending":["aead86c34e456420","7fee508d92451cef"],"utility:other:contested":["fe3448ceb67c13bb"]},"grid_operators":["SPP"],"counts":{"moratorium":24,"water":1,"delay":23,"atlas":20,"permits":3},"record_count":71},{"id":"KY","name":"Kentucky","groups":{"restriction:local:enacted":["a26d4b9555d02fc3","4a7e0503c84a18fb","068617b3ee7c1e34","27a0ce76b943a447","65fd1df9f999e56d","9b96e5de0e107e49","7206025d4f188dc5","a3f8e60045a8e496","3be8e5e1324a2209","ef0ceaa96e4124a9","b8c035523c2353d3","59ddefe2d22f34aa","bcf7474f970300a6","3b2a3d6c317e1650","a1acef1340d31231","a5a9aea1171b918a","baf08a5fdb9be408","626ca6058bcfe492","bcc91f5729167578","ad6f059e45735cb0","c9ad189fcf915368","78d859810fda2f18","971b3f19c633ffe9","0d7d376001869f9f","7cfc5e2b338d1914","0d5a0d6559c93531","341751834d403210","0cd0db1bab37a48b","a1b25cbc5a439391","6dbd46ac8566eabd","f6c91c535f7eae69"],"restriction:local:proposed":["f68fb746468a09f9","e795d08b5d2d9c0b","c509add78042616b"],"restriction:states:enacted":["77733d81d9d3baed"],"restriction:states:failed":["9900fddb93bcc64d"],"delay:rezoning_denial:rezoning_denied":["e55329fac133bb24"],"delay:community_opposition:rezoning_denied":["e55329fac133bb24"],"delay:city_moratorium:moratorium_in_force":["6e62257e2bdac106"],"delay:community_opposition:moratorium_in_force":["6e62257e2bdac106"],"delay:community_opposition:under_review_no_zoning_process":["880dfcdecb0dbbcf"],"delay:no_local_zoning_framework:under_review_no_zoning_process":["880dfcdecb0dbbcf"],"utility:special contract:denied":["253d0f130a165e15"],"utility:tariff:contested":["ae68fdeac34bbc8d"],"utility:other:contested":["42fead8f4bce2aaa"],"utility:tariff:approved":["801dfc830fd07245","4f7f2aea34be5c96","d0cda138d452d757"]},"grid_operators":["NON-RTO","PJM","MISO"],"counts":{"moratorium":36,"delay":39,"atlas":28,"permits":2},"record_count":105},{"id":"LA","name":"Louisiana","groups":{"restriction:local:failed":["082df063713becdd","337eff2a8faaedc2"],"restriction:local:enacted":["450b6661aa0aa3ae"],"restriction:states:enacted":["9ba2486256f256c2","144e7d01d58cef74"],"water:disclosure:enacted":["03f274e9a5dce14c"],"water:disclosure:failed":["f7cd1c9b5f782122"],"water:study:failed":["28f58e0cdd0b7e0e"],"delay:regulatory_transparency_dispute:regulatory_disclosure_dispute":["03dbeebbd06cbb4e"],"delay:ratepayer_cost_concerns:regulatory_disclosure_dispute":["03dbeebbd06cbb4e"],"utility:tariff:approved":["eff42b274f0be9ef","a83e236f50a73f18"],"utility:rate case:pending":["c65e9e2d95997fa6"],"utility:tariff:pending":["69e0ffd4849ee579","88fc6caa48aac8b2"],"utility:statement:pending":["457342b4fea42a74"],"utility:other:pending":["4a0bb7e423217973"],"utility:other:approved":["61067a61b636c781"]},"grid_operators":["MISO","SPP"],"counts":{"moratorium":5,"water":3,"delay":15,"atlas":9,"permits":1},"record_count":33},{"id":"ME","name":"Maine","groups":{"restriction:local:enacted":["ecd5966d9b342311","c36961854ebd6ca7","a4804efbc073f070","d766badde34909ee","3d017e2610e8d02c","b9330f5763dfe845","b2a8fec20ddd4e17","f5a714682b29daa5","8d49ab7b7f89d04b","27b044f270dad65f","be26656565cc2456"],"restriction:local:proposed":["6aff9b58bac5e8f3","ebf579b381f356dd","0afc065fdda3c091","b0ec262465eb00f1","8149b851eb2d0584","e3f47f6089a0ee71","3acc511d9da72bf5","fe1e50be7095ea83"],"restriction:states:enacted":["fe74bf6eed39dbcb","7d62f3ffa4427f55"],"restriction:states:failed":["4e5deea3e7dff0be","0ab980856a66fe1d","a3a43b954eba3113"],"water:moratorium:vetoed":["297d93ad9da5f26a"],"delay:state_moratorium:cancelled":["2156a0ef2be22eb0"],"delay:local_moratorium:cancelled":["2156a0ef2be22eb0"],"delay:water:denied":["922b3fd62f9c070b"]},"grid_operators":["ISO-NE","NON-RTO"],"counts":{"moratorium":24,"water":1,"delay":17,"atlas":19},"record_count":61},{"id":"MD","name":"Maryland","groups":{"restriction:local:enacted":["348298ff6f51a691","08097815a98470c5","4deb89713fe98326","8f74fbbd8993b148","3afe4fa64e87f546","8730de2c9ff67503","c73fe44c03df38ae","8dda8813a9c298d6","764a5ea5baee0c4d","6617f7b48c44c942","a8f91eecf6abf3b5","0afbbaf26cf8f904","83ff2804204a626d","9c034ea2bef0ece8","3373477ac1ec4f02","62bac4f016f1945b","11d1a89900718a96","eb36aed04afe9d8a","499348363c3b81ea","6f9687423e2dc4e7","dc1acf38d039ac19"],"restriction:local:proposed":["265e093c1f9eb417","755b1c07e83184e1","08ca97e19dc7abb4","3e8bbaa7cd3afe15"],"restriction:states:enacted":["17348e6b8d304518","b044300e1a2b5236"],"restriction:states:proposed":["5e23b6297efd7527"],"restriction:states:failed":["3c99947280200b8d","1fcccf76e9b86359","cf6793fd2c12b7d5","f1a32ee4fda04c94"],"water:study:enacted":["558d1f7246d3e647"],"water:moratorium:proposed":["e3bd79694db1db39"],"delay:litigation:litigation_active":["27582584bea51673"],"delay:local_moratorium:litigation_active":["27582584bea51673"],"delay:community_opposition:litigation_active":["27582584bea51673"],"delay:zoning_denial:withdrawn":["5aa3c5c167a2712e"],"delay:community_opposition:withdrawn":["5aa3c5c167a2712e"],"utility:statement:pending":["96ed3e4e28dc5f46"],"utility:tariff:pending":["b5a5ebb9845972c4"],"utility:tariff:contested":["151f94517d5bd763"],"utility:other:pending":["eecc4c5501407ced","de3593715e5e8754","b1f2cd97d9cd0cd1","246625aeebba0d27","e8088afeef1bad4c"],"utility:complaint:contested":["1f79c8153170b0cd"],"utility:policy:approved":["d89063b61a861688"]},"grid_operators":["PJM"],"counts":{"moratorium":32,"water":2,"delay":31,"atlas":22,"permits":12},"record_count":99},{"id":"MA","name":"Massachusetts","groups":{"restriction:local:enacted":["9dfd357ee1d1d79e","6fc10604ec34d46e","f0730563712dc086","e2b170911a980baf","443c78d2d2548652","51aa3706f59d3551","9a147c3e16821a2a","37641c80d5d22ef5","3bcf5029dee4b702"],"restriction:local:proposed":["6df99955fb5274ef","e88057500b5af5a2","251bed6de274003a","4e469b93e2617726","f9879ca8a354d99f","cbe95c8b12548c20","d3546c56fc54089d"],"restriction:states:enacted":["dbbfb14cd16be3f9"],"restriction:states:pause":["187e9da595e7eb96"],"restriction:states:failed":["8472091318232e86"],"water:siting:enacted":["c4f434d0074d8012"],"water:siting:proposed":["12f4ef4de2542657"],"delay:litigation:litigation_active":["655e83c186a87988","2493de70fabc445c"],"delay:environmental_review:litigation_active":["655e83c186a87988"],"delay:community_opposition:litigation_active":["2493de70fabc445c"],"delay:community_opposition:delayed":["27d4f05a55fdde9e"]},"grid_operators":["ISO-NE"],"counts":{"moratorium":19,"water":2,"delay":10,"atlas":9,"permits":3},"record_count":43},{"id":"MI","name":"Michigan","groups":{"restriction:local:proposed":["c78ca68312691303","728e3efd8cbaccb2","f81a68f97adf08c0"],"restriction:local:enacted":["e6998880993aa177","b2511715ae4b990f","e1921072a7125833","98f07a32bbf38bd8","6f83b57549342f0e","2212cea497a5e376","6b17b974dff83ac6","0b835486e1c6675b","248845e3115d1b28","0e4058dda626a25d","576d5da42d138d11","bcdc28bfc405e76e","8408b058fbc315db","5d171a2ab62f7804","dc13381e1263b1fd","09e923cf2b67c07f","987c61998db8747a","1b63965c95a1e946","29918b3b1beffe19","99eeb7d2511ceb55","7bb3ee3000662f52","a0e759d085ba7e52","0d0e24de27bbc37a","2b9943a276289d6a","ee9073c9ad75a86f","9a62b17a98e57199","be5f41b4ec785373","ac7d9bd4ffd00f9e","9cecaa0a00ab43e5","1cb30633bb851922","f1c6da2f0000273a","ca9c48eee9e1d1a5","b70d22d7ae290b7d","c2d9415cc3e16da6","3828b0e2eec67db3","7e420db8d37c15f5","98cdd231fea86e2f","e8f1f476cf2c431f","c35e7a7d7cee74a5","e55663914c7c7dcb","33d2ea51a8acf987","51c80939f7496063","aaefdc75bd8c4aeb","911a6b9444bd1607","a7b6b76bf5329d54"],"restriction:local:failed":["516ad57aeb1648fc","b3ad7b9e668b591e","33b46a0d012daefc","3d03aba3f1700469","82599d14f4fba0f6"],"restriction:states:proposed":["a7533c1f529edc2d","6b7ffd32f765b5a4","456ce7c5d8d8f323","91c4adfd115bdb5d","c8d7e8822cffe0b7","98d30a9bf813c747","e816819481689635"],"water:disclosure:proposed":["c32c25eaa98e91c6","8bcea3f333be2510","905756b51034ebc2"],"water:siting:enacted":["d5816002c74cef1d","a2249bcfc2597539"],"water:closed-loop:proposed":["f8e09c679ee0460a"],"water:disclosure:enacted":["225876463f5c6047"],"delay:water_dispute:delayed":["1a7a2592e25c74aa"],"delay:local_moratorium:delayed":["1a7a2592e25c74aa"],"delay:community_opposition:opposed_planned":["90620f2ccd2b9bdd"],"delay:city_council_resolution_against:opposed_planned":["90620f2ccd2b9bdd"],"delay:rezoning_denial:rezoning_denied_then_litigation_settled":["f83e49f859e07603"],"delay:litigation:rezoning_denied_then_litigation_settled":["f83e49f859e07603"],"delay:city_moratorium:moratorium_delay":["042472b06a41f987"],"delay:community_opposition:moratorium_delay":["042472b06a41f987"],"delay:community_opposition:rezoning_paused":["cc32421f495a41b9"],"delay:planning_commission_postponement:rezoning_paused":["cc32421f495a41b9"],"delay:community_opposition:opposed_proposed":["8155ffe35c87d600"],"delay:transparency_concerns:opposed_proposed":["8155ffe35c87d600"],"delay:litigation:abandoned":["b9b9b57ad82d9568"],"delay:community_opposition:abandoned":["b9b9b57ad82d9568"],"delay:china_ties_backlash:abandoned":["b9b9b57ad82d9568"],"utility:tariff:approved":["630e6b38a0b9bb35"],"utility:special contract:approved":["cd42a1000e119f0e","50f9ae193de9e4a3"],"utility:tariff:denied":["a850b2486651c1d3"],"utility:tariff:pending":["5bc36f6821c8abbf"],"utility:policy:approved":["54c782b0ead7889e"]},"grid_operators":["MISO","PJM"],"counts":{"moratorium":60,"water":7,"delay":91,"atlas":55,"permits":1},"record_count":214},{"id":"MN","name":"Minnesota","groups":{"policy:cost-allocation":["0e9cef0d480c11c6"],"policy:departure":["96d76c523368de3c"],"policy:supply-review":["fa129260c9a1191c"],"policy:clean-energy":["5b0759b74511376b"],"restriction:local:enacted":["b739365ff698ee0a","d80387aab9ef2c1b","c3cc4eb6dd8578c2","0dc094cdf13edec8","5aa9e70c1a21d1c7","3fba111c587a7167","199bf867a340507d","d26a44d5312532d6","8e5e33fb9390f491","5ab133e795e83aed","385a484f3217fe24","793265102ee5e04c","35608fd55ce01e87","4fcdd676bd44f6aa","d1abcacd61245c1f","45935f6103775172","db3bb10a74b42708","ba8faf4607030280","8e02e3b0e7618f3a","3f4d995fd6fa4cfb"],"restriction:states:enacted":["2ab863890b12fdcb"],"restriction:states:proposed":["86e0d1d3835c9be9","c61b092c34b879a0","22e3f68246b5a4cc","797e76275710b3d8","7143edd8de397ba4","89d199639f253ee5"],"restriction:states:failed":["d0a94e01d35c42d4","3e22495abb3596c7","e2236d557902ae56","a3cf11f7c0f5a8bf","dfab67689c609a1b","23cc1180dbd6e5d9","eaed289a984419ff"],"water:moratorium:enacted":["e18e98913f2987dd","e11834d93a5792ed"],"water:shield:failed":["edb4285bd2e6d496","48bbbf542eb24d6c"],"water:siting:failed":["9c0626855c13a619"],"water:closed-loop:proposed":["bec7c68e6812d46b"],"water:siting:enacted":["f02889f2df50210d"],"delay:environmental_review:litigation_active":["51ba402b96b22669"],"delay:litigation:litigation_active":["51ba402b96b22669","2eb3d7b7efd8d959"],"delay:local_moratorium:litigation_active":["2eb3d7b7efd8d959"],"delay:litigation:construction_halted_by_court":["3e814c29543f4a91"],"delay:environmental_review_inadequate:construction_halted_by_court":["3e814c29543f4a91"],"delay:litigation:active_litigation":["6afa0ca47b947af4","f52d37a4709f02d3"],"delay:city_moratorium:active_litigation":["6afa0ca47b947af4"],"delay:environmental_review_challenge:active_litigation":["f52d37a4709f02d3"],"delay:environmental_review_pending:final_decision_paused":["452d128b99f4b891"],"delay:city_moratorium:moratorium_in_force":["7af8f1a65d714f3c"],"delay:planning_commission_denial_recommendation:planning_commission_recommended_denial":["796fdc6d59ce947f"],"delay:community_opposition:withdrawn":["7565837e009abac3"],"delay:council_vote_delay:final_vote_delayed":["800f8019c1868fa1"],"delay:community_opposition:final_vote_delayed":["800f8019c1868fa1"],"utility:tariff:approved":["0669b1659a0e805f"],"utility:tariff:pending":["bdec46fd73a2cf42","8fe5290a1832e86c"],"utility:tariff:contested":["2b6636adee0c7012"],"utility:other:pending":["049d9ec6a4db5efc"]},"grid_operators":["MISO","SPP"],"counts":{"policy":4,"moratorium":34,"water":7,"delay":31,"atlas":30,"permits":7},"record_count":113},{"id":"MS","name":"Mississippi","groups":{"restriction:local:enacted":["ecef92d17dfc1c52"],"restriction:states:failed":["ebb062a18af2c39e","4ed51c6c792fa708","e4e4ee9189096b02"],"water:siting:enacted":["5a06d81d34bea26d"],"delay:litigation:active_litigation":["4063038ccfbba534"],"delay:unpermitted_power_plant:active_litigation":["4063038ccfbba534"],"delay:noise_nuisance:active_litigation":["4063038ccfbba534"]},"grid_operators":["MISO","NON-RTO"],"counts":{"moratorium":4,"water":1,"delay":4,"atlas":12,"permits":1},"record_count":22},{"id":"MO","name":"Missouri","groups":{"restriction:local:enacted":["d90eaac4fe51359a","176fecd092621295","204232d5f8ca8df3","79b2a4ad0fec8c24","7017a935b3b7ecbc","85d940e773175229","f803c38f884f6aa0","de0764506bff684b","08196d135c493f63","8d67875968fb64f7","bed91c8df00c2c5a","21f8768f48599598","14bf3311c27da66b","9d5e52899f706d27","f5c0d2e49453bac0","8e6ecd071b72033d","c6cf03998a9e63c8","a9eede6ea17f0f0b"],"restriction:local:failed":["96f484a5795f8aff"],"restriction:states:proposed":["2195fea337e09dc1"],"restriction:states:failed":["79f07d9601a68a2d"],"water:siting:proposed":["fecf28fd776e3f17"],"water:closed-loop:enacted":["f922a9cc8df7f6f1"],"water:closed-loop:proposed":["c842f3220a560928"],"delay:permit_denial:permit_denied":["b6e024ff51469e78"],"delay:historic_preservation_conflict:permit_denied":["b6e024ff51469e78"],"delay:community_opposition:permit_denied":["b6e024ff51469e78"],"delay:county_moratorium:moratorium_in_force":["d74c3761e71266b9"],"delay:community_opposition:moratorium_in_force":["d74c3761e71266b9"],"delay:interconnection:cancelled":["8cb756be5b7ae3a9"],"delay:water:cancelled":["8cb756be5b7ae3a9"],"utility:tariff:contested":["8de24874c642dcbd","f91605a21f63d072","d9c3570921a04363"],"utility:rate case:pending":["082924cd33e117e5"],"utility:tariff:pending":["7394fb772ac183e9","faf8561206d5bf0f"]},"grid_operators":["MISO","SPP","NON-RTO"],"counts":{"moratorium":21,"water":3,"delay":32,"atlas":33,"permits":25},"record_count":114},{"id":"MT","name":"Montana","groups":{"restriction:local:proposed":["9243773c369f1ecf"],"restriction:local:enacted":["8d6ef72e11d1fccd","3ecba2b53f87c88c"],"utility:tariff:pending":["6dcfac3c7c1172f6"],"utility:tariff:contested":["d367203d6f870b27"]},"grid_operators":["NON-RTO","SPP","MISO"],"counts":{"moratorium":3,"delay":6,"atlas":9},"record_count":18},{"id":"NE","name":"Nebraska","groups":{"restriction:local:enacted":["d3d7827f878ed2cf","c57a91902ce91633","4674af901736f5cc","e196b29819de5c9a","135d7b8ca90eebf7","d568851b5061cdaf","81440ae3fafa3d75","e8af315b45a1acfc","08fcf1d2b6f49514","160252554036f1ad","32303ecaa9e0a2ad"],"restriction:local:proposed":["affd265938fabf3b","8c97d016dfddfc1b"],"restriction:local:failed":["1d8ae470cf5d925b"],"restriction:states:enacted":["230cce9838d45d24","e688676c3ac0f747"],"restriction:states:failed":["67b1ace6369704fd","50fd44805485a090","ff2913405faf7657","8d77947d7b8a528f"],"water:study:enacted":["fe6d9f80cee7122e"],"utility:other:approved":["32c8b9ae8d888b6c"],"utility:statement:pending":["4af3c2798acdbf21"],"utility:rate case:pending":["1e47741959ff4b29"],"utility:tariff:approved":["823eb52c6feaee82"],"utility:policy:effective":["c01aa91e1a04b36d"]},"grid_operators":["SPP"],"counts":{"moratorium":20,"water":1,"delay":32,"atlas":13,"permits":22},"record_count":88},{"id":"NV","name":"Nevada","groups":{"restriction:local:enacted":["333dd9b87e58bcbb","b9a69bbde96b5385","55b16953865e48f5","37f2d1d5eb3e2cea","5b58a9e336830633","6773b1cfaaba1346","935d2182c6d74d12"],"restriction:local:failed":["402c12e2dbad57ba"],"restriction:states:enacted":["619839655d751fb6"],"water:moratorium:proposed":["e61948237d868f0e"],"water:moratorium:enacted":["279be78d9d551bf8"],"water:incentive:enacted":["efec6184955a1086"],"delay:water_dispute:under_appeal":["d29280cf2b0521a1"],"delay:community_opposition:under_appeal":["d29280cf2b0521a1"],"delay:litigation:halted":["a81117457f2cb354"],"delay:environmental_review:halted":["a81117457f2cb354"],"delay:litigation:litigation_active":["114d5609ed0f4f35"],"delay:local_moratorium:halted":["5c9d9715723ce0bb"],"utility:tariff:approved":["a7207409cc3dfd45"],"utility:other:approved":["fb307da5f358f615"]},"grid_operators":["NON-RTO","CAISO"],"counts":{"moratorium":9,"water":3,"delay":22,"atlas":20,"permits":18},"record_count":72},{"id":"NH","name":"New Hampshire","groups":{"restriction:local:proposed":["e63e233025fc94fe","b44152b5d37d167b"],"restriction:local:enacted":["d80de2562936a0f7","92290f0a7d985a7f","36c9c8099e12dd15"],"restriction:states:proposed":["5a9909b17dfc57b4","02f0a87d99437f9b"],"restriction:states:failed":["ea8860685576e23e"],"delay:community_opposition:withdrawn":["c1a6706de3454167"]},"grid_operators":["ISO-NE"],"counts":{"moratorium":8,"delay":4,"atlas":5,"permits":3},"record_count":20},{"id":"NJ","name":"New Jersey","groups":{"restriction:local:enacted":["73ec87cfb0aa92d2","9c00fd42521991f9","a384a032bef8e970","124a77e04ac821ec","f23cd51e2cc7cb7f","238c6e78c54a4877","3af6dd3170f1aa82","714725f2229b99d0","08f19d7681319c4d","8cf681d798655aaf","20d0aeda361ce61b","a2b1b417fb0a76fc","face92012462a2a7","968c4f50d3bde674","ceb24ddecb59d86b","3a5c452ca6841c71","742e4aac2483f4af","80f6f1b93985f9f7","c95d899c60e09eb6","7c69fc6032dd27e8","60c1835a0012ce53","054f376e8df396e6","64e87a1ece4414b3","1b9d7255dcc00d88","e3e0f29d691690ec","01b12fb419074edd","c74b23df8b93a3f0","db82850c96b7a694","9844557ef3af937a","559fbafe318ed5ac","0c592d7ddda2c6ac","a784c9eec1d5c3f7","5fb4b28c2b68eccd","ea304a4830a80fb4","fe372a70ddf19936","48334bde9c2fa0b9","d177f8f0171343b7","62a91ee8ab340642","ebd8ee2e6043e34f","39ed97a814dde3a9","3a432a805dccac1c","50b87b303123480f","9a18c03c18a10dd4","b3ca39b6b1630160"],"restriction:local:pause":["1a9db0d9060caea1"],"restriction:local:proposed":["ae409fafdf46bd29","f884ab9b88fff31b","927a7a3ac1c78482","d95561001f914447","7be184c2d2a57e2b","0e8c72bfcc16a39e","8820df8f26c39fea","78d39318109dd5e8","fd2b054d547ea766","df9befec2a94c308"],"restriction:states:enacted":["4df967540ce38c86","30be08e4be6ac9ca","68de33fe969f9287","0438d1ace3661698"],"restriction:states:proposed":["f19c1038b15c7609","d12af38fe29d843e"],"restriction:states:failed":["f915c938338285f1"],"water:disclosure:vetoed":["800fd0cd4f6bebba"],"water:siting:proposed":["45f1ccb950a71b8a","a375aa38a4210e7c"],"water:disclosure:proposed":["0cf376028b422204","36230e1c7c9edac6","c77115dfc059c958","de400f891c588542","6998a87b3e02ca11"],"water:study:proposed":["a7495217b70ef1e5","9cef65942ed49967","bced9687293104ba"],"water:disclosure:failed":["59ae5b971166ac3c","791cdd88090bef4e","1908cf4216d925bc","073e65e826df6c51","378fb181ac8f016c","60262597b91c5af0"],"water:study:failed":["f640ec3294e3f1f2"],"delay:zoning_denial:litigation_active":["54dc7c86bddf4103","b617e293b82d2ac4"],"delay:litigation:litigation_active":["54dc7c86bddf4103","b617e293b82d2ac4","3b478d5d6f56d1ab"],"delay:local_moratorium:litigation_active":["b617e293b82d2ac4","3b478d5d6f56d1ab"],"delay:community_opposition:litigation_active":["b617e293b82d2ac4"],"utility:tariff:pending":["f28161bfc2c29f8c","3620e96459726891","1a6ae3c2ad122164"],"utility:statement:pending":["2e9ea8571e10d078","7a11205dc76a67a6"],"utility:tariff:approved":["296ea913839e1b58"],"utility:other:contested":["5c1b494458632232"],"utility:policy:effective":["3af8bf166bd3c54d"]},"grid_operators":["PJM"],"counts":{"moratorium":62,"water":18,"delay":72,"atlas":65,"permits":18},"record_count":235},{"id":"NM","name":"New Mexico","groups":{"restriction:local:failed":["818109db81472817","f9afe907073e0002"],"restriction:local:enacted":["297204240678eb0e","9ff51438652ddf60","59bea7e940d70194","ada7aa80e60c9320","5eb7f0ff789e43fa"],"restriction:local:proposed":["8ddb604cc82e2c35","b6fb3ebcb7f6c50f"],"restriction:states:proposed":["a99720a3bb94fcaf","78568f32702491ba","b4b3d5817b49728f"],"delay:litigation:litigation_active":["f3a0c010a8f35a41"],"delay:zoning_denial:litigation_active":["f3a0c010a8f35a41"],"delay:community_opposition:litigation_active":["f3a0c010a8f35a41"],"delay:financing:litigation_active":["f3a0c010a8f35a41"],"utility:other:contested":["8ef259cb295588bc"]},"grid_operators":["NON-RTO","SPP"],"counts":{"moratorium":12,"delay":12,"atlas":10,"permits":7},"record_count":41},{"id":"NY","name":"New York","groups":{"policy:environmental-review":["71f511e90d956ca8"],"policy:permit-hold":["4c560e212a74545e"],"policy:supply-review":["ab3c1a20557c8b23"],"restriction:local:enacted":["77679a7c3332c853","a787c81c1d3730a4","cdc22ba5f2f05b59","b14b8ef8ed1860cc","8cca37bd22e9d7b5","4975cfd97e76b52d","bd582af96f35230a","5ffdbe85acc1bde0","a1694e06d983606d","8981b39c54144dc6","d0967cbc5048c7de","210debbc0355f8ce","f47af1d0c2261335","b9f412d2266126c0","723df3b34c814ee8","cebe672bdd456765","edbfc6143edc2bdf","8a9e37cabb7d8067","59d414cbb6a42f77","17aedba2bb3f2d87","2e58841b837a406b","0e1022291bffc7b7","12dd3a35361949ae","3511a027b56d7d7d"],"restriction:local:proposed":["dcd7ff846525f0e1","08c437cc51d4c950","789641906952093a","28bc949979bb83db","111d81838fa01dde","3e58cfc1f209b083","7ae98bc62927c82c","9137cf580ba6858a"],"restriction:local:failed":["cb6d8c82049c8acb"],"restriction:states:enacted":["869f08a4a1fa556c"],"restriction:states:pause":["841d22380b00ad01"],"restriction:states:proposed":["b7ba31aec1fafd00","47c9cf15c60d51b3","daaf6dec95bd6ec2","07d737c4acf173d7"],"water:moratorium:enacted":["8fc3c7d9b9ff9ba8"],"water:reclaimed:proposed":["4ee636f9337e1806"],"delay:environmental_review:delayed":["51347b4b64fa9e01"],"delay:community_opposition:delayed":["51347b4b64fa9e01"],"delay:state_moratorium:halted":["293beafa3fa06f20"],"delay:local_moratorium:halted":["293beafa3fa06f20","77e9bf4bd7aac210","ee2c0366ee0ef429"],"delay:litigation:litigation_active":["e81eb7c91736a32a"],"delay:state_moratorium:litigation_active":["e81eb7c91736a32a"],"delay:local_moratorium:litigation_active":["e81eb7c91736a32a"],"delay:zoning_denial:litigation_active":["e81eb7c91736a32a"],"utility:other:pending":["57638a6f961a13ac","1552fe1a118cce4c","e654e6cbee2e4334","6cf999b790c4a9a6","5b7294bb9bbf171f","a15e9c634f236eaf"],"utility:tariff:pending":["acb3338b2c56b00c","637843fba8961a3b","f4e2166ff0723f1e"],"utility:tariff:approved":["d8fdd2247363f439"],"utility:other:approved":["4b76df05fa507106"],"utility:statement:pending":["85d4d00b457a99fb"]},"grid_operators":["NYISO"],"counts":{"policy":3,"moratorium":39,"water":2,"delay":41,"atlas":26,"permits":4},"record_count":115},{"id":"NC","name":"North Carolina","groups":{"restriction:local:enacted":["0878148bce531a65","26626f41150f13d7","5d4e94286383e811","45843231657d4577","b767f9b8778c3e9c","0425c77f21429fc9","160ecb6859daba38","f700899151bd3d13","afaf001e2ddc7c0f","9125956ad212eba6","1e5e7d19256112cb","de170f5d806a8488","7e05882bb14eba58","d5446d1a27d68afb","66d7df4ef7713b17","a96570a4d8c02995","03d509191d6a1bb8","d3b97dbcfb4cc458","11b4b426a5a3adeb","9730db9306df2eda","f7b5b5059f3d9a76","a7863b1a8d95a6f9","e6debd81c60b3074","72b422fc810eeab3","6bfcfb56a94aa399","0fe95e27742d2793","7f7b78e8dd0072a4","3ab16e9b6bda0047","58f61d5e2dcac367","901f12fcfb423655","77ad5d31685db4d2","13de2569fd40eab9","2c3f7f7d7474e8df","047fa125450d5c53","d7d45ef0e253b55d","2aa6e2ef54433db5","076a69b4395ac51c","aeb0772ca82eb874","49ad917ecc3002cf","c355e8d58e082040","1eeb09c2f8b5063f","37a1cf7995845834","2bd64ffed6dec4b3","17d8cc51d6a5711f"],"restriction:local:proposed":["84efe8243d6504bc","181bd4b518b2cfed","b83f8907c29714e9","8294c67374182bdf","8b259a9fdb940566"],"restriction:local:failed":["928488ab5100d192","aafc220952d6a48c","e3fad9e4ae5cae83","b68811b610a11964"],"restriction:states:proposed":["f10a82ce8ce07853","2bf52937fb8640a7","d91aa188fd06f5e0"],"restriction:states:failed":["35ebc5f44dd67c98","ccde728219226db1","857477e095526aaf"],"water:moratorium:enacted":["b9f652a9b7c4b011"],"water:moratorium:proposed":["38d2bf42e833778a"],"water:closed-loop:proposed":["ad8e73dba358f034"],"delay:community_opposition:withdrawn":["c8b91c53c8d76443","2364b319549649b0"],"delay:zoning_denial:withdrawn":["c8b91c53c8d76443","2364b319549649b0"],"delay:litigation:litigation_active":["26de238e0f400d29"],"delay:local_moratorium:litigation_active":["26de238e0f400d29"],"delay:community_opposition:delayed":["886117a42038f872"],"utility:tariff:approved":["3733629beaf1ada1"],"utility:statement:contested":["8f109ead8aab43d0"],"utility:statement:pending":["5338dfae87b7a6f7"],"utility:tariff:pending":["535ff2bea70f7e1e"],"utility:other:pending":["36e711f6271a98a9","b8438dca9b49aebd"],"utility:tariff:contested":["1a0900299d02d68d","f4c8c4668d869233"],"utility:rate_case:pending":["45ffc3ccaa151b55"],"utility:other:denied":["7d51d5e504430b5e"]},"grid_operators":["NON-RTO","PJM"],"counts":{"moratorium":59,"water":3,"delay":67,"atlas":44,"permits":34},"record_count":207},{"id":"ND","name":"North Dakota","groups":{"restriction:local:enacted":["918ec9976a6ebc76","5fe4251ab4cdcb1d"],"restriction:local:failed":["da10b7684b67acdc","b94dc16d48f67fd9"],"restriction:local:proposed":["0867cb4ffce5c18b"],"restriction:states:enacted":["10810ad90dae3c22"],"restriction:states:failed":["06b00e83aed9df20","37e09c9be2329183","45f55a5bdae7aa9c","bc1c99050827355d"],"utility:tariff:pending":["bd130d6595b26f7c"]},"grid_operators":["SPP","MISO"],"counts":{"moratorium":10,"delay":6,"atlas":9,"permits":2},"record_count":27},{"id":"OH","name":"Ohio","groups":{"policy:cost-allocation":["55634d9b0e3dbe0d"],"restriction:local:enacted":["461dc19405784392","691815701a1e7b84","407f6a32f3a3a0ae","1d451c4d01991061","c05d611c3e7dd8d5","303593cae196f587","7a83cf56d52a963c","7fc064d20dc788bd","a7e5c5aec188366b","7ce6031118cad4fd","8f219dc030624cd2","950d5e0e199dfb22","c2b95d5838587ff4","9ba6b9b9692b4708","d72f4489e825fef2","940b6159ab502612","f0c97f968bab3081","405f1ab18b45cec2","8542695ddd9b5b30","7026f0fd2b5bc6f0","ca89ad24dc656f79","978214f7dd1d9d8f","c1bda0acec337164","730091555169da66","3b3d27d4919f1e77","a96013d0b5b1c9a2","d8f63ab9b450228a","cc6ca7b31398d910","306d3fab23b96651","f394a0eb7801b57b","0ac4ec70dc0bb4ba","6cbf93fd3792d38e","c0aba8a27555a0c0","d533d9f7cdfc603d","ea2a114d10a3194e","61fe898c9107f2ba","4b26ee4f418c3dd5","cccc5aef83beacac","f1d5c9a4b6023b27","4fbd89f670532629","421b341a093f14c9","53701fd2f75ff500","23811974e54dcac2","b90f5b1569114026","ca5208c669ad2550","ecf81cf135cd7c41","fe4bc2e21abc7fd0","c636f6e8fe61d8bc","70667db94a767cf0","d3ccdcc868a68902","0fc759bfa86292c3","12369281bb53a55f","5f2de78e4e2f9413","2321a1c503022d33","bc140f9d0778a158","88cd458bc7993ab1","e281827c22b8aaa6","904259f746e7f001","668044e9a5218b84","e526f703d4ba3d40","406582468189cd53","e560f4fc1b2d48cf","15eda7648a7da254","1ea75a7e46cea951","8c428e28c6fa59b7","94595b6204b14f34","a795c2b6fa5fb605","a91e87e8e532a81a","0f566e9f055d874d","a3338ba4c589f2a1","024a636c91c52568"],"restriction:local:failed":["941a2b27ff9dd2f9","f0125c1f3d577939","1984235e10d07864","47e7f50ceb79bde2"],"restriction:local:proposed":["329efb5b9ab278b2","fe3263d096bb1d42","f0c8462ea6d10a36","5d2dc1ac11a37fd0"],"restriction:states:enacted":["a33e963e7ed0f3f9"],"restriction:states:pause":["aac6bd4ca937a3a1","790d7df967d13e33"],"restriction:states:proposed":["9791d6ee8a159714","5bb7dbbf3f54e1f6","076c38b44f191708","35dfe120e8f90c81","a4f886faea465453","f67274b3d1ca79e3","b0b20187a84ac61b"],"water:siting:enacted":["1fc784371ef77c63"],"water:closed-loop:proposed":["d9a55d5bd1815a7a"],"water:disclosure:proposed":["07d5958ebc0e2919"],"water:siting:proposed":["af9b7989afe0d6ff"],"water:moratorium:enacted":["b03281ae45156609"],"water:rate:enacted":["f38675b9d14c3301"],"water:shield:failed":["31cb3e61422ae705"],"delay:community_opposition:delayed":["6041ee70dd8ec4f2","33619bda345609b8"],"delay:regulatory_review:regulatory_approval_pending":["67f7d406d0b7de7c"],"delay:power_allocation_dispute:regulatory_approval_pending":["67f7d406d0b7de7c"],"delay:corporate_reassessment:construction_paused":["ec84904200576a9f"],"delay:openai_relationship_change:construction_paused":["ec84904200576a9f"],"delay:tariff_costs:construction_paused":["ec84904200576a9f"],"delay:local_moratorium:proposed_amid_local_moratorium_and_ballot_fight":["ceca7cca8784dd96"],"delay:ballot_initiative_threat:proposed_amid_local_moratorium_and_ballot_fight":["ceca7cca8784dd96"],"delay:ballot_initiative_threat:signature_gathering":["738d37cb16e4b52b"],"delay:statewide_moratorium_push:signature_gathering":["738d37cb16e4b52b"],"delay:local_moratorium:halted":["8924323156a513a6"],"delay:community_opposition:halted":["8924323156a513a6"],"utility:tariff:approved":["b119f3dad60e8067","b0b7b5e3ba42091a","feb6e8ebba7bc21b","d471fb8c04d4d42b","e688652c63a8603c","3b0d6703179b004f"],"utility:tariff:pending":["4e7c1eaf6aefd563","8d64014cf73ea8c5","33358a52bdbff1e9"],"utility:tariff:denied":["d77af2ba4e087bb7"],"utility:rate case:pending":["1f4f51f2805cd230","4e52d117f119a0ab"],"utility:other:pending":["8867995dfeac8af8"]},"grid_operators":["PJM"],"counts":{"policy":1,"moratorium":89,"water":7,"delay":156,"atlas":100,"permits":15},"record_count":368},{"id":"OK","name":"Oklahoma","groups":{"restriction:local:enacted":["50b51ab105de1694","4d5225243a046a38","42183c5f0e187ec9","2da276ac2eced4b7","409936f3ff16ca77","fd3e3e400e15bcb3","311f0b103dd1c20a","e11236c60dcb019b","af39a5a9b91cf374","80850e3b3240130d","6d6d4b47a1f08094","fd7e05f695b792fb","57bfec0310076c02","ac38ecc9080693a4"],"restriction:states:enacted":["5ce11b610f2019f8"],"restriction:states:failed":["c5ac0e3ebaec0fff","df4a0cf535656562"],"water:closed-loop:enacted":["f01e9c7f92ad912f"],"water:disclosure:failed":["4cffe4be712b7fee"],"delay:community_opposition:under_construction_amid_water_concerns":["b02a88e32f069571"],"delay:water_capacity_constraints:under_construction_amid_water_concerns":["b02a88e32f069571"],"delay:city_moratorium_partial_exemption:phase_vote_delayed":["d2464a0059b2da36"],"delay:planning_commission_delay:phase_vote_delayed":["d2464a0059b2da36"],"delay:community_opposition:opposed_proposed":["d6d03051edf8cadd"],"delay:transparency_concerns:opposed_proposed":["d6d03051edf8cadd"],"delay:water:cancelled":["b81165f74fca6c9b","194ddf5960f0882a"],"delay:community_opposition:cancelled":["b81165f74fca6c9b","194ddf5960f0882a"],"delay:financing:cancelled":["b81165f74fca6c9b"],"utility:complaint:contested":["6a0e62dd608338b3"],"utility:tariff:pending":["0244a5050bd89f54","d23c9de2ed780784","369b25b59f1044b0","8caf179819a91899","b44407ade651e171"],"utility:tariff:approved":["7c0393e3288507ab"],"utility:policy:effective":["533edea4d22fcfc3"]},"grid_operators":["SPP"],"counts":{"moratorium":17,"water":2,"delay":29,"atlas":25,"permits":34},"record_count":107},{"id":"OR","name":"Oregon","groups":{"policy:cost-allocation":["ec3aab8c8e487810"],"policy:minimum-payment":["09b69a3ac7ed320c"],"policy:clean-energy":["573b7be7282c24e9"],"policy:regulator-reporting":["82e5b2896507c105"],"restriction:local:enacted":["c46ac99932456879","bfb08271f1889aa3","406a4fe8c580044d"],"restriction:local:proposed":["9fecbaadfc504d91","55072e55f3993603","c167670c15d2c9ec"],"restriction:local:failed":["2217c7fce49a6fcb"],"restriction:states:enacted":["4266a70286a34bc9","fd7d68ca06671d0b"],"restriction:states:pause":["b05de37e3bed5008","0bb7ee781820adb4"],"restriction:states:proposed":["1d87e7ca35d788e4","97e59a9c63be62e9"],"water:moratorium:enacted":["f436cd79501cb106"],"delay:litigation:litigation_active":["189ec25f09c73d30"],"delay:local_moratorium:halted":["fc7ac8c5e0c9a3e0"],"delay:water_dispute:halted":["fc7ac8c5e0c9a3e0"],"delay:tax_incentive_change:halted":["fc7ac8c5e0c9a3e0"],"delay:community_opposition:cancelled":["508cd09772361d44"],"utility:tariff:approved":["8f26d54b8098d83a","933a75515edac858","919ed293cccce0b5"],"utility:other:approved":["fd904a85f9f038d0"],"utility:tariff:pending":["90bff93d506e12d8"],"utility:other:pending":["500c12c6d84c5535"]},"grid_operators":["NON-RTO"],"counts":{"policy":4,"moratorium":13,"water":1,"delay":16,"atlas":8,"permits":28},"record_count":70},{"id":"PA","name":"Pennsylvania","groups":{"restriction:local:enacted":["38de5bf25db60ea6","a07e0f5e3b200bbb","e0e19b054c78ba90","d57a038848981525","08cc6d470b3f20a4","786ec40f80121492","9d46b0435161c347","7f0801a61ac6bdc8","e91f573252606528","30d8d8996a24365c","7a05632963af26b7","0525ead7d8196b60","c49102319b7d9c26","828f9f1b7a9fc4d8","7e498adfb9cf36be","30e2226befeb9e41","d01de37fe2c38608","3ef85431f6a82760","50a74ef750ecebc2","86690394ec34fe0d","f4098716a0ee721b","2f1f35aee33b8d1b","0b7ff980380eafa0","a80d24e122853bfe","83bf5bc987c8973d","b4f499936ec56461","b3ea3d581da9a606","71a38b1ed5950ad1","e191001ca64a606d","f9511193a66cd3bc"],"restriction:local:failed":["491849e21df0aa97"],"restriction:local:proposed":["04f7d83298b30de7","f979d0fdee3f9fa3"],"restriction:local:pause":["533afd77cfc5eebb"],"restriction:states:enacted":["7f4af8a87d95c544","7471943bfacd9b79"],"restriction:states:proposed":["6aa38b3ad7bc8095","30479ff8f518235c","2f437f53e7c38048","535c2efca50b83dc","1b368eec31f98fde","5442b108786851c0","f486ff97ce82e49d","7739eeecd45bc5b3","a5f21a3c4a91636e","a4c98945f6116fb9","122b2ca8ea2dce4c"],"restriction:states:failed":["291e4c7a5a21088d","9a687477c380a153","9ab4c50b87f3e567","c916da28feddac2f","a879ae6745a42d11","ce6deddc6f7620a6","d3752761d30cd8b6"],"water:disclosure:enacted":["71b44216bc39b316","19977f7326ae5f36"],"water:disclosure:proposed":["ce335eca213a335f","268f6575720b3e76"],"water:siting:proposed":["e6cd4c87af287f2e","ec0986faeb616e79","02edb086bcb4ec16"],"water:study:enacted":["7e7071bf9f2d7636"],"water:siting:enacted":["f4b911f9a8638b44"],"water:closed-loop:proposed":["ecec2267314e711d"],"delay:zoning_denial:under_appeal":["221a7177ef54c146"],"delay:community_opposition:under_appeal":["221a7177ef54c146"],"delay:litigation:under_appeal":["221a7177ef54c146"],"delay:litigation:litigation_active":["acb6c23674d3443b","457d01e6aa50ccb9"],"delay:community_opposition:litigation_active":["acb6c23674d3443b","457d01e6aa50ccb9"],"delay:community_opposition:cancelled":["72fbfc95e6717af4"],"delay:zoning_denial:cancelled":["72fbfc95e6717af4"],"delay:community_opposition:delayed":["91270d77ce33c433","b79613921282641a"],"utility:tariff:approved":["4c72868c8e004412","c89690d0346c7890","ac3f1efb2976fc5b"],"utility:rate case:approved":["e934571677cf1704"],"utility:other:pending":["fbc1615a2aea7504","84096c1cd33d1c29"],"utility:tariff:pending":["6ccd7eecfb420cbd","03f4e94591ffe708"],"utility:tariff:effective":["d4a74e67bb8dc281"],"utility:policy:pending":["04bd0eb54a15c158"]},"grid_operators":["PJM"],"counts":{"moratorium":54,"water":10,"delay":84,"atlas":53,"permits":21},"record_count":222},{"id":"RI","name":"Rhode Island","groups":{"restriction:local:enacted":["ed259525eb90ab6d","dab8ece38c5fb9d5","09f9a1112ca9bb16","8758bf36db37de62"],"restriction:local:proposed":["9c9aa6a6cab87eae"],"restriction:states:proposed":["39109139e4499da1"],"restriction:states:failed":["87b18404613879e9","1ca1db6d54c60804"],"delay:zoning_denial:litigation_active":["09f90dd4b212e592"]},"grid_operators":["ISO-NE"],"counts":{"moratorium":8,"delay":6,"atlas":5},"record_count":19},{"id":"SC","name":"South Carolina","groups":{"restriction:local:enacted":["58631f91fad85e5b","b8911b8723010e16","f7b981d36cb76fc6","ead5aac6d1de0198","28116638b206c684","e712a9602d7fc092","17168f8283569007","3fbf04d4d1abbc30","b5c702b7d9d268b1","31c3c407ecaa9b02","08d501a7dce90945","bfe556ca5819bf38","65163505f47f6e65"],"restriction:local:proposed":["d522fdfd4fa7adac","9e6a95af9b1a6338","5e3217c2394c85d9"],"restriction:local:failed":["ead4c3dd6bcf23b7"],"restriction:states:proposed":["70456b2f17fa016f","1bd520760aca35e7","dfe1a31d8cfe99e5"],"restriction:states:failed":["d7cf8717beef89cd"],"water:closed-loop:proposed":["836cb4c1add36778"],"water:siting:proposed":["d5588d305d72ed31"],"water:moratorium:proposed":["feaa74b8ade8d152","e0c20f860681a471"],"water:disclosure:failed":["2a360b96adeac4a5"],"water:closed-loop:enacted":["c4c6394d78cf14cf"],"water:moratorium:enacted":["83129110381c2b8d"],"delay:regulatory_review:permitting_challenged":["ebbc3548ee675c57"],"delay:environmental_petition:permitting_challenged":["ebbc3548ee675c57"],"delay:utility_interconnection_timing:abandoned":["59d31c90f99a8e27"],"delay:withdrawal:abandoned":["59d31c90f99a8e27"],"delay:county_moratorium:moratorium_in_force":["4fd68a1a4d95ecf1"],"delay:permit_denial:halted":["2a19530b645b4515"],"delay:local_moratorium:halted":["2a19530b645b4515"],"delay:community_opposition:halted":["2a19530b645b4515"],"utility:tariff:approved":["a6a9b54dc2f7e887","4acfdfc6ae530074"],"utility:rate case:approved":["836e8495e0094213"],"utility:other:effective":["4650a698f603d88c"],"utility:other:contested":["5976280cf4e599c1"]},"grid_operators":["NON-RTO"],"counts":{"moratorium":21,"water":7,"delay":30,"atlas":22,"permits":3},"record_count":83},{"id":"SD","name":"South Dakota","groups":{"policy:cost-allocation":["e1de11c16d8239a6"],"policy:departure":["b87c8e5ab20d7865"],"policy:supply-review":["5f04413f1e1d314b"],"policy:water-reporting":["3d0987d18045023f"],"policy:local-authority":["d5abe6128808804e"],"restriction:local:failed":["0c5ecfaba5561367"],"restriction:local:proposed":["5a5f4731708d3508"],"restriction:local:enacted":["127e547bdcf06887"],"restriction:states:enacted":["e69882d4dd9dec56","e0c13222b8896f55"],"restriction:states:proposed":["d2cb3118b636a794"],"restriction:states:failed":["3ddf71976e354659"],"water:disclosure:enacted":["95158506706fb5b4"]},"grid_operators":["SPP","MISO"],"counts":{"policy":5,"moratorium":7,"water":1,"delay":4,"atlas":4,"permits":1},"record_count":22},{"id":"TN","name":"Tennessee","groups":{"restriction:local:enacted":["15608211c6ca3581","307b38ee1b228384","23049879ff0a5d1c","7cebe8d5c67147c3","747d1db6063c1a74","51b2b9b3a961b6ab","de659fa3e365eec8","33552bf4e80b18ee","730a5f5d55050cb7","087bbbb5a483b776","0137c4ed47954709","8272522f979f7008","9d632430d6a03021","78dbb699f219d0d0","1f546cb2797f996d","c43fd1c858232412","b97b3954b1b0949c","d68b3a39798f9791","f0bb509eaf3c5b2f","a431da7d7f705e27","048501d4a5383269","8cb4602a6ee8dcbd","af28772857e3903f","3e19367856e206f1","241a6f9524fa5b55","54976e44fee3018e","ebeae99d6b6421df","0d02b8ce1211373d","492d17cc76c60e58"],"restriction:local:proposed":["c72ff700a8b5e0fe","a5263d6dfaed1a21","05ec77d83a2fb722"],"restriction:states:enacted":["3c219120a612265b"],"restriction:states:proposed":["963831dc8907e951"],"restriction:states:failed":["640e5053d7ed492c","2f485290fc876c3d"],"water:reclaimed:proposed":["34047d55aaad8568"],"water:disclosure:failed":["3024f2dbcb00785c","7932fbffdf71a9e7"],"water:siting:proposed":["95d5d77e861f2e1a"],"water:moratorium:proposed":["51b30007138592e5"],"water:closed-loop:proposed":["bdc557047de3e52b","3b9e61fb1da5de65"],"delay:local_moratorium:litigation_active":["b63b7988b1a6e4a0"],"delay:litigation:litigation_active":["b63b7988b1a6e4a0"],"delay:litigation:active_litigation":["f23f3210c5447afd","9783ae8705aab3e7"],"delay:city_moratorium:active_litigation":["f23f3210c5447afd"],"delay:eminent_domain_threat:active_litigation":["f23f3210c5447afd"],"delay:rezoning_denial:rezoning_rejected_moratorium_recommended":["d1de5e4992b534d6"],"delay:county_moratorium_recommended:rezoning_rejected_moratorium_recommended":["d1de5e4992b534d6"],"delay:environmental_review_order:active_litigation":["9783ae8705aab3e7"],"delay:unpermitted_power_plant:active_litigation":["9783ae8705aab3e7"],"delay:community_opposition:under_construction_amid_scrutiny":["18dc39f31efad1cf"],"delay:transparency_concerns:under_construction_amid_scrutiny":["18dc39f31efad1cf"],"utility:tariff:pending":["b63a0876c6c743c3","af3b47ccdb7cb94a"]},"grid_operators":["NON-RTO","PJM"],"counts":{"moratorium":36,"water":7,"delay":38,"atlas":29,"permits":5},"record_count":115},{"id":"TX","name":"Texas","groups":{"policy:site-control":["170b3631ad48f5a9"],"policy:security":["1deb6f4ebbbba3d4"],"policy:curtailment":["56b017e8edee0f3b"],"policy:emissions":["e17cedb3112fd488"],"restriction:local:enacted":["cb4fae95f6ec62e9","226d9579a44729dd","8725a51570228ad5","9cd0e5a2740b6579","49d98f654070e13e","5a6631afcf14f245","1526c144af9c4197","bfaeb2b05925f9bf"],"restriction:local:proposed":["aa120245d3cde2b5","4bbd796802e5b2a9","29dbbc44e88a23f5","d4ddebe26453aec0","fd40bfb18bd582d1","e3d9ca006093dd8c","347c664b42d6867c","f141990e3f9ddb5c"],"restriction:local:failed":["4cf9e86df26cb47f","036f9e40cb83532e","8fbbd5e4d1430368","0148c0779dde3d94","c154399207131e2f"],"restriction:states:enacted":["35fcd20bf3d4a4e3","07b7360c48f3c46e","98ec338e6e03cba0"],"restriction:states:pause":["707703d5f96368d1","41c39b9ee7a58df2","9607cd1000488b0d"],"restriction:states:proposed":["8d85cc66b1113104"],"water:study:proposed":["97674740d6ace3d0"],"water:siting:proposed":["ce0a82530ed2e6c2","617e27c4c491786f"],"water:closed-loop:enacted":["a3bc163e4fc8a78f","b41ba038f3b958e1"],"water:closed-loop:proposed":["0711b71f0ca0c23e","0026ba717d68569a"],"water:shield:enacted":["f512098faa3bf9c4"],"water:siting:enacted":["0d07fe0b0e4fa3bb"],"water:disclosure:enacted":["f4c280b4acf60e61","4fe0a4491af0e56e","ab5ef43c0bd56795","18fff3b222f896e1"],"water:moratorium:enacted":["23aaebd91e78f209"],"delay:state_moratorium:withdrawn":["a8fe02f84bc4a666"],"delay:transformer_supply:delayed":["a60e9b00093891d5"],"delay:gas_pipeline_delay:delayed":["87485593349454ff"],"delay:corporate_realignment:withdrawn":["15ca382a6f880e9f"],"delay:financing:withdrawn":["15ca382a6f880e9f"],"delay:zoning_denial:cancelled":["9832792554ff4c9d","0b4408147f79994e","a1bb576b290d6353"],"delay:water_dispute:cancelled":["9832792554ff4c9d"],"delay:community_opposition:cancelled":["9832792554ff4c9d","0b4408147f79994e","a1bb576b290d6353"],"delay:water_dispute:withdrawn":["0581ab61da4d6697"],"delay:community_opposition:withdrawn":["0581ab61da4d6697","adfb727c5dd4e1cc"],"delay:litigation:litigation_active":["792ce5aec9329c29","109278a363838f96","f27cb758664748d7"],"delay:community_opposition:litigation_active":["792ce5aec9329c29","109278a363838f96"],"delay:corporate_realignment:delayed":["0120772c7188f042"],"delay:community_opposition:delayed":["168b4298a9ab289d","f7513e35f7c721c0","2e380fe2f7f014dc"],"delay:litigation:under_appeal":["f08287b22f91f244"],"delay:local_moratorium:litigation_active":["f27cb758664748d7"],"delay:zoning_denial:delayed":["2e380fe2f7f014dc"],"delay:interconnection_queue:halted":["d5e9430ff55efa0d"],"delay:zoning_denial:withdrawn":["adfb727c5dd4e1cc"],"utility:tariff:approved":["75dc99c20658fe92","aed4fabd0e2dc51c","9a879f558b598ed3"],"utility:rate case:pending":["3af74a147ed90618"],"utility:other:pending":["234c8b4fd863479c","b540667ef8b17e0f","0b11ccddef1877eb","99a349313213c782","87c2bcaca8770a64","ca36e7d667fd52d5","624c21796e30622a","6218dc8d9c2c19aa","a068f88c8918edb0"],"utility:special contract:pending":["85e644b149d44cc3"],"utility:tariff:pending":["179ce9c6749195ff","ecc5b89ff5cb7890"],"utility:statement:pending":["d04486225e3fbb69"],"utility:other:approved":["0b929d848501d87d"],"utility:certificate:approved":["f70bcf2339f86b49"],"utility:policy:rejected":["c7c2a7a3b4cd9ee5"],"utility:policy:effective":["ad4e34e0dfe00af1"]},"grid_operators":["ERCOT","SPP","MISO","NON-RTO"],"counts":{"policy":4,"moratorium":28,"water":14,"delay":83,"atlas":135,"permits":127},"record_count":391},{"id":"UT","name":"Utah","groups":{"restriction:local:enacted":["fe8d104f8d67e17c","093e457d95e139ba","a73c33aad89fd8c4","d39140513b342349","0c19d0bfb2b41666","be172ab12b60089d","7272dd8d9cbcbd97","2c4637d21201bc5a"],"restriction:local:pause":["6689ae5de85fb884"],"restriction:states:enacted":["161bb7df391f5393","29634d18789600f9"],"water:disclosure:enacted":["aa23c2f90b922d2f"],"water:siting:enacted":["92181bfbd0f092dc"],"delay:local_moratorium:litigation_active":["43fe8f06c251d00a"],"delay:zoning_denial:litigation_active":["43fe8f06c251d00a"],"delay:community_opposition:litigation_active":["43fe8f06c251d00a"],"delay:tax_incentive_change:cancelled":["9a747679a42936ff"]},"grid_operators":["NON-RTO","SPP"],"counts":{"moratorium":11,"water":2,"delay":16,"atlas":23,"permits":16},"record_count":68},{"id":"VT","name":"Vermont","groups":{"restriction:local:enacted":["fd5d7c35a8a164d5","ffd4551238ee66c3","24609fa0cc03fd6d"],"restriction:states:failed":["a22c89dd88f7805b"]},"grid_operators":["ISO-NE"],"counts":{"moratorium":4,"delay":1,"atlas":3},"record_count":8},{"id":"VA","name":"Virginia","groups":{"policy:water-reporting":["d2e1f34ebb87db96"],"policy:regulator-reporting":["a2d7165da9c4273d"],"restriction:local:enacted":["5d1933a50e2fffa9","d9c9702f7193a5d0","00ea8549bf7d9107","5e8fa08848e7ea49","b612281109895776","a8439ee49b85f3b9","cb1ee56619c41591","fc8930e333e47393","33da24b96e9450aa","3c8c47c48655c7c2"],"restriction:local:failed":["c0313d873e52c337"],"restriction:local:proposed":["1fb124f1d0600aad"],"restriction:states:enacted":["07bca14c6c769cd9","822881c141b55b58","1bc4820da2e184d8","260f9d0fdac1fb1d"],"restriction:states:proposed":["115a01cddaaebb83","81387474427b857f","de3a5a259065cee6","d9698a681bcb77d1","1ccb96de87be8c20","6f2fd99dffb3ee19","5fbcc9b83d0cea89","5286a63674ab303e"],"restriction:states:failed":["96a928bdb916449a","82304cb623ce2fd1","1c2b5c27f2a20646"],"water:disclosure:enacted":["236efd0b5ce918b3","ea2fc9f0f2561dd5","1bb0eef74b265bbc"],"water:siting:vetoed":["fc6a89d84ea3761e"],"water:reclaimed:failed":["7c9863297abb29b6"],"water:incentive:proposed":["30149d37cde17dd5"],"water:study:enacted":["4d9a8e7a99e3e39b"],"water:disclosure:failed":["133af645ccadb7ec"],"water:siting:enacted":["13c66e32329bf4c9"],"water:disclosure:proposed":["739c2b83e1630596"],"delay:zoning_denial:cancelled":["b654fcba5611c495","3de6fb41fb4c6757","c24066658a7c87b0","c05ff50d0eaddb83","b2f708f236602e8d","1df2fd29204a101c","ae2116cf001391ca","0d43e4ef0a99dcc3","15020a3ca9ed5c0c","4ef0ce9c1aab379b"],"delay:community_opposition:cancelled":["b654fcba5611c495","3de6fb41fb4c6757","c24066658a7c87b0","c05ff50d0eaddb83","b2f708f236602e8d","1df2fd29204a101c","0d43e4ef0a99dcc3","15020a3ca9ed5c0c","4ef0ce9c1aab379b","b0af2cf0f00c0c33","0093933737713687"],"delay:water_dispute:cancelled":["b654fcba5611c495","c24066658a7c87b0"],"delay:litigation:cancelled":["b2f708f236602e8d","3059b79f61908e3d"],"delay:community_opposition:delayed":["2a92789be1587ada","dc394d8881dcfd7f","d7fec75934b138bd","4ef289628ac834d5"],"delay:litigation:litigation_active":["01bbee83623720b2","e5c30ca57b2dbc24","dcf5dbffe665442a","85cd3631575a5bdf","1832912b622cc7ca","e7ee0387e9522f52"],"delay:community_opposition:withdrawn":["4e9752c1f7793fed","dd7e54e17e5d9610","c0eb9b29986c263e","5bd7758d176ed830","c66e2ba9c7927837"],"delay:zoning_denial:withdrawn":["4e9752c1f7793fed","dd7e54e17e5d9610","c0eb9b29986c263e","5bd7758d176ed830","c66e2ba9c7927837"],"delay:community_opposition:litigation_active":["dcf5dbffe665442a"],"delay:zoning_denial:delayed":["ba73fb104a300b67","dc394d8881dcfd7f","d7fec75934b138bd"],"delay:zoning_denial:under_appeal":["f8a6c494d6a909f4"],"delay:community_opposition:under_appeal":["f8a6c494d6a909f4"],"delay:water_dispute:litigation_active":["85cd3631575a5bdf"],"delay:zoning_denial:litigation_active":["e7ee0387e9522f52"],"delay:environmental_review:cancelled":["3059b79f61908e3d"],"utility:tariff:approved":["c2935488c1650819","39c6440688564d5b","87a87dde118e582a"],"utility:IRP:contested":["1d207f181f290a4a","9ba1e9a7df265951","7f6e112a0c84fe66"],"utility:tariff:contested":["d5ac5227a2747fcf","b3484cb6d3aad2da"],"utility:rate case:pending":["7a09881b3efc53a9"],"utility:other:pending":["cb40a9cac60f8cec","925eb6e874d3a48f","53aeac44973adb8a"],"utility:statement:pending":["95c8534650ed9b12"],"utility:tariff:pending":["17c7d5340af6b949"],"utility:other:contested":["e0efcc5e95491272"],"utility:rate case:approved":["2d9b62ed5a5a8c85"]},"grid_operators":["PJM","NON-RTO"],"counts":{"policy":2,"moratorium":27,"water":10,"delay":88,"atlas":73,"permits":642},"record_count":842},{"id":"WA","name":"Washington","groups":{"restriction:local:enacted":["9f5f2923e39b9be8","d4e7ad9cf08df51e","a0fc2d121a678362","0b3a9ecd7c2478dc","de683906483b8fe5","d6189396d865dfc1","a4d0a0075eb42622","844f1f18ded0ca1c","50cb86e7f24d5c8a","5f99587cd1f4762d","e207b014a5280c8e","abcdda3f927a1476","31a8daed20fe189e","af832be8ade36360","510f60e365739621","7eb7d0c92f5f8dd9","5565880179e00904","c8eaae4e91fc4247","4f498d7e9f152136","29f8e05bf47f65e4"],"restriction:states:enacted":["13d139ecdc65b4b1","b6f7e9b035c67d69"],"restriction:states:proposed":["73392c07183451a2","d65bf66b10bb27dc","d97ae6ca24475af1"],"restriction:states:failed":["b0d11e81f4e16dea","fc47b1de08dff922","383388e3142065cd"],"water:moratorium:enacted":["6455f69859c340a2"],"delay:community_opposition:halted":["8ced64a3cbb11f6c"],"delay:local_moratorium:halted":["0d03a9c2805d05b6","2fc49a0ff709020e"],"delay:community_opposition:delayed":["887cc460e5eb83f6"],"utility:tariff:pending":["c168cf070187ea92"],"utility:other:pending":["611e6f5599ef718f","8c8130676232d1c6"],"utility:statement:pending":["4ed38cff9678ccf0","4b866a2091ab3ecc"],"utility:tariff:approved":["325a6b7ee8b34e77"]},"grid_operators":["NON-RTO"],"counts":{"moratorium":28,"water":1,"delay":22,"atlas":30,"permits":13},"record_count":94},{"id":"WV","name":"West Virginia","groups":{"water:disclosure:failed":["8cf5514f4b5ff375"],"delay:community_opposition:delayed":["4124cb9080c91f7c"],"utility:IRP:pending":["a67a61284873a2b2","8da91197a3806bcc"],"utility:special contract:pending":["39679c94f0d7f830"],"utility:other:contested":["c12d842abe5446ff","040b3c446bff4aee","5e6fb296651a928a","6f948a872911044f","0ae82e92301e638b"]},"grid_operators":["PJM"],"counts":{"water":1,"delay":12,"atlas":7},"record_count":20},{"id":"WI","name":"Wisconsin","groups":{"restriction:local:enacted":["197cdb77aa511062","c32fbb4074e34eba","9fa928579bf6e19b","1ef57a5ad557563c","d383195f7d8cd078","07b5a8ef15cadf6b","0a3550a0b812064e","2f12caa1fa8a1620","4efd296b41cadd58","502234e3282fa94d","98de8d31bfd06c50","9baf377f17b48199","2b2ac1debfbe57ca","aee74a04d13b1375","02ac37032bda8131","375f029130348bd2","6e56afd4aed59791","893a3aae04278c40","7650d4a5b8a48f92","e18b7a4b7fbc1df5","b56152d653914388","b916df50f4c51b94","5a64d5c33607de67","643f527e927e4058","7b1745a42047131e","e09c79ad3db16d88","734fd94028341ac3","69f22ea5aa3e34d3","1a270a98a4fa2e6d","d41ed6223bfeed81","112e1e1079c890e9","844ad5858c872078","47a591fadc2e8900","f7cf8bb4ab48824a"],"restriction:local:failed":["0c67dadae5dac0e9"],"restriction:local:proposed":["e66086d4c7d49f01","c8953b5f4533a4b5","68e48cc43363c3ba","f04d2abd046f97a9","1eae3d6650182a35"],"restriction:states:enacted":["5db6a8a411191d98"],"restriction:states:proposed":["d9aeb06afb1cc48b"],"restriction:states:failed":["a7f7ac4ffcf569cf","e87712374a5a9bb6","1fa055042bc56cba","bf5f897298b22196"],"water:moratorium:failed":["dabd0296a8769724"],"water:disclosure:proposed":["52d3503b7b7a29d2"],"water:disclosure:failed":["3d11e7d09b3698e1"],"water:moratorium:proposed":["0d06b92b967fdc00"],"water:siting:proposed":["4157cf76b6d65b0a"],"delay:environmental_review:litigation_active":["debb467bcb4d5430"],"delay:litigation:litigation_active":["debb467bcb4d5430"],"delay:community_opposition:litigation_active":["debb467bcb4d5430"],"delay:litigation:active_litigation":["e199a6213982873d"],"delay:environmental_review_challenge:active_litigation":["e199a6213982873d"],"delay:regulatory_collateral_dispute:active_litigation":["e199a6213982873d"],"delay:corporate_reassessment:construction_partially_paused":["18d12b7d0ac7dea8"],"delay:design_changes:construction_partially_paused":["18d12b7d0ac7dea8"],"delay:community_opposition:under_council_consideration":["28e37770792b4c08"],"delay:withdrawal:cancelled":["ea733b19fc76a19b"],"delay:village_infeasibility_finding:cancelled":["ea733b19fc76a19b"],"delay:interconnection:denied":["fd3e6fff23dec30a"],"delay:water:cancelled":["6b688ff399652711"],"delay:community_opposition:cancelled":["6b688ff399652711"],"delay:financing:cancelled":["6b688ff399652711"],"utility:special contract:approved":["c0e0e62ba225486e"],"utility:tariff:approved":["477299baafe80b07","8b74b857f211fa23","9d22a2aeb195e4fc","124399acbd7a554c"],"utility:tariff:pending":["dde2390c69924c91","4b8f10b414687805","7d0c020f1825cea4"],"utility:rate case:pending":["fbf33f025d17bc1f"],"utility:other:pending":["8f81691272c2cefc"]},"grid_operators":["MISO"],"counts":{"moratorium":46,"water":5,"delay":59,"atlas":44,"permits":6},"record_count":160},{"id":"WY","name":"Wyoming","groups":{"restriction:local:failed":["d0485054fd79e820"],"restriction:local:proposed":["3ed10f6e2d7fa4f4"],"restriction:states:failed":["be934bcf6dde21e3"],"utility:tariff:pending":["b1729fb79f6ff5af"],"utility:tariff:approved":["48ce507193eae507","2e0818019f3d14fe","103e672184e6c568"],"utility:other:pending":["b06ef4aba51b6d71"],"utility:special contract:pending":["31c5bf9bd2103358"]},"grid_operators":["NON-RTO","SPP"],"counts":{"moratorium":3,"delay":10,"atlas":13,"permits":4},"record_count":30}]}